1

द��ण पूव रेलवे SOUTH EASTERN RAILWAY

न�वदा न�वदा न�वदा न�वदा कागजातकागजातकागजातकागजात TENDER DOCUMENT

खुल� न�वदा सचूना स.ं/ Tender

Notice No.

: TRD/ADA/OT-2015/5/BKSC/D-cab ,dtd 28.08.2015

काय का नाम /Name of the Work: : Provision of OHE of line from 'P' Cabin to Loco line along with OHE of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway

न�वदा �प का म!ूय / Cost of

Tender form : Rs 5,700/-( Rupees Five Thousand Seven

only ) ( Tender paper cost:Rs 5,000/- & Service Tax of Rs 700/- )

न�वदा खोलने क$ त%थ /Date of

Opening Of tender

: 14.10.2015

न�वदा क$ अनमुा नत ् लागत /

Approximate Tender Value

: Rs 55,59,898/- (Rupees Fifty Five Lakh Fifty Nine Thousand Eight Hundred Ninety Eight Only)

बयाना रा*श /Earnest Money: : Rs 1,11,120/- ( One Lakh Eleven Thousand One Hundred Twenty only)

िजसे �व-य .कया गया/ SOLD TO :

मेसस/ M/s ---------------------------

---------------------------------

मनी रसीद स.ं / MONEY RECEIPT NO. -----

त%थ/ Date :

वBरC मडंल �वEुत अ*भयतंावBरC मडंल �वEुत अ*भयतंावBरC मडंल �वEुत अ*भयतंावBरC मडंल �वEुत अ*भयतंा( ( ( ( कककक....�व�व�व�व.).).).)

दददद....पूपपूूपू....रेलवे रेलवे रेलवे रेलवे ////आJाआJाआJाआJा

2

SOUTH EASTERN RAILWAY

ADRA DIVISION Description of Work : Provision of OHE of line from 'P' Cabin to Loco line along with

OHE of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway

Sr. No. Contents Page No.

1 Tender paper Money receipt form 1

2 Index 2

3 Tender Notice 3-5

4 Instructions to Tenderers & Terms and Conditions

6-20

5 Conditions of Prices and Payment Terms 21-22

6 Special Conditions -I 23-25

7 Performance Report Sheet 26-27

8 Indemnity Bond 28

9 Bank Guarantee Bond 29

10 Tender Offer Letter 30

11 Quoted Tender Rate – Sheet 31

12 Tender Schedule 32-35

13 Special Conditions 36-37

14 Explanatory Notes on Schedule of items 38-49

15 Total Pages 49

Sr. Divisional Electrical Engineer (TRD)

S. E. Railway, Adra

3

SOUTH EASTERN RAILWAY

OPEN TENDER NOTICE N0: TRD/ADA/OT-2015/5/BKSC/D-cab ,dtd 28.08.2015 Sr. Divisional Electrical Engineer (Traction Distribution), S.E.Railway, Adra, for and on behalf of the President of India, invites sealed tenders for the following work, from the reputed firms/contractors with sufficient experience and financial capabilities including those registered with any Government Department or Public Undertakings and have executed similar nature of works.

1 Description of Work Provision of OHE of line from 'P' Cabin to Loco line along with OHE of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway

2 Approximate Tender Value Rs 55,59,898/- (Rupees Fifty Five Lakh Fifty Nine Thousand Eight Hundred Ninety Eight Only)

3 Earnest Money Deposit Rs 1,11,120/- ( One Lakh Eleven Thousand One Hundred Twenty only)

4 Cost of the Tender Forms Rs 5,700/-( Rupees Five Thousand Seven only ) ( Tender paper cost:Rs 5,000/- & Service Tax of Rs 700/- )

5 Completion Period 09 (Nine ) months from the date of issue of LOA.

6 Date, Time & Place of Selling of tender

Tender Forms can be obtained from the Office of the Sr. Divl. Elect. Engineer (TRD), S.E.Railway, Adra and office of SSE/OHE/BKSC( Bokaro Steel City ) ,S.E.Railway, during working hrs. from 14.09.2015 to 14.10.2015 ( up to 12:00 Hrs) on production of original money receipt for Rs. 3,420/- (non-refundable) Allocation Z-650.

7 Date, Time & Place of Closing

Up to 12:30 hrs. of 14.10.2015. The Tender may be dropped in the special box available in the office of the Sr. DEE(TRD)/S. E. Railway , Adra or office of SSE/OHE/BKSC( Bokaro Steel City ) ,S.E.Railway during office hours.

8 Date, Time & Place of Opening of tender

At office of the Sr.DEE (TRD) / S.E.Railway, Adra and office of SSE/OHE/BKSC( Bokaro Steel City ) ,S.E.Railway 13.00 hrs or later on 14.10.2015 simultaneously.

9 Eligibility Criteria i) Must have successfully completed at least one similar single work for a minimum value of 35% of advertised tender value in the last three financial years (i.e. current year and three previous financial years).

ii) Total contractual amount received during the last three financial years and in the current financial year should be a minimum of 150% of the advertised tender value. In this effect the tenderer has to submit along with the tender the attested authentic certificate from the employer/client, audited balance sheet duly

4

certified by the Chartered Accountant etc., from which the turn over of the Company can be clearly calculated.

(iii) Must have the valid Electric Contractor License and Electrical Supervisory License certificate from State Govt./Central Govt for working in 25 KV or more than 25 KV system

Note: Similar nature of works means “The work pertaining to Design, Supply, Erection & Maintenance of OHE of 25 KV AC traction in Indian Railway”. 10. The following documents should be specified for submission along with tender.

a) List of Personnel, Organization available on hand and proposed to be engaged for the subject work.

b) List of Plant & Machinery available on hand (own) and proposed to be inducted (own hired to be given separately) for the subject work.

c) List of works completed in the last three financial years giving description of work, organization for whom executed, approximate value of contract at the time of award, date of award and date of scheduled completion of the work. Date of actual start, actual completion and final value of contract should also be given with supportive documents/certificates from the organizations with whom they worked/are working should be enclosed. No certificate from private individual for whom such works are executed/being executed would be accepted.

d) List of works on hand indicating description of work contract value, approximate value of balance work yet to be done and date of award with supportive documents/certificates from the organizations with whom they worked/are working should be enclosed. No certificate from private individual for whom such works are executed/being executed would be accepted.

11. Tenders must be accompanied with prescribed amount of earnest money in acceptable form as mentioned in the tender document. Earnest money in the form of Guarantee Bond will not be accepted. Tender without prescribed earnest money will liable to be summarily rejected.

12. Tender Documents should not be sent by Ordinary Post. Tenders received in this office by Registered Post on or before 12:30 hrs. of 14.10.2015 will be deposited in the Tender Box before the closer.

13. In case the office remains closed on the date of opening of the tender for any unforeseen circumstances, the tenders will be received and opened on the next working day at the same time and place.

14. The Railways reserves the right to accept or reject any bid including the lowest one or all the Tenders or part thereof and split the contract without assigning any reason. Conditional bids incomplete/delayed offers for any reason shall stand rejected.

15. Request for issue of tender paper through post is not acceptable. 16. Tender forms are not transferable. 17. The tenderer can also download the tender documents from the NIC’s web site

http://tenders.gov.in , S.E.Railway’s website www.ser.indianrailways.gov.in and can also be dropped in the tender box .However, Tenderer/s will have to deposit non-refundable Demand Draft in favour of FA & CAO, Garden Reach, S.E. Railway or Money Receipt for requisite amount issued by Chief cashier /GRC or Divnl. Cashier/Adra or Chief booking Clerk /Adra as a cost of Tender Form which will have to be attached with the tender Form otherwise the tender Form will be summarily rejected.

Railway administration will not be responsible for any delay/difficulties/ inaccessibility of the downloading facility for any reason whatsoever. In case of any discrepancy between the tender documents downloaded from internet and the master copy available in the office of Sr. DEE (TRD)/ADA, the latter shall prevail and will be binding on the tenderers. No claim on this account shall be entertained.

Sr. Divl.Elect.Engineer (TRD)/ADA For and on behalf of The President of India

5

SOUTH EASTERN RAILWAY

ADRA DIVISION

OHE Works

Tender Notice No & Description of Work Approx. value (Rs) E.M.D (Rs.)

1. TRD/ADA/OT-2015/5/BKSC/D-cab ,dtd 28.08.2015

Provision of OHE of line from 'P' Cabin to Loco line along with OHE of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway

Rs 55,59,898/- Rs 1,11,120/-

Cost of Tender Forms :

Rs 5,700/-( Rupees Five Thousand Seven only ) ( Tender paper cost:Rs 5,000/- & Service Tax of Rs 700/- )

Selling of Tender :

Tender form can be obtained from the office of Sr. Divisional Electrical Engineer (TRD)/ADA or the office of SSE/OHE/BKSC ( Bokaro Steel City ) , S.E.Railway from 14.09.2015 to 14.10.2015 ( up to 12:00 hrs.).

Date, Time & Place of Closing

at 12:30 hrs. on 14.10.2015. The Tender may be dropped in the special box available in the office of the Sr. DEE(TRD)/S. E. Railway , Adra or office of the SSE/OHE/BKSC( Bokaro Steel City ) , S.E.Railway during office hours.

Date of Opening of Tender :

14.10.2015 ( at 13:00 hrs. or later ) at the office of Sr. Divisional Electrical Engineer (TRD)/ADRA and the office of SSE/OHE/BKSC( Bokaro Steel City ) , S.E.Railway

Completion Period : 09 (Nine ) months from the date of issue of L.O.A.

Tender Notice is available at NIC’s web site http://tenders.gov.in , S.E.Railway’s website www.ser.indianrailways.gov.in . Tenderers can also download the tender document from the above website from 14.09.2015 and up to 12:00 hrs. on 14.10.2015 . Tender notice is also available at the notice board of Sr. DEE/TRD/ADA’s office. Note: Similar nature of works means “The work pertaining to Design, Supply, Erection & Maintenance of OHE of 25 KV AC traction in Indian Railway”.

Sr. Divl. Elect. Engineer (TRD)/ADA For and on behalf of The President of India

6

CHAPTER-I

INSTRUCTION TO TENDERERS AND TERMS AND CONDITION OF TENDERING.

(To be signed by the Tenderer and submitted along with the tender) 1.1.1 TENDER PAPER DOCUMENT. The tender paper/documents are divided into Two parts. The part-I consists of Tender notice, instructions to tenderer and terms and condition for tendering including conditions of pricing and payment. Part-II consists of the following.

a) Special conditions of tendering b) Tender form c) Schedule of Price with its explanatory note

1.1.2 GENERAL INSTRUCTIONS It may be noted here that the conditions of General conditions of contract (G.C.C.)(with the latest amendment, if any) of S. E. Railway, all provisions of relevant codes, manual etc.( with the latest amendment, if any), are generally applicable unless specifically mentioned otherwise in this paper. The intending tenderer before submission of tender is advised that in his own interest to study the tender papers carefully without prejudice to the generally of the foregoing and the tenderer shall inspect the site and surrounding of the works specified in the tender documents and shall satisfy himself by careful examination before submission of the tender as the nature of site , soil and local conditions, availability of labour and materials for execution of work, the means of access to site supply of power, water, availability of accommodation etc. and shall make local and independent inquiries as to matters for and things referred to or implied in the tender documents Railways shall not entertain the tenderer in any form or plea of ignorance, difficulties doubts, misconception and mis-appreciation thereof effecting the execution and completion of work. 1.1.3 ALTERNATIVE PROPOSALS: Should the tenderer have alternative proposals for arrangement design and specification which the tenderer considers would reduce the cost of the installation, improve the performance and reliability he should incorporate them in the tender (form 5) for consideration by the purchaser. He shall clearly indicate the technical and financial advantage which would accrue to the purchaser for such alternative proposals suggested by him. Such proposals, shall however be given without any loss of generally of the specification and drawing obtained herein. 1.1.4 SUBMISSION OF TENDER: The tender must be submitted in sealed envelope marked with the tender No. and the name of the work and should dropped in the sealed TENDER BOX’ kept for the purpose at the time as mentioned in the Tender Notice for this purpose. Tenders, sealed and super scribed as above, may also be sent by Registered post addressed to the above mentioned office so as to reach earlier to the date and time of the closing of the tender, No tender which is received after the time and date specified above will be considered under any circumstances. Any tender delivered or sent otherwise will be at the risk of the tenderer. All documents to be submitted in connection with the tender shall be written in English and in ink. 1.1.5 RATES: The tenderer(s) should quote only uniform percentage (ABOVE/BELOW) the rates of all items given in schedule of prices any tender received with different percentage for different items of the schedule stands; summarily rejected. CONDITIONAL OFFERS WILL BE SUMMARILY REJECTED. 1.1.6 CLARIFICATION Clarification required by the tenderer may be obtained from the office of the Sr. Divisional Electrical Engineer (TRD), Adra or as prescribed. 1.1.7 INCOME TAX AND SALES TAX CLEARANCE CERTIFICATE: The tenderer is required to produce along with his tender the current and valid income tax and sales tax clearances certificate, in original (which will be returned when done with) without which the tender will be rejected. The successful tenderer shall have to send current income tax and sales tax clearances along with the bill without which no payment would be made to him. 1.1.8 TAX DEDUCTION: Income Tax @ 2% plus surcharges as applicable on the amount to be paid by the contractor in pursuance of the contract which will be deducted from the bills preferred by him in accordance

7

with section 1204C of the Income Tax Act.1961 as introduced through finance Act of 1972 or as amended from time to time, @ 4% OWST/JWST/WBST will be recovered where it is applicable. In addition to 1% C.Cess is also recoverable if the site of work falls under the Railway settlement limit. 1.1.9 LICENCE AND ELECTRICAL CONTRACTORS CERTIFICATE. Along with the tender, the tenderer shall have to submit valid Electrical Contractor’s Licence issued by the Government in favour of the contractor to execute the work and valid Electrical Supervisory certificate to supervise the Electrical works. Alternatively, the firm must be a Registered Company under State/Central Government for carrying out business in Electrical Construction works. 1.1.10 SIGNING OF TENDERS AND POWER OF ATTORNEY: In case of a firm not registered under partnership Act, all the partners or the attorney duly authorized by all of them should sign the tender and other connected documents. A copy of the document empowering the individual to sign should also be sent with the tender. In any case, tender should disclose his constitution fully and copies of all necessary legal documents in support thereof should be submitted with the tender and originals thereof should be produced as and when called for.

1.1.10.1 Any individual signing the tender or other documents connected therewith should specify whether he is signing.

(i) As sole proprietor of concerned or his attorney or (ii) As a partner or partners of the firm or (iii) For the firm per procreations or (iv) As a director, Manager or Secretary in the case of limited company.

1.1.11 TENDER ADDRESSES: Every tenderer shall state in the tender his postal address fully and clearly. Any communication sent to the tenderer by post at his said address shall be deemed to have reached the tenderer duly and in time notwithstanding the fact that the communication did not reach the tenderer at all or in time for the reasons whatsoever Important document shall be sent by Registered post.

1.1.12 ERASURES OR ALTERNATION: No erasure or alternation in the text of the tender paper is permitted and any such erasure and/or alternation will either be disregarded or render the whole tender void at the option of the Railway Administration. Any correction made in rates for the work shall be initiated in ink and dated. 1.1.13 COMPLIANCE WITH INSTRUCTIONS: Tender which do not comply with the instructions detailed above shall not be considered. 1.1.14 RESULTS OF TENDER : The acceptance of the tender will rest with Sr. Divisional Electrical Engineer (TRD), S.E.Railway, Adra for and on behalf of the president of India who reserves the right to decide the tender amongst more than one tenderer, if deemed necessary and also to reject any or all tenders received without assigning any reasons and does not bind himself to accept the lowest or any tender. 1.1.15 VALIDITY OF TENDER : The contractor shall keep the offer viz. the tender and/or tenders as may be modified by negotiations open for acceptance for a period of 120 days from the date on which tender/tenders is/are opened and in default, the Earnest Money deposited by him shall be forfeited to the Railway. 1.1.16 TIME SCHEDULE AND PROGRAMME: The contractor shall strictly follow the time schedule for all works under this as mentioned in the tender notice if the contractor fails to execute the work completely within the time specified or an authorized extensions thereof, Railway Administration is entitled to recover from the contractor a sum of half percent of the price of that portion of the work not completed by the due date for each and every week or part of the week taken extra by the contractor to complete the work . The amount of damages recovered shall in no case exceed 10% of the value of the contract. If such a failure as aforesaid shall have arisen from any cause which the purchaser may admit as being a reasonable ground for extension of time, the purchaser shall allow such additional time as he may in his absolute discretion consider to be reasonably justified by the circumstances of the case. 1.1.17 TERMINATION OF CONTRACT: Notwithstanding the provisions under other papers the Railway Administration may at any time by a notice in writing summarily terminate the contract without liability to pay any compensation to the contractor in respect thereof in any of the following event:

8

i) INSOLVENCY : The contractor being an individual or a firm any partner in the Contractor’s firm shall at any time be adjudged insolvent or shall have a receiving order for administration of his estate made against him or shall take any proceeding for liquidation on composition under any law relating to insolvency for time being enforce or make any conveyance or assignment of his assets or enter into any arrangements or composition with his Creditors or suspend payment or is the firm be dissolved under the partnership Act. ii) LIQUIDATION : If the contractor being company shall pass a resolution or the court shall make an order for the liquidation of its affairs or a receivers or a manager on behalf of debenture holders shall be appointed or circumstances shall have arisen which entitled the court or debenture holders to appoint a receiver or manager. iii) BREACH OF CONTRACT : If the contractor commits any breach of this contract not herein specifically provided always that such termination shall not prejudice any right of action or remedy which shall have accrued or accrue thereafter to the Railway administration and provided also that the contractor shall be liable to purchase any extra expenditure which the Railway Administration is thereby put to but shall not be entitled to any gain on repurchase in the event of such termination without prejudice to the other right and remedies of the Railway administration including the rights for forfeiting the security deposit, the Railway administration shall be entitled to have the work or the undone portion thereof performed, executed and/or carried out by any other agency at the cost and risk of the contractor liable for reimbursement in the event of any loss on this account. 1.1.17.2 EXCEPTIONS : Termination of contract will not arise in case of voluntary liquidation meant for alternation or reorganization provided with the newly formed company takes over the fully responsibility and Liabilities of the liquidated firm and it is acceptable to the Railway Administration. 1.1.17.3: Termination of contract under this Para will not arise in case of breaches or defects of a minor nature . The Sr.Divl.Elect.Engineer(TRD)/ADA shall be the sole authority, to decide whether breaches and defects are of minor nature. 1.1.18 EARNEST MONEY: Along with his tender the tenderer should deposit cash with the Divisional Cashier, S. E. Railway, Adra (West Bengal). The amount as specified in tender notice or below as Earnest money. The tenderer shall be required to deposit earnest money with the tender for the due performance with the stipulation to keep the offer open till such date as specified in the tender, under the conditions of tender. This earnest money shall be applicable for all modes of tendering. The amount of earnest money to be deposited with tender shall be as indicated below:

Value of the work (Tender value ) EMD

For works estimated to cost up to Rs. 1 Crore

: 2% of the estimated cost of work

For works estimated to cost more than Rs. 1 Crore

: Rs. 2 Lakhs plus ½ % (Half percent ) of the excess of estimated cost of work beyond Rs. 1 crore subject to a maximum of Rs. 1 crore

EMD in the form of bank guarantee bonds is not acceptable. No PEMD is acceptable for the tenders. 1.1.18.1 Earnest money shall be paid in cash or in any of the following forms: i) The Earnest Money should be in cash or Banker’s Cheques /Demand Drafts in favour of FA & CAO of S.E.Railway , executed by State Bank Of India or any of the nationalized Banks or by a Scheduled Bank”.No confirmatory advice from the Reserve Banks of India will be necessary. ii) The documents as referred to this tender document must be attached with the tender without which the tender will not be considered and summarily rejected.

1.1.18.2 The Government securities (Stock securities, Bearer Bonds, Promissory notes, Cash certificates etc.) shall not be accepted as Earnest money.

1.1.18.3 It is stated that the Earnest money as specified is to be submitted in full as initial security.

1.1.18.4 No interest will be allowed or paid for Earnest Money above; the amount will be refunded to the unsuccessful tenderer as soon as possible after the tender is finally decided.

9

1.1.18.5 It shall be understood that the tender documents have been sold/issued to the tenderer and he has agreed to the tender taking into consideration the stipulation on his part that after submitting the tender will not resile from his offer or modify his conditions thereof in a manner not acceptable to the purchaser.

1.1.18.6 Should the tenderer fail to observe or comply with this stipulation, the amount of security deposit referred to in clause 1.1.18.3 above shall be forfeited to the Government.

1.1.19 SECURITY DEPOSIT 1.1.19.1 Unless otherwise specified in the special conditions, if any, the Security Deposit/rate

of recovery/mode of recovery shall be as under :- a) Security Deposit for each work should be 5% of the contract value, b) The rate of recovery should be at the rate of 10% of the bill amount till the full

security deposit is recovered. c) Security Deposit shall be returned to the contractor after the physical

completion of the work as certified by the Competent Authority. The Competent Authority shall normally be the authority who is competent to sign the contract. If this Competent Authority is of the rank of lower than JA Grade, then a JA Grade Officer (concerned with the work) should issue the certificate. The certificate inter alia, should mention that the work has been completed in all respects and that all the contractual obligations have been fulfilled by the contractors and that there is no due from the contractor to Railways against the contract concerned. Before releasing the SD, an unconditional and unequivocal no claim certificate from the contractor concerned should be obtained.

1.1.19.2 The Earnest money of the successful Tenderer will be retained by the Railway as a part of security for due fulfillment of the contract by the Contractor.

1.1.19.3 The National plan load certificate, Government securities (Stock certificate, Bearer bonds, Promissory notes, cash certificates) will not be accepted.

1.1.19.4 No cheque will be accepted towards Security Deposit, even if it is guaranteed by the Bank.

1.1.19.5 Request for transfer of security deposit of any work even if the same is free of all obligations will not be accepted for the purpose of the security deposit of this case.

1.1.19.6 No interest will be allowed or paid for the amount deposited in cash or deducted through bills.

1.1.19.7 As far as practicable tenderer should in their own interest deposit security deposit in cash with Divl. Chief Cashier/S. E. Railway, Adra to facilitate prompt refund of the deposited amount on fulfillment of the terms of the contract.

1.1.19.8 PERFORMANCE GUARANTEE: The procedure for obtaining performance guarantee is outlined below : a) The successful bidder shall have to submit a performance guarantee (PG) with in 30(Thirty) days from the date of issue of letter of acceptance (LOA) extension of time for submission of PG beyond 30 (Thirty) days and up to 60 days from the date of issue of LOA may be given by the authority who is competent to sign the contract agreement . However a panel interest of 15% per annum shall be charged for the delay beyond 30 (Thirty) days i.e. from 31st day after the date of issue of LOA. In case the contractor fails to submit the requisite PG even after 60 days from the date of issue of LOA, the contract shall be terminated duly forfeiting EMD and other dues, if any payable against that contract . The failed contractor shall be debarred from participating in re-tender for that work. b)The successful bidder shall submit the performance guarantee (PG) in any of the following forms amounting to 5% of the contract value : i)A deposit of cash. ii)Irrevocable Bank Guaranty. iii)Government securities including state loan bond at 5% below the market value . iv)Deposit receipts, Pay orders, Demand drafts and Guarantee bonds . These forms of Performance Guarantee could be either of the State Bank of India or of any of the Nationalized Bank. v)Guarantee bond executed or deposits receipts tendered by all scheduled Banks. vi)A deposit in the post office Saving Bank . vii)A deposit in the National Saving certificates.

10

viii)Twelve years National Defense certificates. ix)Ten years Defense Deposits. x)National Defense Bond and xi)Unit Trust Certificates at 5% below market value or at the face value whichever is less. Also FDR in favour of FA&CAO (free from any encumbrance) may be accepted. NOTE : The instrument as listed above will also be acceptable for Guarantees in case of Mobilization Advance. c)The performance guarantee shall be submitted by the successful bidder after the Letter of Acceptance (LOA) has been issued ,but before signing of the contract agreement. This PG shall be initially valid up to the stipulated date of completion plus 60 days beyond that. In case the time for completion of work gets extended, the contractor shall get the validity of PG extended to cover such extended time for completion of work plus 60 days. (d)The value of PG to be submitted by the contractor will not change for variation up to 25% (either increase or decrease).In case during the course of execution, value of the contract increases by more than 25% of the original contract value, an additional Performance guarantee amounting to 5% (Five percent) for the excess value over the original contract value shall be deposited by the contractor. (e)The performance Guarantee (PG) shall be released after physical completion of the work based on ‘completion certificate’ issued by the competent authority stating that the contractor has completed the work in all respect satisfactorily. The security deposit shall however be released only after expiry of the maintenance period and after passing the final bill based on “NO CLAIM CERTIFICATE” from the contractor . (f) Whenever the contract rescinded the Security Deposit shall be forfeited and the performance guarantee shall be encashed. The balance work shall be failed contractor shall be debarred from participating in the tender for executing the balance work. If the failed contractor is a JV or partnership firm then every member / partner of such a firm debarred from participating in the tender for the balance work in his/her individual capacity or as a partner of any other JV/partnership firm. (g) The engineer shall not make a claim under the Performance Guarantee expect for amounts to which the President of India is entitled under the contract (not withstanding and/or without prejudice to any other provisions in the contract agreement) in the event of: (i)Failure by the contractor to extend the validity of the performance guarantee as described here in above in which event the engineer may claim the full amount of the Performance Guarantee. (ii)Failure by the contractor to pay President of India any amount due, either as agreed by the contractor or determined under any of the Clauses/Conditions of the agreement, within 30 days of the service of notice to this effect by engineer. (iii)The contract being determined under provision of the GCC, the Performance guarantee shall be forfeited in full and shall be absolutely at disposal of India.

1.1.20 ADDITIONS AND ALTERATIONS: Railway Administration may require modifications to be carried out on the works Considered necessary either during the execution or after a part of whole of the installations coming within the purview of the contract such modifications shall be carried out, only after the additional prices , if any proposal by the contractor are accepted by the Railway Administration. 1.1.20.1 If any additional quantum of the works specified in the schedule becomes necessary during the course of execution , the contractor may be called upon to carry out such , additional works to the extent of 25% of the original contract quantity at the same rates, terms and conditions without inviting any fresh quotations . 1.1.21 SAFETY MEASURES: The contractor shall take all precautionary measures in order to ensure the Protection of his own personal moving about or working in the Railway premises, but shall then conform to the rules and regulations of the Railways . The contractor shall abide by all Railway regulations in force for the time being and ensure that the same are followed by his Representatives , agent or sub-contractor of workmen . He shall give due notice to his employees and workers about the provisions of the Para. The contractor shall indemnify and keep the Railway Administration indemnified and harmless against all actions, suits , claims, demands, other charges or expenses arising in connection with any accidents , death or injury sustained by any person(s) within the Railway

11

premises and any loss or damage to Railway property sustained , due to the acts or omissions of the contractor, or his staff during the execution of this contract irrespective of whether such liability arising under the workmen’s compensation Act 1923 or fatal accidents Act or any other stature in force for the time being . 1.1.22 EXECUTION OF AGREEMENT The contractor is required to execute a formal agreement in prescribed form (Form 7) with the Railway Administration on the lines of the Tender conditions and until the formal agreement is executed , the LOA by the Railway Administration shall be valid and binding on the contractor in all respects . 1.1.23 RAILWAY PASSES: No free Railway passes will be issued for the contractor. 1.1.24 SPECIFIED RAILWAY STORES: Materials which are to be supplied by the Railways as specified in Annexure for Execution of the work will be handed over to the contractor by the consignee from his store against Indemnity Bond (Form 6) . The loading, handling and transportation of such materials to the work sites shall have to be done by the contractor at his own cost. All other materials as may be required to execute the work and to make the installation, complete in all respects according to the specification and schedule of work shall be supplied by the contractor and cost thereof included in the schedule of prices . The transportation of the materials to the work site shall be borne by the contractor. 1.1.25 REFUND /FORFIETURE OF EARNEST MONEY: The Earnest money including the amount taken as security deposit for the due performance of the stipulation to keep the offer open till the date specified in the tender under clause 1.1.15(i.e Minimum validity of offer ) hereof shall be refunded to the unsuccessful tenderer(s) within a reasonable time after finalization of the tender case . The earnest money deposited by the successful tenderer(s) shall be retained towards the security deposit for the due and faithful fulfillment of the contract but shall be forfeited by the purchaser without prejudice to any other rights or remedies available to it if the contractor fails to execute the Agreement bond or start the work within a reasonable time (to be determined by the Engineer at site) after notification of the acceptance of his/their tender. 1.1.26 COMMUNICATION TO BE IN WRITING : All notices communications, reference and complaints made by the purchaser of his Engineer or the Engineer’s representative or the contractor in tense concerning the works shall be in writing and no notice communications reference or complaint not in writing shall be recognized. The list of addresses to which correspondence and documents relating to the contract should be sent are indicated in the tender papers in Part-II. 1.1.27 SERVICE OF NOTICES ON CONTRACTORS: The contractor shall furnish to the Engineer the name, designation and address of his authorized agent and all complaints , notices, communications and references shall be deemed to have been so duly given to the contractor if delivered to the contractor left at or posted to the address so given and shall be deemed to have been so given in the case of posting on the day on which would have reached such address in the ordinary course of post or on the day on which they were so delivered or left in the case of contract by partners, any change in the constitute of the firm shall be forthwith notified by the contractor to the Engineer. Important documents may be sent by “REGISTERED POST”. 1.1.28 SUBLETTING OF CONTRACT : The contractor shall not assign or sublet the contractors any part thereof or allow any person to become interested therein any manner whatsoever without the special permission of the purchaser. Any breach of this condition shall entitle the purchaser to rescind the contract under clause 1.1.45 (i.e Right to Railway to determine contract ) of these conditions and also render the contractor liable for payment to the purchaser in respect of any loss or damage arising or ensuring from such cancellation. 1.1.29 APPROVAL OF SUBCONTRACTOR OR VENDORS: The name of all sub contractors proposed to be employed on execution of work or any part thereof including manufacture of components shall be submitted by the Contractor to the purchaser and got approved by him before the contractor enters into an agreement with sub-contractor/or vendor for the purpose . The permitted subletting of work by the contractor shall not establish any contractual relationship between the sub-contractor and the purchaser and shall not relieve the contractor of any responsibility under the contract. 1.1.30 RETURN OF UNUTILISED MATERIALS OF THE PURCHASER: Such materials as have been issued to the contractor but left behind with him UNUTILISED, shall be determined after reconciliation with the actual quantum of issued vis-à-vis utilized for execution of the work and returned by the contractor to the purchaser’s depot at no extra cost in the same shape and condition of the materials as were issued to the contractor(s). If the

12

contractor fails to return such materials, the cost of such will be recovered at a rate at twice the book rate or twice the market rate enhanced by 20.38% whichever is higher. Every effort will be made by the purchaser to supply the materials as listed in part-II at the appropriate time. However suitable extension of time will be granted to the contractor in case of delay for supply of said materials by the purchaser any reason whatsoever and no claim of compensation from the contractor for such delay by the purchaser will be entertained. NOTE: The contractor shall hand over all empty drums, wooden carats and other packing materials used for the issue of purchaser’s materials to the purchaser’s depot. CARRIAGE OF MATERIALS : No forwarding orders shall be issued by the purchaser for the transportation of Contractor’s materials, tools and plant by rail or by road to the work site which may be required for use in the works and the contractor shall pay full freight charges at public tariff /rates there for. No Road permit for contractor’s supply material will be issued by Railways. 1.1.31 PROVISION OF EFFICIENT AND COMPETENT SUPERVISOR : The erection of all equipments according to the specification will be done by the contractor at his cost. For this purpose, the contractor shall place and keep on the works at all times efficient and competent representatives to give necessary directions to his workmen and see that they execute their work in sound and proper manner and shall employ only such supervisors, workmen and labour in or about the execution of any of the works as are careful and skilled in their various trades and callings. The said representative shall be present at site during work in hours and any written orders or instructions which the engineer may give to the said representatives of the contractor shall be deemed to have been duly given or communicated to the contractor. The contractor shall furnish the name and address of his agent or representatives for the purpose of this clause. The contractor or his agent or representative will accompany the engineer/s on inspection and/or proceed to their offices whenever called upon to do so. The Contractor shall at once remove from the works any representative, permitted sub-contractor supervisor, workmen or labour who shall be objected to by the engineer and he shall submit a correct return showing the names of all staff and workmen employed by him . In the event of the engineer being of the opinion that the contractor is not employing on the works a sufficient number of staff and worker as is necessary for the proper completion of the work within the time prescribed , the contractor shall forthwith on receiving intimation to this effect take on the additional number of staff and labour specified by the engineer within seven days of being so required . Failure on the part of the contractor to comply with the above instructions will entitle the purchaser to rescind the contract under clause 1.1.45 i.e. Right of Railway to determine contractor of the conditions thereof . 1.1.32 ACCIDENTS AND DAMAGES TO INSTALLATIONS ETC The contractor shall be responsible for all repairs and rectification of damage to installations erected or under erection due to accident or any other cause during the course of the contractors work at site inclusive of the guarantee period at no extra cost to the purchaser. All costs, damages or expense which the purchaser may incur, for which under the terms of contract, the contractor is liable may be either deducted by the purchaser at his discretion from any money due or to become due to refundable by the purchaser to the contractor under the contract , or may be recovered by action of law or otherwise from the contractor . The purchaser reserve the right and shall be entitled to retain payments due to the contractor under this contract and to set off the same against all claims whether arising out of this contractor out of any other transaction whatever with the contractor. 1.1.33 PROVISION OF PAYMENT OF WAGES ACT : The contractor shall comply with the provision of payment of wages Act 1936 as amended up to date and the rules made thereunder in respect of all employees employed by him in the works, if in compliance with the terms of the contract , the contractor directly or through the petty contractors or subcontractors shall supply any labour to be used wholly or partly under the direct orders and control of the engineer whether in connection with the work to be executed here under or otherwise for the purpose of the engineer such labour shall never the less be deemed to be , comprise of person employed by the contractor and any money which may ordered to be paid by the engineer on behalf of the contractor and engineer may on failure by the contractor to repay such moneys due to the contractor in terms of the contractor. The purchaser shall be entitled to deduct from any moneys due to the contractor (whether under the contract or any other of compensation of aforesaid or for costs of expense in connection with any claim there) and the decision of the engineer upon any question arising out of the effect or force of this clause shall be final and binding upon the contractor.

13

1.1.34 WAGES TO LABOUR The contractor shall be responsible to ensure compliance with the provisions of the Minimum Wages Act, 1948 as modified up to date (therein after referred to as the said act), and the rules made there under in respect of any employees employed by him directly or through petty contractors , sub-contractors for the purpose of carrying out this contract. If, in compliance with the terms of the contract , the contractor directly or through petty contractors or sub-contractor supplies any labour to be used , wholly or partly under the direct orders and control of the purchaser whether in connection with any work being executed by the contractor or otherwise for the purpose of the purchaser such labour shall for the purpose of this clause shall be deemed to be persons employed by the contractor. If any money , shall be a result of any claim or application and under the said act be directly to be paid by the purchaser such money shall be deemed to be payable to the purchaser by the contractor and on failure by the contract or to repay the purchaser and moneys paid by it as aforesaid within seven days after the same shall have been demand the purchaser shall be entitled to recover the same from any moneys due or accruing to the contractor under this or any other contract with the purchaser. 1.1.35 POWER OF MODIFICATION TO CONTRACT : The engineer in charge of the execution of the work on behalf of the purchaser shall be entitled by order in writing to enlarge or extend, diminish or reduce the works or make any alternations in their design , character , position site quantities , dimensions or in the method of their execution or in the combination and use of materials for the execution or thereof or to order any additional works to be done or any works not to be done and the contractor will not be entitled to any compensation for any increase/reduction in the quantities of work but will be paid only for the actual amount of work done and for approved materials supplied against a specific order . 1.1.35.1 Unless otherwise specified in the special conditions of the contract, the accepted variation in quantities for the contract overall would be up to 25 % of the quantity originally contracted . The contractor shall be bound to carry out the work at the agreed rates and shall not be entitled to any claim or any compensation whatsoever up to the limit of 25% variation on the contract value originally contracted. 1.1.35.2 The enlargement , extensions, diminution, reductions, alternations or additions referred to in clause in no degree affect the validity of the contract but shall be performed by the contractor as provided therein and be subject to the same conditions, stipulations and obligations as if they had been originally and therein and be subject to the same conditions stipulations and obligations as if they had been originally and expressly included and provided for in the specifications and drawings and the amount to be paid therefore shall be calculated in accordance with the accepted schedule of rates, any extra items/ quantities of work failing outside the purview of the provisions of the sub-clause 1.1.36 above shall be paid for at the rates determined (i.e. rates for the extra items of work of these conditions) 1.1.36 COMPLIANCE TO ENGINEER’S INSTRUCTIONS : The Engineer shall direct the order in which the several parts of the works shall be executed and contractor shall execute without delay all orders given by the engineer from time to time but the contractor shall not be relieved thereby from responsibility for the due performance of the works in all respects. Alternations to be authorized: No alternations in or additions to or commission or abandonment of any part of the works shall be deemed authorized except under instructions from the engineer and the contractor shall be responsible to obtain such instruction in each and every case. EXTRA WORK: Should works over and above those included in the contract required to be executed at the site the contractor shall have no right to entrust with the execution of such works which may be carried out by another contractor or contractors or by other means at the options of the purchaser. Separate contract in connection with works: The purchaser shall have the right to let other contractors in connection with the works the contractor shall afford other contractor reasonable opportunity for the storage of their materials and the execution of their works and shall properly connect and co-ordinate his works there. If any part of the contractor work depends for proper execution or result upon the work of another contractor, the contractor shall inspect and accordingly report to the engineer any defects in such work that render it unsuitably for such proper execution and result . The contractor’s failure so to inspect and report shall constitute acceptance of the other contractor’s work except as to defects which may have developed in the other contractor’s work after the execution of his work.

14

1.1.37 ILLEGAL GRATIFICATION : Any bribe, commission, gifts or advantages given, promised or offered by or on behalf of the contractor or his partner, agent or servant or any one of his or on their, behalf in relation to the obtaining or the execution of this or any other contract with purchaser shall in addition to any original liability which he may incur , subject to the contractor to the recession, of the contract and all other contracts with the purchaser and to the payment of any loss or damage resulting from such rescission and the purchaser or damage resulting from such rescission and the purchaser shall be entitled to deduct the amount so payable from any money due to the contract under the contract or any other contracts with the purchaser. The contractor shall not lend or borrow from or have or enter into any monetary dealings or transactions either directly or indirectly with any employee of the purchaser and if he shall do so the purchaser shall be entitled forthwith to rescind the contracts and all other contracts with the purchaser. Any question or dispute as to the commission of any offence or compensation payable to the purchaser under this clause shall be settled by the General Manager in such manner as he shall consider fit and sufficient and his decisi on shall be final and conclusive. 1.1.38 ADHERENCE TO SPECIFICATION AND DRAWINGS: The whole of the works shall be executed in perfect conformity with specifications and drawings of the contract. If the contractor performs any work in manner contrary to the specifications or drawings or any of them and without such reference to the engineer, shall have to bear all the costs arising of ensuring and shall be responsible for the losses to the purchaser. 1.1.39 WORKS BY OTHER AGENCIES: Any other works undertaken at the same time by the purchaser direct or through some other agency at the same site where the contractor is carrying out his work, will not entitle the contractor to prefer any claim regarding any delays or hindrances he may have to face on this account . The contractor shall comply with any instruction which may be given to his by the purchaser in order to permit simultaneous execution of his own works and of those undertaken by other contractors or the purchaser without being entitled on this account to any extra charge. 1.1.40 If the purchaser is unable to supply materials to the contractor as specified in the contract in time, the contractor shall not be entitled to any extra payment on account of such delay in supply, however such delays in supplies will be reasonable ground for extension of completion dates for the works. 1.1.41 All materials will be subjected to inspection and test either by the purchaser or by an agency appointed for this purpose for individual items as below, at the manufacturer’s work before dispatch and no materials shall be dispatched from the manufacturer’s works until these are inspected and or approved . These materials may also again be inspected at the contractor’s depot/work site . The purchaser or his representative shall have the right to be present during all stages of manufacture and shall be afforded free of charge all reasonable facilities for inspection and testing so as to satisfy himself/themselves that the materials are in accordance with specifications, approved drawings and designs. Any reasonable delay in inspection will be a reasonable ground for extension of time for completion of works. 1.1.42 PROVISIONAL ACCEPTANCE : Immediately after the completion of an installation the contractor will certify and advice the purchaser in writing that the installation is :

i) Complete . ii) Ready for satisfactory regular service and iii) Ready to be handed over. He will also place at disposal of the purchaser the

required staff for inspection, testing and putting it into operation. The test or test specified in part III will be conducted jointly by the purchaser and contractor as soon as possible after receipt of advise of completion of an installation by the purchaser from the contractor.After the purchaser is satisfied with the satisfactory working of the installation, he will issue a “Provision Acceptance Certificate” which would be signed by both the parties. Should the results of inspection and tests be not satisfactory an extension of time for one month will be granted to make good defects and deficiencies pointed out by the purchaser. A fresh inspection and tests will then be carried out after the contractor has attended to the defects and deficiencies . If these are not satisfactory , the purchaser may proceed at the contractor’s expense by all means deemed expedient to have the installation made approved drawings and designs. In such a case or in case of delay in completing the work under this contracts within the time limit the purchaser reserves the right if he deems it possible to use in a reasonable manner any part of the installation even if the work is not completely erected. The purchaser will give

15

to the contractor for this purpose seven days previous notices. The contractor shall then take at his own expenses all necessary steps to complete the works in accordance with the provisions of the contract. In case it becomes impossible to proceed with the above mentioned taking over tests, for reasons other than for which the contractor is responsible, the provisional acceptance certificate shall be issued at or within a mutually agreed reasonable period not exceeding six months after completion of an installation. NOTE: The issue of provisional acceptance certificate will not be withheld for rectification of minor defects as distinct from rejected equipment, which may not be essential for energisation and operation of the installation in such cases, only the value of materials and cost of rectification of the minor defects shall be withheld from payments on provisional acceptance until rectification is completed. 1.1.43 WARRANTY: The contractor shall warranty satisfactory working of the installation erected by him , for a period of twelve months from the date of provisional acceptance of each installation(Para 1.1.42 i.e. provisional acceptance by the purchaser ). During this period the contractor shall make available an experienced Engineer and necessary equipment to attend to any defective installation and be responsible for satisfying himself that the purchaser’s staff follow the prescribed procedure for operation and maintenance of equipment . The contractors shall bear the cost of all modifications, additions or substitutions that may be considered necessary due to faulty materials , designs or workmanship for the satisfactory working of the equipment. The final decision shall rest with the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra. During the period of guarantee the contractor shall be liable for the replacement of any parts which may be found defective in the equipment whether such equipments be of his own manufacturer or those of his sub-contractors whether arising from faulty design, materials, workmanship or negligence in any manner on the part of the contractor provided always that such defective parts as are not repairable at site are promptly returned to the contractor if so required by him at site(contractor’s own expenses). The contractor shall bear the cost of repairs carried out on his behalf by the purchaser at site. In such a case the contractor shall be informed in advance of the works proposed to be carried out by purchaser. If it becomes necessary for the contractor to replace or renew any defective portion of the equipment under the clause aforesaid then the provision of the said clause shall also apply to the portions of the equipments so replaced or renewed until the expiration of six months from the date of such replacement or until the end of the above mentioned period of twelve months, whichever is later, such extension shall not apply in case of defects of a minor nature, the decision of the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra being final in the matter, if any defects be not remedied within a reasonable time during the aforesaid period the purchaser may proceed to do the work at the contractor’s risk and expense, but without prejudice to any other rights and remedies which the purchaser may have against the contractor in respect of such defects or faults. The repaired or renewed parts shall be delivered and erected at site free of charges to the purchaser. Any materials supplied shall also be covered by the provisions of this clause. The liability of the contractor under the guarantee will be limited to re-supply of materials made under clause 1.1.36 such supply shall be effected at the contractor’s depot or in the event of closure of the depot at the stores depot of the engineer at site covered by the contract. In case of materials supplied by the purchaser under clause 1.1.36 no liability will rest on the contractor for failure on account of defects inherent in such materials . 1.1.44 FINAL ACCEPTANCE: The final acceptance of the installation shall take effect from the date of expiration of the period of guarantee as defined in clause 1.1.43 warranty provided the installation previously accepted provisionally are still in good working order . If on the other hand the installation is not in good working order at the end of the guarantee period the purchaser may either extend the period of guarantee until, necessary works are carried out by the contractor or carry out those works or have them carried out successfully on behalf of the contractor and at his expenses . A certificate of final acceptance shall then be issued under the signature of both the parties – The purchaser and the contractor . 1.1.45 RIGHT TO RAILWAY TO DETERMINE CONTRACT: 1.1.45.1 The purchaser shall be entitled to determine and terminate the contractor at any time should in the purchaser’s opinion , the cessation of work become necessary owing to paucity of funds or from any other cause whatsoever in which case the value of approved materials at site and of work done by the contractor will be paid for in full at the rates specified in the contract . Notice in writing from the purchaser of such determination and the reason therefore shall be conclusive evidence thereof.

16

Should the contract be determined under sub-clause 1.1.45.1 of this clause and the contractor claims payment for expenditure incurred by him in the expectation of completing the whole of the works the purchaser shall admit and consider such claims as he deemed reasonable and are supported by vouchers to the satisfaction of the engineer. The contractor shall have no claim to any payment of compensation or otherwise whatsoever on account of any profit of advantage which he might have derived from the execution of the works in full but which he might have derived from the execution of the works in full but which he did not derive in consequence of determination of contract . The purchaser’s decision on the necessity and propriety or such expenditure shall be final and conclusive . 1.Determination of contract owing to default of contractor if the contractor should i) become bankrupt or insolvent or ii) make an arrangement with or assignment in favour of his creditors , or agree to carryout the contract under the committee or

iii) being a company or corporation go into liquidation (other than a voluntary liquidation for the purpose of amalgamation or reconstruction) or iv) have an execution levied on his goods or property on the works , or v) assign the contract or any part thereof otherwise than as provided as terms or these

conditions, or vi) abandon the contract or vii) persistently disregard the instruction of the engineer or contravene any provision

of the contract viii) fail to adhere to the agreed programme of work by a margin of 10% of the stipulated

period or ix) fail to remove materials from the site or to pull down and replace work after receiving

from the engineer notice to the effect that the said materials or works have been condemned or rejected under clause or

x) fail to take steps to employ competent or additional staff and labour as required for supervision of these conditions or

xi) fail to afford the engineer or engineer’s representative proper facilities for inspection the works or any part thereof as required under clause 1.1.41(i.e. inspection and testing ) of these condition, or

xii) promise offer or give any bribe , commission , gift or advantage either himself or through his partner agent himself or through his partner agent or servant to any officer or employee of the purchaser or to any person or his or on their behalf in relation to the executive of this or any other contract with the purchaser or

xiii) At any time after the tender relating to the contract has been signed and submitted by the contractor being a partnership firm, admit as one of its partners or employee under it or being an incorporated company elect or nominate or allow to set as one of its director or employees under it in any capacity whatsoever retired Engineer of the gazetted rank or any other retired gazetted officer working before his retirement whether in the executive or administrative capacity or whether holding any personable post or not , in the engineering department of the any of the railway for the time being owned and administered by the President of India before two year from the date of retirement from the said service of such engineer or officer unless such engineer or officers has obtained permission from the President of India or any officer duly authorized by him in his behalf to become a partner or a director or take employment under the contractor , as the case may be OR

xiv) Fail to give at the time of submitting the said tender . a) the correct information as to the date of retirement of such retired engineer or retired officer from the said service as to whether any such retired engineer or retired officer under the employment of the contractor at the time or submitting the said tender .

b) being a partnership firm , the correct information as to whether any or its partners was such a retired engineer or retired officer or

c) the correct information as to such engineer or officer obtaining permission to take employment under the contractor .

d) being an incorporated company , a correct information as to whether any of its directors was such a retired engineer or a retired officer or

e) being such a retired engineer or retired officer suppress and not disclose at the time of submitted the said tender the fact of his being such a retired engineer or a retired officer or make at the time of submitting the said tender a wrong statement in relation to his obtaining permission to take the contract.

If the contractor be a partnership firm or an incorporated company to be a partner or director of such firm or company as the case may be or so seek employment under the contractor.

17

Then and in any of the said cases, the engineer on behalf of the purchase may serve the contractor with a notice in writing to that effect and if the contractor does not within 7 days after the delivery to him of such notice proceed to make good his default in so far as the same is capable of being made good and carry on the work or comply with such direction as aforesaid to the entire satisfaction of the engineer , the purchaser shall be entitled after giving 48 hrs notice in writing under the hand of the engineer to rescind the contract as a whole or in part or parts (as may be specified in such notice).

2. Right of Railways after rescission of contract owing to default of contractor In the event of any or several of the course referred to clause 1.1.45.3 of these conditions adopted. i) The contractor shall have no claims to compensation for any loss sustained by him by

reason of his having purchased or procured any materials or entered into any commitments or made advance account of or with a view to the execution of the work , or the performance of the contract and contractor shall not be entitled to recover or be paid any sum for any work thereof for actually performed under the contract unless and until the engineer shall have certified the performance of such work and the value payable in respect thereof and the contractor shall only be entitled to be paid the value so certified .

ii) The engineer or the engineer’s representative shall be entitled to take possession if any materials , tools, implements machinery and building on the works or on the property on which these are being or ought to have been executed and to retain and employ the same in the further execution of the works without the contractor being entitled to any compensation for the use and employment thereof for wear and tear or destruction thereof.

iii) The engineer shall as soon as may be practicable after removal of the contractor fix and determine expert or by or after reference to the parties or other such investigation or inquiries as he may consider fit to make or institute and shall certify what amount (if any ) and at the time of rescission of the contract been reasonably earned by or would reasonably accrue to the contractor in respect of the work then actually done by him under the contract and what was value of any unused , or partially used materials, any constructional plant and any temporary works upon the site. The legitimate amount due to the contractor after making necessary deductions and certified by the Engineer should be released expeditiously.

1.1.46 SUPPLY OF SPARE PARTS : The supply of spare parts, components, standby equipments shall be so regulated that all the necessary items that have been ordered shall be delivered at site only after the erection of the main equipments but before the testing and commissioning of system. If the spare parts standby equipments are to be supplied in advance, necessary written and specific permission shall be taken from the engineer 1.1.47 ARBITRATION: 1.1.47.1 In the event of any dispute of difference between the parties hereto as to the construction or operation of this contract or the respective rights and liabilities of the parties on any matter in question dispute or difference on any account or as to the withholding by the railways of any certificate to which the contractor may claim to be entitled to or if the railways fails to make a decision within a reasonable time the n and in any case save the expected matters referred to in clause 63 of the General Conditions of the contract and standard specification 1976 of S.E.Railway the contractor after 90 days but within 180 days of his presenting his final claim on disputed matters shall demand in writing that the dispute or difference is to be referred to arbitration .

1.1.47.2 The demand for arbitration shall specify the matters which are in question, dispute/difference only such disputes and differences in respect of which the demand has been made shall be referred to arbitration and other matters shall not be included in the reference. 1.1.47.3 If the contractor(s) does/do not prefer his/their specific and final claims in writing within a period of 90 days of receiving the intimation from the government that the final bill is ready for payment he/they will be deemed to have waived his/their claim(s) and the railway shall be discharged and released of all liabilities under the contract in respect of these claims. 1.1.47.4 All questions, disputes and/or difference arising under or in connection with this contract or in any way attaching or relating to or concerning the erection, meaning or effect of these conditions or the special conditions of contract (except as to any matter the opinion and/or decision regarding which has been otherwise provided for these conditions or the special conditions of the contract to be final and also except as to any matter regarding which the contractor has given no claim certificate or such Railway officer (Retired or in service) as shall be appointed to be the arbitrator by the General Manager for the time being of the

18

South Eastern Railway in his sole and absolute discretion and the decision of such arbitrator shall be final and conclusive under provision of the Indian Arbitration Act 1948 and of the rules thereunder and all statutory modification thereof. 1.1.47.5 If the sole arbitrator appointed under sub-clause(iv) or one both the Arbitrators/appointed under sub-clause (v) above resigns his appointment or resign their appointments or vacates his office/vacate their office or is /are unable or unwilling to act for any reason whatsoever or arbitrator/arbitrators to act in his/their place /places in accordance with the provisions of sub-clause (iv) or sub-clause (v) above as the case may be shall be entitled to proceed with the reference from the stage at which it was left by the previous arbitrator/arbitrators. The arbitrator / arbitrators umpire so appointed as the case may be shall give the award on all matters referred to arbitration indicating therein break up of the sum awarded separately on each individual item of disputes.

1.1.48 ACCOMMODATION : The contractor shall make his arrangements for the accommodation of his staff, materials, tools etc, electricity for the purpose of execution of the work against this contract may be arranged by railway from its sources , if available near the work site on payment of railway’s specified charges. 1.1.49 LAWS OF INDIA : This contract shall be governed by the laws for the time being in force in the Republic of India. 1.1.50 DEFAULT AND DELAY : The contractor shall execute the work with due diligence and expedition keeping to the approved time schedule . Should he refuse or neglect to comply with any reasonable orders given to him in writing by the purchaser’s engineers in connection with the work or contrivance the provision of the contract or the progress of work lags persistently behind the time schedule due to his neglect , the purchaser shall be at liberty to be given seven days notice in writing to the contractor requiring him to make good the neglect or contravention, complained of or should the contract fail to comply with the requisition made in the notice within seven days from the receipt thereof, it shall be lawful for the purchase to take the work wholly or in part out of the contractor’s hands without any further reference and get the work or any part thereof as the case may, completed by other agencies at the expense of the contractor without prejudice to any other right or remedy of the purchaser . 1.1.51 LOSS SUSTAINED DUE TO DEFAULT AND DELAY: a)In the event of any loss to the purchaser on account of execution and/or completion of the work or any part thereof by agencies other than the contractor, in terms of Para 1.1.50, the contractor shall be liable to reimburse the loss to the purchaser without prejudice to the other rights and remedies of the purchaser, and the reimbursement in full or in part as the case may be, shall be met, at the option of the purchaser, from out of all or any of the following sources viz. i) Any amount due and payable to the contractor by the purchaser on any account whatsoever. ii)The contractor’s security deposit in the hands of the purchaser as far as Available and

iii) Any other assets whatsoever of the contractor. b) In the event of reimbursement from out of sources (i) and or (ii) above mentioned, the purchaser shall have the right of appropriation sue motto.

1.1.52 CORRECTNESS OF WORK AND MATERIALS: a) All designs and drawings submitted by the contractor shall be based on a thorough study and shall be such that the contractor is satisfied about their suitability . The purchaser’s approval will be based on these considerations . Notwithstanding approval communicated by the purchaser, during the progress of the contract , for designs and drawings prototype samples of components , materials and equipments after inspection and adjustments to installations. The ultimate responsibility for correct design and execution of work shall rest with the contractor unless the purchaser insists on adoption of his own designs in spite of the contractor not being agreeable to its . b) If any dimension figured upon a drawing differs from that obtained by sealing

the drawings the figures dimension should be normally taken as correct unless it is prima facie a mistake but all such cases shall be brought to the notice of the purchaser’s engineers and the discrepancy set right before execution .

1.1.53 CONTRACTOR’S RESPONSIBILITY FOR DISCREPANCY : a) All designs and drawings submitted by the contractor shall be based on a Thorough study

and shall be such that the contractor is satisfied about their suitability . The purchaser‘s approval will be based on these considerations. Not withstanding approval communicated by the purchaser , during the progress of the contract , for designs and drawings, prototype samples of components , materials and equipments after inspection and

19

adjustments to installations, the ultimate responsibility for correct design and execution of work shall rest with the contractor unless the purchaser insists on adoption of his own designs in spite of the contractor not being agreeable to its.

b) The contractor shall be responsible for and shall bear and pay the costs for any alternation of works arising from any discrepancies , errors or omissions in the designs and drawings have been approved by the purchaser or not .

1.1.54 ADDITIONS AND ALTERATIONS TO ERECTED EQUIPMENTS: The purchaser may require additional installations or modifications to be carried Out on the works he deems necessary, either during the execution or after a part or whole of the installations coming within the purview of the contract has been put into commercial service. In case the prices for such additional works or modifications are not covered by the Schedule of prices and are such that either partly consider additional prices for such Works justified , such additional works or modification shall be carried out, only after the additional prices proposed by the contractor are accepted by the purchaser In case additional installations or modifications are required to be carried out under this para, the purchaser shall grant a reasonable extension of time, should this be considered necessary. 1.1.55 CONTRACT LABOUR ACT: The contractor is liable to observe the provisions of contract labour Act and get himself registered under the concerned labour officer as per provision of the Act. He has to state the number of labour engaged by him for carrying out the work before signing of agreement . For any violation of the said Act , the contractor is liable for prosecution by the Labour Enforcement Officer (Central) under whose jurisdiction the Work is being executed and the amount of penalty if any , will be deducted from contractor’s final bill on advise of the labour court. 1.1.56 ISSUE OF TOOLS AND PLANTS TO THE CONTRACTOR: For the purpose of carrying out the work , Railway will not issue any tools and plants. However, if the executive officer in charge of the work is of the opinion that in the interest of faster progress of the work, any tools and plants items are to be provided to the contractor, the same may be provided to the contractor on fulfilling of an indemnity bond and the book value of the materials will kept deducted from running bills of the contractor till return of the tools and plants. The determination of book value of the T&P items is as per the Railways book or the cost of procurement of the item with normal escalation @ 10% per year added to it, whichever is higher. 1.1.57 TRANSPORTATION: All materials connected with this work whether to be supplied by the railways or the contractors have to be transported from the railway stores depot to the site by the contractors only. The contractor has also to arrange for transportation of Railway staff and supervisors connected with the work to the site of work from the Railway station during execution of the work.

1.1.58 Employment of diploma holder/Engineer Graduate : The contractor shall be required to employ un-employed Electrical Engineering graduate/Diploma holder on monthly salary during execution or works as indicated below.

Contract Value No. of Engg. Diploma holder/Graduate holder

Duration

a. Above Rs. 5 Lakhs & upto Rs. 15 Lakhs

One qualified diploma holder. During the period of currency of contract.

b. Rs. 15 lakhs and above. One qualified Electrical Engineer Graduate.

During the period of currency of contract.

In case, the contractor fails to employ the technical staff as aforesaid, he shall be liable to pay a reasonable amount not exceeding a sum of Rs. 20,000/- for diploma holder and not exceeding a sum of Rs. 40,000/- for Electrical Engineer Graduate for the month or a part of default. The decision of the Engineer-in-Charge as to the period for which the required technical staff was not employed by the contractor as to the reasonableness of amount to be deducted on this account shall be final and binding on the contractor. The deputed staff of the contractor has to keep good liaison with the Railway for execution of work .

1.1.59 Conservancy cess charges shall be deducted from on account bills in accordance with Rly Board letter No. F(X)I-95/1/1 dt.16.07.2012 which is as follows.

Description of category Average no. of Labourer or Workman Employed per

Proposed conservancy Cess Charges to be recovered PER MONTH

20

day.

1. Railway Contractors: a.Engg. Works Contractors (Engg, Elect. Mech. Signal etc.)

1 to 5 5 to 10 11 to 25

Rs. 106/- Rs. 208/- Rs. 523/-

b. Genl. Goods handling Contractors including contractors awarded by stores department

26 to 50 51 to100 101 to 200

Rs. 762/- Rs.1,023/- Rs.1,285/-

c. Coal handling ash pit cleaning contractors

201 to 300

Rs. 1,546/-

d. Railway siding used by the Contractor

301 to 750 751 to 1500

Rs. 1,785/- Rs. 3,590/-

e. Contractor supplying water to Engines

1501 to 3000 3000 & over

Rs.7,182/- Rs. 14,345/-

1.1.60 Imposition of token penalty for delay in the completion work. The existing clause 17(B) of GCC provides for recovery of liquidated damages from the contractor for delay in completion of work. It has now been decided that the Competent authority while granting extension to the currency of contract under clause 17(B) of GCC may also consider levy of token penalty as deemed fit based on the merit of the case.

---------------------- x-------------------------

21

CHAPTER-2 1.2 CONDITIONS OF PRICES AND PAYMENT TERMS: 1.2.1 SCOPE This chapter deals with prices to be paid for supply and erection including testing , commissioning of various plants/equipments for items of works or for supplies and other amounts payable in accordance with accepted schedules of prices and rates and terms and conditions of payment mentioned herein. 1.2.1.1 This is a composite works contract. The total prices for the completed items of work are the actual prices to the contractor as per the terms and conditions of the contract. 1.2.2. UNIT PRICES: 1.2.2.1 The rate quoted by the tenderer and accepted by the purchaser shall hold good till the completion of the work and no additional individual claim will be admissible on account of fluctuation in market rates etc. or due changes in tax structures 1.2.2.2. The rate quoted by the tenderer shall include the cost of materials, all taxes and ED Erection, testing and commissioning including all incidental charges like freight, Transport, loading /unloading, handling of materials, lifting , descent, insurance Coverage or bankers charges, indemnity bond etc. 1.2.2.3 The rate quoted by the tenderer shall include the cost of materials including all incidental charges mentioned in 1.2.2.2. Above in case specifically directed by Railway for supply only. 1.2.2.4 The rate quoted by the tenderer shall include the cost of erection ,testing and commissioning including all incidental charges in case of the materials supplied by the purchaser as indicated in the schedule. 1.2.3 EXPLANATORY NOTES : Explanatory notes for various items of works included in the schedule are given in Part II of the tender paper. Tenderer should carefully read and include all the Cost of materials and erection testing and commissioning as clearly explained in the explanatory notes . 1.2.4 TERMS OF PAYMENT: (i) Subject to any deduction or recoveries which the purchaser may be entitled to make under the contract, the contractor shall unless otherwise agreed to be entitled to get the payments subject to conditions stipulated in the subsequent clauses. (ii) Payment will be arranged by Sr. Divisional Finance Manager, S.E.Railway, Adra for the bills submitted to Sr. Divisional Electrical Engineer (TRD)/Adra, through Depot-in-charge, subject to following :- i) Execution of indemnity bond on stamp duty in case of any materials taken by contractor from Railways. The bills for payment should accompany a copy of penalty imposed during the execution of the work for which payment is claimed and clearing certificate from the Depot-in-charges, indicating the successful job completed by tenderer. 1.2.5 ON ACCOUNT PAYMENT On account payment to the extent of 90% will be made on the total unit price of such items included in the schedule of prices only for those items included in the schedule of prices and executed in terms of this contract for which Sr. Divisional Electrical Engineer (TRD), S. E. Railway, Adra considers appropriate and acceptable to make the on account payment. All invoices shall be accompanied by the : i) Contractor’s challan along with manufacturer’s challan for supply of items only. ii) Inspection certificate granted by the Inspecting authority as authorized by Sr. Divisional

Electrical Engineer (TRD), S. E. Railway, Adra. iii) Execution of indemnity bond on stamp duty in case of materials supplied by the

Railways. iv) Certificate of current statutory taxes and duties. v) Detailed entries made in the Measurement Book. 1.2.6 FINAL PAYMENT : Balance 10% payment will be made through the final bill only after satisfactory completion of the entire contractual work , satisfactory operation and handing over of the assets to the Railway duly tested and commissioned subject to compliance of the following application:

i) On supply of catalogue and operation manual/instruction books wherever applicable.

ii) On supply of “as Erected Drawing “ of the equipment/installation, if applicable. iii) A “No claim” certificate in favour of Railway is issued by the contractor.

1.2.7 PAYMENT FOR SPARES AND FOR ADDITIONAL SUPPLIES: The contractor shall be eligible for receipt of full 90% payment for supply of spares and additional supplies ordered on him in accordance with prices included in the schedule after

22

handing over of the spares to the Railway in good working condition. Balance 10% payment will be made through final bill. 1.2.8 PAYMENT OF PRICE VARIATION : Price variation clause will be applicable as per Clause 46A-Price variation clause tothe General condition of contract (GCC) or General Condition of Contract (with the latest amendment, if any) of S.E.Railway or as per extant rule of Railway circulated vide (i) Railway Board letter no.2007/CE-1/CT/18Pt.19, dtd 14.12.12 and (ii) Railway Board letter no. 2007 /CE-1/CT/18Pt.19, dtd 07.05.13 1.2.9 PAYMENT OF STATUTORY VARIATION IN TAXES AND DUTIES: The unit prices quoted by the tenderer and accepted by the Railway Administration Shall be firm. Also the purchaser will not be responsible for payment of duties and taxes made by the tenderer under misappropriation of law. 1.2.10 FINAL SETTLEMENT AND REFUND OF SECURITY DEPOSIT: On expiry of the warranty period and issue of the certificate for final acceptance produced all the dues payable by the contractor to the Railway have been duly paid or otherwise made good by the contractor, the security deposit will be refunded to the contractor on production and surrender of the relative original receipts granted by the Railway in case it was paid in cash, and where the security deposit is in the form of bank guarantee will terminate the contract. 1.2.10.1 The security deposit shall however , be liable to the forfeited in case of any breach by the contractor of any of the conditions of the contract or for non completion of the full contract without prejudice to other rights and remedies of the Railway whether specifically provided for herein or otherwise. 1.2.11 POST PAYMENT AUDIT: It is an agreed term of the contract that the Railway reserves to itself the right to carryout a post payment audit and or technical examination of the works and the final bills, including all supporting vouchers, abstracts etc. and to make a claim on the contractor for the refund of any excess amount paid to him if as a result of such examination any over payment to him is discovered to have been made in respect of any work done or alleged to have been done by him under the contract. 1.12.12 MEASUREMENT: Payment for the work shall be made in accordance with the specifications, approved designs and drawings and measured in relevant units . The measurement will be made generally in accordance with Tender schedule in conformity with the explanatory notes of the Tender schedule , specification and standard engineering practices. 1.2.12.1 MEASUREMENT OF WORK : The contractor shall be paid for the works at the rates in the accepted schedule of rates and on the measurement taken by the Engineer or the Engineer’s representative in accordance with the rules prescribed for the purpose of the Railway: i) The quantity for items the unit for which it is prevalent ,accepted schedule of rates shall be recorded . ii)Such measurement will be taken of the work in progress from time to time and at such intervals as in the opinion of the engineer or his representative shall be proper having regard to the progress of work . The date and time on which the measurement are to be made shall be communicated . The contractor who shall be present at the site and shall sign the results of the measurement which shall also be signed by the Railway’s Engineer or the Engineer ‘s representative recorded in the official measurement book as an acknowledgement of his acceptance of the accuracy of the measurement . In the event of failure, on the part of the contractor to attend the work may be measured in his absence and such measurements shall not withstanding such absence be binding upon the contractor whether or not he shall have sign the measurement book , provided always that any objection made by him to any measurement shall be duly investigated and considered in the manner set out below :- a) It shall be open to the contractor to take specific objection to any recorded measurement or classification on any ground within 3 days from the date of measurement . Any measurement taken by the Engineer or his representative in the presence of the contractor or in his absence after due notice has been given to him on consequence of the objection made by the contractor , shall be final and binding on the contractor and no claim whatsoever shall thereafter be entertained regarding the accuracy and classification of the measurement . b) If any objection raised by the contractor is found by the Engineer to be incorrect, the contractor shall be liable to pay the actual expenses incurred in the measurements

--------------------------------X---------------------------------

23

SPECIAL CONDITION-I

1) Transportation of all materials issued by Railway has to be carried out by the

contractor with own arrangement to work sites and Railway will not provide any assistance towards transportation of materials required in connection with the execution of work. The materials will be supplied from purchasers’ depot at RRD/Adra or any other depot under jurisdiction of Adra Division.

2) The contractor has to obtain as “Erection Insurance” Policy from the General Insurance Company before execution of the work without which no materials can be handed over to the contractor and for any delay in obtaining of necessary insurance, the contractor only will be held responsible.

3) The Railway will not provide any drawings/specifications etc. required in connection with the execution of work as mentioned in the tender document. The contractor has to arrange all drawing and documents at his own cost from the office of CORE/RDSO or Sr.DEE/TRD/ADA’s office on payment.

4) All materials to be supplied by the contractor have to be duly inspected by RITES or a Competent Railway official as appointed by Sr.DEE/TRD/ADA. No payment will be made unless the inspection certificate has been submitted along with Manufacturer’s original challans and test certificates. The materials have to be procured only from CORE/RDSO approved sources wherever applicable.

5) The Railway has the right to supply any item if available with the railway even though it is covered under the scope of supply by the contractor. The quantities to that effect will be reduced from the scope of supply accordingly.

6) Any work falling under power block will be determined by the Railway Engineer and the power blocks will be arranged by the Railways supervisor. The contractor has to work with minimum power block with adequate arrangement of manpower, tools & plants and materials as decided by the Railway and penalty can be imposed to the contractor for exceeding of the arranged power block in a particular type of work or for not arranging adequate manpower, tools & plants and materials. Any dispute in this regard each only be decided by Sr.DEE/TRD/ADA and his decision will be final and binding on the contractor.

7) The cost incurred in carrying out cube test for concrete foundation sample shall be borne by the contractor.

8) New Clause 42 (4) to Indian Railways General Conditions of contract. Variation in the contract will be governed by Rly. Bd’s Letter No. 2007/CE.I/CT/18

Pt.XII, dtd: 31.12.2010 Quantity of any item may vary during execution of the work as decided by

Sr.DEE/TRD/ADA or his authorized representative. The procedure detailed below shall be adopted for dealing with variation in quantities

during execution of contracts: 1. Individual N/S Items in contracts shall be operated with variation of plus or minus 25% and payment would be made as per the agreement rate. For this, no finance concurrence would be required.

2. In case an increase in quantity of an individual item by more than 25% of the agreement quantity is considered unavoidable, the same shall be got executed by floating a fresh tender. If floating a fresh tender for operating that item is considered not practicable, quantity of that item may be operated in excess of 125% of the agreement quantity subject to the following conditions:

a. Operation of an item by more than 125% of the agreement quantity needs the approval of an officer of the rank not less than S.A. grade.

i) Quantities operated in excess of 125% but up to 140% of the agreement quantity of the concerned item, shall be paid at 98%of the rate awarded for that item in that particular tender.

ii) Quantities operated in excess of 140% but up to 150% of the agreement quantity of the concerned item shall be paid at 96% of the rate awarded for that item in that particular tender.

24

iii) Variation in quantities of individual items beyond 150% will be prohibited and would be permitted only in exceptional unavoidable circumstances with the concurrence of associate finance and shall be paid at 96% of the rate awarded for that item in that particular tender.

b) The variation in quantities as per the above formula will apply only to the Individual items of the contract and not on the overall contract value.

c) Execution of quantities beyond 150% of the overall agreemental value should not be permitted and, if found necessary, should be only through fresh tenders or by negotiating with existing contractor, with prior personal cocurrence of FA&CAO/FA&CAO(C) and approval of General Manager.

3) In cases where decrease is involved during execution of contract.

a). The contract signing authority can decrease the items up to 25% of individual item without finance concurrence.

b) For decrease beyond 25% for individual items or 25% of contract agreement value, the approval of an officer not less than rank of SA Grade may be taken, after obtaining ‘No Claim Certificate’ from the contractor and with finance concurrence, giving detailed reasons for such decrease in the quantities.

c) It should be certified that the work proposed to be reduced will not be required in the same work.

4) The limit of varying quantities for minor value items shall be 100% (as against 25% prescribed for other items). A minor value item for this purpose is defined as an item whose original agreement value is less than 1% of the total original agreement value.

5. No such quantity variation limit shall apply for foundation items.

6. As far as SOR items are concerned, the limit of 25% would apply to the value of SOR schedule as a whole and not on individual SOR items. However, in case of NS items, the limit of 25% would apply on the individual items irrespective of the manner of quoting the rate (single percentage rate or individual item rate) .

7. For the tender accepted at Zonal Railway level, variation in the quantities will be approved by the authority in whose powers revised value of the agreement lies.

8. For tender accepted by the General Manager, variation up to 125% of the original agreement value may be accepted by General Manager.

9. For tender accepted by the Board Members & Railway minister, variation up to 110% of the original agreement value may be accepted by General Manager.

10. The aspect of vitiation of tender with respect to variation in quantities should be checked and avoided. In case of vitiation of the tender (both for increase as well as decrease of value of contract agreement), sanction of competent authority as per single tender should be obtained.

9) The tenderer should survey the site/location and get himself acquainted with all the details site conditions before making the offer.

10) The LD Clause will be applicable in Phase wise both for non-completion of work as

detailed in the plan for execution of the job and non-supply of materials by the tenderer/contractor in time.

11) If there is any item which is not covered by the special conditions of contract or by the

terms and conditions mentioned elsewhere in the tender, the terms and conditions mentioned in the General Conditions of Contracts with latest amendment if any, applicable to works contract of S.E. Railway shall apply. In case there is any condition between special conditions and General Conditions of Contract, the special conditions of contract shall prevail.

12) The following documents should be specified for submission along with tender.

a) List of personnel organization available on hand and proposed to be engaged for the subject work.

b) List of Plan and machinery available on hand (own) and proposed to be inducted (own and hired to be given separately) for the subject work.

25

c) List of work completed in the last three financial years giving description of work, organization for whom executed, approximate value of contract at the time of award, date of award and date of schedule completion of work. Date of actual start, actual completion and final value of contract should also be given.

d) List of works on hand indicating description of work contract value, approximate value of balance work yet to be done and date of award.

NOTE: 1) In case of items (c) and (d) above, supportive documents/ certificates from the

organization with whom they worked/are working should enclosed 2) Certificate from private individuals for whom such works are executed/being

executed should not be accepted. 13. Decision of Sr.DEE/TRD/ADA regarding minus and / or plus variation as per the

Railway’s requirement will be final and binding on the contractor. 14. If the tenderer does not quote above/below percentage, then in such cases ‘above’ will be

considered. If the quoted rate in words & figures are not tallying in such cases tender will be rejected. (Ref. CVO (E)/GRC’s letter No. GM/V/System Improvemet/45,dtd: 29.11.2002).

15. Rates to be quoted by the tenderer should be inclusive of all taxes/charges, Lead, Lifts, Transportation and other charges leviable by the Govt. from time to time. No extra charges will be paid

a. . Any instructions issued by the Railway from time to time regarding payment of wages

to labour will be adhered to by the contractor and Decision of Sr.DEE/TRD/ADA regarding this will be final and binding on the contractor.

----------------------- X --------------------

26

PERFORMANCE REPORT SHEET To be filled in and the documents in support to be attached by the tenderer.

1. Name and address of the firms :

a) Individual/Proprietorship firm : b) Partnership firm : c) Private Ltd/Public Ltd :

d) Government undertaking : 2. Financial Capacity : a) Audited annual turnover for the

i) 2012-2013 ii) 2013-2014 iii) 2014-2015

b) Banker’s solvency certificate from a schedule bank to be attached.

3. Detailed plants and machineries owned by the tenderer and proof thereof :

Sl. No.

Name and make of Machinery with capacity

Date of purchase

Condition of machinery

Place deployed presently

Whether the machinery can be deployed immediately If contract awarded.

1 2 3 4 5 6

4. Experience of Tenderer’s :

a) Details of works executed and completed in the last 3 years(Enclose separate sheet if required)

Sl. No.

Name of work and contract No.

Agreemental value

Final completion value of work

Name and address of Employer

Completion time as per Agreement

Actual time take to complete the and regarding to details if any

Remarks

1 2 3 4 5 6 7 8

b) Works in hand:

Sl. No.

Name of work and contract No.

Agreemental Value

Name and address of Employer

Completion time as per original agreement and whether extension given or not, if extended furnish the reasons of extension

% of progress of principal items of

1 2 3 4 5 6

5. Particulars of contracts terminated with RISK & COST on the contractor , if any :- 6. Details of arbitration cases with Railway administration and other organization,

27

Signature of the Tenderer/Contractor Seal & Date Note : Documentary evidence regarding above declaration are to be attached by the Tenderer and if found incorrect after verification of the declarations , their offers may be rejected without any further correspondence in this regard with the tenderers. 7. UNDERTAKING I/We __________________________________ in my/our capacity as ___________________________ Of the tenderer hereby declare that the above mentioned particulars are true and correct to the best of my /our knowledge and belief. I/We understand that action can be taken against the firm within the preview of the contract any of the particulars declared by above are found to be misleading or incorrect.

----------------------x-----------------------

28

FORM 6

INDEMNITY BOND FOR ON ACCOUNT PAYMENTS

We, M/s _________________________ hereby undertake that we hold at _____________ (fill in the name of location) for and on behalf of the president of India acting in the premises through the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra ( herein after referred to as the “Purchaser” and as his property in trust for him all materials works for which on account payments have been made to us against the contract for _______vide letter of acceptance of tender No.__________ dated ___________ until such time the materials/works are duly installed /and communicated or otherwise handed over to him. We shall be entirely responsible for the safe custody and protection of the said materials against all risk till they are duly delivered as installed / and commissioned to the purchaser or as he may direct otherwise and shall indemnity the purchaser against any loss, damage or deterioration whatsoever in respect of the said materials while in our possession. The said materials/works shall at all time be open inspection by officer authorized by the Sr. Divisional Electrical Engineer (TRD), S. E. Railway , Adra..

Should any loss, damage or deterioration of materials/works occur and refund become due, the purchaser shall be entitled to recover from us the full cost without prejudice to any other remedies available to him by deduction from any sum due or any such which at any time hereafter become due to us under the said or any other contract. Dated___________day of ______200… For and on behalf of M/s________________(contractor) Signature of witness Name of witness in Block letters_________ Address_______________

29

(FORM No. 3)

REVISED MODEL FORM OF BANK GUARANTEE BOND

GUARANTEE BOND

1) In consideration of the president of India acting through ----------------- (hereinafter called “the said Government”) having agreed to exempt ____________(hereinafter called the said contractor(s)”) from the demand under the terms and conditions of an agreement , dated ___________ made between __________ and __________ for _________ (hereinafter called the said Agreement ), of security Deposit for due fulfillment of by the said contractor(s) of the terms and conditions contained in the said agreement , on production of a Bank gurantee for Rs --------- ( Rupees----------------only) we,------------- ( hereinafter referred to as “The Bank”) at the request of _______(Contractor(s) do hereby undertake to pay to the Government and amount not exceeding Rs ___________against any loss or damage caused to or suffered or would be caused to or suffered by the Government by reason of any breach by the said contractor(s) of any of the terms and conditions contained in the said agreement . 2. We_______(indicate the name of the bank) do hereby undertake to pay the amount due and payable under this guarantee without any demur, merely on a demand from the Government stating that the amount claimed is due by way of loss or damage caused to or suffered by the Government by reason of breach by the said contractor(s) of any of the terms and conditions contained in the said agreement or by reasons of the contractor(s) failure to perform the said agreement. Any such demand made on the bank shall be conclusive as regard the amount due and payable by the bank under this guarantee. However, our liability under this guarantee shall be restricted to an amount not exceeding Rs.------------------------. 3. We undertake to pay the government any money so demanded not withstanding any dispute or disputes raised by the contractor(s)/supplier(s) in any suit or proceeding pending before any court or Tribunal relating thereto our liability under this present being absolute and unequivocal . The payment so made by us under this bond shall be a valid discharge of our liability for payment there under and contractor(s)/supplier(s) shall have no claim against us for making such payment. 4. We-----------------(indicate the name of the bank ) further agree that the guarantee herein contained shall remain in full force and effect during the period that would be taken for the performance of the said agreement and that it shall continue to be enforceable till all the dues of the government under or by virtue of the said agreement , have been fully paid and its claims satisfied or discharged or till -----------(Office /department) Ministry of ----------------------certifies that the terms and conditions of the paid agreement have fully and properly carried out by the said contractor(s) and accordingly discharges this guarantee, unless a demand or claim under this guarantee is made on us in writing on or before the -------------- we shall be discharged from all liabilities under this guarantee thereafter. 5. We--------------(indicate the name of bank) further agree with the Government shall have the fullest liberty without our consent and without affecting in any manner our obligations hereunder to vary any of the terms and conditions of the said agreement or to extend time of performance by the said contractor(s) form time to time any of the powers exercisable by the government against the said contractor(s) and to forbear or enforce any of the terms and conditions relating to the said agreement and we shall not be relieved from our liability by reason of any such variation , or extension being granted to the said contractor(s) or by any such indulgence by the government to the said contractor(s) or by any such matter or thing whatsoever which under the law relating to sureties would, put for this provision, have effect of so relieving us.

6. This guarantee will not be discharged due to the charge in the constitution of the bank or the contractor(s)/supplier(s). 7. We --------------(indicate the name of bank) lastly undertake not to revoke this guarantee during its currency except with the previous consent of the government in writing . Dated ___________day of 200… For________________________(indicate the name of the bank)

30

TENDER FORM

OFFER LETTER

To The President of India,

Acting through the Divisional Electrical Engineer (TRD),

South Eastern Railway

Adra.

1. I/We M/s………………………………………………… have read the various conditions to tender attached hereto and hereby agree to abide by the said conditions. I/We also agree to keep this tender open for acceptance for a period of …………days from the date fixed for opening the same and in default thereof, I/We will be liable for forfeiture of my/our security deposit. I/We offer to do the works as detailed in the attached schedule of prices. 2. I/We hereby bind myself /our self to complete the work within the time limits specified in the conditions of tender. I/We also hereby agree to abide by the general and special conditions of contract and to carry out the works according to the specifications of materials and work laid down by the Railway for the present contract.

3. I/We hereby declare that I/We possess a copy of the S.E.Railway schedule of labour and materials rate, revised section 1974, volume (1) and general conditions of contract and standard specification 1994, Volume (2) corrected upto date have gone through the rates , regulations , for tender and contracts , general conditions, standard specifications and other particulars embodied therein and have fully understood and abide by them .

4. A sum of Rs……… ………….. (Rupees ……………………………………………………….) only vide………………………………………. is hereby forwarded as earnest money . The full value of the earnest money shall stand forfeited without prejudice to any other rights for remedies if :

b) I/We withdraw my/our offer within the validity of tender. c) I/We do not execute the contract documents within seven days after receipt

of notice issued by the Railways that such documents are ready , d) I/We do not commence the work within ten days after receipt of order to

that effect. 5. Until a formal agreement is prepared and executed acceptance of this tender shall constitute a binding contract between us subject to modifications as may be mutually agreed to between us indicated in the letter of acceptance of my/our offer for this work. 6. I/We enclosed the Income Tax , sales tax clearance certificate or a declaration to that effect as required under Para 1.1.7 of the tender papers pertaining to me/us for the year. Tenderer’s Address: Signature of Tenderer/s Date: Signature of witnesses 1. 2.

31

SOUTH EASTERN RAILWAY

ADRA DIVISION

QUOTED TENDER RATE-SHEET (PERCENTAGE ABOVE/BELOW)

Name of work : Provision of OHE of line from 'P' Cabin to Loco line along with OHE

of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway

Completion period: 09 months from the date of issue of L.O.A. OPEN TENDER NOTICE NO: TRD/ADA/OT-2015/5/BKSC/D-cab ,dtd 28.08.2015

Sl. No.

Description of the works Quoted Tender Rate (%age ABOVE/BELOW in figures and words)

1

Schedule Of work (Schedule Value : Rs 55,59,898/- (Rupees Fifty Five Lakh Fifty Nine Thousand Eight Hundred Ninety Eight Only)

_______ ____ABOVE/BELOW (%age in figure)

______________________ABOVE/BELOW (%age in words)

BASIC RATES GIVEN IN SCHEDULE OF PRICES NOTE: i) Conditional Tenders will be summarily rejected without any condition

Whatsoever. Tenderer should not quote any Percentage ABOVE/BELOW in the schedule of prices.

ii) Tax and levies will be deducted at source as applicable.

iii) The rates quoted should be inclusion of all taxes, ED etc. iv) The tenderer should quote single percentage for the Schedule of work

Signature of the Tenderer (s) with seal

32

SOUTH EASTERN RAILWAY

ADRA DIVISION

Tender Schedule

Name of the Work :- Provision of OHE of line from 'P' Cabin to Loco line along with OHE of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway ( NOTE: This Schedule of price should be read in conjunction with explanatory notes attached to it.)

Schedule-I ( Supply components )

Sr. No.

Description Unit Qty. Rate in Rs. Total

1 Supply of rolled or fabricated and galvanized traction masts, auxiliary transformer masts, Feeder mast.

MT 14.50 83188.00 1206226.00

2 Supply of TTC Structures and Portals with boom.

MT 5.0450 84707.00 427346.82

3 Supply of fabricated and galvanized steel work other than traction mast (SPS)

MT 2.6030 101231.00 263504.29

4 Supply of single cantilever assembly complete with insulator for conventional OHE

Each 50 23123.00 1156150.00

5 Supply of guy rod assembly Each 8 7346.00 58768.00

6

Supply of regulating equipment, 3 (three )pulley type, with all accessories including counter weight assembly, SS wire rope for conventional OHE.

Each 4 65277.00 261108.00

7

Supply of materials for termination of double conductor (including supply of cut-in insulator) of overhead equipment.

Each 7 7574.00 53018.00

8

Supply of materials for termination of a single conductor (including supply of cut-in insulator) of OHE or a terminating wire.

Each 1 5909.00 5909.00

9

Supply of OHE excl. catenary, contact, ,jumper , Dropper wire and large span wires(which will supplied by Railway).

TKM 1.50 49093.00 73639.50

10 Supply on extra for additional, fittings at a turnout/crossings/overlaps.

Each 5 3007.00 15035.00

11 Supply of section insulator assembly .

Set 2 42175.00 84350.00

12 Supply of 25KV single pole isolator with earth contact assembly.

Each 2 51133.00 102266.00

33

13 Supply of anti-creep arrangement (including supply of insulator) with railway supply catenary wire.

Each 1 8318.00 8318.00

14 Supply of structure bonds (other than platform)

Each 40 511.00 20440.00

15 Supply of Transverse, Cross or Special bond.

Each 5 607.00 3035.00

16 Supply of longitudinal bonds Each 2 401.00 802.00

17 Supply of Catenary wire splices Each 2 516.05 1032.10

18 Supply of Contact wire splices Each 2 1126.29 2252.58

19 Total for schedule-I 37,43,200.29

Schedule-II ( Works components )

Sr. No.

Description Unit Qty. Rate in Rs. Total

1

Preparation of all drawing and design for over head equipment including preparation of pre-pegging, pegging and OHE layout plan.

TKM 1.500 11803.00 17704.50

2

Concrete for foundation & trench and brick work in all type of soil including hard/rocky soil (Including excavation and supply of all materials viz. sand, cement and ballast etc.) trench.

Cum 197.141 5428.00 1070081.35

3 Erection of rolled or fabricated and galvanized traction masts, auxiliary transformer masts, Feeder mast.

MT 14.500 2857.00 41426.50

4 Erection of TTC Structures and Portals with boom.

MT 5.045 6894.00 34780.23

5 Erection of fabricated and galvanized steel work other than traction mast (SPS)

MT 2.603 5765.00 15006.30

6 Erection of single cantilever assembly complete with insulator for conventional OHE

Each 50 727.00 36350.00

7 Erection of guy rod assembly Each 8 918.00 7344.00

8

Erection of regulating equipment, 3 (three ) pulley type, with all accessories including counter weight assembly, SS wire rope for conventional OHE.

Each 4 3337.00 13348.00

34

9 Erection of materials for termination of double conductor (including cut-in insulator) of overhead equipment.

Each 7 1532.00 10724.00

10

Erection of materials for termination of a single conductor (including cut-in insulator) of OHE or a terminating wire.

Each 1 891.00 891.00

11

Erection of OHE excl. catenary, contact, jumper , Dropper wire and large span wires(which will supplied by Railway).

TKM 1.50 25585.00 38377.50

12 Erection for additional, fittings at a turnout/crossings/overlaps.

Each 5 1296.00 6480.00

13 Erection of section insulator assembly .

Each 2 4263.00 8526.00

14 Erection of 25KV single pole isolator with earth contact assembly.

Each 2 3102.00 6204.00

15 Erection of anti-creep arrangement (including insulator) with railway supply catenary wire.

Each 1 1577.00 1577.00

16 Erection of structure bonds (other than platform)

Each 40 155.00 6200.00

17 Erection of Transverse, Cross or Special bond.

Each 5 137.00 685.00

18 Erection of longitudinal bonds Each 2 217.00 434.00

19 Erection of Catenary wire splices Each 2 58.36 116.72

20 Erection of Contact wire splices Each 2 125.94 251.88

21 Transfer of OHE from one mast or support to another mast and adjustment of dropper.

Each 5 1408.00 7040.00

22 Adjustment of OHE and Tower Wagon checking of existing OHE

Span 50 322.65 16132.50

23 Provision of an additional bracket assemblies.

Each 12 322.65 3871.80

24 Dismantling & removal of cantilever assembly

Each 13 1003.00 13039.00

25 Dismantling & removal of OHE termination assembly.

Each 2 904.00 1808.00

26 Dismantling & removal of Guy Rod assembly

Each 2 464.00 928.00

27 Dismantling & removal of &Cutting of mast/TTC/portal uprights from ground level.

Each 8 387.00 3096.00

35

28 Dismantling & removal of Small parts steel including portal/TTC boom

MT 0.246 3616.00 889.54

29

Work under power block: Any erection work for schedule-II item no. 3 to 15 and 21 to 28 as per schedule if done under power block is subject to have extra rate

'@100% Extra 230281.33

30 Total for schedule-II ( without service tax) :Rs 15,93,594.14

31 Service tax @ 14% on erection components :Rs 2,23,103.18

32 Total Schedule-I & II ( Without Service Tax ) :Rs 53,36,794.43

33 Total Schedule-I & II ( With Service Tax ) :Rs 55,59,897.61

Rounded Off: 55,59,898.00

( Rupees Fifty Five Lakh Fifty Nine Thousand Eight Hundred Ninety Eight only )

Sr. DEE/TRD/ADA

36

SOUTH EASTERN RAILWAY

Special Conditions -II 1. Whenever an item of work covers supply of materials/erection/installation etc such

item will include supply of all associated accessories (such as bolts, nuts, washer of GI & SS clamps, foundation bolts etc or any other ancillary materials as per CORE/RDSO latest specification and drawings) which will be required to complete the work in all respect as per site condition to the satisfaction of Railway as well as to maintain the relevant standard, code of practice ensuring safe working. No separate payment for fastener is admissible.

2. (a) Erection/Installation of equipment (in respect of supply either by Railway or by the contractor) will include testing, satisfactory functioning as well as detail briefing regarding erection/maintenance/periodical schedules etc for the beneficial use of the Railways, such briefing will include as necessary with four copies of drawings literature/notes/operating manuals/maintenance manuals etc. on demand by the Railways.

(b) The basic quantity of components and materials require to make up a unit of work for the selected items are indicated for guidance only. There may be minor variation to suit erection but no adjustment in prices shall be made on that account.

3. (a) The tenderer should read the tender schedule along with explanatory notes in respect of the work and site condition carefully and seek clarification if any before submitting the tender paper. No clarification/dispute will be entertained afterwards. Any clarification/disputes after opening of tender in this regard will be decided by Sr.DEE/TRD/ADA and his decision shall be final and binding on the contractor.

(b) Tender should carefully understand the tender schedule along with explanatory notes and inspect the site to satisfy himself in all respect to complete the project/work before submitting the offer. After submission of offer it will be deemed that the contractor has understood the project/work and will complete the project/work at the quoted rate. It is understood and agreed that the contractor has, by carefully examination, satisfied himself as to the nature and location of the work, the conformation of the ground, the character, quality and quantity of the materials to be encountered, the character of equipment and facilities needed preliminary to and during the progress of the works, the general and local conditions, the labour conditions prevailing therein and all other matters which can in any way affect the works under the contract.

(c) The rates entered in the accepted schedule of rates of the contract are intended to provide for works duly and properly completed in accordance with general and special (if any) conditions of the contract and the specifications and drawings together with such enlargements, extensions, diminutions, reductions, alterations or additions as may be ordered in terms of clause 42 of G.C.C and without prejudice to the generality thereof.

4. All the machines, components, equipment (including ancillary parts/components) shall be of RDSO/CORE approved sources and wherever any items are not covered under RDSO/CORE approved list of vendor it should be of reputed make/brand subject to prior approval to be obtained from Sr.DEE/TRD/ADA before its supply irrespective of such stipulation mentioned against the items in the schedule or not.

5. Tenderer should quote only the uniform percentage above or below or at par to the total cost of the schedule and not for individual item. Price variation is not acceptable.

6. Machines/Components/Equipments shall be as per relevant Railway specification and where Railway’s specification is not available relevant IS specification to be observed.

7. In every case the quoted cost should cover the transportation cost of materials by the contractor at his own risk from any depot of S.E.Railway to site and contractor will have to return all released/unused materials from the site of work to Railway store at no extra cost.

8. All the works shall be carried out duly observing the relevant standard/code of practice, IR rules and specification and drawings approved by Railways. The successful tenderer on receipt of the LOA and after observing all the basic formalities must provide a detailed planning for the execution of work with time limit and got the approval before commencement of work.

9. The special condition for schedule items are enclosed and tenderer shall go through them thoroughly before submitting offer.

10. The work for Provision of OHE of line from 'P' Cabin to Loco line along with OHE of over run line with cross over near 'D' Cabin at Outward yard of

37

BKSC of ADRA division of S.E.Railway. As soon as “The Letter of Acceptance ’’ (LOA) is issued, the contractor should carry out the detailed survey of work-site and should prepare and submit plan of action in Bar-Chart for which location nos. /name of sections shall be provided by the Railway along with the LOA . The said plan of action in Bar-Chart for execution of work at locations /sections should be submitted to Sr. DEE/TRD/ADRA’s office for its approval within first thirty days of issue of LOA .

11. After submission of the said plan of action in Bar-Chart, the Railway will scrutinize the same and necessary approval will be given on the plan of action in Bar-Chart fifteen days of its submission.

12. The contractor should make preliminary arrangement for execution of work immediately after issue of LOA and should start the work immediately after approval of plan of action in Bar-Chart i.e. foundation works should be started without any delay once the plan of action in Bar-Chart .

13. The contractor will have to carry out the detailed site- survey for the assessment of the quantity of materials along with its character, quality, type/style, size in detail of the materials to be encountered. After assessing the requirement of material as per site, the contractor should place order for procurement of all materials within fifteen days of approval of plan of action in Bar-Chart as per schedule of work/or as per instruction of the Railway, if any and purchase order copy of materials should be submitted to Sr. DEE/TRD/ADRA’s office, accordingly.

14. Procurement action of the materials should invariably be in accordance with requirement of site i.e. it must be ensured by the contractor to supply materials first which will be required first in course of execution of work.

15. All the materials duly inspected should be supplied within six months from the date of approval of plan of action in Bar-Chart

16. Any delay in submission of plan of action in Bar-Chart for approval or in supply & delivery of materials shall be recorded in your performance for future necessary action.

17. The LD Clause will be applicable in Phase wise both for non-completion of work as detailed in the plan for execution of the job and non-supply of materials by the contractor in time.

18. The contractor shall have to deploy one of his representatives for making liaison for power block planning and execution of work for which he will have to consult with CTPC/ADRA one day in advance for power block of the next day .

19. The contractor will have to undertake the work of “Provision of OHE of line from 'P' Cabin to Loco line along with OHE of over run line with cross over near 'D' Cabin at Outward yard of BKSC of ADRA division of S.E.Railway” as per plan and programme for which Tower wagon will be provided by the Railway as per requirement .

20. The work should be completed within stipulated completion period as per tender notification.

----------------X----------------

38

EXPLANATORY NOTES for Schedule -I

Item No.1 Supply of Rolled or fabricated and galvanized traction masts, upright, portals and Auxiliary Transformer Mast [including TTC upright with boom (8/5.5m) and portal with boom]

The traction mast should be procured from CORE/RDSO’s approved suppliers only conforming to latest CORE/RDSO’s approved drawings and specifications. The type of mast will be as per approved design and the supply will be made on written order of Sr.DEE/TRD/ADRA. The price shall cover supply of main masts whether rolled or fabricated including those for head span, fabricated structure etc. Note for measurements of item 1

For the purpose of payment, the weight of individual traction mast and masts of head span shall be determined for each type on the basis of the payable weights per metre length as shown below for standard types. For special types, the payable weight per metre length will be indicated by the purchaser at the time of approval of designs.

Payable unit weight for standard Masts:

Sr. No Type of masts Weight in Kg per including galvanized

1 6”X6” BFB 38.03

2 8”X6” RSJ 53.39

3 K100 23.70

4 K125 30.30

5 K150 38.18

6 K175 43.72

7 K200 49.87

9 K250 66.72

10 B100 27.71

11 B125 32.47

12 B150 39.07

13 B175 44.61

14 B200 50.76

15 B225 61.50

16 B250 70.72

17 162 X 154 X 27.1 Kg BFB 38.00

18 200 X 200 X 49.9 Kg. BFB 51.20

19 S1 53.30

20 S3 76.40

21 S4 53.39

22 S5 111.53

23 S6 53.39

24 S7 76.40

25 S8 111.53

Item No.2 Supply of TTC structures and portal with boom

The materials should be supplied from CORE/RDSO approved suppliers only. The price shall also cover supply of TTC structures complete with upright, boom, knee plate and all type of fasteners conforming to the latest CORE/RDSO’s drawing/specification and procured from approved source. The price shall also include the cost of supply of portals complete with uprights, boom pieces, knee bracing, cover angles and all type of fasteners conforming to latest CORE/RDSO drawing/specification and procured from approved source. Supply will be made on written order of Sr.DEE/TRD/ADRA. Item No. 2 Supply of fabricated and galvanized steel work other than traction mast (SPS): The materials should be supplied from CORE/RDSO approved suppliers only.

39

The price shall cover the cost of supply only of all fabricated steel and mast fitting for hook insulator and mast bracket fitting assembly for attachment to the structure for erection of cantilever excluding fasteners, which are required to be supplied by the contractor. For standard fabricated steel work for which RDSO approved drawings are available, the weight of steel work as specified in RDSO drawings shall be considered for payment. However, in case the unit sectional weight of any member indicated in RDSO drawing is not in conformity with the unit sectional, weight as per the latest IS specification, the weight of the fabricated steel work shall be calculated on the basis of latest IS specification and the same will be considered for payment. For the non-standard fabricated steel work, the calculated weight to be considered for payment under this item shall be included in the relevant drawing based on, latest IS sectional weight at the time of submitting the designs for approval of the purchaser. The price shall cover supply, fabrication of arrangements for mounting of traction mast on bridge piers/girder. Notes for measurement of item 3 1) For purpose of payment against items 3 the weight of structures of fabricated steel work will be calculated according to the weight of black steel given in section books for the lengths of various members shown in the approved drawings. There will be no addition for increased weight due to galvanizing or painting or weld material or reduction for holes or skew cuts. 2) Unless specifically indicated none of the other items of work shall include the cost of supply and/or erection of small part steel work which will invariably be paid for under item 3 as applicable. Item No.4 Supply and fabrication of single bracket assembly complete (excluding supply of insulators ) for Conventional OHE Price shall cover on a flat rate basis of any bracket assembly of CORE/RDSO approved make on traction masts or support on drop arm and shall include those on high/ low level platform in the vicinity of turnout over bridges or overlaps and at location with reduced encumbrance or terminating wires.

The materials should be supplied from CORE/RDSO approved suppliers only. The price shall include the cost of supply of all components including galvanized steel tubes conforming to latest CORE/RDSO specification and inspection and complete with bolts and nuts etc if any, and also including stay insulators, bracket insulator , but excluding dropper wire and small parts steel work . Single bracket assembly generally consists of the following:

R.I. No. Description of components Qty per unit

3020 Mast fitting for hook insulators with 2 off bolts, nuts

lock nuts and washer of 16 ϕ 1 Set

2400 Tubular stay arm assembly including galvanized steel tube

1 Set

2130/2380 Catenary suspension bracket or hook bracket 1 off

1160/2140 Suspension clamp 1off

2080 Bracket tube assembly complete with tube cap and sleeve where required including galvanized steel tube

1 set

3070-1/2 Mast bracket fitting assembly including 2 off bolts,

nuts, lock nuts and washer of 16 ϕ for attachment to structure for small parts steel work

1 set

2160-1/2150-1

Register arm hook assembly complete with bolt nut and lock nut

1 off

2420/2430 Register arm assembly of raised register arm RRA assembly including galvanized steel tube

1 Set

2270-4 or 5, 2460-2, 2470-2

Register arm dropper assembly excluding dropper wire but complete with bolt nut etc. 2 set

2390/2540, 2520

BFB steady arm or bent steady arm where required As required

2360/2490-2 25 mm steady arm drop bracket /clamp As required

1220/1370-1 Contact wire swivel clip for raised register arm clamp

1 off

2550-1/2 Anti wind clamp assembly As required

Price shall include the cost of supply of forged steel OHE fittings/ components pertaining to Single Bracket assembly wherever required .

40

Item No. 5 Supply of Guy rod Assy. The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover supply of guy rod assembly of various length of traction mast, feeder mast or supports complete with mast guy rod fittings, guy rod with adjustment and parts to be grouted in anchor block. The price shall not include the cost of supply of dwarf or stub mast with anchor plate drilled or welded in position where required for anchorage and small parts steel work complete with bolts , and nuts etc if any for attaching the mast guy rod fitting to the mast/structure, which shall be paid separately under the relevant item. Price indicated against all other item should be exclusive of the price of supply of guy rod, if any which will be paid for under this item.

Guy rod assembly generally consists of:

RI No. Description of component Qty per unit

3232 (Mast Guy rod fitting welded) with four short bolt and nuts, lock nuts & washers for attachment to masts/SPS including appropriate fittings

1 off.

5001/5001-1/5001-3

Anchor bolt complete with nuts, lock nuts and split pins

1set.

5002 Guy rod stirrup 1 off

5004/5005/5006-1, 9070 or 9071

Guy rod with nut, washer & split pin 1 off

5007-1 Anchor “V’ Bolt 2 Off

5220 Guy rod double strap assembly (Style-1 or 2) 1 off or 2 off as required.

Item No. 6 Supply of regulating equipment, three pulley type (3:1) ratio, complete with all accessories including counter weight assembly and SS wire rope for conventional OHE Price shall cover supply of counter weight assembly including 9T adjuster with double strap assembly, Mast anchor fitting assembly (for modified 3: 1 ratio three pulley type regulating equipment) and normal/anti theft guide tube assembly, the supply of regulating equipment ( Modified 3: 1 ratio three pulley type) , Hex pipe of suitable length and stainless steel wire rope required for the regulating equipment and small part steel work as well as associated fasteners as per requirement, if any. Item No.7 Supply of materials for termination of double conductor(excluding supply of cut-in-insulator) of overhead equipment (Conventional Type) Supply: The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover supply of all materials necessary for the termination of double conductor of overhead equipment on a traction mast or structure including appropriate mast anchor fitting, clevis assembly, three adjusters, anchor double straps, ending clamp, Double eye distance rod, equalizing/compensating plate for catenary or contact wire or terminating wire and fitting but excluding terminating wire and insulators. Item No.8 Supply of materials for termination of a single conductor (excluding supply of cut-in-insulator) of overhead equipment of a terminating wire:

The materials should be supplied from CORE/RDSO approved suppliers only. Price shall cover supply of all materials necessary for the termination of single conductor of overhead equipment or terminating wire, but excluding required insulator, on a traction mast or structure including appropriate mast anchor fitting clevis assembly, adjuster, anchor double straps, ending clamp for catenary or contact wire or terminating wire and fitting but excluding terminating wire and Insulator if any. Note for measurement of item 8 In case of V type anchorage is adopted for terminating a single conductor such an arrangement would be counted as 2 off under item 7 & 8 for the purpose of payment.

41

Item No.9 Supply of overhead equipment excluding catenary, contact jumper and dropper wire: The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover supply of all components as per site requirement including dropper clips, parallel clamps for Jumpering, Contact wire ending clamp, Catenary ending clamp, Large span wire clamp, Adjuster , Anchor double strap assembly , Compensating plate/equalizing plate and splices (where their use is approved), but excluding contact wire, catenary wire, jumper wire, terminating wire and small part steel work complete with nuts and bolts etc. The price shall include provision of number plate conforming to RDSO drawing NO.ETI/OHE/PI7503 Rev. A on traction mast or structures. The price shall exclude supply of small part steel work complete with bolt and nut for attachment of retro-reflective number plate to mast/structure. Note for measurement of item No. 9 For the purpose of payment against item, the length of overhead equipment, which shall include terminating wire, shall be measured form the center line of the traction mast/structure at which two ends of each tension length of OHE are anchored. The length shall be the difference between the actual chainage of the two traction masts/structures at which the ends of each tension length are anchored or by the sum of the actual span between the same two points whichever is higher as included in the as erected layout plan. For purpose of progress payment reference to layout plans as approved shall be made. Overhead equipment generally consists of 1040-2 Contact wire parallel clamp 1180 Contact wire dropper clip. 1192 Catenary wire dropper clip complete with bolts, nuts etc. Retro-reflective number plate complete with bolts, nuts and washer. 1110-2 Contact wire ending clamp 1120 Catenary ending clamp 1140 Large span wire clamp 5020 -1 /2 Adjuster 5030 Anchor double strap assembly 5191 Compensating plate & 5192 Equalizing plate 1080-1 Contact splices 1090 Catenary splices 6170 Contact wire parallel clamp Item No.10 Supply on extra for additional, fittings at a turnout/crossings/overlaps for conventional type OHE

The materials should be supplied from CORE/RDSO approved suppliers only The price shall cover, on flat rate basis, supply of additional components and fittings required' at turnout/ crossovers/ overlaps (insulated or un-insulated) including overlaps knuckle or crossing equipment at a turnout, or a diamond crossing and parallel clamps/bimetallic parallel clamp for jumper connections between two sets of overhead equipment conductor at a turnout, diamond crossing, overlaps or neutral section, but exc1uding jumper wire and insulator. Note for measurement item 10 A crossover shall be paid as 2 off of item 10, special configuration of OHE commonly known as half overlap shall be paid for as 1 off under this item. This shall apply in case of half overlap used in changing over from regulated to unregulated equipment or unregulated to regulated equipment.

Item No. 11 Supply of section insulator assembly (including supply of core & cut-in-insulator.) ( conventional OHE) The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover supply of all components required for a standard section insulator assembly including special arrangement for supporting the equipments and terminal fittings for conductors and the section insulator assembly including section insulator

42

number tag, etc (Adjustable dropper wire will be supplied by Railways) including supply of core & cut-in-insulator. Item No.12 Supply of 25 KV single pole isolator with earth contact assembly (including Post insulator & Operating insulator):

Supply: The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover supply of 25 KV single pole isolator (CORE/RDSO approved make) complete with arcing horns, operating rods, operating rod guides, mounting base and interlocking mechanism , Post insulator & Operating rod insulator etc. including earth contact assembly. The price also covers the supply of isolator number plate of approved design for each isolator. Price shall include supply of materials for making jumper connection with OHE excluding supply of jumper wire. The price shall also cover supply of ALCU strips, a padlock and a number plate of approved design for each isolator. Price shall not include the cost of supply of SPS for support of isolators on gantry/masts and supports jumper and jumper connectors to insulators. Item No. 13 Supply of Anti-creep with cadmium copper caty. Wire (including supply of 9T insulator) The materials should be supplied from CORE/RDSO approved suppliers only. Price shall cover the supply of all materials for anti creep including adjusters (RI No. 5020) mast anchor fittings (RI 3231) with bolts and nuts etc at its termination on either side on structure ending clamps and other fittings viz 18 mm, single clevis assembly (RI 5040/3010), anchor double strap assembly (RI 5030), double suspension clamp (RI 1170), double eye distance rod (RI 5183) & two insulators but excluding anti-creep wire. Anti-creep wire for anti creep will be supplied by Railways. Item No. 14 Supply of a structure bond ( other than platform ) The materials should be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway. The price shall cover supply of 40 x 6 mm Mild steel flat required to provide a structure bond along with fasteners . The price shall include the cost of shaping / fabrication of 40 x 6 mm Mild steel flat into required length of structure bond as per site

Item No. 15 Supply of Transverse, Cross or Spl.bond.

The materials should be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway. The price shall cover supply of all materials including 40 x 6 mm mild steel flats, fasteners etc. required to provide Transverse, Cross or Spl.bond connecting rails of the same/adjacent tracks at the locations to be specified by the purchaser.The price shall also cover providing of special bonds at a level crossing, foot over/road over bridge/protective screen etc. for with the location will be specified by the Railway . The price shall include the cost of shaping / fabrication of 40 x 6 mm Mild steel flat into required length of Transverse, Cross or Spl.bond as per site

Item No. 16 Supply of longitudinal bonds The materials should be supplied from CORE/RDSO approved suppliers only or as per instruction of Railway. The price shall cover the supply of all materials including 40 x 6 mm. Mild steel flats, fasteners etc,. required to provide longitudinal bond connecting 2 rails at the rail joint at the locations to be specified by the Railway. The price shall include the cost of shaping / fabrication of 40 x 6 mm Mild steel flat into required length of longitudinal bonds as per site .

Item No. 17

Supply of Catenary wire splices

The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost of catenary wire splice required for splicing of terminated overhead equipment for extension.

43

Item No. 18

Supply of Contact wire splices

The materials should be supplied from CORE/RDSO approved suppliers only. The price shall cover the cost of contact wire splice required for splicing of terminated overhead equipment for extension and consequent adjustment of the affected equipment

EXPLANATORY NOTES for schedule item -II Item No.1 Preparation of all drawing and design for over head equipment including preparation of pre-pegging, pegging and OHE layout plan.: Price shall cover the following: -Survey of site and submission of drawings, LOP, Plan of action with Bar Chart for Railways’ approval . The drawing and LOP should be printed in different coloured ink clearly indicating all the details of existing OHE and modification works to be carried out. These should be in three sets. One set will be returned to Contractor duly approved for execution of work. -Preparation of cross section drawings (CSD) and structure erection drawings (SED) for individual location. - Choice of type and size of foundations with soil investigation. - Supply of drawings on approval of drawings. 6 copies of CSD and SED shall be supplied for reference at field, office and TRD officials. - Preparation and supply of as erected drawings shall be one copy in original + 2 RTF + 3 Ammonia prints + 1 soft copy in AUTOCAD as per instruction of Railway.

NOTES FOR MEASUREMENT ITEM NO.1 For the purpose of payment against this item, the length of track shall be measured as under : i) GENERAL:The difference in the chainage of the length under consideration, as incorporated in the layout plans in Km.

ii) TURN OUTS:The track taking off shall be deemed as starting from the toe of the switch of the turnout. iii) CROSS OVERS:The length of track shall be taken as the difference in the chainage of the toes of switches of the two turnouts constituting the crossover. iv) DIAMNOD CROSSING WITH OR WITHOUT SLIP:The two track crossing each other shall be measured independently as per note 1 above as though there were no crossing. No extra payment for allowance shall be provided for slip points.

v) DEAD ENDS AND TOP OF LOOPS: The lengths for payment under this item shall up to the chainage of anchor mast of the terminating OHE. Item No.2 Concrete for foundation and plinth in all type of soil including hard/rocky soil (including excavation and supply of all materials viz sand, cement and ballast etc.) The price shall cover excavation, supply and handling of all materials and accessories temporary arrangements for excavation, concreting and grouting thereafter including supply of cement, sand, ballast and other materials whatsoever. Price also includes supply and handling of arrangements for shoring and shuttering where necessary, casting:-- concrete, grouting of mast/structure and finishing the top of concrete foundations with muff. Price also includes dismantling of temporary arrangement and removal and dressing of soil. Notes for measurement of Item 2. i) The rates per cubic metre (cum) under item No.2 shall be same 'for any shape or size of concrete blocks. In calculating the individual volume of concrete, fraction of a cubic metre beyond the third decimal shall be rounded off to the next nearest third decimal. ii) The price shall apply for concreting of all foundation for mast, gantries, portals, anchor blocks for guy rods and fencing uprights, TIC, dwarf mast etc. iii) For purpose of computation of volume of concrete under item no. 2 the volume of steel work embedded in the foundation block and shall be ignored.

44

iv) Cost of all concrete will be paid for only under Item no. 2 and the prices of other items shall not include cost of concrete. v) For purpose of computation of volume of concrete under item no. 2, the volume of concrete shall include the volume of sand and bitumen in sand cored foundation. vi) For purpose of computation of volume of concrete the volume of each muff for all masts shall be taken as 0.02 cum except for masts with balance weight and for each upright of portal, each head span mast, 2 or 3 track cantilever masts and special fabricated masts for which the volume of muff shall be taken as 0.08 cum irrespective of the size and shape of muff on a flat rate basis. vii) The price under item no. 2 shall also include the cost of concrete for embedment of drain pipes where required. viii) The prices under item no. 2 shall also cover the cost of concrete for diversion of Masonry/earth drains wherever necessary for casting of foundation. ix) Cement for use in the Work should be procured by the contractor form the main producers/their authorized dealers only. x) Cement bags should bear the following information in legible markings. a. Manufacturers name: b. Registered trade mark of manufacturer, if any c. Type of cement d. Weight of each bag in kg. e. Date of manufacture, generally marked as week of the year/year of manufacture e.g. 30/99 which means 30th week of 1999. f. Grade of cement not less than 43. xi) To ensure quality control, test certificate from the manufacturer should be produced by the contractors, which should conform to the relevant specifications (Latest may be incorporated). xii) Railways may also take samples during the course of work and get the cement tested to ascertain their conformity to specification. xiii) Concrete of foundation shall be nominal mix of grade M-10 obtained by mixing cement coarse aggregate, fine aggregate and water in accordance with table –3 of IS:456. For grouting, muffing, embedding of structure in foundation and for cable trench at switching stations, normal mix concrete M-15 obtained by mixing materials in proportion as indicated in table 3 of IS :456 shall be used. Xiv)Cube test report : The contractor shall arrange concrete cube test as per relevant BSI specification to be used in the foundation. The cost of cube test shall carry out by the contractor for completion of each 50 Cu. M or its fraction for entire volume of work. Item No.3 Erection of Rolled or fabricated and galvanized traction masts, upright, portals and Auxiliary Transformer Mast including TTC upright and portal

Erection price shall cover cost of erection, alignment and setting before grouting of individual traction mast, feeder mast, main masts of switching and booster transformer stations and masts for LT supply transformer stations, whether rolled or fabricated including those for head spans. Note for measurements of item 3For the purpose of payment, the weight of individual traction mast and masts of head span shall be determined for each type on the basis of the payable weights per meter length as shown below for standard types. For special types, the payable weight per meter length will be indicated by the Railway at the time of approval of designs.

Payable unit weight for standard Masts:

Sr No Type of masts Weight in Kg per including galvanized

1 6”X6” BFB 38.03

2 8”X6” RSJ 53.39

3 K100 23.70

4 K125 30.30

5 K150 38.18

6 K175 43.72

7 K200 49.87

9 K250 66.72

10 B100 27.71

11 B125 32.47

12 B150 39.07

13 B175 44.61

14 B200 50.76

15 B225 61.50

45

16 B250 70.72

17 162 X 154 X 27.1 Kg BFB 38.00

18 200 X 200 X 49.9 Kg. BFB 51.20

19 S1 53.30

20 S3 76.40

21 S4 53.39

22 S5 111.53

23 S6 53.39

24 S7 76.40

25 S8 111.53

Item no. 4 Erection of TTC structures and portal with boom

Erection price shall cover cost of erection, alignment and setting before grouting of individual TTC structures and portal with boom Item No. 5 Erection of fabricated and galvanized steel work other than traction mast (SPS):

The price shall cover the cost of erection, alignment and setting before grouting, wherever required of portals, gantries, 2/3 tracks cantilever structures including cantilevers and tower/steel work for feeders for traction sub-station, drop arms, standard super-masts and suspension brackets for feeders and return conductors, dwarf mast or stub masts for anchoring complete with anchor plates drilled and welded in position, multiple cantilever cross arm, chairs, adopters and attachments for bracket assemblies and all other small part steel works, the erection of which is carried out by the contractor irrespective of whether they are supplied by the purchaser or the contractor. The prices shall also include supply and erection of galvanized bolts, nuts washers etc. wherever required as per approved designs and drawings. Notes for measurement of item 5 1) For purpose of payment against items, weight of structures of fabricated steel work will be calculated according to the weight of black steel given in section books for the lengths of various members shown in the approved drawings. There will be no addition for increased weight due to galvanizing or painting or weld material or reduction for holes or skew cuts. 2) The rates against item 5 shall be applicable to the erection of small part steel work, which are not covered under the various other items of work. Unless specifically indicated none of the other items of work shall include erection of small part steel work which will invariably be paid for under item 5 as applicable. Item No.6 Erection of single bracket assembly complete including insulators for Conventional OHE Price shall cover on a flat rate basis of erection of any bracket assembly on traction masts or support on drop arm and shall include those on high/ low level platform in the vicinity of turnout over bridges or overlaps and at location with reduced encumbrance or terminating wires. Price shall cover erection of all components of single bracket assembly including solid core insulators and erection, fabrication of dropper wires but excluding small parts steel works if any.

Item No. 7 Erection/adjustment of Guy rod Assy. The price shall cover erection of guy rod assembly of various length of traction mast, feeder mast or supports complete with mast guy rod fittings, guy rod with adjustment and parts to be grouted in anchor block. The price shall not include the cost of erection of dwarf or stub mast with anchor plate drilled or welded in position where required for anchorage and small parts steel work complete with bolts , and nuts etc if any for attaching the mast guy rod fitting to the mast/structure, which shall be paid separately under the relevant item.

Item No. 8 Erection of regulating equipment, three pulley type (3:1) ratio, complete with all accessories including counter weight assembly and SS wire rope for conventional OHE The price shall cover erection of counter weight assembly including 9T adjuster with double strap assembly, Mast anchor fitting and normal/anti theft guide tube assembly, regulating equipment ( Modified 3 pulley type) and stainless steel wire rope required for the regulating equipment and small part steel work, if any. The price shall also cover adjustment of the entire regulating equipment. The price shall not include erection of termination, which will be paid separately.

46

Item No.9 Erection of materials for termination of double conductor (including cut-in-insulator) of overhead equipment (Conventional Type) The price shall cover erection of all materials necessary for the termination of double conductor of overhead equipment on a traction mast or structure including appropriate mast anchor fitting, clevis assembly, three adjusters, anchor double straps, ending clamp, Double eye distance rod, equalizing/compensating plate for catenary and/ or contact wire or terminating wires and fitting including 9 T insulator ,terminating wire and insulators , if any. Item No.10 Erection of materials for termination of a single conductor (including cut-in-insulator) of overhead equipment of a terminating wire:

Price shall cover erection of all materials necessary for the termination of single conductor of overhead equipment or terminating wire, but excluding required insulator, on a traction mast or structure including appropriate mast anchor fitting clevis assembly, adjuster, anchor double straps, ending clamp for catenary and/ or contact wire or terminating wire and fitting including terminating wire and 9T Insulator if any. Note for measurement of item 10 In case of V type anchorage is adopted for terminating a single conductor such an arrangement would be counted as 2 off for the purpose of payment.

Item No.11

Erection of overhead equipment including catenary, contact, jumper and dropper wires: Price covers erection of all components and wires and conductors including contact wire or catenary wire or both contact and catenary wire as per work site requirement , droppers, jumpers including anti-theft jumpers and terminating wire, if any , dropper clips, parallel clamps for jumpering , Contact wire ending clamp , Catenary ending clamp, Large span wire clamp, Adjuster , Anchor double strap assembly , Compensating plate/equalizing plate and splices but excluding small part steel work, if any. The price shall include provision of number plate conforming to RDSO drawing No.ETI/OHE/PI7503 Rev. A on traction mast or structures. The price shall also include the cost of painting the setting distance of mast/structure, contact height, rail level, temperature marking for counter weight movement , elementary section and location of emergency sockets on mast/structure. No additional payment will be made for manual stringing of conductor viz. catenary, contact wire etc. The price shall also cover the adjustment /inspection of erected OHE for which Tower Wagon will be provided by the Railway. Note for measurement of item NO. 11 For the purpose of payment against item 11, the length of overhead equipment, which shall include terminating wire, shall be measured form the center line of the traction mast/structure at which two ends of each tension length of OHE are anchored. The length shall be the difference between the actual chainage of the two traction masts/structures at which the ends of each tension length are anchored or by the sum of the actual span between the same two points whichever is higher as included in the as erected layout plan. For purpose of progress payment reference to layout plans as approved shall be made. Overhead equipment generally consists of items / components as detailed in item no. 9 of schedule-I Item No.12 Erection for additional, fittings at turnout/crossings/overlaps for conventional type OHE

Erection: The price shall cover erection of all materials including jumper wire, insulators and all adjustments required at turnouts, crossings, overlaps and neutral sections. The price shall also cover erection of potential equalizer jumpers at insulated overlaps. The price shall not include extra bracket assembly, overhead equipment, termination which will be paid for under respective items of schedule separately. Note for measurement item 12: A crossover shall be paid as 2 off of item 12, special configuration of OHE commonly known as half overlap shall be paid for as 1 off under this item. This shall apply in case of half overlap used in changing over from regulated to unregulated equipment or unregulated to regulated equipment.

Item No.13 Erection of section insulator assembly including core & cut-in-insulator Price shall cover erection and adjustment of all components of section insulator assembly including 9 T insulators and shaping / installation of adjustable droppers as per instruction of Railway.

47

Item No.14 Erection of 25kV single pole isolator assembly (including insulators)

The price shall cover erection of a single pole isolator complete in all respect with mounting base, operating rod, operating rod guide and operating rod insulator, post insulator required for the operation of the isolator . The price shall also cover erection of ALCU strips, a padlock and a number plate of approved design for each isolator. The price shall not include erection of small parts steel work for support of isolators and for support of operating rods on gantries masts. Necessary checks, tests and commissioning shall be arranged by the contractor. Erection of earthing Heel/ earthing contact assembly in an isolator

(i) Erection of MS flat for earth (50X6mm)

The price shall cover erection/ installation per meter length of 50x6mm mild steel flat buried at a depth of 60cm below ground level. The price shall also cover connections of the steel flats to the main earth ring and to the steel structures and metallic frame work/terminals of various equipments, as required. The price shall cover laying earth system flat exposed or fixed on wooden gutties on walls as per approver drawing. The price shall also include laying earth system flat underground at depth of 50 cm below ground level.The price shall also cover cutting, bending, arc welding and drilling wherever required as per sire condition. Before laying the earth bar system the same shall be painted with two coats of red oxide zinc chromate primer and two coats with bitumen paint. The price shall also include connection the earth bus strips at the control cubical to earth electrodes or structure to be earthed and also connected to non track circuited rails. It shall also cover the cost of marking recesses in concrete foundation block or floor or cubicle and covering them up. The connection of earth bus strips to each other shall be made either by re-vetting or by arc welding. The connection of earth strips to various equipments. Structure or fencing post shall be made with G.L. bolt. Nut and spring washers / lock nuts which also cover under this item. (ii) Erection of earth electrode and other associated materials required for earthing Heel/ earthing contact assembly in an isolator

The price shall cover Erection of earth electrode and other associated materials required for earthing Heel/ earthing contact assembly in an isolator along with fasteners and clamps. The price shall cover the installation of a protective concrete box with removable cover as shown in the drawing. The price shall include the testing of earth value and painting the particulars on the box. Item No. 15 Erection of Anticreep with cadmium copper catenary wire including 9T insulator The prices shall include erection of all materials including 9 T insulator assembly along with anti-creep wire or cadmium copper catenary wire as an anti- creep wire . Price also includes replacement of suspension clamp by double suspension clamp required for provision of anti-creep. Payment shall be made on flat rate basis irrespective of length of anti-creep.

Item No. 16 Erection of a structure bond The price shall cover erection of 40 x 6 mm. Mild steel flat required to provide a structure bond connecting a traction mast or structures to the nearest non-track circuited rail, or earth electrode, including all fastenings at both ends. The price shall include shaping and drilling of the rail if required as per instruction of Railway , mast, and bond with erection of all materials including the bond. The price also cover connections or earthing terminals of equipments like L.T. transformer with structures and then to Rails as per relevant drawing.

Item No. 17 Erection of Transverse, Cross or Special bond. The price shall cover erection of 40 x 6 mm. Mild steel flat required to provide a Transverse, Cross or Spl.bond including all fastenings at both ends. The price shall include shaping and drilling of the rail if required as per instruction of Railway , mast, and bond with erection of all materials including the bond..

Item No. 18 Erection of longitudinal bonds

The price shall cover erection of 40 x 6 mm. Mild steel flat required to provide longitudinal bonds including all fastenings at both ends. The price shall include shaping and drilling of the rail if required as per instruction of Railway , mast, and bond with erection of all materials including the bond.

48

Item No. 19 Erection of Catenary wire splices The price shall cover splicing of terminated overhead equipment for extension and consequent adjustment of the affected equipment other than mentioned in item no. 11 or wherever required in execution of work. The extended overhead equipment shall be deemed as starting from the center line of the structure preceding the old terminating structure and the extended over head equipment shall be paid for under item-11.

Item No. 20 Erection of Contact wire splices The price shall cover splicing of terminated overhead equipment for extension and consequent adjustment of the affected equipment other than mentioned in item no. 11 or wherever required in execution of work. The extended overhead equipment shall be deemed as starting from the center line of the structure preceding the old terminating structure and the extended over head equipment shall be paid for under item-11.

Item No. 21 Transfer Of Equipment from one mast or support to another mast . The price shall cover transfer of overhead equipment to a bracket assembly on a new mast or support ( dismantling of the existing bracket assembly from the old mast of support will be paid under appropriate items of schedule) and consequent adjustment to overhead equipment required such as re-spacing of droppers, leveling etc. The foundation and steel work and bracket assembly for the new mast or structure will be paid for under appropriate items of schedule.

Item NO. 22 Adjustment of OHE & T/W checking of existing OHE. The price shall cover adjustment and final checking of OHE by Tower Wagon at each location and each span for smooth running of electric traffic and finally testing OHE & commissioning the same for which Tower Wagon will be provided by the Railway. Item NO. 23 Provision of additional bracket assembly/assemblies on a mast or support.

The price shall cover dismantling of an existing bracket assembly/assemblies and provision of a multiple cantilever cross arm wherever required, supplied free of cost by the purchaser and erection of bracket assemblies on the multiple cantilever cross arm. The prices shall include any consequential adjustments to traction overhead equipment such as re-spacing of droppers leveling etc. This prices shall not include the price for erection of any additional bracket assemblies which will be paid for under item-6. The dismantled equipment/materials, if any, shall be handed over to the purchasers stores depot. The price is inclusive of transporting all the released materials/equipments to the purchasers’ stores depot.

Item NO. 24 Dismantling & removal of cantilever assembly

The price shall cover dismantling of the existing cantilever assembly as per instruction of Railway authorized representatives. All such dismantled equipment/materials shall be handed over to the purchasers’ stores depot. The price is inclusive of transporting all the released materials/equipments to the Railway’s representative stores depot.

Item NO. 25 Dismantling & removal of OHE termination assembly. The price shall cover dismantling of the existing OHE termination assembly as per instruction of Railway authorized representatives. All such dismantled equipment/materials shall be handed over to the purchasers stores depot. The price is inclusive of transporting all the released materials/equipments to the Railway’s representative stores depot.

Item No. 26 Dismantling & removal of Guy Rod assembly The price shall cover dismantling of the existing Guy Rod assembly as per instruction of Railway authorized representatives. All such dismantled equipment/materials shall be handed over to the purchaser’s stores depot. The price is inclusive of transporting all the released materials/equipments to the Railway’s representative stores depot. Item NO. 27 Cutting of mast/TTC/portal uprights Price shall cover cutting of mast/TTC/portal uprights up to ground level, or uprooting of the

mast as per instruction of Railway authorized representatives, and remove the same without any damage and shifted them suitably so that there is no infringement in train movement. The

49

work is to be executed under power block/non-power block by contractor's labour, tools and tackles. All such dismantled equipment/materials shall be handed over to the purchaser’s stores depot. The price is inclusive of transporting all the released materials/equipments to the Railway’s representative stores depot.

Item no. 28

Dismantling & removal of Small parts steel including portal/TTC boom

Price shall cover Dismantling & removal of Small parts steel including portal/TTC boom as per instruction of Railway authorized representatives, and remove the same without any damage and shifted them suitably so that there is no infringement in train movement. The work is to be executed under power block/non-power block by contractor's labour, tools and tackles. All such dismantled equipment/materials shall be handed over to the purchaser’s stores depot. The price is inclusive of transporting all the released materials/equipments to the Railway’s representative stores depot

Note on Item No. 3-28

All claims under this item have to be supported by the following certificate to be furnished by the contractor on the connected bills.

a) The modifications are not on account of non-compliance of specifications approved and instructions given by the Railways for execution of works.

b) The quantities of work involved for modification have been finalized jointly with the Railway’s Engineers before taking the work in hand.

c) The dismantled materials where applicable have been handed over to the Railway’s representative at Store Depot.

Item No. 29 Work under power block: Any erection work as per schedule if done under power block is subject to have extra rate. The price under this item cover extra charges over and above erection rates of such items for erection of equipment in the vicinity of energized overhead equipment and feeders or erection of equipment with joints equipment already energized or an energized equipment which calls for a power block (shut-off of traction power). The price payable under this item shall be 100% extra over the erection rates of the items referred to above provided such work is not called for on account of non-compliance with specifications, approved drawings and instructions given by the purchaser from time to time. The extra erection rate under this item will not be payable, If power block is given for a total duration of 4 hours or more in a day whether continuously or in different spells. Where the prices under this item are applicable, the contractor shall finalize the quantities of various items of works to be done under a power block, jointly with the purchaser’s engineer prior to taking the work on hand.

--------------X-----------