Upload
others
View
4
Download
0
Embed Size (px)
Citation preview
Request for Proposal for
Selection
of Bidders for
Design, Supply, Erection, Testing, Commissioning and
Operation and Maintenance for 25 years of
Grid Connected Rooftop Solar Photovoltaic Power Projects on
Govt. Secretariat buildings
In
Jaipur, Rajasthan Under
RESCO Mode
Cost of Bid:
Rs. 5,000/-+18% GST i.e. Rs. 5,900/-
Department of personnel
Jan Path, C-Scheme, Jaipur
CIN ----------------------------------
Phone: 0141-2227700 / 2921921
Fax: 0141-2227700
Email:[email protected]
Website:- www.dop.rajasthan.gov.in
GENERAL INSTRUCTIONS FOR TENDER SUBMISSION i. The bidders are requested to submit their bids prior to last date of submission to avoid
non-submission of their bids within prescribed date & time due to non-availability /
hanging of website, at either ends at last moment, or any other reason whatsoever. The
last date of submission of bids will not be extended on such account. ii. The offer of the Bidders shall be for Minimum 970 KW capacity. The offers for less than
970 KW capacity will be rejected. iii. The tender cost, Bid Security and e-tender processing fees of RISL and e-challan copy as
detailed under to be deposited to Room No-5009, Main building Govt. Ssecretariat up to
2 1 /09/2019, 02:00 PM
positively.* *(This is essential otherwise the bid in electronic form (Cover 1, Cover 2 and Cover
3) of that bidder will not be opened.) The bidder will have to deposit in ENVELOPE–I
a) Rs.5,000/- & GST @18% i.e. Rs. 5,900/- (Rupees Five Thousand Nine Hundred Only) out of which Rs 5000/- will be deposit online from e- grass challan as per Finanace (G&T) circular on dated 27-04-2020. And GST amount Rs 900/- will be deposited through DD/Bankers Cheque in favour of Joint Secretary, DOP (B) Govt Secretariat, Jaipur.
b) Rs. 1,000/- (Rupees One Thousand Only) will have to deposit online from e- grass challan as per Finanace (G&T) circular on dated 27-04-2020. c) Bid Security Rs. 7 Lacs (@ Rs 7 Lacs per MWp) as detailed at Clause No. 3.15.1 will
be deposit online from e- grass challan as per Finanace (G&T) circular on dated 27-04-2020.
iv. ONLINE SUBMISSION OF BID: List of required Formats/documents to be submitted online duly signed digitally by
Authorized Signatory: (1) Cover-1:- Upload the scanned copy of deposit online e- grass challan Cost of
tender Document, processing fee of RISL and scanned copy of deposit online from e-
grass challan of BID Security (in .pdf format) with copy of relevant Certificate for
Exemption of BID Security (If applicable) as detailed in point no. ii & GST deposited
through DD/Bankers Chequecopy in favour of Joint Secretary, DOP (B) Govt Secretariat, Jaipur..
(2) Cover-2:- All Non-financial information in the Formats as per tender with Complete
Bid Document (duly signed on each and every page as proof of acceptance of all terms
and condition of Bid).
(3) Cover-3:- Financial Bid as per Format attached.
NOTE: 1. The financial bid is to be submitted online only as per format Section VIII.
This format is to be downloaded from http://eproc.rajasthan.gov.in filled &
uploaded back to http://eproc.rajasthan.gov.in.
2. Financial Bids submitted/uploaded on http://eproc.rajasthan.gov.in any other format
may be rejected. Submission of price in cover-2 will be finally rejected and such
bids will be considered as disqualified in technical evaluation and cover-3 (on-line)
of such bids will not be opened. v. Cutting / overwriting, if any, in the figures of the tendered documents is required to be
clarified / indicated in words, duly signed, failing which the tender may be rejected. vi. The Bidder(s) shall not quote any deviations/ amendments/modifications/alterations
in the Financial Bid(s). Financial Bid(s) with any such deviations shall be rejected.
vii. The Bidder(s) shall provide complete information at the time of submission of Bid(s). If
the Bidder(s) is asked to furnish some more clarification(s)/confirmation(s)/document(s),
it shall be required to furnish the same within specified time, failing which the case shall
be finalized/ decided on the basis of available information/document(s). The
responsibility of ignorance of its Bid(s) on account of delay in furnishing of desired
information/document(s) shall be of the Bidder(s). However, if there are any
shortcomings in the submission of the information which do not materially affect the
qualification criterion, then the Bid Evaluation Committee shall have the power to
consider the facts on the merit of the case and decide the Bid evaluation accordingly. viii. All the required information shall be furnished strictly in the prescribed formats only.
Any information indicated other than the prescribed formats shall not be entertained. The
Bid(s) shall be evaluated on the basis of information furnished in the prescribed formats
only. ix. This RFP shall essentially be signed digitally and submitted/uploaded on
http://eproc.rajasthan.gov.in as part of Cover 2, (It is also Instructed to all the bidders that
all the documents uploaded should be clearly legible/readable) prior to the Bid Deadline
as specified in Bid Information. x. Bidder(s), who wish to participate in this RfP, shall be required to register on
http://eproc.rajasthan.gov.in if not registered earlier. To participate in e-tendering,
Bidder(s) shall have Digital Signature Certificate (DSC) - Class II (e-tender supportive)
or Class III as per requirement under Information Technology Act-2000 using which they
can sign their electronic Bid(s) (i.e. Envelope-2). Bidder(s) can procure the same from
any Controller of Certifying Authorities (CCA) approved certifying agency or they may
contact e-Procurement Cell, Department of IT&C, Government of Rajasthan on the
following address: e-Procurement Cell, RISL, Yojana Bhawan, Tilak Marg, C-Scheme, Jaipur, e-mail:
xi. Bidders are also advised to refer “Bidder‟s Manual” available under “Downloads” section
on http://eproc.rajasthan.gov.in for further details about the e-tendering process.
xii. The Rajasthan Transparency Public Procurement Service Act-2012 and Rules-2013 are
effective from 26-01-2013 so all the provisions of the said Act will be effective on the
contract.
xiii. Contact details of Staff of Govt Secretariat in reference to this RFP
Name: - Joint Secretary, DOP (B)
Address: Govt. Secretariat, Jan Path, C-Scheme, Jaipur, Rajasthan- 302001
Phone: 0141-2227700 / 2921921
e-mail: [email protected]
Note: All correspondence in reference to this RFP by mail shall essentially be sent only to
e-mail id: www.dop.rajasthan.gov.in
Joint Secretary,
DOP (B)
Govt. Secretariat, Phone: 0141-2227700
TABLE OF CONTENT A. BID INFORMATION SHEET
B. GENERAL INSTRUCTIONS FOR BID SUBMISSION
C. DEFINITIONS & ABBREVIATIONS
D. INTERPRETATIONS
SECTION-I: INTRODUCTION
SECTION-II: INSTRUCTIONS TO THE BIDDER
SECTION III: BID EVALUATION
SECTION IV: SUCCESSFUL BIDDERS SELECTION
SECTION V : SCOPE OF WORK
SECTION VI: CHECKLIST
SECTION VII: TECHNICAL PARAMETERS
SECTION VIII: FINANCIAL BID FORMAT
SECTION IX: FORMATS FOR SUBMITTING RFP
FORMAT 1 COVERING LETTER
FORMAT 2 GENERAL PARTICULARS OF THE BIDDER
FORMAT 3 SHARE HOLDING CERTIFICATE
FORMAT 4 BG FOR BID SECURITY
FORMAT 5 BG FOR CONST. PERFORMANCE BANK GUARANTEE
FORMAT 6 CHECK LIST FOR CONST. PBG
FORMAT 7 POWER OF ATTORNEY
FORMAT 8A FINANCIAL ELIGIBILITY CRITERIA
FORMAT 8B TECHNICAL ELIGIBILITY CRITERIA
FORMAT 9 CERTIFICATE OF RELATIONSHIP OF AFFILIATE WITH BIDDER
FORMAT 10 FORMAT FOR UNDERTAKING
FORMAT 11 FORMAT FOR AGREEMENT
FORMAT 12 CONSORTIUM AGREEMENT
FORMAT 13 DECLARATION BY THE BIDDER
FORMAT 14 COMPLIANCE WITH THE CODE OF INTEGRITY AND NO CONFLICT
OF INTEREST
FORMAT 15 GRIEVANCE REDRESSAL PROCESS
ANNEXURE-I : PPA uploaded separately
DEFINITIONS AND ABBREVIATIONS In this “Bid / RFP Document” the following words and expression will have the meaning as herein defined where the context so admits:
1. “Affiliate” shall mean a Company / Limited Liability Partnership (LLP) Firm/ Partnership
Firm/ Sole Proprietor that directly or indirectly
i. controls, or
ii. is controlled by, or
iii. is under common control with
a Bidder or a member (in case of a Consortium) and control means ownership by one
Bidder/member of at least 26% paid up equity capital in any other Bidder/member. Any
bank or financial institution shall not be considered as Affiliate.
2. “B.I.S” shall mean specifications of Bureau of Indian Standards (BIS).
3. “Bid” shall mean the Technical and Financial proposal submitted by the Bidder along with
all documents/credentials/attachments annexure etc., in response to this RFP, in
accordance with the terms and conditions hereof.
4. “Bidder(s)” shall mean bidding Company/Limited Liability Partnership (LLP) firm/
Partnership Firm/ Sole Proprietor or Consortium in any form submitting the Bid. Any
reference to the Bidder includes its successors, executors and permitted assigns as the
context may require.
5. “Bidding Consortium or Consortium” shall refer to a group of bidding
Company/Limited Liability Partnership (LLP) firm/ Partnership Firm/ Sole Proprietor that
has collectively made a Bid, in response to RFP for the project.
6. “Bid Deadline” shall mean the last date and time for submission of Bid in response to this
RFP as specified in Bid Information Sheet.
7. “Bid Security” shall mean Bid Security to be submitted by the Bidder along with the Bid
as per clause 3.15;
8. “CEA” shall mean Central Electricity Authority;
9. “Capacity Utilization Factor” (CUF) in a Year shall mean the ratio of the output of the
SPV Power Plant in a Year versus installed Project capacity x 365 x 24.
(CUF = Cumulative Project output in kWh / (installed Project capacity in kWp x 24 x
365)).
However, for demonstration of successful Completion, CUF shall mean the ratio of the
output of the SPV Power Plant in a day versus installed Project capacity x 1 x 24, adjusted
to seasonality as per provisions of Clause 3.18.
10. “Chartered Accountant” shall mean a person practicing in India or a firm whereof all the
partners practicing in India as a Chartered Accountant(s) within the meaning of the
Chartered Accountants Act, 1949.
11. “Competent Authority” shall mean Pr. Secy DOP himself and/or a person or group of
persons nominated by him for the mentioned purpose herein;
12. “Completion” shall mean supply and erection/installation of the Project and
demonstration of CUF as per provisions of clause3.18.
13. “Commissioning” shall mean demonstration of successful operation of the Grid Connected Project or part thereof, in accordance with prevailing regulations and clause
6.12, by the Power Producer.
14. “Commercial Operation Date” or “COD” shall mean Day when full PPA Capacity of
the Project shall be commissioned;
15. “Company” shall mean a body incorporated in India under the Companies Act, 1956 or
Companies Act, 2013 including any amendment thereto.
16. “Comprehensive Operation and Maintenance” or “Comprehensive O&M” shall mean
insurance, warranty, spare parts and operation & maintenance of Projects during the term
of the PPA.
17. “Day(s)” shall mean a 24 (twenty four) hour period beginning at 00:00 hours Indian Standard Time and ending at 11:59:59 hours Indian Standard Time;
18. “Effective Date” shall mean date of execution of PPA between Power Producer and
DOP;
19. “Eligibility Criteria” shall mean the Eligibility Criteria as set forth in this RFP;
20. “Eligible Bidder(s)” shall mean the Bidder who, after evaluation of their Technical Bid as
per Eligibility Criteria, stand qualified for opening and evaluation of their Financial Bid
21. “Expiry Period” shall mean the 25th anniversary of the SCOD of the Project.
22. “Financial Bid” shall mean online financial Bid, containing the Bidder’s fixed quoted
levelized Tariff for duration of PPA, as per format given in RFP.
23. “First Operational Year” shall mean the period commencing from the Initial Part
Commissioning and expiring at the end of the Calendar Month in which Project completes
twelve (12) Months from the COD of PPA Capacity.
24. “Free reserves” means free reserves as defined in definition No. 43 in Companies Act, 2013.
25. “IEC” shall mean specifications of International Electro technical Commission.
26. “Initial Part Commissioning” shall mean the commissioning of first part capacity of
PPA Capacity by Power Producer, and shall include COD if the entire project
commissioned together.
27. “Inspecting Authority” shall mean the authority designated by the competent authority
for the said purpose.
28. “kWp” shall mean Kilo Watt Peak.
29. “kWh” shall mean Kilo Watt Hour.
30. “LCoE” shall mean Levelised Cost of Energy quoted by the bidders, which shall remain
fixed for 25 operational years of the project.
31. “LOA” shall mean Letter of Allocation.
32. “Lead Member” shall mean the member of Bidding Consortium which is designated as
leader of the Consortium by other member to represent them as Bidder for this RFP.
33. “MNRE” shall mean Ministry of New and Renewable Energy, Government of India.
34. “Month(s)” shall mean a calendar month as per the Gregorian calendar.
35. MWp” shall mean Mega Watt Peak.
36. “Agency” Joint Secretary, DOP (B) Address: Govt. Secretariat, Jan Path, C-Scheme,
Jaipur, Rajasthan- 302001
37. “Operational Year(s)” the First Operational Year and thereafter each period of 12
(twelve) Months till the Expiry Date of PPA. It is pertinent that, last Operational Year
would get shortened by number of months by which Commissioning of Project got
delayed from the SCOD.
38. “Part Commissioning” shall mean the Commissioning of capacity lower than the PPA capacity for the purpose of receiving the Commissioning certificate for part capacity.
39. “Paid-up share capital” means the paid up share capital as defined in Section 2 of the
Company Act, 2013.
40. “Performance Test” shall mean tests as defined in Article 3.18 which establish successful
installation and working of equipment at desired level as per the requirement of issuing
authority.
41. “Power Producer” shall mean any one who has accepted the LoA then, enters into a PPA
with the DOP for supply of solar power and has legal ownership of all the equipment of
the Project. After Expiry Date of PPA, ownership of Project will be transferred DOP Govt
Secretariat as provided in the PPA.
42. “Power Purchase Agreement or PPA” shall mean the Power Purchase Agreement to be
executed between Power Producer and the DOP Govt Secretariat . The prescribed format
for execution of PPA is attached as to this RFP.
43. “PPA Capacity” shall mean the capacity undertaken by the Power Producer for
implementation of grid connected roof top solar PV Projects for sale of solar power to
DOP after undertaking a technical analysis of the likely capacity under the RFP.
44. “Premise” shall mean any land, building or structure or part thereof or combination
thereof including any other vacant /non-vacant area which is part of the DOP
establishment.
45. “Procurer means DOP Govt Secretariat” shall mean the person or company or
organization procuring solar power from the Power Producer at competitively determined
tariff under the RFP and the PPA.
46. “Project(s)” shall mean the Grid Connected Solar PV Project(s). 47. “Project Capacity” means the capacity of the Projects mentioned in the Agreement. The
Project capacity specified is on “DC” Side only.
48. “Project Company” shall mean Company incorporated by the Bidder as per Indian Laws
in accordance with 3.9.
49. “Prudent Utility Practices” shall mean the practices, methods and standards that are
generally accepted nationally from time to time by electric utilities for the purpose of
ensuring the safe, efficient and economic design, construction, commissioning, operation
and maintenance of power generation equipment of the type specified in this RFP, as per
requirements of Indian Law.
50. “Qualified Bidder(s)” shall mean, for given scope of work, the Eligible Bidder having
quoted minimum Financial Bid or Eligible Bidder matching minimum Financial Bid.
51. “RESCO” shall mean a person or an entity, which is in the business of supplying power
generated through Project installed in the Premise of the DOP on mutually agreed terms.
52. “RESCO Mode” shall mean where the Bidders intend to use a Premise owned/used by
the DOP and enters into the PPA with DOP for supply of solar power as per RFP.
53. “RFP” shall mean Request for Proposal (RFP)/Bid document/Tender document and shall
include formats and annexures in it.
54. “Scheduled Commercial Operation Date” or “SCOD” shall mean 05 months from the
date of Issuance of LoA.
55. “Statutory Auditor” shall mean the auditor of a Company appointed under the provisions
of the Companies Act, 1956 or Companies Act, 2013 or under the provisions of any other
applicable governing law.
56. “Successful Bidder(s)” shall mean the Qualified Bidder(s) selected by DOP Govt
Secretariat pursuant to this RFP for implementation of Project as per the terms and
condition of the RFP Documents, and to whom LoA has been issued. 57. “Term of PPA” shall mean the period from the Effective Date until the Expiry Date.
58. “Year” shall mean 365 Days or 366 Days in case of leap year when February is of 29
Days.
INTERPRETATIONS 1. Words comprising the singular shall include the plural & vice versa
2. An applicable law shall be construed as reference to such applicable law including its
amendments or re-enactments from time to time.
3. A time of day shall save as otherwise provided in any agreement or document be construed
as a reference to Indian Standard Time.
4. Different parts of this contract are to be taken as mutually explanatory and supplementary
to each other and, if there is any differentiation between or among the parts of this
contract, they shall be interpreted in a harmonious manner so as to give effect to each part.
5. The table of Contents and any headings or sub-headings in the Contract has been inserted
for case reference only and shall not affect the interpretation of this document.
SECTION-I: INTRODUCTION
1. INTRODUCTION:
1.1. Request for Proposal for Selection of Power Producer for Implementation of 970 KWp of Grid Connected Roof Top Solar PV Systems for Sale of Solar Power under RESCO Mode at various locations in the Secretariat Rajasthan, India in accordance with MNRE/ RERC/ concerned distribution licensee norms.
1.2. The Bidder is advised to read carefully all instructions and conditions of this RFP and
understand the scope of work completely. All information and documents required as
per the RFP must be furnished with the bid. DOP Govt Secretariat reserves the right to
seek clarifications on submitted bids. Failure to provide the information and/or
documents as required shall render the Bid(s) unacceptable for further evaluation and
may lead to rejection of the bid(s). All bidders qualifying the technical stage shall be
treated at par. Financial Bid of the Bidder qualifying at technical stage only shall be
opened. 1.3. Bidder shall be deemed to have examined the RFP, to have obtained information in all
matters whatsoever that might affect carrying out of works in line with the scope of
work specified in the RFP at the Bid price and to have satisfied himself of the
sufficiency of his Bid. The Bidder shall be deemed to know the scope, nature and
magnitude of the works and requirement of materials, equipment, tools and labour
involved, wage structures and as to what all works Power Producer shall have to
complete in accordance with the RFP, irrespective of any defects, omissions or errors
that may be found in RFP. 2. BID DETAILS: 2.1. The bidding process is for approximate Nine Hundred Seventy Kilo Watt Peak
(970 KWp) capacity for Implementation of Grid Connected Roof Top Solar PV
Systems for Sale of Solar Power under RESCO Mode at various locations in the
Secretariat Rajasthan, Jaipur. 2.2. No Subsidy / Incentive is available for any of the Projects mentioned as part of this RFP.
Therefore, developers have a liberty to choose among Indian make or foreign make
modules. However, the SPV Modules supplied shall be meeting the requirements
of MNRE OM No. 283/54/2018 GRID SOLAR dated 02.01.2019 in respect of
Approved Makes and Manufacturers. Such Projects are eligible for concessional
funding under World Bank Financing. Bidder can choose to avail the above facility at
its own discretion. The final decision to provide debt funding will lie with respective
banks. DOPwill take no responsibility/ liability for debt funding.
2.3. Key Dates The Key Dates shall be as mentioned in Bid Information Sheet.
2.4. Conditions Precedent
Conditions Precedent for DOP:
2.4.1.1. DOP shall allocate sufficient shadow free space in its Premises to the Successful
Bidder, and provide last twelve (12) Months of electricity bills (at least of six (6)
Months), to the Successful Bidder. DOP shall allow Successful Bidder to visit the
Premise for assessment of required space and locating the proposed project.
Minimum space provided by DOP shall be based on superstructure design prepared
by bidder & approved by DOP.
2.4.1.2. On allocating enough space for installation of Project, Successful Bidder may ask
for a change in location within Premise, but final decision on the location shall be
taken by DOP and it shall be binding on Successful Bidder.
2.4.1.3. DOP Govt Secretariat should inform Successful Bidder, in writing, about the space
provided for Project implementation.
2.4.1.4. PPA shall be signed by the DOP with Successful Bidder within ten (15) Days
from the submission of C-PBG DOP.
2.4.1.5. Any delay beyond 60 days insibning PPA with the Successful Bidder Procurer”s
Project shall be exculuded from further deliberations. Conditions Precedent for Successful Bidder: 2.4.1.6. Confirmation on acceptance of LoA within 15 Days from the date of issuance of
LoA.
2.4.1.7. Immediately after acceptance of LoA, the Successful Bidder shall initiate Site
Survey, assess free capacity of the concerned DT, analyse last twelve (12) Months of
electricity bills (at least six (6) Months) received from DOP, and submit the letter of
request for PPA Capacity to DOP.
2.4.1.8. The DOP Govt Secretariat shall approve the proposed capacity of Solar Rooftop
System by the successful bidder after survey of the building for signing PPA.
2.4.1.9. DOP Govt Secretariat shall communicate to Successful Bidder the PPA Capacity within ten (10) Days from the submission of the site survey report and letter of request. 2.4.1.10.Submission of C-PBG shall be within fifteen (15) Days from the confirmation by
DOP Govt Secretariat on the PPA Capacity.
2.4.1.11.The bidders shall complete the commissioning of entire allocated capacity within 05
Months from the date of issue of LoA. Consequences of non-fulfillment of conditions precedent: 2.4.1.12.In case, DOP Govt Secretariat cancels the LoA issued to Successful Bidder due to
non- compliance of Successful Bidder, DOP Govt Secretariat shall ask the
subsequent Bidder in the ascending order for issuance of LoA at the rate quoted by
L1 for which LoA has been cancelled.
2.4.1.13.At any point of time, if it is found that Successful Bidder is non-compliant or is not
signing the PPA for any specific type of Building(s), DOP Govt Secretariat may take
strict action against the Successful Bidder. It may lead to cancellation of LoA
issued to that Successful Bidder. SECTION-II: INSTRUCTIONS TO THE BIDDER
3. INSTRUCTIONS TO THE BIDDER:
3.1. Bidder shall meet the Eligibility Criteria. Consortium of maximum of three companies
is allowed under RFP. Consortium may comprise of Companies or Sole Proprietor or
Limited Liability Partnership Firms or Partnership Firms or any combination thereof. In
case of consortium, Lead Member must independently meet the Financial Eligibility
Criteria.
3.2. Further, Bidder must note that for evaluation of qualification against Financial
Eligibility Criteria, following conditions shall be applicable:
a) Bidder shall establish net-worth as required by this RFP.
b) In-case Bidder / Lead Member of Consortium has referred its Affiliate to meet the
Financial Eligibility criteria, then relationship with the Affiliate by the Bidder shall
continue i.e., equity holding should be more than 26% for period of the First
Operational Year. Further, Affiliate of Bidder and member of Consortium shall
furnish information as sought in FORMAT 9 & FORMAT 12.
3.3. A Bidder shall not have a conflict of interest for the bid. Bidder(s) shall be disqualified
where it has conflict of interest. The Bidder may be considered to have conflict of
interest with one or more parties in this bidding process, if:
a) A Bidder submits more than one Bid in the bidding process, either individually
[including bid submitted as authorized representative on behalf of one or more
Bidder(s)] or as Member of consortium.
b) They have a relationship with each other, directly or through common third parties,
that puts them in position to have access to information about or influence on the Bid
of another Bidder, or influence the decisions of DOP Govt Secretariat regarding this
bidding process. 3.4. DOP Govt Secretariat have rights to annul/cancel the Bid of Bidders who will
take any assistance or support in any form from any of the independent consultant or
consulting agency who is directly associated with DOP Govt Secretariat during
preparation of RFP and PPA. 3.5. The Bidders shall have to submit their Technical Bid and Financial Bid and other
required relevant documents / certificates, if any, online only (duly encrypted bids) as
per time schedule (Key dates) as mentioned in Clause 2.3. Bid information sheet.
3.6. ELIGIBILITY CRITERIA
3.6.1 GENERAL The Bidder should be a body corporate incorporated in India under the Companies Act,
1956 or 2013 including any amendment thereto or a Partnership Firm having executed
partnership deed and registered as per sections 58 & 59 of the Partnership Act, 1932, as
amended or a Limited Liability Partnership Firm (LLP) registered under section 12 of
Limited Liability Partnership Act, 2008, as amended or registered Sole Proprietor. A
copy of certificate of incorporation, partnership deed or LLP/ Sole Proprietor
registration, as applicable and relevant, shall be enclosed with Format 2. Bidder or consortium shall be ineligible for participation in this RFP in following cases:
i. If Bidder or any member of consortium has not performed satisfactorily in the Work
Order(s) of a n y go v t de pa r tm e n t , leading to cancellation of Work Order(s) of
value more than or equal to twenty five percent (25%) of cumulative value of Work
Order(s) awarded in last five (5) Years. (Bidder has to submit under taking in the
Format 13) ii. If Bidder or any member of consortium is involved in litigation or arbitration with
a n y go v t de pa r tm e n t arising out of work completed or under execution by it, of
value more than or equal to twenty five percent (25%) of cumulative value of Work
Order(s) awarded in last five (5) Years.
3.6.2 FINANCIAL ELIGIBILITY CRITERIA: 3.6.2.1 The Bidder should have minimum Net worth of INR T w o (2) crores, subject to
provisions of clause 3.2. In case of Consortium, Net worth should be fulfilled by
Lead member only. The Computation of Net worth shall be based on latest
available unconsolidated audited annual accounts but not older than two (2)
Years. Share premium can be included in the Net worth calculation only in case
of listed companies in India. The formula of calculation of net-worth shall be as
follows: Net-worth = (Paid up share capital) + (Free reserves) + (Share premium of
listed / private companies)-(Revaluation of reserves)-(Intangible assets) -
(Miscellaneous expenditure to the extent not written off and carry forward losses)
3.6.2.2 In relation to a Partnership Firm/ Limited Liability Partnership Firm, the Net-
worth shall be equal to Partner‟s Capital. In case of Sole Proprietorship the net
worth shall be equal to Proprietor‟s Capital Account (including any reserves)
Note:- i. All requisite documents, such as balance sheet, P&L account, schedules
etc., duly certified by a Chartered Accountant (CA) and the Bidder, in
support of Bidder claim for meeting the financial eligibility criteria shall
be required to be submitted.
ii. It is essential to submit financial eligibility criteria requirement and
undertaking form as attached in Format 8A and Format 10 of this RFP.
a) For the purposes of meeting financial requirements, only unconsolidated
audited annual accounts shall be used. However, audited consolidated
annual accounts of the Bidder may be used for the purpose of financial
requirements provided the Bidder has at least twenty six percent (26%)
equity in each company whose accounts are merged in the audited
consolidated accounts.
b) Bidder shall furnish documentary evidence as per the Format 9, duly
certified by Authorized Signatory and the Statutory Auditor / Practicing
Chartered Accountant of the Bidder in support of their financial capability.
c) Bidder can use the financial strength of its Affiliate to fulfill the Financial Eligibility Criteria mentioned in RFP.
d) In case of Consortium, Financial Eligibility Criteria has to be met
individually by Lead Member and/or its Affiliate.
e) Bidders shall have to give a declaration to the effect that they fulfill the
terms and conditions of eligibility as per FORMAT 13. If the declaration
to above effect is found to be false, the eligibility would be considered
null and void. 3.6.3 TECHNICAL ELIGIBILITY CRITERIA:
The bidder should have designed, supplied, installed & commissioned at least one
(1) number of G r i d c o n n e c t e d solar power plant with a minimum capacity
of 250 kWp and cumulative G r i d c o n n e c t e d solar power plant capacity of
1.0 MWp commissioned in the last five (5) years, prior to bid submission date. Note:-
i. The bidders must submit documentary proof for technical eligibility certified
by concerned Government Organisation /SECI/MNRE Authorised
Agency/Project Owner for work executed.
ii. Bidder can use the technical strength of its Affiliate to fulfill the Technical
Eligibility Criteria mentioned in RFP.
iii. In case of consortium, Technical Criteria shall be fulfilled either by Lead
Member or by other consortium partners individually. 3.7. CHECK-LIST:
All bidding related documents should only be submitted online through e-proc
website. The hard copy of only payments and guarantees should be sent to the DOP
Govt Secretariat . To ensure all requisite and relevant documents are uploaded online
and is complete in all respects, a check-list of documents has been provided in
SECTION VI as part of RFP. 3.8. INCORPORATION OF A PROJECT COMPANY:
In case a Bidder is selected as a Successful Bidder, it can choose to incorporate a
Project Company. In case a Bidder is a consortium, Bidder is responsible to
incorporate a Project Company within forty five (45) Days from the issuance of LoA.
Further, Bidder shall be responsible to get all required clearances in the name of the
Project Company, also transfer already obtained clearances, if any. The aggregate equity share holding of the Successful Bidder in the issued and paid up
equity share capital of the Project Company shall not be less than fifty one percent
(51%) up to a period of one (1) Operational Year. Company formed by members of
the consortium who is a Successful Bidder shall have at least aggregate equity share
holding of 51% held by the member of the Consortium in a newly formed Company,
up to a period of one (1) Operational Year. Further, any member of the Successful
consortium shall maintain individual equity in newly formed Company of at least,
51% (0.51) of its share in the bidding consortium, up to a period of one (1)
Operational Year.
In case of Successful Bidder being a Partnership Firm or an LLP, the equity
ownership of the partners in the Successful Bidder or the Project Company shall
remain in same proportion as mentioned in the partnership deed submitted along with
the Bid, up to a period of one (1) Operational Year. DOP Govt Secretariat shall be
notified, within a month, in case of any change in equity proportion for ownership of
such Successful Bidder. Any change in ownership and liabilities after one (1) Operational Year shall be
permissible, however Power Producer should inform DOP Govt Secretariat in writing
within 30 Days of change in ownership. 3.9. BID SUBMISSION BY THE BIDDER:
The information and/or documents shall be submitted by the Bidder as per the formats
specified in this document. Bid(s) that are incomplete in any respect or those that are
not consistent with the requirements as specified in this RFP or those that do not
adhere to formats prescribed herein, wherever specified, may be considered non-
responsive. However, DOP Govt Secretariat reserves the right to seek additional
information/clarifications from the Bidders, if found necessary, during the course of
evaluation / processing of the Bid(s). Non-submission or delayed submission of
such additional information or clarifications sought by DOP Govt Secretariat may be
a ground for rejecting the Bid(s). Each format has to be duly signed and stamped by
the authorized signatory of the Bidder. In case of a Consortium, it has to be signed
by representative of the Lead Bidder. Strict adherence to the documents required to
be submitted Check List-I, as per clause
3.12 shall be ensured, failure on this account may lead to rejection of Bid. The Bidder shall furnish documentary evidence in support of meeting eligibility
criteria as indicated in this RFP to the satisfaction of DOP Govt Secretariat and
shall also furnish unconsolidated/ consolidated audited annual accounts in support of
meeting financial & technical requirement, which shall consist of unabridged annual
accounts, profit and loss account, profit appropriation account, auditor’s report,
technical experience etc., as the case may be. The Bidding Company should designate one person to represent the Bidding
Company in its dealings with DOP Govt Secretariat . The person should be authorized
to perform all tasks including, but not limited to providing information, responding
to enquires, signing of Bid etc. The Bidding Company should submit, along with Bid,
a Power of Attorney in original as per FORMAT 7, authorizing the signatory of the
Bid. 3.10. CLARIFICATIONS AND PRE-BID MEETING:
The Bidder may seek clarifications or request amendments to RFP by submitting their Clarification/Suggestions through the link available on the Home Page of DOP
website http://www. www.dop.rajasthan.gov.in
The Bidder(s) or their authorized representative(s) is /are invited to attend pre-bid
meeting(s), which will take place on date(s) as specified in Bid information Sheet. The purpose of the pre-bid meeting will be to clarify any issues regarding the RFP
including in particular, issues raised in writing and submitted by the Bidder. DOP Govt Secretariat is not under any obligation to entertain/ respond to suggestions
made or to incorporate modifications sought for. 3.11. BID DOCUMENTS:
BID FORMATS: The Bid in response to this RFP shall be submitted by the Bidder in
the manner provided in the RFP. The Bid shall comprise of the following:
a) CHECK LIST-I : The following documents are to be submitted in physical (hard
copy) upto the date and time mentioned in this RFP. The scanned copies of these
documents are also required to be uploaded Online in Cover-1:
Covering Letter as per prescribed FORMAT 1
Cost of tender document
e-proc Processing Fee
Bid Security of required value as mentioned in Clause 3.15,
Certificate issued by the Competent Authority for Exemption/Concessional
EMD, if applicable. b) CHECK LIST - II TECHNICAL DOCUMENTS: The following documents are
to be submitted Online Only:
Original power of attorney (on the stamp value of Rs.1000/ -, as per
FORMAT 7) issued by the Bidder in favour of the authorized person
signing the Bid, in the form prescribed in this RFP (Power of Attorney
must be supplemented by Board Resolution to above effect for the company
incorporated under Company Act 1956 or Company Ac t-2013).
General particulars of Bidder as per Format 2 of this RFP, including
Certificate of Incorporation of Bidder/ Affiliate as applicable.
Bidder‟s composition and ownership structure as per prescribed Format 3
as shareholding certificate certified by Director/practicing Chartered
Accountant/Company Secretary and authorised signatory of the Bidder (as
applicable).
Format 8A & 8B for meeting Eligibility Requirements along with all
supporting documents.
Format 9, if applicable, supported by Board Resolution of the Affiliate.
Undertaking(s) from the member of Consortium or Affiliate of Bidder/
member of Consortium as per Format 10, as applicable.
Format 12 for Consortium Agreement, if applicable.
Format 13 on Declaration for submission of Bid.
Format 14 Compliance with Code of Integrity & No Conflict of Interest
Format 15 Grievance Redressal Process
Signed and stamped Copy of RFP including amendments & clarifications
by authorised signatory of Company on each page. METHOD OF BID SUBMISSION
a) Bidders are required to submit technical bid, along with all relevant documents as
detailed in Clause 3.9 and 3.11 above, on e-tendering website. No hard copy of tender
related documents will be accepted, except for challan /payment/fee.
b) The tender shall be submitted through online mode only, on or before the Bid
Deadline.
c) Financial Bid shall also be submitted through online mode only, with due encryption
process in place.
DOP shall not be responsible for any delay in receipt of the technical bid. It should be
noted that except Financial Bid, no other document shall contain any
information/document relating to Financial Bid. DOP Govt Secretariat shall
not be responsible for premature opening of the Financial Bid in case of non-
compliance of above. While preparing the bid, All constituent pages of the Bid, to be
scanned and uploaded, except for the Bid Security, and any other document executed
on non-judicial stamp paper, forming part of the Bid and corrections in the Bid if any,
must be signed by the authorized signatory on behalf of the Bidder. In case of a
Consortium, it has to be signed by representative of the Lead Bidder. It is clarified
that the same authorized signatory shall sign all pages of the Bid. Further, any
published document uploaded with the Bid shall be signed by the authorized
signatory. Bidder shall upload the scanned Bid in original, duly signed by their
authorized signatory of the Bidder.
3.12. BID DEADLINE:
3.12.1. The Bidder should submit the online Bid on or before the time schedule mentioned in
Bid Information Sheet. 3.13. VALIDITY OF BID:
The bid shall remain valid for a period of ninty (90) Days from the date of online Bid
submission. In case, Successful Bidder is revoking or cancelling his offer or varying
any term & conditions in regard thereof or not accepting Letter of Allocation
(LoA), DOP Govt Secretariat shall forfeit the Bid Security furnished by the
Bidder. The date of issuance of LoA shall be intimated by the DOP Govt Secretariat
to the Successful Bidder. In exceptional circumstances when LoA is not issued, the
DOP Govt Secretariat may solicit the Bidder's consent to an extension of the period of
Bid Validity Period. In such circumstances, the Bid Security provided shall also be
suitably extended. 3.14. COST OF BIDDING:
The Bidder shall bear all the costs associated with the preparation and submission of
his offer and DOP Govt Secretariat will in no case be responsible or liable for those
costs, under any conditions. The Bidder shall not be entitled to claim any costs,
charges and expenses of and incidental to or incurred by him through or in connection
with submission of Bid even though DOP Govt Secretariat may elect to
modify/withdraw the invitation of Bid. 3.15. BID SECURITY: 3.15.1 BID SECURITY:
The bid security shall be 2% of the estimated value of subject matter of procurement
put to bid. In case of Small Scale Industries of Rajasthan it shall be 0.5% of the
quantity offered for supply and in case of sick industries, other than Small Scale
Industries, whose cases are pending with Board of Industrial and Financial
Reconstruction, it shall be 1% of the value of bid. Concessional bid security may be
taken from registered bidders as specified by the State Government. Every bidder, if
not exempted, participating in the procurement process shall be required to furnish the
bid security as stated in the table below: Minimum Capacity
in kWp
Bid Security Bid Security for Small Scale
Industries of
Rajasthan
Bid Security for other than Small Scale Industries, whose cases
are pending with Board of Industrial
and Financial Reconstruction
970 Rs.7,00,000 Rs.1,75,000 Rs.3,50,000
All provisions regarding exemptions of EMD shall be as per provisions of RTPP Act
and GF&AR of GoR. Whereas it is described: Under rule 57 (2)(a)(i) of GF&AR –
Part-II (FD Order No. F1(1)FD/GF&AR/93-II, dated: 01/07/1996.
In lieu of bid security, a bid securing declaration shall be taken from Departments' of
the State Government and Undertakings, Corporations, Autonomous bodies,
Registered Societies, Cooperative Societies which are owned or controlled or
managed by the State Government and Government Undertakings of the Central
Government. Such bidders are exempted from Bid Security on producing bid
securing declaration in Hard Copy in Envelope-1 and also online in Cover-1. The Bid Security shall be from a nationalized/ scheduled bank in the form of Demand
Draft drawn in favour of Joint Secretary, DOP (B), Govt Secretariat Jaipur payable
at Jaipur OR Bank guarantee as per prescribed format 4.
The initial validity of Bid Security shall be for a period of One hundred and eighty
(180) Days from the Bid Deadline, which shall be extended by the Bidder on the
advice of DOP Govt Secretariat, if required, at any time before bid process is
concluded.
Bid Security shall be returned to all other Bidders except Successful Bidder, within
fifteen (15) Days from date of submission of C-PBG by the Successful Bidders or
within three (3) Months of opening of Financial Bid result, whichever is earlier.
The bid security for the successful bidder shall be returned within 15 days of
submission of CPBG.
In order to avail the benefit of concessional bid security, In case of JV / consortium,
all the partners of the JV / consortium must be Small scale industries of Rajasthan as
defined under this clause. The Bid Security shall be denominated in Indian Rupees and:
a) Bid Security should be confirmed for payment to DOP Govt Secretariat by
respective banks.
b) Bid Security shall be submitted in its original form and copies will not be accepted. The Bid Security shall be forfeited without prejudice to the Bidder being liable
for any further consequential loss or damage incurred to DOP Govt Secretariat under
following circumstances: a) If a Bidder withdraws/revokes or cancels or unilaterally varies his bid in any
manner during the period of Bid Validity specified in the RFP document.
b) If Successful Bidder fails to fulfill its Conditions Precedent as specified in 2.4. c) If Successful Bidder fails to sign the PPA within the indicated time unless the
default from DOP as per Article 2.4.1.5.
3.16. CONSTRUCTION BANK GUARANTEES (C-
PBG)/PERFORMANCE SECURITY 3.16.1.1. The Successful Bidder shall furnish C-PBG/ Performance Security at rate
as detailed below or part thereof from a nationalized/ scheduled bank in the form
of Bank Guarantee as per prescribed Format 5 or Bank Draft / Banker's Cheque of
a scheduled bank. C-PBG Amount (Rs.)
C-PBG for Small
Scale Industries of
Rajasthan
C-PBG for other than Small Scale
Industries, whose cases are pending
with Board of Industrial and Financial
Reconstruction
17.50 Lacs per MW
Rs 4.375 Lacs per MW Rs 8.75 Lacs per MW
Performance security shall be solicited from all successful bidders except the
department's of the State Government and undertakings, corporations, autonomous
bodies, registered societies, co-operative societies which are owned or
controlled or managed by the State Government and undertakings of the Central
Government. However, a performance security declaration shall be taken from
them. 3.16.1.2. Submitted C-PBGs shall be valid till six (6) Months from the SCOD with a further
claim period of six (6) Months / (After the comple te ins tal la t ion of
so la r pana ls )Whicheve r i s la te r or required to be extended as deemed
necessary. The Successful Bidder shall furnish C-PBG within fifteen (15) Days
from the date of receipt of DOP Govt Secretariat response on change in PPA
Capacity and before the signing of PPA. Failure to submit C-PBG, as above,
without sufficient justification acceptable to the DOP Govt Secretariat, shall be
considered as refusal to execute the PPA and DOP Govt Secretariat shall have
right to forfeit the Bid Security. 3.16.1.3. DOP shall release C-PBG to Successful Bidder within three (3) Months from COD. 3.16.1.4. In case of delay in signing of PPA, of more than 60 days, from the submission of
C-PBG, DOP Govt Secretariat shall cancel the issued LoA and release the C-PBG
within fifteen (15) days from the cancellation of LoA.
3.16.1.5. Further, in case of delay in achieving/fulfilling any milestone as mentioned in COD
Schedule or as per Conditions Subsequent of PPA, C-PBG shall be forfeited. 3.16.1.6. In case, Power Producer fails to achieve the Completion of the Project within the
given timeline, DOP Govt Secretariat shall forfeit the BG. 3.17. LIQUIDATED DAMAGES:
In case of natural calamity or any reason beyond the control of Power Producer or
unavoidable circumstances, the work is not completed within the given timeframe,
DOP Govt Secretariat may consider grant of extension after the reason submitted by
Power Producer are found to be satisfactory. Delay in receipt of equipment of Solar
System like solar panel, PCU, etc. from the vendors, to whom the Bidder has placed
order, shall not be considered as a reason for extension. If the Power Producer fails to execute the work and Commission the project on or
before the SCOD, DOP Govt Secretariat shall have the right to impose penalty
equivalent to 5% of C-PBG value per week from the SCOD subject to maximum of
twenty (20) weeks delay. In case of delay beyond extended timeline of twenty (20)
weeks, DOP Govt Secretariat may cancel the PPA and Power Producer shall be liable
to pay Liquidated Damages to the DOP Govt Secretariat .
3.18. PERFORMANCE MONITORING MECHANISM The Power Producer shall demonstrate that the said project delivers Capacity
Utilization Factor (CUF) of at least 15%, adjusted for seasonality as tabulated
below, for one (1) day before declaration of successful Completion of the Project. Month kWh generation in 1 day per kWp system
January 3.36
February 3.52
March 4.28
April 4.14
May 4.05
June 3.71
July 3.21
August 3.28
September 3.48
October 3.66
November 3.48
December 2.88
For the purpose of measuring CUF:- Power Producer shall ensure that all Projects are Remote Monitoring System
(RMS) enabled. The data from such RMS enabled Projects would be monitored
or analyzed remotely by DOP Govt Secretariat , independently or at its Centralized
Monitoring Centre, to ensure desired level of performance. The Power Producer
shall ensure and shall have no objection to provide access to RMS for data
acquisition and monitoring the performance of Project(s) by DOP Govt Secretariat
The Power Producer shall support DOP Govt Secretariat in establishing technical
handshake between RMS and the Centralized Monitoring Centre being established by
DOP Govt Secretariat. The Power Producer shall ensure that the connectivity of the
Project with the Centralized Monitoring Centre of DOP Govt Secretariat is
uninterrupted at all times during O&M period and shall make all necessary
arrangements for the same. DOP Govt Secretariat or its authorized agency reserves
right to validate the authenticity of such data for which Power Producer
shall extend full access and its cooperation. 3.19. OPERATION AND MAINTENANCE:
During the course of twenty five (25) Operational Years, the Power Producer (s)
will service and maintain the system including replacement of the product, as per
Prudent Utility Practices. The Power Producer will have to arrange all required
instruments, tools, spares, components, manpower and other necessary facilities at
his own cost. It is advisable for the Bidder to ensure proper arrangements for
cleaning of panels (at least 16 cycles in a Year and Year must exclude June to
September period) in order to maintain the requisite performance expectations.
The power producer shall maintain the system in full working condition, if any
fault occurs then he will rectify the fault within specified time period.
1. Minor fault within 24 hrs.
2. Major fault within 3 days.
If fault will not rectified within specified time period then penalty will be imposed
on power producer.
1. For Minor fault Rs 50/- per hour after 24 hrs
2. For Major fault Rs 5000/- per day after 3 days.
Penalty will be recovered from the payment made to power producer for energy
charges/ performance guarantee.
During the course of twenty five (25) Operational Years, the Power Producer
Shall keep sufficient technical staff at solar control room for maintaining the
system during operational hours.
After successful completion of 10 years power producer will submit performance
bank guarantee / FDR (pledged in the name of JS DOP B) of Rs 10.00 lacs valid
for next 15 years within 15 days time.
sno Fault type Detail
1 Major fault Interruption in solar power supply. Fault in solar
invertor, main cable, switch gear etc.
2 Minor fault Fault in solar panel connecting cable, individual solar
panel, main cable termination, improper earthing.
Irregularity in service/maintenance work etc.
3.20. POWER PRODUCER’S DEFECT LIABILITY: If it shall appear to the DOP Govt Secretariat that any supplies have been executed
with unsound, imperfect or unskilled workmanship, or with materials of any inferior
quality, the Power Producer shall forthwith rectify or remove and replace that
item so specified and provide other proper and suitable materials at its own charge
and cost if so desired by DOP Govt Secretariat in writing. The Power Producer shall also be undertaking the operation and maintenance of
the project and consequently shall be required to rectify any defects that emerge
during the operation & maintenance of the Project for the entire term of the PPA.
3.21. RIGHT TO WITHDRAW THE RFP AND TO REJECT ANY BID:
This RFP may be withdrawn or cancelled by the DOP Govt Secretariat at any
time without assigning any reasons thereof. The DOP further reserves the right,
at its complete discretion, to reject any or all of the Bids without assigning any
reasons whatsoever and without incurring any liability on any account. The DOP Govt Secretariat reserve the right to interpret the Bid submitted by the
Bidder in accordance with the provisions of the RFP and make its own
judgment regarding the interpretation of the same. In this regard the DOP Govt
Secretariat shall have no liability towards any Bidder and no Bidder shall have any
recourse to the DOP Govt Secretariat with respect to the selection process. Bid(s) that are incomplete in any respect or those that are not consistent with the
requirements as specified in this RFP or those that do not adhere to formats
prescribed herein, wherever specified, may be considered non-responsive.
However, DOP Govt Secretariat reserves the right to seek additional information/
clarifications from the Bidders, if found necessary, during the course of
evaluation / processing of the Bid(s). Non-submission or delayed submission of
such additional information or clarifications sought by DOP Govt Secretariat may
be a ground for rejecting the Bid(s). Strict adherence to the documents required to be
submitted in Check List– I, as per Section VI shall be ensured, failure on this
account may lead to rejection of Bid. DOP reserves its right to vary, modify, revise, amend or change any of the terms
and conditions of the RFP before Bid Deadline. The decision regarding acceptance of
Bid by DOP Govt Secretariat will be full and final.
3.22. ZERO DEVIATION: This is a zero deviation bidding process. Bidder is to ensure compliance of all
provisions of the RFP and submit their Bid accordingly. Bid with any deviation to
the RFP conditions shall be liable for rejection without any explanation. 3.23. EXAMINATION OF BID DOCUMENT:
Before submission of Bid, Bidder is required to carefully examine the technical
specification, terms and conditions of RFP/ Agreement, and other details relating
to envisaged work as per the RFP. The Bidder shall be deemed to have examined the RFP and Agreement, to have
obtained information on all matters whatsoever that might affect the execution of
the Project activity and to have satisfied himself as to the adequacy of his Bid.
The Bidder shall be deemed to have known the full scope, nature and magnitude
of the work and related supplies and the requirements of material and labour
involved etc. and as to all supplies he has to complete in accordance with the
RFP. Bidder is advised to submit the Bid on the basis of conditions stipulated in the
RFP. Bidder‟s standard terms and conditions, if any for what-so-ever reasons, will
not be considered. The cancellation / alteration / amendment / modification in
RFP shall not be accepted by DOP Govt Secretariat and shall invite rejection of
such Bid. Bid not submitted as per the instructions to Bidder is liable to be
rejected. Bid shall confirm in all respects with requirements and conditions referred
in this RFP or its amendments, if any. The Comprehensive O&M of solar PV system shall include wear, tear,
overhauling, machine breakdown, appropriate insurance (if and as required), and
replacement of defective modules, invertors / Power Conditioning Unit (PCU),
spares, consumables, super GI structure & other parts for a period of twenty five
(25) Operational Years. 3.24. TAXES AND DUTIES:
The Financial Bid should include all taxes and duties etc., if any. Power Producer
shall be entirely responsible for all taxes, duties, license fees, etc. All taxes
payable shall be payable by the Power Producer. However, if any new change in
tax/duty and cess is effected in the period after the Bid Submission Deadline and
any time during the period of Agreement, the same will be passed on by the
Power Producer to the Dop as determined by the Competent Authority.
To evaluate impact of any change of laws in future, the rates applicable for each
component shall be considered in the ratio of:-
Material Component- 80% of the Benchmark
Erection, Installation and Commissioning (I&C) component- 20% of
The Benchmark Cost and
Yearly operational cost will be considered as 3% of the Benchmark
cost The Quoted Tariff would be adjusted as below based on the variations in the
capital cost and operational cost on account of change in taxes. Adjustment shall
be allowed only if the extent of variation in taxes is beyond the deviations
specified in table below:
Variation due to change in taxes
Proportionate adjustments to the tariff
Capital Cost (Adjustments will be considered
only if the change is more than
2.5%)
+ X% + 0.8 X%
- X% - 0.8 X%
Operational Cost (Adjustments will be made only if change is more
than 5%)
+ Y% + 0.1 Y%
- Y% - 0.1 Y%
3.25. SCHEDULE OF RATES FOR ADDITIONAL WORKS: The Rates of additional electrical work within the premises will be decided on the
basis of at par rates of Schedule Of Rates (SOR), for Electrical works, Public
Works Department (PWD), Jaipur, Govt. of Rajasthan amended from time to
time; The rates of additional civil work shall be as per at par the rates of Schedule Of
Rates (SOR) for building works, Public Works Department, (PWD), Jaipur, Govt.
of Rajasthan,, amended from time to time; 3.26. PROGRESS REPORT:
Power Producer shall have to commission the Project within Five (05)
Months from the date of issuance of LoA. The Power Producer shall submit
monthly progress report to DOP Govt Secretariat, in prescribed pro-forma to be
designed in discussion with Power Producer, for the period from signing of PPA
toCoD. DOP Govt Secretariat will have the right to depute his/their representatives
to ascertain the progress at the premises of work of the Power Producer. 3.27. FORCE MAJEURE:
For purpose of this RFP, force majeure shall mean an event beyond the control of
the Power Producer and not involving his fault or negligence and not foreseeable,
in its contractual capacity. Such events may include but are not restricted to Acts
of God, wars or revolutions, fires, floods, epidemics, quarantine restriction, fright
embargoes, site clearance, etc. Whether a force majeure situation exists or not,
shall be decided by DOP Govt Secretariat and its decision shall be final and
binding on the Power Producer and all other concerned. In the event that the Power Producer is not able to perform his obligations under
this Agreement on account of force majeure, he will be relieved of his obligations
during the force majeure period. If a force majeure situation arises, the Power Producer shall promptly notify
DOP Govt Secretariat in writing, not later than seven(7) Days from the date
such situation arises (in case, communication is not possible to DOP Govt Secretariat,
Power Producer shall notify DOP Govt Secretariat not later than one (1)Day from the
day when communication system will be restored). The Power Producer shall notify
DOP Govt Secretariat not later than three (3) Days of cessation of force majeure
conditions.
After examining the cases and associated facts, DOP Govt Secretariat shall decide
and grant suitable additional time for the completion of the work, if required. Failure of such Power Producer in timely intimating DOP Govt Secretariat will
suspend its right for any relief otherwise eligible under such force majeure
conditions. 3.28. APPLICABLE LAW:
The Agreement shall be interpreted in accordance with the laws of India. 3.29. SETTLEMENT OF DISPUTE:
If any dispute of any kind whatsoever arises between DOP Govt Secretariat and
the Power Producer / Successful Bidder in connection with or arising out of
the Agreement including without prejudice to the generality of the foregoing,
any question regarding the existence, validity or termination, the parties shall seek to
resolve any such dispute or difference by mutual consent. If the parties fail to resolve, such a dispute or difference by mutual consent,
within forty five (45) Days of its arising, then the dispute shall be referred by
either party by giving notice to the other party in writing of its intention to refer to
arbitration conducted under the provisions of the “The Arbitration and
Conciliation Act, 1996”. The decision of The Arbitration and Conciliation Act
shall be final and binding up on the parties. The language of the arbitration
proceedings and that of the documents and communications between the parties
shall be English. All the dispute will be settled in the High Court of Rajasthan. No
arbitration proceedings will commence unless such notice is given.
Notwithstanding any reference to the arbitration herein, the parties shall continue
to perform their respective obligations under the Agreement unless they otherwise
agree. Cost of arbitration shall be borne as per the award of the arbitration. 3.30. LANGUAGE:
All documents, drawings, instructions, design data, calculations, operation,
maintenance and safety manuals, reports, labels and any other data shall be in
Hindi/ English Language. The Agreement and all correspondence between the
DOP Govt Secretariat and the Bidder shall be in Hindi/ English language.
3.31. OTHER CONDITIONS: Power Producer has to obtain all the necessary approvals/Consents/Clearances
required for design, engineering, supply, installation, testing and commissioning
including Comprehensive O&M of the Project including connectivity to the
licensee‟s network. T he DOP will extend possible cooperation to Power
Producer in this regard. However, the Power Producer shall be solely responsible
for obtaining such approvals/consents/clearances.
The initial validity of Bid Security shall be for a period of One hundred and eighty
(180) Days from the Bid Deadline, which shall be extended by the Bidder on the
advice of DOP Govt Secretariat, if required, at any time before bid process is
concluded.
The Power Producer shall not transfer, assign or sublet the Project under the
Agreement pursuant to this RFP to any party other than lenders.
3.32. AMENDMENT: DOP reserves the right to modify, amend or supplement RFP documents including all
formats and annexures at any time. Interested and eligible Bidder are advised to
follow and keep track of DOP web-site for updated information. No
separate notifications will be issued for such notices/ amendments/
clarification etc. in the print media or individually. DOP Govt Secretariat shall not
be responsible and accountable for any consequences to any party. 3.33 SUCCESSORS AND ASSIGNS:
In case the Power Producer may undergo any merger or amalgamation or a
scheme of arrangement or similar re-organization and this PPA is assigned to any
entity partly or wholly, the PPA shall be binding mutatis mutandis upon the
successor, entities and shall continue to remain valid with respect to obligation of
the successor, entities. 3.34 SEVERABILITY:
It is stated that each paragraph, clause, sub-clause, schedule or annexure of this
contract shall be deemed severable, and, in the event of the unenforceability of
any paragraph, clause sub-clause, schedule or the remaining part of the paragraph,
clause, sub-clause, schedule annexure & rest of the contract shall continue to be in
full force and effect.
3.35 TAX EXEMPTIONS: DOPwill extend possible cooperation to Power Producer in availing any tax
exemptions. However, the responsibility of availing any such exemptions, if any,
would rest with the Power Producer. 3.36 FRAUD AND CORRUPTION
The Power Producers, suppliers and contractors and their sub-contractors under
the contracts are required to observe the highest standard of ethics during the
procurement and execution of such contracts. In pursuance of this, the DOP
Govt Secretariat :
I. Defines, for the purpose of this provision, the terms set forth below as follows:
(i) “corrupt practice” is the offering, giving, receiving or soliciting, directly
or indirectly, of anything of value to influence improperly the actions of
another party;
(ii) “fraudulent practice” is any act or omission, including a
misrepresentation, that knowingly or recklessly misleads or attempts to
mislead, a party to obtain a financial or other benefit or to avoid an
obligation;
(iii) “collusive practice” is an arrangement between two or more parties
designed to achieve an improper purpose, including to influence
improperly the actions of another party;
(iv) “coercive practice” is impairing or harming, or threatening to impair or
harm, directly or indirectly, any party or the property of the party to
influence improperly the actions of a party;
(v) “obstructive practice” is
aa) deliberately destroying, falsifying, altering or concealing of evidence material to the investigation or making false statements to
investigators in order to materially impede a DOP Govt Secretariat ‟s
investigation into allegations of a corrupt, fraudulent, coercive or
collusive practice; and/or threatening, harassing or intimidating any
party to prevent it from disclosing its knowledge of matters relevant
to the investigation or from pursuing the investigation;
or ab) acts intended to materially impede the exercise of the DOP Govt Secretariat inspection and audit rights.
II. will reject a proposal for award if it determines that the Bidder recommended
for award has, directly or through an agent, engaged in corrupt, fraudulent,
collusive, coercive or obstructive practices in competing for the contract in
question; III. will sanction a firm or individual, including declaring ineligible, either
indefinitely or for a stated period of time, to be awarded a contract if it at any
time determines that the firm has, directly or through an agent, engaged in
corrupt, fraudulent, collusive, coercive or obstructive practices in competing
for, or in executing, a contract; and IV. will have the right to require that the provision be included in Bidding
Documents and in contracts, requiring Bidders, suppliers, and contractors and
their sub-contractors to permit the DOP Govt Secretariat to inspect their
accounts and records and other documents relating to bid submission and
contract performance and to have them audited by auditors appointed by the
DOP Govt Secretariat .
3.37 DEBARRED FROM PARTICIPATING IN TENDER
DOP Govt Secretariat reserves the right to carry out the performance review of
each Bidder from the time of submission of Bid onwards. In case it is observed
that a Bidder has not fulfilled its obligations in meeting the various
timelines envisaged, in addition to the other provisions of the RFP, such Bidder
may be debarred from participating in DOP Govt Secretariat any future tender/
RFP for a period as decided by the competent authority of DOP Govt
Secretariat.
SECTION III: BID EVALUATION
4. BID EVALUATION: 4.1. THE EVALUATION PROCESS COMPRISES THE FOLLOWING FOUR
STEPS: Step I-Responsiveness check of Technical Bid
Step II-Evaluation of Bidder‟ fulfilment of Eligibility Criteria described in Section-II
Step III-Evaluation of Financial Bid
Step IV-Selection of Successful Bidder 4.2. RESPONSIVENESS CHECK OF TECHNICAL BID:
The Technical Bid uploaded by Bidder shall be scrutinized to establish
responsiveness to the requirements laid down in the RFP. Any of the following
may cause the Bid to be considered “Non-responsive” and liable to be rejected, at
the sole discretion of DOP Govt Secretariat , subject to sufficient justification: 4.2.1.1. Bid not uploaded in prescribed Check List format.
4.2.1.2. Bid that are incomplete, i.e. not accompanied by any of the applicable formats;
4.2.1.3. Bid not accompanied by contents of Check List as mentioned in Section VI.
4.2.1.4. Bid not signed by authorized signatory and /or stamped in the manner indicated
in this RFP;
4.2.1.5. Material inconsistencies in the information /documents submitted by the
Bidder affecting the Eligibility Criteria;
4.2.1.6. Information not uploaded in the formats specified in this RFP;
4.2.1.7. Bid being conditional in nature;
4.2.1.8. Bid not submitted by the Bid Deadline;
4.2.1.9. Bid having conflict of interest;
4.2.1.10. Bidder makes any misrepresentation;
4.2.1.11. Any other act of Bidder which may be unlawful for the purpose of this RFP.
4.2.1.12. Bid submitted is not in requisite format(s). 4.3 Each Bid shall be checked for compliance with the submission requirements set
forth in this RFP before the evaluation of Bidder‟s fulfilment of Eligibility
Criteria is taken up. 4.4. EVALUATION OF FINANCIAL BID:
Financial Bid of the Eligible Bidder shall be opened online in presence of the
representatives of such Eligible Bidder, who wish to be present, on date as may be
intimated by DOP Govt Secretariat to the Bidder through e-proc website. The
evaluation of Financial Bid shall be carried out based on the information
furnished. The Financial Bid submitted by the Bidder shall be scrutinized to
ensure conformity with the RFP. Any Bid not meeting any of the requirements
of this RFP may cause the Bid to be considered “Non-responsive”.
SECTION IV: SUCCESSFUL BIDDER(S) SELECTION
5. SUCCESSFUL BIDDER(S) SELECTION: 5.1. Bid qualifying as per Eligibility Criteria shall only be evaluated in this stage.
5.2. All Bidder qualifying Eligibility Criteria shall be placed as equal. Technical
qualification is must for a Bidder to become eligible for assessment on financial
criteria.
5.4. Eligible Bidders shall be ranked from the lowest to highest quote based on the Financial Bid submitted by the Bidders.
5.5. Eligible Bidder with lowest Quoted Tariff for given scope of work shall become
the Qualified Bidder.
5.6. In case where two or more Eligible Bidders bid the same Quoted Tariff, Eligible
Bidder with highest Net Worth shall be placed above the bidder having lower Net-
Worth in Ascending Order.
5.7. The LoA shall be issued by the DOP Govt Secretariat to the Successful Bidders.
5.8. If Successful Bidder fails to acknowledge the same, submit the C-PBG, the D O P
reserves the right to annul/cancel the LoA to Successful Bidder.
5.9. DOP at its own discretion, has the right to reject any or all the Bid without
assigning any reason whatsoever.
SECTION V: SCOPE OF WORK 6. DETAILS OF WORKS: 6.1. Designing, engineering, supply, installation, testing and Commissioning of various
capacities of Project as per standard design and specifications and connecting up to
existing Mains /ACDB and interfacing internal electrical loads of Project with
licensee’s network/electrical loads with Comprehensive O&M for period of twenty
five (25) Operational Years for Sale of Solar Power. Power Producer would have to
take approval for the interfacing the Project with Grid/Electrical Loads of every
location from distribution licensee/ CEIG, as applicable. Comprehensive O&M for
twenty five (25) Operational Year shall be required for each of the Project. Bidder shall be responsible for all the works related to Commissioning and
operation for twenty five (25) Operational Years of Project. In no case, DOP Govt
Secretariat shall be responsible to pay or increase in tariff for any work related to
Project. It is clarified that the projects awarded under this RFP would not include energy
storage with rooftop solar project. However, if DOP desires to have such arrangement,
it would need to pay separately for the battery storage, and associated change in design
and civil and electrical works. Such arrangement would not affect the tariff
discovered for sale of power under this RFP. 6.2. THE SCOPE OF WORK SHALL ALSO INCLUDE THE FOLLOWING:
A layout plan of the site should be submitted to the Inspecting Authority clearly
indicating the identified location for installation of SPV modules & control room,
where control panels shall be installed. The Power Producer shall also submit (a) The mode in which the system will operate is in accordance with the provisions of
Rajasthan Electricity Regulatory Commission (Connectivity and Net Metering for
Rooftop and Small Solar Grid Interactive Systems) Regulations 2015 issued by
RERC vide Notification Dated: 26-02-2015 as amended from time to time;
(b) Detailed planning of time bound smooth execution of Project;
(c) Performance testing of the Completion and Successful Commissioning of the
Project;
(d) Comprehensive O & M of the Project for twenty five (25) Operational Year
to assure faultless operation, and inventory maintenance;
(e) Supply of Power from Commissioning to Termination or for twenty five (25)
Operational Years;
(f) Coverage of risk liability of all personnel associated with implementation and
realization of the Project;
(g) The Power Producer shall maintain sufficient inventory of the spare parts to
ensure that the Project is functional during the term of PPA;
(h) The Power Producer shall done sun path analysis of the whole project and submit
the sun path analysis DOP in soft and hard copy for approval.
(i) The Power Producer is responsible for the waterproofing of the roof disturbed/
pierced for installation of Project for the Comprehensive O&M period of first 5 Operational Years. The Power Producer should immediately take necessary action to repair any damage to the water proofing. However, in such situations,
Power Producer shall bear any loss or damage to Project and rectify the same within reasonable time frame but any generation loss in such eventualities shall not be . If Power Producer fails to do required water proofing within 7 days from the day of identification of issue, DOP may get the same done at prevailing market rate and Power Producer shall reimburse the same to DOP. If the Power Producer fails to reimburse the expenses to the DOP then such expenses shall be adjusted by the DOP from the energy bills of the next months. Power Producer shall be responsible for O &M of the Project from the first Part
Commissioning or SCOD, whichever is earlier, to the completion of twenty five
(25) Operational Years.
(j) The solar plant on the North west parking shall be installed at roof top on super
structure not less that 8 feet in height as per site requirement. The cost of super
structure shall be included in the project, no extra payment shall be done for super
structure.
The solar structure on North West parking building should be designed in a way that
the vehicles parked on the roof are protected from exposure to water in rainy days and
sunlight. The power producer shall use fiber sheet below solar panel for water
protection.
Power Producer shall intimate the DOP the total weight of the solar system to be
installed at site for determining roof load bearing feasibility including the weight of
super structure.
6.3. INTERNAL ELECTRIFICATION: Inspection of the existing electrical network of each of the Project site;
Inspection of the Project in respect of its interfacing with licensee network/
identified electrical load;
Preparation and submission of electrical drawing for the site with quantity of
material required;
Obtaining prior approval of the work and drawing from Inspecting Authority;
Execution of the work in accordance with the norms and regulation directives for
testing and completion of the Project to the satisfaction of the DOP Govt Secretariat.
Solar plant will be installed on the following buildings:-
1. North west parking roof
2. SSO building roof.
3. Food building roof.
4. Minister block roof.
5. Archieve block roof.
6. Library block roof.
If solar plant capacity of 970 KWp will not fulfill on these area then Main building
roof will be used.
The Power Producer shall take care necessary precaution of already installed various
equipment on the roof for installing solar plant, If any damage to installed
equipment will be done by Power Producer then its cost will be recovered from
power producer.
The Power producer shall check incoming cable & switch gear size at the point of
solar plant connectivity, If incoming cable & switch gear size is not sufficient as per
solar plant capacity then power producer shall intimate the DOP for insufficient
size of the incomer cable & switch gear and DOP shall provide the suitable size
incomer cable & switch gear at site.
On the SSO building old unusable solar plant of 25 KW is already installed at
roof, power producer shall dismental old plant and deposit old material in
DOP before new installation.
In the CMO building 25 KW solar power plant is already working from last 3
years.
6.4. GRID CONNECTION: The Power Producer shall be responsible for synchronization of the Project with
licensee’s network under Rajasthan Electricity Regulatory Commission
(Connectivity and Net Metering for Rooftop and Small Solar Grid Interactive
Systems) Regulations 2015 issued by RERC vide Notification Dated: 26-02-2015
as amended from time to time.
6 . 5 METERING AND GRID CONNECTIVTY:
Metering and grid connectivity of the Projects would be the responsibility of the Power Producer in accordance with the prevailing guidelines of the concerned
distribution licensee and / or CEA and net metering provisions in the state of
Rajasthan. DOP Govt Secretariat may facilitate in the process; however t he entire
responsibility lies only with the Power Producer. The cost of required meters shall be
borne by Successful Bidder (Power Producer).This includes purchase of net meters under
Rajasthan Electricity Regulatory Commission(Connectivity and Net Metering forRooftop
and Small Solar Grid Interactive Systems) Regulations 2015 issued by RRECL vide
Notification Dated: 26-02-2015 as amended from time to time.
The Power Producer shall install the Generation Meter separately near the output of
Inverter and Net-Meter shall be located in place of present discom’s metering
system. There are two 33 KV HT connection in the secretariat, and the present
installed meters are leading power factor blocking meters, The Power Producer shall
install leading power factor blocking Net Meter for both the connections.
Meters and metering equipment shall be tested as per provision of RERC and as per
IS 14697 at CPRI or at any NABL accredited/distribution licensee lab before installation
at site on the cost of power producer and should be properly sealed in the presence of
designated authority from DOP at the time of installation.
The accuracy class, current rating and certifications of the net meter and
generation meter shall confirm with the standards for net meter and standards for
generation meter as provided by Rajasthan Electricity Regulatory Commission
(Connectivity and Net Metering for Rooftop and Small Solar Grid Interactive
Systems) Regulations 2015 issued by RERC vide Notification Dated: 26-02-2015 as
amended from time to time. 6.6. INSURANCE: The Power Producer shall also take insurance for third party liability covering loss
of human life, engineers and workmen and also covering the risks of damage, theft of
material/ equipment/ properties after completion of the work(s). Before commencement
of the work, the Power Producer shall ensure that all its employees and
representatives are covered by suitable insurance against any damage, loss, injury
or death arising out of the execution of the work. Liquidation, Death,
Bankruptcy etc., shall be the responsibility of Power Producer.
6.7. WARRANTY AND GUARANTEES: The Bidder shall warrant that the goods supplied under this Agreement are new, unused, of
the most recent or latest technology and incorporate all recent improvements in design and
materials as per standards specified in the technical specifications of this RFP.
The Power Producer shall provide warranty covering the rectification of any and all
defects in the design of equipment, materials and workmanship including spare parts for
a period of twenty five (25) Operational Years.
The responsibility of operation of warranty and guarantee clauses and claims/ settlement of
issues arising out of said clauses shall be responsibility of the Power Producer and DOP
will not be responsible in any way for any claims whatsoever on account of the above. 6.8. TYPE AND QUALITY OF MATERIALS AND WORKMANSHIP: The design, engineering, manufacture, supply, installation, testing,
commissioning and performance of the equipment shall be in accordance with
latest/ appropriate IEC/Indian Standards as detailed in the technical specifications of
this RFP or its subsequent amendments. Where appropriate Indian Standards and
Codes are not available, other suitable standards and codes as approved by the
MNRE/ CEA/ electricity regulators/ DOP Govt Secretariat shall be used. the
relevant test certifications must be kept valid up to one (1) Year from the COD of the
Project.
The specifications of the components should meet the technical specifications
mentioned in this RFP or its subsequent amendments.
Any supplies which have not been specifically mentioned in this RFP but which
are necessary during construction or Comprehensive O&M period of the Project
shall be provided by the Power Producer without any extra cost and within the
time schedule for efficient and smooth construction and Comprehensive O &M of
the Project.
6.9. CONSTRUCTION OF CONTROL ROOM ETC. Construction of control room or any other relative civil work essential for
Commissioning of Project; 6.10. ADDITIONAL WORKS
Any Additional civil, structural or electrical works required for completion of
installation of solar panel power plant will be in the scope of the bidder.
6.11. PROVISION OF SIGN BOARD Power Producer will have to provide sign board of dimension 6’x4’ s i ze (M.S.
sheet) of 16 gauge, o n M.S. angle o f s i z e 40x40x5 mm with essential
bracing & adequate grouting with PCC 1:3:6 i/c painting & writing) at each site
with complete specification & matter will be installed at site with PPA. 6.12. COMPLETION AND COMMISSIONING 6.12.1.1. Part Commissioning is allowed for all the Project.
6.12.1.2. Power Producer, in coordination with the Discom, shall submit Commissioning
certificate, issued by the concerned Discom, in accordance with all applicable
regulations/policies.
6.12.1.3. Further, DOP shall issue the Commissioning Certificate for the capacity of
the Project Completed on issuance of Completion Certificate for capacity.
6.12.1.4. In case of Part Commissioning, Power Producer shall be required to submit all
the above mentioned requisites with submission of every Part Commissioning of
capacity. For the purpose of obtaining Completion certificate following documents
shall be required: (a) Inspection Report of the Work(s) for all equipments/material
(b) CEIG Approval for the PPA Capacity or part thereof, if applicable;
In case of part Completion, Power Producer shall be required to submit all the
above mentioned requisites with request for every part capacity Completion.
SECTION VI: CHECKLIST
Checklist -I S.
NO Particular Format No. Copy Attch
1 Covering Letter 1 Yes / No
2 Cost of Tender Document (Non-Refundable) Yes / No
3 e-proc charges (Non-Refundable) - Yes / No
4 Bid Security (In Bank Guarantee/DD) along with documentary evidence in support of Exemption/ Concession
4 (in case of Bank Guarantee)
Yes / No
Checklist -II S.s
S.
Particular Format No. Copy Attch
1. Power of Attorney in favour of authorised signatory, on requisite value of stamp paper (Rs. 1000/-).
7 Yes / No
2. Board Resolution in support of power of attorney in favour of authorized signatory (applicable for companies)
- Yes / No
3. General Particulars 2 Yes / No
4. Bidder's composition and ownership structure (applicable for companies)
3 Yes / No
5. Declaration for Eligibili ty Criteria Requirement (Financial & Technical)
8A & 8B
Yes / No
6. Format For Certificate Of Relationship in case of Affiliate (if applicable)
9 Yes / No
7. Certificate of Incorporation - Yes / No
8. Undertaking Form 10 Yes / No
9. Consortium Agreement (If applicable) 12 Yes / No
10. Declaration 13 Yes / No
11. Board Resolution/power of attorney in favour of Lead Bidder (if applicable)
7 Yes / No
12. Compliance with Code of Integrity & No Conflict of Interest
14 Yes / No
13. Grievance Redressal Process 15 Yes / No
14. RFP Document Sealed and Signed along with the corrigenda and addenda (if any)
- Yes / No
15. Electrical inspector licence - Yes / No
SECTION VII: TECHNICAL PARAMETERS
The proposed Projects shall be completed as per the technical specifications given below.
The Bidder are hereby advised to take a note of the draft guidelines issued by MNRE dated
09-08-2016 or any amendments thereof in respect of minimum technical requirements,
quality standards, best practices and specifications for grid connected roof top PV systems in
addition to technical parameters mentioned in this RFP and comply accordingly. 8. PARAMETERS 8.1. A Project consists of SPV array, Module Mounting Structure, Power Conditioning
Unit (PCU) consisting of Maximum Power Point Tracker (MPPT), charge
controller (if required), Inverter, Controls & Protections, interconnect cables and
switchgear. PV Array should be mounted on a suitable super structure not
exceeding 4 feet from roof level as per site requirement. Project should be designed
with necessary features to synchronize with the grid power. Components and parts
used in the Project including the PV modules, metallic structures, cables, junction box,
switches, PCUs etc., should conform to the BIS or IEC or international
specifications, wherever such specifications are available and applicable. 8.2. PROJECT SHALL CONSIST OF FOLLOWING EQUIPMENT/ COMPONENTS:
8.2.1 Solar Photovoltaic Modules 8.2.1.1 The PV modules used should be Indian make or foreign make. However, the SPV
Modules supplied shall be meeting the requirements of MNRE OM No.
283/54/2018 GRID SOLAR dated 02.01.2019 in respect of Approved Makes and
Manufacturers.
8.2.1.2 The PV modules used must qualify to the latest edition of IEC PV module
qualification test or equivalent BIS standards Crystalline Silicon Solar Cell
Modules IEC 61215/IS14286. In addition, the modules must conform to IEC
61730 Part-1- requirements for construction & Part 2 – requirements for testing,
for safety qualification or equivalent IS.
8.2.1.3 For the PV modules to be used in a highly corrosive atmosphere throughout their
lifetime, they must qualify to IEC 61701/IS 61701.
8.2.1.4 The total solar PV array capacity should not be less than allocated capacity (kWp)
and should comprise of solar crystalline modules of minimum 370 Wp and above
wattage. Module capacity less than minimum 370 Wp should not be accepted.
8.2.1.5 Protective devices against surges at the PV module shall be provided. Low
voltage drop bypass diodes shall be provided.
8.2.1.6 PV modules must be tested and approved by one of the IEC authorized test centers.
8.2.1.7 The module frame shall be made of corrosion resistant materials, having Pre-
galvanized/ anodized Aluminium or superior material.
8.2.1.8 The Power Producer shall carefully design & accommodate requisite numbers of
the modules to achieve the rated power in his Bid.
8.2.1.9 Other general requirement for the PV modules and subsystems shall be the following: (a) The rated output power of any supplied module shall have tolerance of +
3% ( Only positive tolerance solar module is allowed).
(b) The peak-power point voltage and the peak -power point current of any supplied
module and/or any module string (series connected modules) shall not vary by more
than 2 (two) per cent from the respective arithmetic means for all modules and/or for
all module strings, as the case may be.
(c) The module shall be provided with a junction box with either provision of external
screw terminal connection or sealed type and with arrangement for provision of by-
pass diode. The box shall have hinged, weather proof lid
with captive screws and cable gland entry points or may be of sealed type and IP-
65 rated.
(d) I-V curves at STC should be provided by Power Producer. 8.2.1.10 Modules deployed must use a RF identification tag. The following
information must be mentioned in the RFID used on each modules This should be
inside laminate only.
(a) Name of the manufacturer of the PV module
(b) Name of the manufacturer of Solar Cells.
(c) Month & year of the manufacture (separate for solar cells and modules)
(d) Country of origin (for solar cells)
(e) I-V curve for the module Wattage, Im, Vm and FF for the module
(f) Unique Serial No and Model No of the module
(g) Date and year of obtaining IEC PV module qualification certificate.
(h) Name of the test lab issuing IEC certificate.
(i) Other relevant information on traceability of solar cells and module as per
ISO 9001 and ISO 14001
8.2.1.11 Warranties
a. Material Warranty (i) Material Warranty is defined as: The manufacturer should warrant the Solar
Module(s) to be free from the defects and/o r failures specified below for
a Period not less than 10 years from the date of sale to original customer.
(ii) Defects and/or failures due to manufacturing
(iii) Defects and/or failures due to quality of materials
(iv) Non conformity to specifications due to faulty manufacturing and/or
inspection processes. If the solar Module(s) fails to conform to this warranty,
the manufacturer will replace the solar module(s)
b. Performance Warranty
The predicted electrical degradation of power generated not exceeding 20% of the
minimum rated power over the twenty five (25)Year period and not more than
10% at the end of tenth (10th
) Year of the full rated original output. 8.2.2 Array Structure 8.2.2.1 Hot dip galvanized MS mounting structures may be used for mounting the
modules/ panels/arrays. Each structure should have angle of inclination as per the
site conditions to take maximum insulation. However to accommodate more
capacity the angle inclination may be reduced until the Project meets the specified
performance ratio requirements.
8.2.2.2 The Mounting structure shall be so designed to withstand the speed for the
wind zone of the location where a Project is proposed to be installed (for minimum
wind speed of 169.20 km/hour). Suitable fastening arrangement that do not
require drilling in rooftops should be adopted to secure the installation
against the specific wind speed.
8.2.2.3 The mounting structure steel shall be as per latest IS 2062: 1992 and
galvanization of the mounting structure shall be in compliance of latest IS 4759.
8.2.2.4 Structural material shall be corrosion resistant and electrolytically
compatible with the materials used in the module frame, its fasteners, nuts and
bolts. Aluminium structures also can be used, that can withstand the wind
speed of respective wind zone. Necessary protection towards rusting need to be
provided either by coating or anodization.
8.2.2.5 The structures shall be designed to allow easy replacement of any module. The
array structure shall be so designed that it will occupy minimum space without
sacrificing the output from the SPV panels.
8.2.2.6 Regarding civil structures the Power Producer need to take care of the load
bearing capacity of the roof and need arrange suitable structures based on
the quality of roof.
8.2.2.7 The structure should be supported by base plate of appropriate size and thickness
with suitable size civil masonary pedestal. But for North west parking fastner can
be used as per structural requirement & suitable arrangement shall be made by
o\power producer for water proffing.
8 . 2 .2 .8 The to ta l load of the s t ructure (when ins ta l led wi th PV
modules ) on the t e r race should be le ss than 60 kg pe r m2
8.2.2.8 The minimum clearance of the structure from the roof level should be
1 2 1 9 . 5 mm. (4 feets) 8.2.2.9 The solar plant on the North west parking shall be installed at roof top on
super structure not less that 8 feet in height as per site requirement. The cost
of super structure shall be included in the project, no extra payment shall be
done for super structure.
The solar structure on North West parking building should be designed in a
way that the vehicles parked on the roof are protected from exposure to water in
rainy days and sunlight. The power producer shall use fiber sheet below solar
panel for water protection.
8.2.3 Junction Boxes (JBS) Based on System Design Requirements 8.2.3.1 The junction boxes are to be provided in the PV array for termination of
connecting cables. The J. Boxes (JBs) shall be made of GRP/FRP/Powder Coated
Aluminium/cast aluminium alloy with full dust, water & vermin proof
arrangement. All wires/cables must be terminated through cable lugs. The JBs
shall be such that input & output termination can be made through suitable cable
glands.
8.2.3.2 Copper bus bars/terminal blocks housed in the junction box with suitable
termination threads Conforming to IP65 standard and IEC 62208 Hinged door
with EPDM rubber gasket to prevent water entry. Single / double compression
cable glands with provision of earthing. It should be placed at 5 feet or suitable
height for ease of accessibility.
8.2.3.3 Each Junction Box shall have High quality Suitable capacity Metal Oxide
Varistors (MOVs) / SPDs, suitable Reverse Blocking Diodes. The Junction Boxes
shall have suitable arrangement monitoring and disconnection for each of the
groups.
8.2.3.4 Suitable markings shall be provided on the bus bar for easy identification and the
cable ferrules must be fitted at the cable termination points for identification 8.2.4 DC Distribution Board Based on System Design Requirements 8.2.4.1 DC Distribution panel to receive the DC output from the array field.
8.2.4.2 DC DPBs shall have sheet from enclosure of dust & vermin proof conform to IP
65 protection. The bus bars are made of copper of desired size. Suitable capacity
MCBs/MCCB shall be provided for controlling the DC power output to the PCU
along with necessary surge arrestors. 8.2.5 AC Distribution Panel Board 8.2.5.1 AC Distribution Panel Board (DPB) shall control the AC power from PCU/
inverter, and should have necessary surge arrestors. Inter connection from ACDB
to mains at LT Bus bar while in grid tied mode.
8.2.5.2 All switches and the circuit breakers, connectors should conform to IEC 60947,
part I, II and III/ IS60947 part I, II and III.
8.2.5.3 The changeover switches, cabling work should be undertaken by the Power
Producer as part of the project.
8.2.5.4 All the Panels shall be metal clad, totally enclosed, rigid, floor mounted, air -
insulated, cubical type suitable for operation on three phase / single phase, 415
/230 volts, 50 Hz.
8.2.5.5 The panels shall be designed for minimum expected ambient temperature of 45
degree Celsius, 80 percent humidity and dusty weather.
8.2.5.6 All indoor panels will have protection of IP54 or better. All outdoor panels will
have protection of IP65 or better. Indoor or outdoor panel as per site requirement.
8.2.5.7 Should conform to Indian Electricity Act and rules (till last amendment).
8.2.5.8 All the 415 AC or 230 volts devices / equipment like bus support insulators,
circuit breakers, SPDs, VTs etc., mounted inside the switchgear shall be suitable
for continuous operation and satisfactory performance under the following
supply conditions:- Variation in supply voltage +/- 10 %
Variation in supply frequency +/- 3 Hz
8.2.6 PCU/Array Size Ratio a) The combined DC wattage of all inverters should not be less than rated
capacity of Project under STC.
b) Maximum power point tracker shall be integrated in the PCU/inverter to
maximize energy drawn from the array.
c) The DC AC ratio should not exceed 1.1:1 in order to avoid clipping losses
during peak generation month. 8.2.7 PCU/ Inverter
a) As SPV array produce direct current electricity, it is necessary to convert
this direct current into alternating current and adjust the voltage levels to
match the grid voltage. Conversion shall be achieved using an electronic
Inverter and the associated control and protection devices. All these
components of the Project are termed the “Power Conditioning Unit
(PCU)”. In addition, the PCU shall also house MPPT (Maximum Power
Point Tracker), an interface between Solar PV array & the Inverter, to the
PCU/inverter should also be DG set interactive. The PCU should also have
provision of charge controller in case of systems. If necessary Inverter
output should be compatible with the grid frequency.
Typical technical features of the inverter shall be as follows:
Switching devices: IGBT/MOSFET
Control : Microprocessor /DSP
Nominal AC output voltage and frequency: 415V, 3 Phase, 50 Hz (In case
single phase inverters are offered, suitable arrangement for balancing the
phases must be made.)
Output frequency: 50 Hz
Grid Frequency Synchronization range: + 3 Hz or more
Ambient temperature considered: -20o
C to 50o
C
Humidity: 95 % Non-condensing
Protection of Enclosure: IP-20(Minimum) for indoor: IP-65(Minimum) for
outdoor.
Grid Frequency Tolerance range: + 3 or more
Grid Voltage tolerance: - 20% & + 15 %
Inverter efficiency(minimum): > 93% ( In case of 10kWp or above )
Inverter efficiency (minimum ): > 90% (In case of less than 10 kWp)
THD: < 3%
PF: > 0.9
b) Three phase PCU/ inverter shall be used as required. c) PCU/inverter shall be capable of complete automatic operation including
wake-up, synchronization & shutdown.
d) The output of power factor of PCU inverter is suitable for all voltage ranges
or sink of reactive power; inverter should have internal protection
arrangement against any sustainable fault in feeder line and against the
lightning on feeder.
e) Built-in meter and data logger to monitor Project performance retrievable
through external computer shall be provided.
f) The power conditioning units/inverters should comply with applicable IEC/
equivalent BIS standard for efficiency measurements and environmental
tests as per standard codes IEC 61683/IS 61683 and IEC 60068-
2(1,2,14,30)/Equivalent BIS Std. g) The charge controller (if any) / MPPT units environmental testing should
qualify IEC 60068-2(1, 2, 14, 30)/Equivalent BIS standard. The junction
boxes/ enclosures should be IP 65(for outdoor)/ IP 54 (indoor) and as per
IEC 529 specifications.
h) The PCU/ inverters should be tested from the MNRE approved test
centres/NABL/BIS/IEC accredited testing-calibration laboratories. In case
of imported power conditioning units, these should be approved by
international test houses. 8.3 Integration Of PV Power With Grid 8.3.1 For better grid interaction and functioning of Project, the following
arrangement shall be ensured by Power Producer:
a) Project should have appropriate instruments installed at solar panel output,
inverter and load to facilitate minute-wise recording and storage of monthly
data (voltage, current, generation, consumption and grid injection) for
twelve (12) Months of energy flow at various nodes.
b) In case of network failure, or low or high voltage, Project shall go under
islanding mode but not be out of synchronization so far as its operation with
connected load is concerned. The supply from Project to the load points
would be resumed, once the DG set comes into service, Project shall again
be synchronized with DG supply and load requirement would be met to the
extent of availability of power. 4 pole isolation of inverter output with
respect to the grid / DG power connection need to be provided.
c) The Project commissioned under the Rajasthan Electricity Regulatory
Commission (Connectivity and Net Metering for Rooftop and Small Solar
Grid Interactive Systems) Regulations 2015 issued by RERC vide
Notification Dated: 26-02-2015 as amended from time to time, shall be
provided with reverse protection relays in order to prevent reverse flow of
active power into the Grid. The relay and devices used for such
arrangement shall be of relevant standards. 8.4 Data Acquisition System / Project Monitoring 8.4.1 Data Acquisition System shall be provided for each of the solar PV Project.
8.4.2 Data Logging Provision for Project control and monitoring, time and date
stamped system data logs for analysis computer for data monitoring, metering and
instrumentation for display of systems parameters and status indication to be
provided.
8.4.3 The following parameters should be accessible via the operating interface display
in real time separately for Project:
a) AC Voltage
b) AC Output current.
c) Output Power
d) Power factor
e) DC Input Voltage
f) DC Input Current
g) Time Active
h) Time disabled
i) Time Idle
j) Power produced
k) Protective function limits (Viz-AC Over voltage, AC Under voltage, Over
frequency, Under frequency ground fault, PV starting voltage, PV stopping
voltage.
8.4.4 All major parameters available on the digital bus and logging facility for energy
auditing through the internal microprocessor and read on the digital front panel at
any time) and logging facility (the current values, previous values for up to a Year
and the average values) should be made available for energy auditing through the
internal microprocessor and should be read on the digital front panel.
8.4.5 String and array DC Voltage, Current and Power, Inverter AC output voltage and
current (All 3 phases and lines), AC power (Active, Reactive and Apparent),
Power Factor and AC energy (All 3 phases and cumulative) and frequency shall
be monitored.
8.4.6 The data shall be recorded in a common work sheet chronologically date wise. The data file shall be MS Excel compatible. The data shall be represented in both
tabular and graphical form.
8.4.7 All instantaneous data should be available through RMS.
8.4.8 Software shall be provided for USB download and analysis of DC and AC
parametric data for individual Project.
8.4.9 Provision for Internet monitoring and download of data shall be necessarily
incorporated for projects.
8.4.10 Remote Monitoring and data acquisition through Remote Monitoring System
software with latest software/hardware configuration and service connectivity for
online / real time data monitoring/control complete to be supplied and
Comprehensive O&M/control to be ensured by the supplier. Provision for
interfacing these data on DOP server shall be made. 8.5 Transformer “If Required” & Metering 8.5.1 Dry/oil type appropriate kVA, of transformer Step up along with all protections,
switchgears, Vacuum circuit breakers, cables etc. along with required civil work.
8.5.2 The Power Producer must take approval/NOC from the concerned distribution
licensee for the connectivity, technical feasibility, and synchronization of Project
with distribution network and submit the same to DOPbefore Commissioning
Project.
8.5.3 Reverse power relay shall be provided by Power Producer (if necessary), as per the local distribution licensee‟s requirement.
8.6 Power Consumption Regarding the generated power consumption, priority needs to be given for
internal consumption first and thereafter any excess power can be exported to the
distribution licensee network. 8.7 Protections
The Project should be provided with all necessary protections like earthing,
Lightning, and grid islanding as follows: 8.7.1 Lightning Protection
The SPV power Project shall be provided with lightning & overvoltage protection
of appropriate size. The main aim in this protection shall be to reduce the over
voltage to a tolerable value before it reaches the PV or other sub system
components. The source of over voltage can be lightning, atmosphere
disturbances etc. The entire space occupying the SPV array shall be suitably
protected against Lightning by deploying required number of Lightning Arrestors.
Lightning protection should be provided as per IEC 62305 standard. The
protection against induced high-voltages shall be provided by the use of metal
oxide varistors (MOVs) and suitable earthing such that induced transients find an
alternate route to earth. 8.7.2 Surge Protection
Internal surge protection shall consist of three MOV type surge-arrestors
connected from +ve and –ve terminals to earth (via Y arrangement). 8.7.3 Earthing Protection
a) Each array structure of the PV yard should be grounded/ earthed properly as
per IS:3043-1987. In addition the lighting arrester/masts should also be
earthed inside the array field with separate earth electrode.
b) Earth resistance shall not be more than 5 ohms. It shall be ensured that all the
earthing points are bonded together to make them at the same potential. 8.7.4 Grid Islanding 8.7.4.1 In the event of a power failure on the electric grid, it is required that any
independent power-producing inverters attached to the grid turn off in a short
period of time. This prevents the DC-to-AC inverters from continuing to feed
power into small sections of the grid, known as “islands.” Powered islands
present a risk to workers who may expect the area to be unpowered, and they may
also damage grid-tied equipment. The Project shall be equipped with islanding
protection. In addition to disconnection from the grid (due to islanding protection)
disconnection due to under and over voltage conditions shall also be provided.
8.7.4.2 A manual disconnect 4pole isolation switch, besides automatic disconnection to
grid would have to be provided at utility end to isolate the grid connection by the
utility personnel to carry out any maintenance. This switch shall be locked by the
DOP. 8.8 Cables 8.8.1 Cables of appropriate size to be used in the Project shall have the following
characteristics:
a) Shall meet IEC 60227/IS 694, IEC 60502/IS1554 standards b) Temp. Range: –10℃
to +80℃.
c) Voltage rating 660/1100V d) Excellent resistance to heat, cold, water, oil, abrasion, UV radiation e) Flexible
f) Sizes of cables between array interconnections, array to junction boxes,
junction boxes to Inverter etc. shall be so selected to keep the voltage dr op
(power loss) of the entire Project to the minimum. The cables (as per IS) should be
insulated with a special grade PVC compound formulated for outdoor use.
g) Cable Routing/ Marking: All cable/wires are to be routed in a GI cable tray and
suitably tagged and marked with proper manner by good quality ferule or by other
means so that the cable easily identified.
h) The Cable should be so selected that it should be compatible up to the life of the
solar PV panels i.e. twenty five (25) Operational Years.
i) The ratings given are approximately, Power Producer to indicate size and length
as per system design requirement. All the cables required for the Project provided
by the Power Producer. All cable schedules/layout drawings approved prior
to installation.
j) Multi Strand, Annealed high conductivity copper/aluminium conductor PVC type
“A‟ pressure extruded insulation or XLPE insulation. Overall PVC/XLPE
insulation for UV protection Armored cable for underground laying. All cable trays
including covers to be provided. All cables conform to latest edition of IEC/
equivalent BIS Standards as specified below: BOS item / component Standard
Description Standard Number Cables General Test and Measuring Methods,
PVC/XLPE insulated cables for working
Voltage up to and including 1100 V ,UV resistant for outdoor installation IS
/IEC 69947.
k) The size of each type of DC cable selected shall be based on minimum voltage
drop.
l) The size of each type of AC cable selected shall be based on minimum voltage
drop however; the maximum drop shall be limited to 2 %.
m) All such external electrical works shall be required to be done as per
PWD BSR. 8.9 Connectivity
The maximum capacity for interconnection with the grid at a specific voltage level shall
be as specified in the Distribution Code/Supply Code of the State and amended from time to
time. Following criteria have to be followed for selection of voltage level in the distribution
licensee’s network for ready reference of the solar suppliers. The work should be done
in compliance with respective regulations and policy. 8.10 Tools & Tackles and Spares 8.10.1 The requirement of maintaining tools, tackles and spares at site or at service center is
left to the discretion of the bidder with a condition that the same would be made available
immediately as and when required.
8.10.2 The bidders are advice to ensure a response time of 24 hours and maximum expected
turnaround time of 72 hours (under special circumstances, additional time limit may be
considered).
8.10.3 Minimum requisite spares to be maintained by the Power Producer, in case of
PCU/inverter comprising of a set of control logic cards, IGBT driver cards etc. Junction Boxes,
fuses, MOVs / arrestors, MCCBs etc. along with spare set of PV modules be indicated, shall be
maintained at site or at nearest service centre for the entire period of Comprehensive O&M. 8.11 Danger Boards and Signages
Danger boards should be provided as and where necessary as per IE Act. /IE rules as
amended up to date. 8.12 Fire Extinguishers
The fire fighting system for the proposed Project for fire protection shall consist of portable
fire extinguishers in the control room for fire caused by electrical short circuits. The installation
of Fire Extinguishers should confirm to NBC guidelines, TAC regulations and BIS
standards. The fire extinguishers shall be provided in the control room housing PCUs as well as
the PV Array have been installed. 8.13 Drawings and Manuals 8.13.1 Two sets of Engineering, electrical drawings and Installation and Comprehensive O&M
manuals are to be supplied. Power Producer shall provide complete technical data
sheets for each equipment giving details of the specifications along with make/makes in
their bid with basic design of the Project and power evacuation, synchronization as
also protection equipment.
8.13.2 Approved ISI and reputed makes for equipment be used. 8.13.3 For complete electro-mechanical works, Power Producer shall supply complete design, details
and drawings to DOP. 8.14 Planning and Designing 8.14.1 The Power Producer should carry out Shadow Analysis at the site and accordingly design
strings & arrays layout considering optimal usage of space, material and labour. The Power
Producer should submit the array layout drawings along with Shadow Analysis Report to the
designated authority of DOP.
8.14.2 DOPreserves the right to modify the landscaping design, Layout and specification of sub-systems
and components at any stage as per local site conditions/requirements.
8.14.3 The Power Producer shall submit preliminary drawing for approval & based on any
modification or recommendation, if any. The Power Producer shall submit one sets and soft copy in
CD of final drawing for formal approval to proceed with construction work.
8.15 Safety Measures The Power Producer shall take entire responsibility for electrical safety of the
installation(s) including connectivity with the grid and follow all the safety rules
& regulations applicable as per Electricity Act, 2003 and CEA guidelines etc.
SECTION VIII: FINANCIAL BID FORMAT
Financial Bid
(To be submitted Online only in Cover-III)
Tender Inviting Authority: Joint Secretary, DOP (B) Govt Secretariat Name of Work: Design, Supply, Erection, Testing & Commissioning and Operation & Maintenance (O&M) of Grid Connected Rooftop Solar Power Projects of 970 KW capacity on Rajastahan Secretariat Buildings in Rajasthan under RESCO Mode.
Contract No: NIT No. TN- 05 /2019-20
Name of the Bidder/ Bidding Firm / Company :
PRICE SCHEDULE (DOMESTIC TENDERS - RATES ARE TO GIVEN IN RUPEES (INR) ONLY)
(This BOQ template must not be modified/replaced by the bidder and the same should be uploaded after filling the relevant columns, else the bidder is liable to be rejected for this tender. Bidders are allowed to enter the Bidder Name and Values only)
Sl. No. Item Description Fixed Tariff (Rs/kWh) Fixed Tariff (Rs/kWh) In Words
1 2 3 4
1
Design, Supply, Erection, Testing & Commissioning and Operation & Maintenance (O&M) of Grid Connected Rooftop Solar Power Projects of 970 KW
capacity on Rajastahan Secretariat Buildings in Rajasthan under RESCO Mode.
INR Only
Quoted Rate in Words INR Only
Note:
1. Quoted Fixed Tariff must be applicable for sale of Solar Power to DOP from Initial Part
Commissioning to twenty-five (25) Operational Years, Bidder to provide the Quoted Fixed
Tariff up to 4 decimal places.
2. Quoted Fixed Tariff shall remain fixed for twenty-five (25) Operational Years of the Project.
3. The above Quoted Fixed Tariff is inclusive of any applicable taxes. However, if any new
change in tax/duty is effected in the period after the Bid Deadline and any time during the
period of Agreement, the same will be passed on by the Power Producer to the DOP.
4. Further, for clarification, PPA shall be signed for individual Project but Quoted Fixed Tariff
shall remain the same for all Project. However, it shall be applicable in accordance with respective dates of COD.
This information should be filled on-line in Cover-III (.xls format) only on e-
procurement site as per procedure. If Quoted Fixed Tariff is submitted in Cover-
I and/or in Cover-II (technical bid) by any bidder, their offer will be summarily
rejected.
SEAL AND SIGN
AUTHORIZED SIGNATORY
SECTION IX: FORMATS FOR SUBMITTING RFP
FORMAT 1
COVERING LETTER (The covering letter should be on the Letter Head of the Bidder/ Lead Member of Consortium)
Ref.No. Date:
From:
Insert name and address of Bidder)
Tel.: Fax:_
E-mail address:
To: The Joint Secretary, DOP (B)
Address: Govt. Secretariat, Jan Path, C-Scheme, Jaipur, Rajasthan- 302001
Phone: 0141-2227700 / 2921921
e-mail: [email protected]
Sub: Request for Proposal (RFP) for Selection of Bidders for Implementation o f Roof Top
Solar PV Projects aggregating to about (in words) KWp under RESCO Mode at various
locations in the state of Rajasthan with RFP Specification No……………….
Dear Sir,
We, the undersigned [insert name of the Bidder] having read, examin ed and understood in detail the Request for Proposal (RFP) for Standardization of Rates for work of
Design, Engineering, Supply, Installation, Testing and Commissioning Including Comprehensive
Operation & Maintenance (for twenty five (25) Operational Years for Sale of Solar Power
aggregating to about (in words) KWp under RESCO Mode at various locations in the state of
Rajasthan, India., hereby submit our Bid comprising of Financial Bid and Technical Bid. We
confirm that neither we nor any of our Affiliate has submitted Bid other than this Bid directly or indirectly in response to the aforesaid RFP.
We give our unconditional acceptance to the RFP, dated and RFP attached
thereto, issued by Joint Secretary, DOP (B) Govt. Secretariat, as amended. As a token of our
acceptance to the RFP, the same have been initialled by us and enclosed to the Bid. We shall ensure that we execute such RFP as per the provisions of the RFP and provisions of such
RFP shall be binding on us.
Bid Security
We have enclosed Bid Security in form of DD/Bank Guarantee of amount as mentioned in this
RFP.
We have submitted our Financial Bid strictly as per this RFP, without any deviations, conditions and
without mentioning any assumptions or notes for the Financial Bid in the said format(s).
Acceptance
We hereby unconditionally and irrevocably agree and accept that the decision made by Rajasthan
Joint Secretary, DOP (B) Govt. Secretariat, in respect of any matter regarding or arising out
of the RFP shall be binding on us. We hereby expressly waive any and all claims in respect of Bid
process.
We confirm that there are no litigations or disputes against us, which materially affect our ability to
fulfil our obligations with regard to execution of projects of capacity offered.
Familiarity with Relevant Indian Laws & Regulations
We confirm that we have studied the provisions of the relevant Indian laws and regulations as required to enable us to submit this Bid and execute the RFP, in the event of our selection as Bidder.
We further undertake and agree that all such factors as mentioned in RFP have been fully examined and considered while submitting the Bid.
We undertake that we have satisfied ourselves with the site conditions of the projects and our
proposed financial bid takes into consideration the existing site conditions.
Contact Person
Details of the contact person are furnished as under:
Particulars Description
Name Designation
Company
Address
Phone Nos.
Fax Nos.
E-mail address
We are enclosing herewith the Check List-I (Covering letter, Cost of Tender document, e-proc
charges and Bid Security). Technical documents as per Check List–II containing duly signed formats, as desired in the RFP is uploaded Online on eproc website for your consideration.
It is confirmed that our Bid is consistent with all the requirements of submission as stated in the RFP
and subsequent communications from DOP Govt Secretariat. The information submitted in our
Bid is complete, strictly as per the requirements stipulated in the RFP and is co Govt. Sectt.t to the
best of our knowledge and understanding. We would be solely responsible for any errors or
omissions in our Bid. We confirm that all the terms and conditions of our Bid are valid for
acceptance for a period of one hundred and eighty (180) Days from Bid Deadline. We confirm that
we have not taken any deviation so as to be deemed non-responsive.
Dated the day of 2019
Thanking you,
We remain,
Yours faithfully,
Name, Designation and Signature of Authorized Perso n in whose name Power of
Attorney/ Board Resolution.
FORMAT 2
GENERAL PARTICULARS OF THE BIDDER
1 Name of the Company
2 Registered Office Address
3 E-mail
4 Web site
5
Authorized Contact Person(s) with name, designation, Address and Mobile Phone No., E-mail address/ Fax
No. to whom all references shall be made
6 Year of Incorporation
7 Have the Bidder/Company ever been debarred By any Govt. Dept. / undertaking for undertaking any work.
8 Reference of any documentation formation attached by the Bidder other than specified in the RFP.
9 Whether the Bidder wishes to form a Project Company for execution of work
Yes/No
10 Bidder is listed in India Yes/No
11 TIN No.
12 CST
13 GST No.
14 PAN No.
15 Service Tax (ST-2)
16 Certificate of Incorporation of Bidder/ Affiliate (as applicable) enclosed
Yes/No
17 Partnership deed or LLPF/ Sole Proprietor registration (as applicable) enclosed
Yes/No
_
(Signature of Authorized Signatory)
With Stamp
FORMAT 3
SHAREHOLDING CERTIFICATE
Name of the Equity
holder
Type and
Number of
shares owned
% of equity
holding
Extent of Voting
rights
(Signature of Authorized Signatory) With Stamp
(Signature of Company Secretary/Director/Chartered Accountant)
FORMAT 4
FORMAT FOR BANK GUARANTEE FOR BID SECURITY (To be on non-judicial stamp paper of INR 1000/-)
Ref.
Date:
_ Bank Guarantee No._
In consideration of the [Insert name of the Bidder] (hereinafter referred to as Bidder)
submitting the response to Request for Proposal (RFP) for Selection of Power Producer for
Implementation of Grid Connected Roof Top Solar PV Projects for Sale of Solar Power aggregating to
about (in words) KWp under RESCO Mode at various locations in the state of Rajasthan response to
the RFP No. Dated issued by Joint Secretar J.S. DOP (B) Govt. Secretariat, (hereinafter referre to as DOP Govt Secretariat ) and DOP Govt Secretariat considering such response to the RFP of
[insert the name of the Bidder] as per the terms of the RFP, the [insert name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to DOP at
[Insert Name of the Place from the address of DOP Govt Secretariat ] forthwith on
demand in writing from DOP Govt Secretariat or any Officer authorized by it in this behalf, any
amount upto and not exceeding Rupees
name of the Bidder]. [Insert amount] only, on behalf of M/s. [Insert
This guarantee shall be valid and binding on this Bank up to and including [insert date of validity in accordance with this RFP] and shall not be terminable by notice or any change in the constitution of the
Bank or the term of Agreement or by any other reasons whatsoever and our liability hereunder shall not
be impaired or discharged by any extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective Agreement.
Our liability under this Guarantee is restricted to Rupees (Rupees only). Our Guarantee shall remain in force until [insert date of Bid Validity Period in accordance with this
RFP.Only DOP Govt Secretariat shall be entitled to impose penalty equivalent to this Guarantee till
[Insert date which is 30 Days after the date in the preceding sentence].
The Guarantor Bank hereby agrees and acknowledges that only the DOP Govt Secretariat shall have a
right to impose penalty equivalent to this BANK GUARANTEE in part or in full, as it may deem fit.
The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the written
demand by DOP Govt Secretariat, made in any format, raised at the above mentioned address of the
Guarantor Bank, in order to make the said payment to DOP Govt Secretariat . The Guarantor Bank shall make payment hereunder on first demand without restriction or conditions and
notwithstanding any objection by [Insert name of the Bidder] and/or any other person. The Guarantor
Bank shall not require DOP Govt Secretariat to justify the invocation of this BANK GUARANTEE, nor
shall the Guarantor Bank have any recourse against DOPin respect of any payment made hereunder.
This BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts at
Jaipur shall have exclusive jurisdiction.
The Guarantor Bank represents that this BANK GUARANTEE has been established in such form and
with such content that it is fully enforceable in accordance with its terms as against the Guarantor Bank in the manner provided herein.
This BANK GUARANTEE shall not be affected in any manner by reason of merger, Amalgamation,
restructuring or any other change in the constitution of the Guarantor Bank.
This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly DOP
shall not be obliged before enforcing this BANK GUARANTEE to take any action in any court or
arbitral proceedings against the Bidder, to make any claim against or any demand on the Bidder or to give
any notice to the Bidder or to enforce any security held by DOP Govt Secretariat or to exercise, levy
or enforce any distress, diligence or other process against the Bidder.
Notwithstanding anything contained hereinabove, our liability under this Guarantee is restricted to
Rupees (Rupees only) and it shall remain in force until [Date to be inserted on
the basis of this RFP] with an additional claim period of thirty (30) Days thereafter. We are liable to pay
the guaranteed amount or any part thereof under this Bank Guarantee only if DOP Govt Secretariat serves upon us a written claim or demand.
Power of Attorney No.
For [Insert Name of the Bank]
Banker's Stamp and Full Address.
Dated this day of _, 20_
FORMAT 5
FORMAT FOR CONSTRUCTION PERFORMANCE BANK GUARANTEE (To be on non-judicial stamp paper of Minimum Rs. 1000/-)
In consideration of the [Insert name of the Bidder] (hereinafter referred to as (Bidder)
submitting the response to Request for Proposal (RFP) for Selection of Bidders for Implementation of
Grid Connected Roof Top Solar PV Projects for Sale of Solar Power aggregating to about KWp
under RESCO Mode at various locations in the state of Rajasthan in response to the RFP dated
issued by Joint Secretary, DOP (B) Govt. Secretariat, (hereinafter referred to as Nodal
Agency) and DOP Govt Secretariat considering such response to the RFP of
[insert
the name of the Power Producer] (which expression shall unless repugnant to the context or meaning thereof include its executers, administrators, successors and assignees) and selecting the Project of the
Power Producer and issuing LoA No. _to (Insert Name of Power
Producer) as per terms of RFP and the same having been accepted by the selected Project Company, M/s
applicable].
{a Special Purpose Vehicle (SPV) formed for this purpose}, if
As per the terms of the RFP, [insert name & address of bank] hereby agrees
unequivocally, irrevocably and unconditionally to pay to DOP at [Insert
Name of the Place from the address of the DOP] forthwith on demand in writing from DOP Govt
Secretariat , or any officer authorized by it in this behalf, any amount upto and not
exceeding
Rupees [Rupees _(Total Value in words)] only, on behalf of M/s [Insert name of the Power Producer / Project Company].
This guarantee shall be valid and binding on this Bank up to and including and shall not be terminable by notice or any change in the constitution of the Bank or the term of Agreement or by any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any
extension of time or variations or alternations made, given, or agreed with or without our knowledge or consent, by or between parties to the respective Agreement.
Our liability under this Guarantee is restricted to Rupees words)
_(both in numbers and
Our Guarantee shall remain in force until DOPshall be entitled to invoke this Guarantee
till _. The Guarantor Bank hereby agrees and acknowledges that DOP
shall have a right to invoke this BANK GUARANTEE in part or in full, as it may deem fit.
The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the
written demand by DOP Govt Secretariat, made in any format, raised at the above mentioned
address of the Guarantor Bank, in order to make the said payment to DOP Govt Secretariat .
The Guarantor Bank shall make payment hereunder on first demand without restriction or
conditions and notwithstanding any objection by [Insert name of the Power Producer. The
Guarantor Bank shall not require DOP Govt Secretariat to justify the invocation of this
BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against DOP Govt
Secretariat in respect of any payment made hereunder.
This BANK GUARANTEE shall be interpreted in accordance with the laws of India and the courts
at Jaipur shall have exclusive jurisdiction.
The Guarantor Bank represents that this BANK GUARANTEE has been established in such form
and with such content that it is fully enforceable in accordance with its terms as against the
Guarantor Bank in the manner provided herein.
This BANK GUARANTEE shall not be affected in any manner by reason of merger,
amalgamation, restructuring or any other change in the constitution of the Guarantor Bank.
This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank and accordingly
DOPshall not be obliged before enforcing this BANK GUARANTEE to take any action in any
court or arbitral proceedings against the selected Power Producer / Project Company, to make
any claim against or any demand on the Power Producer or to give any notice to the Power
Producer / Project Company or to enforce any security held by DOP Govt Secretariat or to exercise,
levy or enforce any distress, diligence or other process against the Power Producer / Project
Company.
Notwithstanding anything contained hereinabove, our liability under this Guarantee is
restricted to Rupees (Rupees only) and it shall remain in force until we are
liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only if D O P
Govt Secretariat serves upon us a written claim or demand.
Signature
Name
Power of Attorney No.
For
[Insert Name of the Bank]
Banker's Stamp and Full Address.
Dated this day of _, 20
Witness:
Signature
Name and Address
Signature
Name and Address
FORMAT 6
CHECK LIST FOR C-PBG
S. No. Details of checks YES/NO
1 Is the Bank Guarantee on non-judicial Stamp paper of appropriate value, as per applicable Stamp Act of the place of execution
2 Whether date, purpose of purchase of stamp paper and name of the purchaser are indicated on the back of Stamp paper under the Signature of Stamp vendor? (The date of purchase of stamp paper should be not later
than the date of execution of Bank Guarantee and the stamp paper should
be purchased either in the name of the executing Bank or the party on whose behalf the Bank Guarantee has been issued. Also the Stamp Paper
should not be older than six (6) Months from the date of execution of
Bank Guarantee).
3 Has the executing Officer of Bank Guarantee indicated his name, designation and Power of Attorney No./Signing Power no. on the Bank
Guarantee?
4 Is each page of Bank Guarantee duly signed / initialled by executant and whether stamp of Bank is affixed thereon? Whether the last page is signed
with full particulars including two witnesses under seal of Bank as
required in the prescribed Performa?
5 Does the Bank Guarantees compare verbatim with the Performa
prescribed in the Bid Documents?
6 Are the factual details such as Bid Document No. / Specification No., /
LOI No. (if applicable) / Amount of Bank Guarantee and Validity of Bank Guarantee coGovt. Sectt.tly mentioned in the Bank Guarantee
7 Whether overwriting/cutting if any on the Bank Guarantee have been
properly authenticated under signature & seal of executant?
FORMAT 7
POWER OF ATTORNEY (To be on non-judicial stamp paper of Minimum Rs. 1000/-)
Power of Attorney to be provided by the Bidder in favour of its representative as evidence of
authorized signatory‟s authority.
Know all men by these presents, We (name and address of the registered office of the Bidder as applicable) do hereby constitute, appoint and authorize Mr./Ms.
(name &residential address) who is presently employed with us and holding the position of
as our true and lawful attorney, to do in our name and on our behalf, all such acts,
deeds and things necessary in connection with or incidental to submission of our Bid for Selection of
Bidders for Implementation of Roof Top Solar PV Projects aggregating to about (in words) kWp
under RESCO Mode at various locations in the state of Rajasthan in response to the RFP
No………………. Dated: issued by DOP Govt Secretariat including signing and submission of the
Bid and all other documents related to the Bid, including but not limited to undertakings, letters,
certificates, acceptances, clarifications, guarantees or any other document which the DOP Govt
Secretariat may require us to submit.
The aforesaid Attorney is further authorized for making representations to the Joint Secretary,
DOP (B) Govt. Secretariat,and providing information / responses to DOP Govt Secretariat
representing us in all matters before DOP Govt Secretariat and generally dealing with DOP Govt
Secretariat in all matters in connection with Bid till the completion of the bidding process as per the
terms of the above mentioned in RFP.
We hereby agree to ratify all acts, deeds and things done by our said attorney pursuant to this Power of Attorney and that all acts, deeds and things done by our aforesaid attorney shall be binding on us and
shall always be deemed to have been done by us.
All the terms used herein but not defined shall have the meaning ascribed to such terms under the
RfP.
_
Signed by the within named
(Insert the name of the executants company)
through the hand of
Mr
duly authorized by the Board to issue such Power of Attorney
Dated this day of
Accepted
_
Signature of Attorney
(Name, designation and address of the Attorney)
Attested
_
(Signature of the executant)
(Name, designation and address of the executant)
_ _
Signature and stamp of Notary of the place of execution
Common seal of
Resolution dated
WITNESS
has been affixed in my/our presence pursuant to Board of Director‟s
(Signature)
Name
Designation
_
(Signature)
Name
Designation
FORMAT 8A
FINANCIAL ELIGIBILITY CRITERIA REQUIREMENT (To be submitted on the letterhead of Bidder/ Lead Member/ Member of Consortium)
To
------------------------------------ Jaipur
Dear Sir,
Sub: Selection of Bidders for Implementation of Grid Connected Roof Top Solar PV Projects for Sale
of Solar Power aggregating to about (in words) KWp under RESCO Mode at various locations in
the state of Rajasthan in response to the RFP No: …………. Dated: …………..
We submit our Bid for which details of our Financial Eligibility Criteria Requirements are as follows.
Net worth of Indian Rupees Lakh computed as per instructions provided in this RFP
based on unconsolidated audited annual accounts (refer Note-1 below). The relevant financial statement
for respective years shall be enclosed, duly signed by authorised signatory.
Name of
Entity being
evaluated
Financial
Year
Financial Criteria (fill as applicable) to be met as per Clause 3.6.2
Networth (INR Lakh)
Note:
The bidders shall declare in undertaking (Format-10) the criteria on which they fulfil the financial
eligibility as per the provisions of this RFP. Yours faithfully
(Signature and stamp of Authorized Signatory of Bidder)
Name: Date:
Place:
(Signature and stamp (on each page) of Chartered Accountant/Statutory Auditors of Bidder.
Name:
Date: Place:
Notes: Audited consolidated annual accounts of the Bidder may also be used for the purpose of financial
criteria provided the Bidder has at least 26% equity in each company whose accounts are merged in
the audited consolidated accounts and provided further that the financial capability of such companies (of which accounts are being merged in the consolidated accounts) shall not be considered again for
the purpose of evaluation of the Bid.
FORMAT 8B
TECHNICAL ELIGIBILITY CRITERIA REQUIREMENT (Please attach certificates in support from the concerned DOP Govt Secretariat /Government Organisation/SECI/ MNRE authorised Agency /Project owner for work executed)
S. No.
Details of
RTS Project installed till Bid Deadline
Commissioning date
Department/Agency
/Beneficiary for which work carried out
Total
kW size of
work
Cost of works in
{Amt in
Lakhs.}
A. Minimum Cumulative capacity of 1000 kWp
1
2
3
4
5
Total Capacity
B. Single Project of Minimum 250 kWp capacity
1
SIGNATURE and SEAL OF BIDDER
FORMAT 9
FORMAT FOR CERTIFICATE OF RELATIONSHIP OF AFFILIATE WITH THE
BIDDER To,
Dear Sir,
Sub: Request for Proposal (RFP) Selection of Bidders for Implementation of (in words) MWp Grid
Connected Roof Top Solar PV Systems for Sale of Solar Power under RESCO Mode at various
locations in the State of Rajasthan
We hereby certify that M/s ,M/s ,M/s _are the Affiliate(s) of
the Bidder as per the definition of Affiliate as provided in this RFP and based on details of equity
holding as on seven (7) Days prior to the Bid Deadline.
The details of equity holding of the Affiliate /Bidder or vice versa as on seven (7) Days prior to the Bid
Deadline are given as below:
a) In case of Bidder being Company/ LLP/ Partnership Firm/ Sole – Proprietor:
Name of Company/ LLP/
Partnership Firm/ Sole –
Proprietor
Name of the Affiliate Details of
Equity Holding of
OR b) In case of Bidder being Consortium
Name of Member of Consortium
Name of the Affiliate Details of Equity Holding
Yours Faithfully
(Insert Name and Signature of Statutory Auditor or practicing Company Secretary of the Bidder/
Member of Consortium)
FORMAT 10
UNDERTAKING FORM
Undertaking from Affiliate of Bidder/ Lead Member/ Member of Consortium
Name:
Full Address:
Telephone No.:
E-mail address:
Fax/No.:
To,
Dear Sir,
We refer to the RFP No: ………….. Dated:
Selection of Bidders for Implementation of
for Request for Proposal (RFP) for
(in words) KWp Grid Connected Roof Top
Solar PV Systems for Sale of Solar Power under RESCO Mode at various locations in the State
of Rajasthan.
We have carefully read and examined in detail the RFP regarding submission of an
undertaking, as per the prescribed Format at Annexure of the RFP.
We confirm that M/s (Insert name of Bidder) has been authorized by us to
use our financial capability for meeting the Financial Eligibility as specified in the RFP
referred to above in terms of Networth.
We have also noted the amount of the Performance Guarantees and Bid Security required
to be submitted as per the RFP by
event of it being selected as the Power Producer.
(Insert the name of the Bidder) in the
In view of the above, we hereby undertake to you and confirm that in the event of failure
of (Insert name of the Bidder) to submit the Performance Guarantees and Bid
Security in full or in part at any stage, as specified in the RFP, we shall submit the
Performance Guarantee and Bid Security not submitted by
the Bidder).
We also undertake that we shall maintain our ownership in M/s_
(Insert name of
(insert name
of bidder) at minimum 26% for period of one (1) Year from COD, subject to provisions of
Clause 3.3b). (in case of affiliate)
We have attached hereto certified true copy of the Board Resolution, whereby the Board of
Directors of our Company has approved issue of this Undertaking by the Company.
All the terms used herein but not defined, shall have the meaning as ascribed to the said
terms under the RFP.
Signature of Chief Executive Officer/Managing Director
Common seal of has been affixed in my/our presence pursuant to
Board of Director‟s Resolution dated
WITNESS
(Signature)
Name
Designation
(Signature)
Name
Designation
64
FORMAT 11
FORMAT FOR AGREEMENT
(To be submitted on non-judicial stamp paper of INR 1000/-) This agreement is signed on this ---- (day)------- of ----(month)---- of ----(year)------ at Jaipur between
M/s------------------------------------------------------------------------------------ (here-in-after called as
“Party No 1”), and Joint Secretary, DOP (B) Govt. Secretariat,, Jaipur (here-in-after called as
“Party No.2”), on the following terms and conditions:
That, the “Party No.1” has agreed to Execute Work as per Scope, Specifications and all terms and
conditions mentioned in the RFP No: ………. Dated: ………….issued by “Party No.2”.
That, the “Party No.1” has also agreed to execute work of Design, Engineering, Supply, Installation,
Testing and Commissioning, including Insurance, Warranty, Spare Parts and Operation & Maintenance of Grid Connected Roof Top Solar PV Projects for Sale of Solar Power under RESCO
mode as per scope of work, specifications and all terms and conditions mentioned in RFP No:
………….. Dated: ………. issued by “Party No.2”, on the rates already accepted / agreed upon as mentioned in the annexed “Financial Bid” sheet, on standardized rates.
That, the rates shown in the Financial Bid sheet(s) enclosed are valid up to - -20 .
That, all terms and conditions, scope of work and specifications mentioned in RFP No: ………..
Dated: ………. issued by “Party No.2”, which have been agreed upon and also the condition(s)
contained in the correspondence(s) made in this matter will also form part of this Agreement.
That all the terms and conditions of the Agreement for twenty five (25) Operational Years
Comprehensive O&M shall form part of this agreement.
That, in the event of any dispute or difference whatsoever arising under this Agreement, the same
shall be referred to arbitrator which shall be as per the provisions of the Indian Arbitration Act, 1996 and the Rule(s) there under. All the proceedings under arbitration will take place in Jaipur . The award
in such arbitration shall be final and binding on both the parties.
The agreement will be valid up to - -20 . The validity period may be extended further
with the Mutual Consent on unchanged Terms & Condition(s), Specification(s) and Rate(s) up to one
Year.
For, the matter(s) of any dispute between the “Party No.1” and “Party No.2” shall be subjected to
Jaipur jurisdiction.
That, this agreement executed between the parties who affix their signatures at Jaipur , in witness
whereof the parties hereto have signed the agreement:
Witnesses;
Party No.1
1. Party No.2
2.
66
FORMAT 12 FORMAT FOR CONSORTIUM AGREEMENT
Joint Bidding/ Consortium Agreement Format for Participation in “Request for Proposal (RFP) For
Selection of Bidder For Design, Engineering, Supply, Installation, Testing and Commissioning
Including Insurance, Warranty, Spare Parts and Operation &Maintenance of Grid Connected Roof
Top Solar PV Projects for Sale of Solar Power under RESCO mode At Various Locations in the State of Rajasthan
(To be executed on Stamp Paper of INR 1000/-)
THIS JOINT BIDDING AGREEMENT is entered into on this day of 2019.
BETWEEN { _, party on First Part of consortium} and having its registered
its registered office at (Hereinafter referred to as the “First Part” or
“Lead Member” which expression shall, unless repugnant to the context include its successors and permitted assigns)
AND
Having its registered office at
. (Hereinafter referred to as the “Second Part” or “Member” which expression shall, unless repugnant to the context include its successors and permitted assigns) The above mentioned parties of the First and Second Part are
collectively referred to as the “Parties” and each is individually referred as a “Party”
WHERE AS,
i. D e p a r t m e n t o f p e r s o n a l (hereinafter referred to as the “DOP” which expression
shall, unless repugnant to the context or meaning thereof, include its administrators, successors and
assigns) has invited applications (the “Applications”) by its RFP No: …………..
Dated: for award of the rate contract/ work under “Selection of Bidders for Design, Engineering, Supply, Installation, Testing and Commissioning Including Insurance, Warranty, Spare Parts and Operation &Maintenance of Grid Connected Roof Top Solar PV Projects for Sale of Solar
Power under RESCO mode at Various Locations in the State of Rajasthan (hereinafter called
“Project”) and Selection of Bidders for the same.
ii. The Parties are interested in jointly bidding for the Project as members of consortium in accordance
with the terms and conditions of the RFP document and other bid documents in respect of the Project,
and
iii. It is a necessary condition under the RFP document that the members of the Consortium shall enter
into a Consortium agreement and furnish a copy thereof with the Application.
NOW IT IS HEREBY AGREED as follows:
Definitions and Interpretations
In this agreement, the capitalized terms shall, unless the context otherwise require, have the Meaning
ascribed thereto under the above mentioned RFP.
1. Consortium The Parties do hereby irrevocably constitute a consortium (the “Consortium”) for the purposes of jointly participating in the Bidding Process. The Parties hereby undertake to participate in the Bidding
Process as per Table 1 of this RFP, only through this Consortium and not individually and/ or through
67 NIT No: TN-05/2019-20/SPV Roof Top/RESCO, Dated:05/09/2019
any other consortium constituted for this RFP, either directly or indirectly or through any of their
Affiliate(s).
2. Role of the Parties The Parties hereby undertake to perform the roles and responsibilities as described below:
a) The parties agree to submit bid as Consortium for Project.
b) Only First Part shall be evaluated for qualification against Financial eligibility criteria as per RFP.
c) First Part shall have the power of attorney from all Parties for conducting all business for and on
behalf of the Consortium during the Bidding Process and after its selection as Successful Bidder.
d) First Part would be responsible and obligated for successful execution of all work awarded to
them by Joint Secretary, DOP (B) Govt. Secretariat,and in no circumstances the same
shall be the responsibility of Second Part. Pursuant to selection of Successful Bidder as per criteria delineated in the RFP, all obligations as
per RFP shall be borne by the First Part.
e) Second Part shall work in accordance with roles and responsibilities assigned to them by First Part as a part of their internal understanding.
f) Parties have agreed and documented clearly stated roles and responsibilities between First Part
and Second Part for execution of work awarded by Joint Secretary, DOP (B) Govt. Secretariat,.
g) Subject to the terms of this agreement, the share of each Member of the Consortium in the “issued
equity share capital” shall be in the following proportion: (if applicable)
Name of Member Proposed % Equity holding
Lead Member ………………. (At least 50%)
Member
3. Termination
This Agreement shall be effective from the date hereof and shall continue in full force and effect until the date of validity period of Award and further in accordance with the LoA subsequently issued if
bid arrives as successful. However, in case the Consortium is either not pre-qualified for the Project or
does not get selected for Award of the work, the Agreement will stand terminated in case the Applicant is not pre-qualified.
4. Miscellaneous This Joint Bidding Agreement shall be governed by laws of India. The Parties acknowledge and accept that this Agreement shall not be amended by Parties without the prior written consent of the
GOVT. SECTT.. Party of First Part would decide on the representative of Consortium at Joint Secretary, DOP (B) Govt. Secretariat,.
IN WITNESS WHERE OF THE PARTIES ABOVE NAMED HAVE EXECUTED AND DELIVERED THIS AGREEMENT AS OF THE DATE FIRST ABOVE WRITTEN.
SIGNED, SEALED AND DELIVERED For
and on behalf of Lead Member by:
SIGNED, SEALED AND DELIVERED For
and on behalf of Second Part:
(Signature) (Signature)
(Name & Designation) (Name & Designation)
(Address) (Address) In Presence of : In Presence of : Witness -1 Witness -1
Witness -2 Witness -2
68NIT No: TN-05/2019-20/SPV Roof Top/RESCO, Dated:05/09/2019
FORMAT 13
DECLARATION (Required to be submitted by the Bidder on Original Letter Head of company)
We have carefully read and understood the enclosed Terms and Conditions of the RFP and
agree to abide by them. We declare that we are (please specify & tick mark the relevant point(s) and cross the others):
1. We declare that we have not been Black listed or otherwise for any Supply of Goods /
Services / Works by any Ministry / Department / PSU of Central Government / Any of
the State Government(s), anytime / anywhere in the Country Debarred or have failed to
execute any previous work .
2. We solemnly undertake that the responsibility of execution of the Work as per the terms
and conditions of the RFP/ Contract Agreement shall be entirely ours.
3. We declare that we have not taken any support from any of the independent Consultant or
Consulting Agency who is associated with DOP in any form while preparing RFP.
4. We under take as per tender clause 3.6.1 that “we or any our member of consortium has
not performed satisfactorily in the Work Order(s) of a n y go v t de pa r tm e n t , leading
to cancellation of Work Order(s) of value more than or equal to twenty five percent
(25%) of cumulative value of Work Order(s) awarded in last five (5) Years. And We or
any member of o u r consortium is involved in litigation or arbitration with a n y go vt
de pa r t me n t arising out of work completed or under execution by it, of value more than
or equal to twenty five percent (25%) of cumulative value of Work Order(s) awarded in
last five (5) Years.”
If this Declaration is found to be incorrect or if any RFP Condition is found violated by us,
then without prejudice to any other action our Bid Security may be forfeited in full and the
Proposal to the Extent of Acceptance / anytime during Execution of Assignment may be
cancelled.
(Signature of Authorized Signatory)
(Name & Designation in block letters)
FORMAT 14
COMPLIANCE WITH THE CODE OF INTEGRITY AND NO CONFLICT OF
INTEREST
Any person participating in a procurement process shall –
(a) Not offer any bribe, reward or gift or any material benefit either directly or indirectly
in exchange for an unfair advantage in procurement process or to otherwise influence
the procurement process;
(b) Not misrepresent or omit that misleads or attempts to mislead so as to obtain a
financial or other benefit or avoid an obligation;
(c) Not indulge in any collusion, Bid rigging or anti-competitive behaviour to impair the
transparency, fairness and progress of the procurement process;
(d) Not misuse any information shared between the procuring Entity and the Bidders with
an intent to gain unfair advantage in the procurement process;
(e) Not indulge in any coercion including impairing or harming or threatening to do the
same, directly or indirectly, to any party or to its property to influence the procurement
process;
(f) Not obstruct any investigation or audit of a procurement process;
(g) Disclose conflict of interest, if any; and
(h) Disclose any previous transgressions with any Entity in India or any other country
during the last three years or any debarment by any other procuring entity.
Conflict of Interest:-
Bidder participating in a bidding process must not have a Conflict of Interest. A Conflict of Interest is considered to be a situation in which a party has interests that could improperly
influence that party's performance of official duties or responsibilities, contractual
obligations, or compliance with applicable laws and regulations i.e. A Bidder may be
considered to be in Conflict of Interest with one or more parties in a bidding process if,
including but not limited to:
a. Have controlling partners/ shareholders in common; or
b. Receive or have received any direct or indirect subsidy from any of them; or
c. Have the same legal representative for purposes of the Bid; or
d. Have a relationship with each other, directly or through common third parties, that
puts them in a position to have access to information about or influence on the Bid of
another Bidder, or influence the decisions of the Procuring Entity regarding the
bidding process; or
e. The Bidder participates in more than 1(One) Biding a bidding process. Participation
by a Bidder in more than one Bid will result in the disqualification of all Bids in which
the Bidder is involved. However, this does not limit the inclusion of the same
subcontractor, not otherwise participating as a Bidder in more than one Bid; or
f. The Bidder or any of its affiliates participated as a consultant in the preparation of the
design or technical specifications of the Goods, Works or Services that are the subject
of the Bid; or
g. Bidder or any of its affiliates has been hired (or is proposed to be hired) by the
procuring entity as engineer-in-charge consultant for the contract.
SIGNATURE and SEAL OF BIDDER
69 NIT No: TN-05/2019-20/SPV Roof Top/RESCO, Dated:05/09/2019
FORMAT 15
GRIEVANCE REDRESSAL PROCESS The designation and address of the First Appellate Authority is the Joint Secretary, DOP (B)
Govt. Secretariat,, Jaipur. The designation and address of the Second Appellate Authority is the
Chairman, Joint Secretary, DOP (B) Govt. Secretariat,, Jaipur.
1) Filing an appeal
If any Bidder or prospective Bidder is aggrieved that any decision, action or omission
of the Procuring Entity is in contravention to the provisions of the Act or the Rules or
the Guidelines issued there under, he may file an appeal to First Appellate Authority,
as specified in the RFP within a period of 10 (Ten) days from the date of such decision
or action, omission, as the case may be, clearly giving the specific ground or grounds
on which he feels aggrieved:
Provided that after the declaration of a Bidder as successful the appeal may be filed
only by a Bidder who has participated in procurement proceedings:
Provided further that in case a Procuring Entity evaluates the Technical Bid(s) before
the opening of the Financial Bid(s), an appeal related to the matter of Financial Bid(s)
may be filed only by a Bidder whose Technical Bid is found to be acceptable.
2) The officer to whom an appeal is filed under para (1) shall deal with the appeal as
expeditiously as possible and shall endeavor to dispose it of within 30 (Thirty) days
from the date of the appeal.
3) If the officer designated under para (1) fails to dispose of the appeal filed within the
period specified in para (2), or if the Bidder or prospective Bidder or the Procuring
Entity is aggrieved by the order passed by the First Appellate Authority, the Bidder or
prospective Bidder or the Procuring Entity, as the case may be, may file a second
appeal to Second Appellate Authority specified in the RfP in this behalf within 15
(Fifteen)days from the expiry of the period specified in para (2) or of the date of
receipt of the order passed by the First Appellate Authority, as the case may be.
4) Appeal not to lie in certain cases
No appeal shall lie against any decision of the Procuring Entity relating to the following
matters, namely:-
(a) Determination of need of procurement;
(b)Provisions limiting participation of Bidders in the Bid process;
(c) The decision of whether or not to enter into negotiations;
(d)Cancellation of a procurement process;
(e) Applicability of the provisions of confidentiality.
5) Form of Appeal
a. An appeal under para (1) or (3) above shall be in the annexed form along with as
many copies as there are respondents in the appeal.
b. Every appeal shall be accompanied by an order appealed against, if any, affidavit
verifying the facts stated in the appeal and proof of payment of fee.
70 NIT No: TN-05/2019-20/SPV Roof Top/RESCO, Dated:05/09/2019
c. Every appeal may be presented to First Appellate Authority or Second Appellate
Authority, as the case may be, in person or through registered post or authorised
representative.
6) Fee for filing appeal
a. Fee for first appeal shall be Rs. 2,500 (Rupees Two Thousand Five Hundred) and for
second appeal shall be Rs.10,000 (Rupees Ten Thousand), which shall be non-
refundable
b. The fee shall be paid in the form of bank demand draft or banker's cheque of a
Scheduled Bank in India payable in the name of Appellate Authority concerned.
7) Procedure for disposal of appeal
a. The First Appellate Authority or Second Appellate Authority, as the case may be,
upon filing of appeal, shall issue notice accompanied by copy of appeal, affidavit and
documents, if any, to the respondents and fix date of hearing.
b. On the date fixed for hearing, the First Appellate Authority or Second Appellate
Authority, as the case may be, shall,-
i. hear all the parties to appeal present before him; and
ii. Peruse or inspect documents, relevant records or copies thereof relating to the
matter.
c. After hearing the parties, perusal or inspection of documents and relevant records or
copies thereof relating to the matter, the Appellate Authority concerned shall pass an
order in writing and provide the copy of order to the parties to appeal free of cost.
d. The order passed under sub-clause (c) above shall also be placed on the State Public
Procurement Portal.
SIGNATURE and SEAL OF BIDDER
71 NIT No: TN-05/2019-20/SPV Roof Top/RESCO, Dated:05/09/2019
ANNEXURE-I : PPA uploaded separately.
72 NIT No: TN-05/2019-20/SPV Roof Top/RESCO, Dated:05/09/2019
RESCO Power Purchase Agreement
RESCO
POWER PURCHASE AGREEMENT (PPA)
For
PROCUREMENT OF kWp SOLAR POWER ON LONG TERM BASIS
(Under RESCO Model)
Between
_ __ _ [Insert Name of Power
Producer] (Power
Producer)
And
(Procurer)
, 2020
RESCO Power Purchase Agreement
TABLE OF CONTENT
ARTICLE 1: DEFINITIONS AND INTERPRETATION ..................................................................... 5
ARTICLE 2: TERM OF PPA ............................................................................................................... 15
ARTICLE 3: CONDITION PRECEDENT........................................................................................... 16
ARTICLE 4: CONSTRUCTION AND INSTALLATION OF THE SYSTEM................................... 17
ARTICLE 5: SYNCHRONISATION, COMMISSIONING AND COMMERCIAL OPERATION ... 28
ARTICLE 6: DISPATCH ..................................................................................................................... 30
ARTICLE 7: METERING AND BILLING.......................................................................................... 31
ARTICLE 8: TARIFF AND PAYMENT ............................................................................................. 32
ARTICLE 9: INSURANCES................................................................................................................ 37
ARTICLE 10: FORCE MAJEURE ........................................................................................................ 38
ARTICLE 11: CHANGE IN LAW ......................................................................................................... 41
ARTICLE 12: EVENTS OF DEFAULT AND TERMINATION .......................................................... 43
ARTICLE 13: LIABILITY AND INDEMNIFICATION ...................................................................... 48
ARTICLE 14: GENERAL COVENANTS ............................................................................................. 50
ARTICLE 15: ASSIGNMENTS AND CHARGES................................................................................ 53
ARTICLE 16: GOVERNING LAW AND DISPUTE RESOLUTION .................................................. 54
ARTICLE 17: SUBSTITUTION RIGHTS OF LENDERS .................................................................... 56
ARTICLE 18: REPRESENTATIONS & WARRANTIES .................................................................... 62
ARTICLE 19: MISCELLANEOUS PROVISIONS ............................................................................... 64
SCHEDULE 1: SCOPE OF WORK ........................................................................................................... 69
SCHEDULE 2: TECHNICAL SPECIFICATIONS ................................................................................... 74
SCHEDULE 3: TARIFF SCHEDULE ....................................................................................................... 75
SCHEDULE 4: COD SCHEDULE ............................................................................................................ 76
ANNEXURE 1: LETTER FROM DOPCONFIRMING THE CAPACITY ............... 77
FORMAT-1: FULFILLMENT CERTIFICATE......................................................................................... 78
FORMAT 2: FORMAT FOR CONSTRUCTION PERFORMANCE BANK GUARANTEE ................. 79
RESCO Power Purchase Agreement
This Power Purchase Agreement is signed on the XXthDay of of 2020 at .
Between
[Insert name of the
Power Producer], a Company/Limited Liability Partnership (LLP) firm/ Partnership Firm/ Sole
Proprietor/ Consortium/Project Company in any form submitting the Bid incorporated under the
Appropriate Act /any other relevant lawsas applicable, having its registered office at
[Insert address of
the registered office of Power Producer] (hereinafter referred to as “Power Producer”, which
expression shall, unless repugnant to the context or meaning thereof, be deemed to include its
successors and permitted assigns) as a Party of the first part;
And
[Insert name of the Power
Procurer],having its registered office at
(hereinafter referred to as “Procurer”, which expression shall, unless repugnant
to the context or meaning thereof, be deemed to include its successors and assigns) as a Party of
the second part.
The Power Producer and Procurer are individually referred to as „Party‟ and collectively referred to
as „Parties‟.
Whereas:
A. DOP Govt. Secretariat has identified the Procurer for procuring the grid interactive rooftop
solar PV Project.
B. After meeting the eligibility requirements, the Power Producer has been selected by Nodal
Agency for development of solar power Project, generation and sale of solar energy.
C. The Power Producer has been notified by DOP Govt. Secretariat for “Design, engineering,
supply, installation, erection, testing &Commissioning along with Comprehensive
Operation and
Maintenance (O&M) of the Grid Connected Rooftop Solar Project for Sale of Solar Power
for a period of 25 Operational Years” and has been awarded kWp of capacity
in as per technical specification & other details of the RFP against NIT TN:05/2019-20
dated 05.09.2019 and this PPA.
D. Pursuant to the issuance of Letter of Allocation (LoA) by DOP Govt. Secretariat for signing
of PPA and other agreement, if any, the Power Producer has agreed to set-up solar PV
Project
based on Photo-voltaic technology of kWp capacity at the Premises of
RESCO Power Purchase Agreement
Procurer at .
E. The Power Producer is engaged in the business of building and operating power plants,
including grid interactive rooftop solar PV Project.
F. The Power Producer has agreed to sign this PPA with Procurer to sell solar power from the
Project to Procurer as per the terms and conditions of this PPA read in conjunction with
those of RFP.
G. Procurer has agreed to purchase such solar power from Power Producer for consumption
within Premise.
H. Procurer agrees to procure entire power from the Power Producer up to the PPA Capacity
at Fixed Tariff offered by Power Producer and finalized through the selection process as
per the terms of RFP.
I. The Parties, hereby, agree to execute this PPA setting outthe terms and conditions for the
sale of power by Power Producer to Procurer.
Now therefore, in consideration of the premises and mutual agreements, covenants and conditions
set forth herein, it is hereby agreed by and between the Parties as follows:
RESCO Power Purchase Agreement
ARTICLE 1: DEFINITIONS AND INTERPRETATION
1.1 Definitions
The terms used in this PPA, unless as defined below or repugnant to the context, shall have the
same meaning as assigned to them by the Electricity Act, 2003 and the rules or regulations framed
there under, including those issued / framed by the Appropriate Commission (as defined
hereunder), as amended or re-enacted from time to time.
“Act” or “Electricity Act,
2003”
shall mean the Electricity Act, 2003and include any amendments and
substitution from time to time;
“Agreement”
shall mean agreement executed thereof between Power Producer and
Procurer for power purchase, and permission for use of whole Premise
or part thereof and other related documents, including the schedules,
amendments, modification and supplements made in writing by the
parties from time to time;
“Affected Party”
shall have meaning as per ARTICLE 10:
"Appropriate
Commission"
shall mean the State Electricity Regulatory Commission referred to in
section 82 of the Electricity Act 2003 (as amended from time to time);
“Bid”
shall mean technical Bid or/ and Financial Bid submitted by a Bidder, in
response to RFP, in accordance with the terms and conditions of the
RFP;
“Bid Documents” or
“Bidding Documents”
means the RFP against NIT TN:05/2019-20 dated 05.09.2019 along
with all its attachments or/ and any amendments thereto or clarifications
thereof.
"Bill Dispute Notice"
shall mean the notice issued by a Party raising a Dispute regarding a
Monthly Bill or a Supplementary Bill issued by the other Party;
“Business Day”
shall mean with respect to Power Producer and Procurer, a Day other
than Sunday/ public holiday or a statutory holiday, on which the banks
remain open for business in Jaipur;
“Capacity Utilisation
Factor” or “CUF”
(CUF) in a Year shall mean the ratio of the output of the SPV Power
Plant in a Year versus installed Project capacity x 365 x 24.
(CUF = Cumulative Project output in kWh / (installed Project capacity
in kWp x 24 x 365));
However, for demonstration of successful Completion, CUF shall
mean the ratio of the output of the SPV Power Plant in a day versus
installed Project capacity x 1 x 24, adjusted to seasonality as per
provisions of Article4.9.
“CERC”
shall mean the Central Electricity Regulatory Commission of India,
constituted under sub – section (1) of Section 76 of the Electricity Act,
2003, or its successors;
“Change in Law”
shall have the meaning ascribed thereto in ARTICLE 11: of this PPA;
RESCO Power Purchase Agreement
“Completion”
As defined in Article5.2.2 of this PPA.
“Commissioning”
shall have the meaning ascribed in ARTICLE 5: of this PPA;
“Commercial Operation
Date” or “COD”
“Competent Authority”
shall mean the Day when full PPA Capacity of the Project is
commissioned;
shall mean Joint Secretary, DOP (B) Govt. Secretariat, Jaipur himself
and/or a person or group of persons nominated by him for the
“Competent Court of
Law”
shall mean any court or tribunal or any similar judicial or quasi-judicial
body in India that has jurisdiction to adjudicate upon issues relating to
this PPA;
“Consents, Clearances
and/ or Permits” or
“Consents”
shall mean all authorizations, licenses, approvals, registrations, permits,
waivers, privileges, acknowledgements, agreements, or concessions
required to be obtained from or provided by any concerned authority for
the purpose of setting up of the generation facilities and/ or supply of
power;
“Consumer(s)”
shall mean any person who is supplied electricity for his own use by a
licensee or the Government or by any other person engaged in the
business of supplying electricity to the public under the Act or any other
law for the time being in force and includes any person whose Premises
are, for the time being, connected for the purpose of receiving electricity
with the works of a Distribution Licensee, the Government or such other
person, as the case may be. Users who have merely wheeling/ supply
arrangements with the licensee are also covered as Consumers;
“Construction Period”
shall mean the period between the Effective Date and COD of full PPA
Capacity;
“Consultation Period”
shall mean the period of sixty (60) Days or such other longer/ shorter
period as the Parties may agree, commencing from the date of
issuance of a Power Producer Preliminary Default Notice or Procurer
Preliminary Default Notice as provided in ARTICLE 12: of this PPA, for
consultation between the Parties to mitigate the consequence of the
relevant event having regard to all the circumstances;
“Day(s)”
shall mean a 24 (twenty four) hour period beginning at 00:00 hours
Indian Standard Time and ending at 23:59:59 hours Indian Standard
Time;
“Delivery Point(s)”
shall mean such points, at such a location mutually agreed by the
parties, in line with applicable policy/ regulation/ rules, where solar
power is delivered by the Power Producer from the Project to the
Procurer, in such a way as to enable measurement of gross energy
generated by Project. Multiple Delivery Points are possible even in case
of a single Project;
“Deemed Generation”
shall mean energy (in units or kWh) deemed to have been generated per
day average from the Project in the same month of previous Year or, if
RESCO Power Purchase Agreement
the period of consideration is within the first twelve (12) Months of
Operation, the deemed generation per day will be equal to multiplication
of PPACapacity (kWp) and 4.10.2;wherein if the affected period between
6 am to 6 pm, it could be prorated for on hourly basis by considering 12
hours of operation;
“Designated Bank
Account”
Shall mean a bank account opened as stated by the lender which will be
used only for transactions related the assets funded by the lender.
“Discom” or “Discom(s)”
shall mean the local distribution utility providing electric distribution and
interconnection services to Procurer at the Premises of Procurer;
“Dispute”
shall mean any dispute or difference of any kind between Procurer and
the Power Producer, in connection with or arising out of this PPA
including but not limited to any issue on the interpretation and scope of
the terms of this PPA or/ and relevant provisions of RFP;
“DREO”
shall mean District Renewable Energy Officer, an authorized
representative of DOP;
"Due Date"
shall have the same meaning ascribed thereto in Articleb) of this PPA;
“Effective Date”
shall have the meaning ascribed thereto in Article2.1 of this PPA;
“Electricity Laws”
shall mean the Electricity Act, 2003 and the rules and regulations made
there under from time to time along with amendments thereto and
replacements thereof and any other Law pertaining to electricity
including regulations framed by the Appropriate Commission;
“Event of Default”
shall mean the events as defined in ARTICLE 12: of this PPA;
“Expiry Date” shall mean the 25th anniversary of the Scheduled Commercial
Operation Date of the Project for full PPA Capacity, considering the
extensions granted, if any, by DOP Govt. Secretariat;
“Financing Agreements”
shall mean the agreements pursuant to which the Power Producer has
sought financing for the Project including the loan agreements, security
documents, notes, indentures, security agreements, letters of credit and
other documents, as may be amended, modified, or replaced from time
to time, but without in anyway increasing the liabilities of Procurer;
“First Operational Year”
shall mean the period commencing from the Initial Part Commissioning
and expiring at the end of the Calendar Month in which Project
completes twelve (12) Monthsfrom the COD;
“Force Majeure” or
“Force Majeure Event”
shall have the meaning ascribed thereto in ARTICLE 10:of this PPA;
“Functional / Technical
Specifications”
means the technical requirements and parameters described in of this
Technical Specifications of PPA and as provided in Grid Code relating
to the operation, maintenance and dispatch of the Project;
“Grid Code” / ”IEGC” or
“State Grid Code”
shall mean the Grid Code specified by the CERC under Clause (h) of
Sub-section (1) of Section 79 of the Electricity Act, as amended from
RESCO Power Purchase Agreement
time to time, and/or the State Grid Code as specified by the concerned
State Commission, referred under Clause (h) of Subsection (1) of
Section 86 of the Electricity Act 2003, as applicable;
“Indian Governmental
Instrumentality”
shall mean the Government of India, Governments of state(s) of
Rajasthan and any ministry, department, board, authority, agency,
corporation, commission under the direct or indirect control of
Government of India or any of the above state Government(s) or both,
any political sub-division of any of them including any court or
Appropriate Commission(s) or tribunal or judicial or quasi-judicial body
in India;
“Initial Part
Commissioning”
shall mean the commissioning of first part capacity of PPA Capacity by
Power Producer, and shall include CoD if the entire project is
commissioned together;
“Insurances”
shall mean the insurance cover to be obtained and maintained by the
Power Producer in accordance with ARTICLE 9: of this PPA;
“Invoice” or “Bill”
shall mean either a Monthly Bill / Supplementary Bill or a Monthly
Invoice/ Supplementary Invoice raised by any of the Parties;
“Late Payment
Surcharge”
shall have the meaning ascribed thereto in Article8.5.1 of this PPA;
“Liquidated Damages or
LD”
shall mean the penalty levied on the Power Producer due to delay in
commencement of supply of solar power, from the SCOD or extended
SCOD in accordance with Article4.19to Procurer;
“Law”
shall mean in relation to this PPA, all laws including Electricity Laws in
force in India and any statute, ordinance, regulation, notification or
code, rule, or any interpretation of any of them by an Indian
Governmental Instrumentality and having force of law and shall further
include without limitation all applicable rules, regulations, orders,
notifications by an Indian Governmental Instrumentality pursuant to or
under any of them and shall include without limitation all rules,
regulations, decisions and orders of the Appropriate Commissions;
“Lenders”
means the banks, other financial institutions, multilateral agencies,
Reserve Bank of India registered non-banking financial companies,
mutual funds and agents or trustees of debenture / bond holders,
including their successors and assignees, who have agreed as on or
before COD of the grid interactive rooftop solar PV Project to provide
the Power Producer with the senior debt financing described in the
Capital Structure Schedule, and any successor banks or financial
institutions to whom their interests under the Financing Agreements
may be transferred or assigned:
Provided that, such assignment or transfer shall not relieve the Power
Producer of its obligations to Procurer under this PPA in any manner
and shall also does not lead to an increase in the liability of any of
RESCO Power Purchase Agreement
Procurer; “Letter of Credit” or “L C”
shall have the meaning ascribed thereto in Article8.8 of this PPA;
“LoA”
shall mean Letter of Allocation;
“Meters” or “Metering
System”
means meter(s) and metering devices owned by the Power Producer and
installed at the Delivery Point(s) for measuring and recording the delivery and
receipt of solar energy, as required by a Project as per RFP; “Metering Date”
means the first Business Day of each calendar month, subsequent to the
month in which the solar power is generated by Project, on which the Power
Producer takes joint meter reading with the Procurer. The billable units shall be
equal to the difference between the meter reading on the Metering Date and
the meter reading on the previous month‟s Metering Date; “Maintenance Outage”
shall have the meaning as ascribed to this term as per the provisions of the
Grid Code; "Month(s)"
shall mean a calendar month as per the Gregorian calendar;
“DOP” “Normative Project
Cost”
Designated Bank
Account”
shall mean Rajasthan Renewable Energy Corporation Ltd.; Benchmark Capex for 2020-21 notified by MNRE + Lower of (SOR cost, Actual
cost) for any additional work done. Shall mean a Bank Account as notified by Joint Secretary, DOP (B) Govt.
Secretariat, Jaipur which shall be used for transaction with parties under this RfP.
“Operational Year(s)”
shall mean the First Operational Year and thereafter each period of 12
(twelve) Months till the Expiry Date of PPA;
Part Commissioning
shall mean the Commissioning of capacity lower than the PPA capacity for the
purpose of receiving the Commissioning certificate for part capacity;
"Party" and "Parties"
shall have the meaning ascribed thereto in the recital to this PPA;
“Payment Security
Mechanism”
shall have the meaning ascribed thereto in Article8.8 of this PPA;
“Construction
Performance Bank
Guarantee” or “C-PBG”
Means the irrevocable, unconditional bank guarantee, to be submitted by the
Power Producer to DOP Govt. Secretariat in the form as mentioned in RFP
and which shall include any additional bank guarantee furnished by the
Power Producer under this PPA, if any;
"Performance Test "
means the test carried out in accordance with RFP;
"Power Purchase
Agreement" or "PPA"
shall mean this Power Purchase Agreement including its recitals and Schedules,
amended or modified from time to time in accordance with the terms hereof;
shall mean the capacity of kWp or the capacity as approved by the DOP Govt.
Secretariat as per Article 3.2.3 for implementation
of grid
“PPA Capacity”
shall mean the capacity of kWp or the capacity as approved by the
DOP Govt. Secretariat as per Article 3.2.3 for implementation
of grid
RESCO Power Purchase Agreement
connected roof top solar PV Projects for sale of solar power to Procurer
after undertaking a technical analysis of the likely capacity under the
PPA.;
“Preliminary Default
Notice”
shall have the meaning ascribed thereto in ARTICLE 12: of this PPA;
“Premise(s)”
shall mean any land, building or structure or part thereof or combination
thereof including any other vacant /non vacant area which is part of the
Procurer establishment;
“Power Purchase
Agreement” or “PPA”
shall mean this Power Purchase Agreement including its recitals and
Schedules, amended or modified from time to time in accordance with
the terms hereof;
“Procurer(s)‟”
shall mean the person or company or organization procuring solar
power from the Power Producer at competitively determined tariff for at
least 25 Operational Years;
“Project(s)”
means grid interactive rooftop solar PV project.
“Project Documents”
Mean
Power Purchase Agreement
Land Lease or Land Use Permission Agreement
Documents as required in RFP as well as RFP documents; and
any other agreements designated in writing as such, from time to time,
by Procurer and the Power Producer;
“Prudent Utility
Practices”
shall mean the practices, methods and standards that are generally
accepted internationally from time to time by electric utilities for the
purpose of ensuring the safe, efficient and economic design,
construction, commissioning, operation and maintenance of power
generation equipment and which practices, methods and standards
shall be adjusted as necessary, to take account of:
a) operation and maintenance guidelines recommended by the
manufacturers of the plant and equipment to be incorporated in the
Power station;
b) the requirements of Indian Law; and
c) the physical conditions at the site of the Project;
“Rebate”
shall have the same meaning as ascribed thereto in Article8.6 of this
PPA;
“RESCO MODEL”
shall mean where the Power Producer intend to use a Premise
owned/used by the Procurer and enters into the PPA with Procurer for
supply of Solar Power for 25 Operational Years at a fixed tariff
determined through mutual arrangement or competitive bidding;
“RFP”
shall mean Request For Proposal against NIT TN:05/2019-20 dated
05.09.2019, with all its terms and conditions along with all schedules,
Annexure and RFP Project Documents attached thereto, issued by
RESCO Power Purchase Agreement
DOP Govt. Secretariat and shall include any modifications, amendments or alterations thereto.
“Rupees” or “Rs”
shall mean Indian rupees, the lawful currency of India;
“Power Producer”
shall mean the Bidder selected pursuant to the RFP to set up the
Project and supply power there from to Procurer as per the terms of
PPA or/ and RFP;
“Scheduled Commercial
Operation Date” or
“SCOD”
shall mean twenty four months from Date of issuance of LoA by Nodal
Agency;
“Supplementary Bill” or
“Supplementary Invoice”
means a bill other than a Monthly Bill or Monthly Invoice raised by any
of the Parties in accordance with Article8.7;
“Tariff”/”Quoted Fixed
Tariff”
shall have the same meaning as provided for in ARTICLE 8: of this
PPA;
“Tariff Payment”
shall mean the payments to be made under Monthly Bills as referred to
in Article8.1.1 and the relevant Supplementary Bills in accordance with
the Article8.10;
“Termination Notice”
shall mean the notice given by either Parties for termination of this PPA
in accordance with ARTICLE 12: of this PPA;
“Term of PPA”
shall have the meaning ascribed thereto in ARTICLE 2: of this PPA;
“Total Debt Amount”
means the sum of the following amounts, expressed in Rupees (with all
amounts denominated in currencies other than Rupees being converted
to Rupees at the Reference Exchange Rate, the selling rate in Rupees
for the Foreign Currency on the relevant Day, as notified by the State
Bank of India as its TT Rate at 12:00 noon on the date of issuance of
Substitution Notice by the Lenders
(a) the principal amount of the senior debt incurred by the Power
Producer (as per the terms of the Financing agreements) to finance the
Project according to the Capital Structure Schedule which remains
outstanding on the date of issuance of Substitution Notice by the
Lender after taking account of any senior debt repayments which could
have been made out of the Monthly Tariff Payments received by the
Power Producer on or before the date of issuance of Substitution Notice
by the Lender as per the terms provided in the Financing agreements ;
and
(b) all accrued interest and financing fees payable under the Financing
agreements on the amounts referred to in (a) above from the date of
supply of power till the date preceding the date of issuance of
Substitution Notice by the Lender or, if supply of power has not yet
begun, from the most recent date when interest and financing fees were
capitalised, and
(c) if this PPA is terminated during the Construction Period, any
RESCO Power Purchase Agreement
amounts owed to the construction contractor for work performed but not
paid for under the construction contract (other than amounts falling due
by reason of the Power Producer‟s default);
Unavailability of Grid
shall mean any time when the grid is unavailable during solar
operational hours starting from 06:00 hrs to 18:00 hrs in a day shall be
considered as grid unavailability period;
“Week”
shall mean a calendar week commencing from 00:00 hours of Monday,
and ending at 24:00 hours of the following Sunday;
“Year”
shall mean 365 days or 366 days in case of leap year when February is
of 29 days;
RESCO Power Purchase Agreement
1.2 Interpretation
Save where the contrary is indicated, any reference in this PPA to:
1.2.1. “PPA" shall be construed as including a reference to its Schedules and/or Appendices
and/or Annexure;
1.2.2. An "Article", a "Recital", a "Schedule” and a “paragraph / clause" shall be construed as
a reference to an Article, a Recital, a Schedule and a paragraph/clause respectively of
this PPA;
1.2.3. An “affiliate” of any party shall mean a company that either directly or indirectly controls
or is controlled by or is under common control of the same person which controls the
concerned party; and control means ownership by one company of at least twenty six
percent (26%) of the voting rights of the other company;
1.2.4. A “Crore” means a reference to ten million (10,000,000) and a “Lakh” means a
reference to one tenth of a million (1,00,000);
1.2.5. An "encumbrance" shall be construed as a reference to a mortgage, charge, pledge,
lien or other encumbrance securing any obligation of any person or any other type of
preferential arrangement (including, without limitation, title transfer and retention
arrangements) having a similar effect;
1.2.6. “Indebtedness” shall be construed so as to include any obligation (whether incurred as
principal or surety) for the payment or repayment of money, whether present or future,
actual or contingent;
1.2.7. A "person" shall be construed as a reference to any person, firm, company,
corporation, society, trust, government, state or agency of a state or any association or
partnership (whether or not having separate legal personality) of two or more of the
above and a person shall be construed as including a reference to its successors,
permitted transferees and permitted assigns in accordance with their respective
interests;
1.2.8. "Rupee", "Rupees", “INR” or “Rs” shall denote Indian Rupees, the lawful currency of
India;
1.2.9. The "winding-up", "dissolution", "insolvency", or "reorganization" of a company or
corporation shall be construed so as to include any equivalent or analogous
proceedings under the Law of the jurisdiction in which such company or corporation is
incorporated or any jurisdiction in which such company or corporation carries on
business including the seeking of liquidation, winding-up, reorganization, dissolution,
arrangement, protection or relief of debtors;
1.2.10.Words importing the singular shall include the plural and vice versa;
1.2.11.This PPA itself or any other PPA or document shall be construed as a reference to this
or to such other PPA or document as it may have been, or may from time to time be,
amended, varied, novated, replaced or supplemented;
1.2.12.A Law shall be construed as a reference to such Law including its amendments or re-
RESCO Power Purchase Agreement
enactments from time to time;
1.2.13.A time of Day shall, save as otherwise provided in any PPA or document be construed
as a reference to Indian Standard Time;
1.2.14.Different parts of this PPA are to be taken as mutually explanatory and supplementary
to each other and if there is any inconsistency between or among the parts of this
PPA, they shall be interpreted in a harmonious manner so as to give effect to each
part;
1.2.15.The tables of contents and any headings or sub-headings in this PPA have been
inserted for ease of reference only and shall not affect the interpretation of this PPA;
1.2.16.All interest, if applicable and payable under this PPA, shall accrue from Day to Day
and be calculated on the basis of a year of three hundred and sixty five (365) Days;
1.2.17.The words “hereof” or “herein”, if and when used in this PPA shall mean a reference to
this PPA;
1.2.18.The terms “including” or “including without limitation” shall mean that any list of
examples following such term shall in no way restrict or limit the generality of the word
or provision in respect of which such examples are provided;
RESCO Power Purchase Agreement
ARTICLE 2: TERM OF PPA
2.1 Effective Date
2.1.1 This PPA up to Article 3 shall come into force from the date of execution of the PPA. Rest
of this PPA shall come into effect from the date of fulfilmentof Condition Precedent
mentioned in Article 3, which is also referred as the Effective Date.
2.2 Term of PPA
2.2.1 This PPA, subject to Article2.3 and 2.4, shall be valid for a term from the Effective Date
until the Expiry Date.
2.3 Early Termination
2.3.1 This PPA shall terminate before the Expiry Date:
a) if either Procurer or Power Producer terminates the PPA, pursuant to ARTICLE 12: of this
PPA; or
b) in such other circumstances as the Procurer may agree, in writing, in accordance with
Article 12.1 (Premature Termination).
2.4 Survival
2.4.1 Notwithstanding anything to the contrary herein, the expiry or termination of this PPA shall
not affect any accrued rights, obligations and liabilities of the Parties under this PPA,
including the right to receive penalty as per the terms of this PPA, nor shall it affect the
survival of any continuing obligations for which this PPA provides, either expressly or by
necessary implication, which are to survive after the Expiry Date or termination including
those under Article 4.3.1, ARTICLE 9: (Insurance), Liquidated Damages for delay in
commencement of supply of power to Procurers under Article4.19,ARTICLE 10: (Force
Majeure), ARTICLE 12: (Events of Default and Termination), ARTICLE 13: (Liability and
Indemnification), ARTICLE 16: (Governing Law and Dispute Resolution), ARTICLE 17:
(Miscellaneous Provisions), and other Articles and Schedules of this PPA which are
indispensable for survival or amicable settlement of events and transactions pursuant to
this PPA.
RESCO Power Purchase Agreement
ARTICLE 3: CONDITION PRECEDENT
3.1 Condition Precedent of the Procurer
3.1.1 Procurer shall allocate sufficient shadow free space in its Premise and provide last twelve
(12) Months of electricity bills (at least of six (6) Months), to the Power Producer. Procurer
shall allow Power Producer to visit the Premise for assessment of required space and
locating the proposed project. Minimum space provided by Procurer shall be based on 100
square feet per kWp.
3.1.2 Procurer should inform DOPand Power Producer, in writing, about the space provided for
Project implementation.
3.1.3 Within 10 days of approval by DOPconsequent to Article 3.2.2, Procurer shall confirm the
capacity and send a confirmation copy to DOPand Power Producer.
3.2 Condition Precedent of the Power Producer
3.2.1 Within 15days after providing access of premises by Procurer ,the Power Producer shall
undertake Site Survey, assess free capacity of the concerned DT, analyse last twelve (12)
Months of electricity bills (at least six (6) Months) received from Procurer, and submit the
Capacity (with due analysis) to GOVT. SECTT.L, copying Procurer..
3.2.2 DOPshall, within ten (10) Days of submission of letter of request for intimating the capacity
as per clause 3.2.1, approve to the Power Producer with a copy to the Procurer.
3.2.3 The DOPshall release a letter pursuant to clause 3.1.3 to the Power Producer within five
(5) days, with a copy to the Procurer confirming the capacity. This letter shall form an
integral part of the PPA and shall be annexed as Annexure-I of the PPA. The capacity
mentioned in Annexure –I shall than become the PPA capacity.
3.2.4 Consequent to Article 3.2.3, if there is any change in capacity, revised C-PBG shall be
submitted within 15 days of confirmation of the capacity by DOP. When DOP Govt.
Secretariat receives C-PBG of the needful value, it would be considered as the Day of
fulfilment of Conditions Precedent.
3.3 Consequences of non-fulfilment of conditions precedent
3.3.1 Unless any delay from Procurer in allocating space for the project, if the Power Producer
fails to complete the conditions precedents mentioned in Article 3.2 of the PPA, DOPmay
forfeit the C-PBG submitted by the Power Producer and the PPA may be terminated.
3.3.2 If the CPBG as per Article 3.2.4 is not submitted, the PPA shall stands cancelled.
3.3.3 Power Producer shall be entitled for a day to day extension for delay by Procurer pursuant
to Article 3.3.1. Any delay beyond thirty (30) Days in providing sufficient space to Power
Producer by the Procurer shall lead to termination of PPA and C-PBG for the project shall
be returned to the Power Producer.
3.3.4 In case of termination of PPA pursuant to Article 3.3.2, both the parties shall be relieved
from their responsibilities and no party shall be liable to make any payment to the other
party.
RESCO Power Purchase Agreement
ARTICLE 4: CONSTRUCTION AND INSTALLATION OF THE SYSTEM
4.1 Condition Subsequent of the Procurer
4.1.1 Procurer shall set up the payment security mechanism, in accordance with RFP, within
sixty (60)Days from the Effective Date;
4.2 Condition Subsequent of the Power Producer
4.2.1 Submit Project design and drawings to the Procurer within thirty (30)Days from the
Effective Date;.
4.2.2 Power Producer shall have sent a written notice, within thirty (30)Days from the Effective
Date, to Procurer and DOP indicating the major Milestones to achieve the SCOD (in the
format provided in SCHEDULE 4). Power Producer must mention the progress of Net-
Metering application, without failing, in every monthly progress report.
4.2.3 Successful Completion of Project; 4.2.4 The Power Producer shall furnish C-PBG within fifteen (15) Days from the date of sanction
of capacity by DOP Govt. Secretariat before the signing of PPA. Failure to submit C-
PBG, as above, without sufficient justification acceptable to the DOP, shall be considered
as refusal to execute the PPA and DOPshall have right to forfeit the Bid Security.
4.2.5 In case of delay in signing of PPA, of more than 60 days, from the submission of C-PBG,
DOPshall cancel the capacity sanctioned and release the C-PBG within fifteen (15) days
from the cancellation of capacity except if delay is because of Procurer or DOP Govt.
Secretariat.
4.2.6 Power Producer shall be accountable for submission of below mentioned details to
Procurer, copying DOP Govt. Secretariat, within sixty (60)Days from the Effective Date:
i. Copy of Net-Metering application and acknowledgement of Discom on successfully receipt
of application;
ii. Project layout/drawing;
iii. Bill of Material (BoM) along with requisite test reports and relevant certifications;
4.3 Consequences of non-fulfilment of conditions subsequent
4.3.1 In case of delay of the Power Producer to fulfil any one or more of the conditions specified
in Article4.12 due to any Force Majeure event, the time period for fulfilment of the
conditions subsequent by DOP/Procurer as mentioned in Article4.1, shall be appropriately
extended. Accordingly, any delay in the fulfilment of Conditions subsequent as mentioned
under Article4.12 by DOP/Procurer, shall also lead to appropriate extension in the time
period for fulfilment of the conditions subsequent by the Power Producer as mentioned in
Article4.2, especially the SCOD. In such cases, Power Producer must have sent a written
notice to Procurer and DOP indicating the timelines to complete the remaining major
Milestones along with extended SCOD, once Power Producer gets the appropriate
extension in Schedule COD.
4.3.2 Save for Article4.3.1, 4.4.1e) and 4.17, in case of a failure to meet the requirements
mentioned under Article4.2, the Procurer shall have right to terminate this PPA by giving a
notice to the Power Producer, with information to DOP, in writing only after fifteen (15) Days
of breach from the timelines provided in Article 4.2. The termination of the PPA shall take
effect upon the expiry of the 15th Day of the above notice. For the avoidance of doubt, it is
clarified that this Article shall survive the termination of this PPA. Further, C- PBG shall
be forfeited, in accordance with Article 4.8Error! Reference source not found., in case of
delay by Power Producer in fulfilling any of the conditions mentioned in 4.2.
4.4 Power Producer’s Obligations
4.4.1 The Power Producer undertakes to be responsible, at its own cost and risk, for:
a) all approvals including Consents required under local regulations, building codes and
approvals required from Discom(s) etc. relating to installation and operation of the Project
and generation and supply of solar power from the Project to Procurer and maintain the
RESCO Power Purchase Agreement
same in full force and effect during the Term of this PPA and Indian Law, as required and
relevant. Power Producer shall update SNA each month on the status of the approvals, In
case the Power Producer is facing any difficulties in obtaining any approval it can request
SNA for timeline extension for the same.
b) supply to Procurer promptly with copies of each application that it submits to relevant
authorities, and copy/ies of each Consent/ license which it obtains. For the avoidance of
doubt, it is clarified that the Power Producer shall be solely responsible for maintaining/
renewing any Consents and for fulfilling all conditions specified therein during the Term of
the PPA.
c) design, engineering, supply, erection, testing and Commissioning along with
Comprehensive Operation &Maintenance of the grid interactive rooftop solar PV Project
along with supply of power, with desired level of performance, for a period of twenty five
(25)Operational Years of Project in accordance with the applicable Law, the Grid Code and
the terms and conditions of this PPA and those prescribed in RFP.
d) providing a timely basis relevant information on Project specifications which may be
required for interconnecting Project with the Grid. However, any capital expenses incurred
towards grid connection of the Projects shall be borne by Procurer and shall be carried out
by Power Producer in accordance with technical requirement of relevant rules, regulations
and procedures.
e) save for Force Majeure events, commencing the supply of power for the PPA Capacity to
Procurer no later than the SCOD and continuance of the supply of power throughout the
Term of PPA.
f) operate and maintain the Project throughout the Term of PPA free and clear of
encumbrances, except those expressly permitted under ARTICLE 15:.
g) maintaining its controlling shareholding prevalent at the time of signing of PPA up to a
period of one (1)Operational Year after COD in accordance with the RfP.
h) fulfilling all obligations undertaken by the Power Producer under this PPA, read in
conjunction with terms and conditions of RFP; upon Termination, it shall be the
responsibility of the Power Producer to transfer the rooftop to Procurer free of all
encumbrances and at zero cost.
i) Upon Termination, it shall be the responsibility of the Power Producer to restore the rooftop
and clear all the surfaces at power producer‟s cost.
j) ensure operations of the solar power plant in a prudent utility basis with an objective of
regular power supply to Procurer.
k) submission of Project Manager name to Procurer and DOP, who will act as a
single point of contact for future communication.
l) submit a monthly progress report during Construction Period (from Effective Date to COD)
to DOP, copying Procurer, within first seven (7) days of the subsequent month.
4.5 Procurer’s Obligations
4.5.1 The Procurer shall be responsible to fulfil obligation undertaken by it, including those
required as facilitation for installation of Project at the Premises of Procurer, under this PPA
at its own cost and risk.
4.5.2 Provide access to Power Producer to the Premises for project COD and for regular
operation and maintenance of the Project.
Provide access to Project Lenders and Lenders Representatives during the tenor of the
loan facility. In cases, where the Procurer and Building Owner are different, then similar
undertaking for access to premises in favour of Lenders has to be provided by the Building
Owner.
RESCO Power Purchase Agreement
Procurer should not have any lien over the assets financed by Banks like solar modules,
inverters, etc. on the procurer‟s rooftop as those assets belong to the lenders financing the
project.
4.5.3 Regularly pay bills for power offtake as per the Monthly Bills submitted by the Power
Producer.
4.5.4 Pay the Termination Payment, if required, as per the terms of PPA
4.6 Bank Guarantees
4.6.1 Construction Performance Bank Guarantee (C-PBG)
4.6.1.1 The Power Producer shall furnish C-PBG at rate as detailed below or part thereof from a
nationalized/ scheduled bank in the form of Bank Guarantee as per prescribed FORMAT 2.
C-PBG Amount (Rs.)
C-PBG for Small Scale Industries of Rajasthan
C-PBG for other than Small Scale Industries, whose cases are pending
with Board of Industrial and Financial Reconstruction
Rs. 17.50 Lacs per MW
Rs. 4.375 Lacs per MW Rs. 8.75Lacs per MW
Performance security shall be solicited from all successful bidders except the
department's of the State Government and undertakings, corporations, autonomous
bodies, registered societies, co-operative societies which are owned or controlled or managed by the State Government and undertakings of the Central Government. However, a performance security declaration shall be taken from them.
4.6.1.2 Submitted C-PBGs shall be valid till twenty four (24) Months from the LoA with a further
claim period of six (6) Months, or required to be extended as deemed necessary. The
Power Producer shall furnish C-PBG within fifteen (15) Days from the date of sanction of
capacity by DOP Govt. Secretariat before the signing of PPA. Failure to submit C-
PBG, as above, without sufficient justification acceptable to the DOP, shall be
considered as refusal to execute the PPA and DOP Govt. Secretariat shall have right
to forfeit the Bid Security.
4.6.1.3 DOPshall release C-PBG to Power Producer within three (3) Months from
COD.
4.6.1.4 In case of delay in signing of PPA, of more than 60 days, from the submission of C-PBG,
DOP Govt. Secretariat shall cancel the issued LoA and release the C-PBG within
fifteen (15) days from the cancellation of LoA.
4.7 Power Producer's Construction Responsibilities
4.7.1 The Power Producer shall be responsible for design, engineering, supply, erection, testing
and Commissioning along with Comprehensive Operation & Maintenance of the grid
interactive rooftop solar PV Project, with desired level of performance, for a period of 25
Operational Years of the Project in accordance with the following, it being clearly
understood that in the event of inconsistency between two or more of the following, the
order of priority as between them shall be the order in which they are placed, with
„applicable law‟ being the first:
a. Applicable Law; b. the Grid Code;
c. the terms and conditions of this PPA; d. the Functional Specifications as per RFP;
and
e. Prudent Utility Practices.
4.7.2 Notwithstanding anything to the contrary contained in this PPA, the Power Producer shall
ensure that the technical parameters or equipment limits of the Project shall always be
subject to the requirements as specified in points Article4.7.1(a) to (e) above and under no
event shall over-ride or contradict the provisions of this PPA and shall not excuse the
Power Producer from the performance of his obligations under this PPA.
4.7.3 Construction, Installation, Testing and Commissioning of the Project
RESCO Power Purchase Agreement
a) The Power Producer will be responsible for design, engineering, supply, erection, testing
and Commissioning along with Comprehensive Operation &Maintenance of the grid
interactive rooftop solar PV Project, with desired level of performance, for a period of 25
Operational Years in accordance with this PPA/ RFP. The Power Producer shall provide to
the DOP, with a copy to Procurer, a bill of materials listing the major equipment
constituting the Project. Such bill of materials shall be provided within 30 Days of the COD.
b) The Power Producer shall have access to Premises, as reasonably permitted by the
Procurer, to perform the works related to Commissioning and O&M during the Term of PPA
at the Premises in a manner that minimizes inconvenience to and interference with the use
of the Premises to the extent commercially practical for the purpose of the Project.
c) The Power Producer shall provide and lay the dedicated electrical cables for delivery of
solar power from the Project up to the Delivery Point(s). Distribution of solar power beyond
this point will be responsibility of the Procurer in accordance with this PPA.
d) Unless otherwise agreed between the Parties, the Power Producer shall not do (a) chipping
of rooftop; or (b) disturb water proofing of roof (c) carry out any other modification of the
Premises without the written consent of the Procurer. One time cost for strengthening of
Premise to the extent required for setting up Solar PV Project during construction shall be
borne by Power Producer. Any delay due to strengthening of Premise shall not be
considered to extend the SCOD unless it is approved by Procurer in written. Cost of repair
or maintenance of Premise to the extent required for the Solar PV Project, during the
Comprehensive O &M of Project, shall be the responsibility of Power Producer, other than
cost required for water proofing. The cost for water proofing will be the responsibility of
Power Producer for a period of first three (3) Operational Years.
e) The Power Producer shall maintain general cleanliness of area around the Project during
construction and operation period, i.e.,Term of the PPA of the Project.In case any damages
is caused to the equipment / facilities owned by the Procurer due to the Power Producer,
the same shall be made good / rectified by the Power Producer at its risk and cost.
f) Subject to any punch-list items which shall be agreed by the Procurer as not being material
to Completion of the Project,the Power Producer agrees that it shall achieve the COD of
the Project within twenty four(24) Months from the date of issuance of LoA by DOP.
g) At the time of Commissioning, Procurer shall ensure that sufficient load is available at the
Delivery Point(s) to ensure synchronization and drawl of power from the Project.
h) If the Power Producer is unable to commence supply of solar power to the Procurer by the
SCOD, other than for the reasons specified in ARTICLE 10: or Article12.2 , the Power
Producer shall pay to DOPLiquidated Damages for the delay in such commencement of
supply of solar power as per the RFP and/or PPA.
i) Procurer, in coordination with Power Producer, shall ensure that all arrangements and
infrastructure for transmission or/ and distribution solar power beyond the Delivery Point(s)
are ready on or prior to the COD and is maintained in such state in accordance with
applicable laws through the Term of PPA.
4.8 Liquidated Damages 4.8.1 In case of natural calamity or any reason beyond the control of Power Producer or
unavoidable circumstances, the work is not completed within the given timeframe, DOPmay
consider grant of extension after the reason submitted by Power Producer are found to be
satisfactory, Delay in receipt of equipment of Solar System like solar panel, PCU, etc.
from the vendors, to whom the Bidder has placed order, shall not be considered as a
reason for extension.
4.8.2 If the Power Producer fails to Commission the project on or before the SCOD,
DOPshall have the right to impose penalty equivalent to 5% of C-PBG value per week from
the SCOD subject to maximum of twenty (20) weeks delay. In case of delay beyond
RESCO Power Purchase Agreement
extended timeline of twenty (20) weeks, DOPmay Cancel the PPA and Power Producer shall
be liable to pay Liquidated Damages to the DOP Govt. Secretariat, which DOP Govt.
Secretariat shall route to the procurer.
4.9 System Acceptance Testing
4.9.1 The Power Producer shall, in the presence of designated representatives of DOPand
Procurer, conduct testing of the Project, as prescribed in RFP, to establish successful
Commissioning of the Project.
4.9.2 The Power Producer shall demonstrate that the said project delivers Capacity Utilization
Factor (“CUF”) of at least 15%, adjusted for seasonality as tabulated below, for one (1) day
before declaration of successful Completion of the Project.
Month Wh generation in 1 day per kWp system
January 3.36
February 3.52
March 4.28
April 4.14
May 4.05
June 3.71
July 3.21
August 3.28
September 3.48
October 3.66
November 3.48
December 2.88
4.9.3 If the results of such testing indicate that the Project is capable of generating electrical
energy and Power Producer shall submit Commissioning certificate of the Project issued by
the concerned Discom, in accordance with the applicable rules/regulation/policies, as
prescribed in RFP, Power Producer shall send a written notice to DOP, with a copy to
Procurer, to that effect, and the date of successful conducting such tests and injection
of solar power at Delivery Point(s) shall be the “Commercial Operation Date” as certified
as per RFP and/or PPA.
4.10 Measuring CUF
4.10.1 Power Producer shall ensure that all Projects are Remote Monitoring System (“RMS”)
enabled. The data from such RMS enabled Projects would be monitored or analysed
remotely by DOP, independently or at its Centralized Monitoring Centre. The Power
Producer shall support DOP Govt. Secretariat or its authorised representatives in
establishing technical handshake between RMS and the Centralized Monitoring Centre.
The internal data logger of the RMS system shall work on store-and-forward mechanism. It
should be able to store data in case of connectivity outage and forward the stored data
once the connectivity is attained. The power producer shall ensure data for a minimum
period of one year is stored in the data logger. The RMS system must also be capable of
interfacing with external data loggers as may be installed by the DOPor its authorised
representatives at no extra cost. The Power Producer shall ensure that the connectivity of
the Project with the Centralized Monitoring Centre of DOP Govt. Secretariat is uninterrupted
at all times during O&M period and shall make all necessary arrangements
RESCO Power Purchase Agreement
for the same. In addition to the above, the Power Producer shall ensure and shall have no
objection to provide access to RMS and / or any other medium used to transfer data for
data acquisition and monitoring the performance of Project(s) by DOP Govt. Secretariat.
DOP or its authorized agency reserves right to validate the authenticity of such data for
which Power Producer shall extend full access and its cooperation.
4.10.2 Performance of RMS System - The system should have ability to send data on defined
internal time so that data should not be lost due to performance and load issue. The
information should be shared with trusted system only and should not be available to any
other unknown system. The Power Producer must ensure the availability and connectivity
of the RMS system to be at least 98%.
4.11 Project Operation & Maintenance (O&M)
4.11.1 Power Producer shall operate and maintain Project, with desired level of performance,
during the Term of PPA,read with terms and conditions of RFP,at its sole cost and
expenses; provided,that any repair or maintenance costs incurred by the Power Producer
as a result of Procurer‟s negligence or breach of its obligations hereunder, as certified by
DOP, shall be reimbursed in full by Procurer.The timelines for O&M would be 7
A.M. to 7 P.M. plus one hour during non-generation hours as mutually decided between
Procurer and the Power Producer.
4.11.2 Procurer shall not undertake any O&M activity related to Project. Power Producer shall
ensure that Project is adequately maintained and operated to serve the purpose envisaged
in PPA and RFP.
4.11.3 The Power Producer will have to arrange all required instruments,tools,spares, components,
manpower and other necessary facilities at his own cost. It is advisable for the Bidder to
ensure proper arrangements for cleaning of panels (at least 16 cycles in a Year and
Year must exclude June to September period) in order to maintain the requisite performance
expectations.
4.12 Power Producer’s Defect Liability
4.12.1 If it shall appear to the DOPthat any supplies have been executed with unsound, imperfect
or unskilled workmanship, or with materials of any inferior quality, the Power Producer shall
forthwith rectify or remove and replace that item so specified and provide other proper and
suitable materials at its own charge and cost if so desired by DOPin writing.
4.12.2 The Power Producer shall also be undertaking the operation and maintenance of the
project and consequently shall be required to rectify any defects that emerge during the
operation & maintenance of the Project for the entire term of the PPA.
4.13 Project Disruptions
4.13.1 Unavailability of Premises
a) If, for reasons other than the Power Producer‟s breach of its obligations under PPA/ RFP,
Power Producer is not provided with the access to the Premises as necessary to operate
and maintain the Project, such time period shall be excluded from the calculation of CUF.
b) If, for reasons other than the Power Producer‟s breach of its obligations under PPA/ RFP,
energy generation from Project is hampered significantly or stopped, such time period shall
be excluded from the calculation of CUF.
c) Period during which the grid is unavailable due to power cut or grid is unstable during
generation hours and in turn leading to lower generation, such hours shall be excluded for
the purpose of calculation of CUF.
d) Procurer shall continue to make all payments for the solar power during such period of
Project disruption other than ARTICLE 10: at same Tariff as applicable for the period of
Project disruption (“Disruption Period”). For the purpose of calculating solar power
payments and lost revenue for such Disruption Period, Deemed Generation shall be
RESCO Power Purchase Agreement
considered for calculation of lost revenue or payment obligation of Procurer. Loss in
revenue for the Disruption Period would be multiplication of Quoted Fixed Tariff and
difference in Deemed Generation and Actual Generation over such period. Power Producer
shall inform about the disruption or outage in Project, for reasons attributable to Procurer in
writing with date and time of such occurrence, and Procurer‟s liability shall start from the
date of intimation of disruption or outage in the rooftop system, on account of Procurer.
4.13.2 Roof repair and other Project disruptions
a) In the event that (i) the Procurer repairs the Premises‟ roof for any reason not directly
related to damage, if any, caused by the Project, and such repair requires the partial or
complete temporary disassembly or movement of Project, or (ii) any act or omission of
Procurer or Procurer‟s employees, affiliates, agents or subcontractors (collectively, a
“Procurer Act”) results in a disruption or outage in Project generation, and such events are
attributable to Procurer except Force Majeure, then, in either case, Procurer shall:
i. Pay the Power Producer such amount of money as prudently determined and agreed by
and between Power Producer and Procurer for all work required by the Power
Producer to disassemble or move or shifting the Project. The costing would be at mutually
decided rate or latest Schedule of Rates (SOR) published by concerned distribution
utilitywhichever is lower for similar works; and
ii. Continue to make all payments for the solar power during such period of Project
disruption at same Tariff as applicable for the period of Project disruption (“Disruption
Period”). For the purpose of calculating solar power payments and lost revenue for such
Disruption Period, Deemed Generation shall be considered for calculation of lost revenue or
payment obligation of Procurer. Loss in revenue for the Disruption Period would be
multiplication of Quoted Fixed Tariff and difference in Deemed Generation for number of days
such event occurs and Actual Generation.Power Producer shall inform about the disruption or
outage in Project, for reasons attributable to Procurer in writing with date and time of such
occurrence, and Procurer‟s liability shall start from the date of intimation of disruption or
outage in system production, on account of Procurer.
b) In the event that the Procurer fails to ensure adequate space for solar equipment to ensure
that other structures do not partially or wholly shade any part of the Project and if such
shading occurs, the Power Producer may apply for Deemed Generation furnishing the
calculation for loss in revenue due to such shading supported by the relevant data, which
shall be approved by Procurer within one month of submission, failing which the Power
Producer shall claim provisional Deemed Generation till the issue is finally settled.
Calculation for loss in revenuefor the period = (Deemed Generation X number of days such
event occurs - Actual generation) X Quoted Fixed Tariff.
c) The Power Producer is responsible for the waterproofing of the roof disturbed/ pierced for
installation of Project for the Comprehensive O &M period of first 3 Operational Years. The
Power Producer should immediately take necessary action to repair any damage to the
water proofing. However, in such situations, Power Producer shall bear any loss or damage
to Project and rectify the same within reasonable timeframe but any generation loss in such
eventualities shall not be passed on to Procurer. If Power Producer fails to do required
water proofing within 7 days from the day of identification of issue, Procurer may get the
same done at prevailing market rate and Power Producer shall reimburse the same to
Procurer. If the Power Producer fails to reimburse the expenses to the Procurer then such
expenses shall be adjusted by the Procurer from the energy bills of the next six (6) months.
4.14 Quality of Workmanship
4.14.1 The Power Producer shall ensure that the Project is designed, built and completed in a
good workman like manner using sound engineering construction practices and using only
RESCO Power Purchase Agreement
materials and equipment that are new and of international utility grade quality such that, the
useful life of the Project will be till the Expiry Date.
4.14.2 The Power Producer shall ensure that design, construction and testing of all equipment, facilities, components and systems of the Project shall be in accordance with Indian
Standards and Codes issued by Bureau of Indian Standards (BIS)/ International Electro
technical Commission (IEC).
4.15 Construction Documents
4.15.1 The Power Producer shall retain at the Premises, and make available for inspection to
Procurer at all reasonable times, copies of the results of all tests specified in Tariff Schedule hereof.
4.16 Delivery of Solar Power
4.16.1 Purchase Requirement
i. Procurer agrees to purchase one hundred percent (100%) of the solar energy generated by
the Project and made available by the Power Producer to Procurer at the Delivery Point(s) during each relevant month of the Term of PPA.
a) While calculating Minimum CUF, period of unavailability of Grid shall be excluded.
4.16.2 Suspension of Delivery
The Power Producer shall be entitled to suspend delivery of electricity from the Project to the
Delivery Point(s) for the purpose of maintaining and repairing the Project upon giving notice of at
least 3 days in advance to the Procurer, except in the case of emergency repairs. Such
suspension of service shall not constitute a breach of this PPA, provided that the Power Producer shall use commercially reasonable efforts to minimize any interruption in service to the Procurer. However, any preventive maintenance shall be done only during the period when Project is not generating.
4.16.3 Title to the Project
Throughout the duration of the PPA, the Power Producer shall be the legal and beneficial owner of the Project at all times, and the Project shall remain a property of the Power Producer and shall not attach to or be deemed a part of, or fixture to, the Premises. The title to the project will be
transferred to the Procurer at Termination of the PPA at the end of the Term (i.e after completion
of 25 Operational Years) within thirty (30) days. The title to be transferred to Procurer free of all encumbrances and at zero cost to the Procurer.
4.17 Extensions of Time
4.17.1 In the event that the Power Producer is prevented from performing its obligations under Article4.4 by the SCOD due to:
a. any Procurer Event of Default; or b. Force Majeure Events affecting Procurer; or c. Force Majeure Events affecting the Power Producer; or d. Power Producer, after successful Completion, shall not be able to achieve Commissioning
on or before SCOD due to delay on account of receipt of commissioning
approval/certificate from concerned Distribution Company.
The SCOD shall be deferred, subject to the limit prescribed in Article4.17.2, for a reasonable
period but not less than „Day for Day‟ basis, to permit the Power Producer or Procurer through the
use of due diligence, to overcome the effects of the Force Majeure Events affecting the Power Producer or Procurer, or till such time such Event of Default is rectified by Procurer.
4.17.2 Subject to Article4.17.6 and 4.17.7, in case of extension occurring due to reasons
specified in Article4.17.1a and d, any of the dates specified therein can be extended,
subject to the condition that the SCOD would not be extended by more than one hundred
and fifty (150) Days.
4.17.3 In case of extension due to reasons specified in Article4.17.1b and c, and if such Force
Majeure Event continues even after a maximum period of sixty (60) Days, any of the
Parties may choose to terminate the PPA as per the provisions of Article12.5. 4.17.4 If the Parties have not agreed, within fifteen (15) Days after the affected Party‟s
performance has ceased to be affected by the relevant circumstance, on the time period by
which the SCOD should be deferred by, any Party may raise the Dispute to be resolved in
accordance with ARTICLE 16:.
4.17.5 As a result of such extension, the SCOD newly determined shall be deemed to be the
RESCO Power Purchase Agreement
SCOD for the purposes of this PPA.
4.17.6 Notwithstanding anything to the contrary contained in this PPA, any extension of the SCOD
arising due to any reason envisaged in this PPA shall not be allowed beyondsix (6) Months
or the Date determined pursuant to Articles 4.17.2 or/ and 4.17.3, whichever is later.
4.17.7 For getting extension of time under Article4.17.1 d), Power Producer shall notify DOPand
Procurer, at least fifteen (15) days in advance of SCOD, and detailed out the probable
reasons for delay. Any delay on account of non-compliance of Power Producer, in
accordance with Policy and Regulation, in getting Commissioning approval/certificate, DOPshall levy a one-time penalty of INR 500 /kWp for full PPA Capacity.
4.18 Inspection/ Verification
4.18.1 The Power Producer shall be further required to provide entry to the Premises of the
Project free of all encumbrances at all times during the Term of PPA to Procurer and DOP.
The Lenders and Lender‟s Representatives shall be provided access to the Premises of the project by the Procurer/Building Owner (as the case may be) so as to enable Lenders to
conduct regular site inspection.
4.18.2 DOPshall be responsible for inspection and verification of the Project works being carried
out by the Power Producer at the Premises. If it is found that the construction works/ operation of the Project is not as per RFP/ PPA, it may seek clarifications from Power Producer or require the works to be stopped or to comply with the instructions of DOP.
4.19 Liquidated Damages for delay in commencement of supply of power to Procurer
4.19.1 If the Power Producer is unable to commence supply of solar power to Procurer by the
SCOD (including time extension approved by DOPand Procurer) for reasons other than
those specified in Article4.17.1, the Power Producer shall pay to DOP, Liquidated Damages
of a sum equivalent to 5% of C-PBG shall be levied per week of delay or part thereof, If delay is beyond 20 weeks, DOPmay Terminate the PPA and Power Producer is liable to pay
Liquidated Damaged to the DOP.
4.19.2 In case, DOPallows Power Producer to work with penalty at the said rate, COD shall be
done within 20 weeks from the SCOD. If COD shall not be achieved within granted
extension time period, DOPmay terminate the PPA. ARTICLE 5: SYNCHRONISATION, COMMISSIONING AND MMERCIAL OPERATION
5.1 Synchronization
5.1.1 The Power Producer shall give the concerned Discom, DOP Govt. Secretariat and Procurer
at least Thirty (30) Days advanced preliminary written notice and at least Fifteen (15) Days advanced final written notice, of the date on which it intends to synchronize the
Project.
5.1.2 Subject to Article5.1.1, the Project may be synchronized by the Power Producer when it meets all the connection conditions prescribed in applicable Grid Code then in effect and
otherwise meets all other Indian legal requirements for synchronization to the Grid. Prior to
synchronization of the Project, the Power Producer shall be required to get the Project certified for the requisite acceptance/ performance test as may be laid down by Central Electricity Authority or an agency identified by the central government / state government to
carry out testing and certification for the solar rooftop projects.
5.1.3 The synchronization equipment shall be installed by the Power Producer at its generation
facility of the Project at its own cost. The Power Producer shall synchronize its system with
the utility system only after the approval of synchronization scheme is granted by the
concerned Discom and checking/verification is made by the concerned authorities of the
Discom.
5.2 Completion, Commissioning and Commercial Operation
5.2.1 When the Power Producer fulfils his obligation under the PPA, it shall obtain completion
certificate from DOP Govt. Secretariat.
5.2.2 For the purpose of obtaining Completion certificate following documents shall be required.
5.2.2.1 Inspection Report of the Work(s) as per prescribed format provided by DOP.
5.2.2.2 CEIG Approval for the PPA Capacity, if applicable;
5.2.2.3 Project fulfilment certificate for the PPA Capacity (in accordance with FORMAT-1)
certified by DOP Govt. Secretariat and Procurer both.
RESCO Power Purchase Agreement
5.2.2.4 Document in support of performance of the Project and achievement of CUF of 15%
subject to seasonality as per provisions of RFP, as certified by the DOP Govt.
Secretariat. Separate performance report shall be submitted by Power Producer.
5.2.3 Full PPA Capacity of the Project shall be commissioned by SCOD.
5.2.4 Part Commissioning:
i. Part Commissioning of the Project shall be allowed;
ii. Power Producer shall need to comply with all the compliances and regulations to be
required and undertake the commissioning in accordance with RFP for Part Commissioning
as well;
5.2.5 The Power Producer shall undertake a commissioning in accordance with RFP, as soon as
reasonably practicable [and in no event later than two (2) weeks or such longer period as
mutually agreed between the Power Producer and Procurer after the point at which it is no
longer prevented from doing so by the effects of Force Majeure Events or Procurer‟s Event of Default (as appropriate and applicable)] and if such Commissioning of PPA Capacity is not duly completed on or before the SCOD, Power Producer shall be required topay Liquidated Damages to DOPin accordance with Article4.19.
5.2.6 Power Producer shall be required to get the Project certified for the desired performance
for Commissioning as laid down in RFP. Project shall be commissioned on the Day after the date when Procurer receives a final Commissioning certificate from the DOPin
accordance with prevalent policy and regulation along with relevant clauses mentioned in
RFP.Power Producer starts injecting power from the Project to the Delivery Point(s) from
the day of Initial Part Commissioning but only limited to Commissioned part of the PPA
Capacity.
5.2.7 The Power Producer expressly agrees that all costs incurred by it in synchronizing, connecting, Commissioning and/ or Testing a Project shall be solely and completely to its
account and Procurer‟s liability shall not exceed the amount of the Tariff payable for such power output or as per relevant Law applicable at the time.
5.2.8 The Parties shall comply with the provisions of the applicable Law including, in particular, Grid Code as amended from time to time regarding operation and maintenance of the
Project and all matters incidental thereto.
5.2.9 For clarification, Power Producer shall submit the commissioning certificate certified by Discom and DOPfor the capacity Commissioned.
ARTICLE 6: DISPATCH
6.1 Dispatch
6.1.1 The Project shall be required to maintain compliance to the applicable Grid Code
requirements and directions, if any, as specified by concerned SLDC/ RLDC from time to
time.
RESCO Power Purchase Agreement
ARTICLE 7: METERING AND BILLING
7.1 Metering
7.1.1 Metering and grid connectivity, of Project would be the responsibility of the Power Producer in accordance with the prevailing guidelines of the concerned DISCOM and / or CEA and
Rajasthan Electricity Regulatory Commission (Connectivity and Net Metering for Rooftop
and Small Solar Grid Interactive Systems) Regulations 2015 issued by RERC vide
Notification Dated: 26-02-20015and their amendments/ substitutions. DOP/ Procurer could
facilitate in the process; however the entire responsibility towards such arrangements lies
with Power Producer only. 7.1.2 the Power Producer shall install the Generation Meter separately near the output of Inverter
and Net-Meter shall be locatedin place of present discom‟s metering system. The accuracy class, current rating and certifications of the net meter and generation meter shall confirm with the standards for net meter and standards for generation meter as provided Rajasthan Electricity Regulatory Commission (Connectivity and Net Metering for Rooftop and Small Solar Grid Interactive Systems) Regulations 2015 issued by RERC vide Notification Dated: 26-02-2015 and any subsequent amendment.
7.1.3 The Metering System shall have such inbuilt provisions that it senses grid availability and
when grid is not available, isolates project, operating on net metered basis from the grid 7.1.4 The meter will be read by the Power Producer‟s personnel on the Metering Date on
monthly basis. The authorized representative of the Procurer can be present at the time of meter reading. Both the Parties shall sign a joint meter reading report. However, in case the joint meter reading report is not signed in the first three Business Days of Metering Date of any month due to non-availability of the Procurer‟s authorized representative, the report signed by the Power Producer shall be considered as joint meter reading report, the
Parties agree that such joint meter reading report shall be final and binding on the Parties. 7.1.5 Meters and metering equipment shall be tested as per provision of RERC (Grid Connected
Net Metering) Regulations and as per IS 14697 at CPRI or at any NABL accredited lab
before installation at site on the cost of power producer and should be properly sealed in the presence of designated authority from procurer at the time of installation.
7.1.6 The Metering System at the Delivery Point(s) and any additional meters required by
Applicable Law shall be tested, maintained and owned by the Power Producer. 7.1.7 The Procurer may, at its own discretion, install a check meter, at its cost, to verify the
measurements of the Metering System. 7.1.8 The risk and title to the solar power supplied by the Power Producer shall pass to the
Procurer at the Delivery Point(s). 7.1.9 The energy metering of Projects, in kWh, shall be on monthly basis and equal to gross
energy generated for a net metered project. 7.2 Billing
a) The energy billable to Procurer, by Power Producer, shall be computed on monthly basis
by multiplying the Quoted Fixed Tariff with the summation of gross energy generated for a
net metered Project; 7.2.1 Import and export of energy from Project shall be settled as per RERC Net Metering
Regulations, and their amendments/ substitutions.
ARTICLE 8: TARIFF AND PAYMENT
8.1 Consideration
8.1.1 Procurer shall pay to the Power Producer monthly payment towards energy consumed
from the Project as per the Metering and Billing as described in ARTICLE 7: above for each
calendar month during the period from the Commissioning of Part Capacity to Expiry Date
at a Tariff corresponding to the Quoted Fixed Tariff upon pursuant to RFP.
All the payment from Procurer to Power Producer shall be routed through the Lender‟s designated Bank Account.
8.1.2 Quoted Fixed Tariff shall be applicable for the period from Initial Part Commissioning till the
end of 25th Operational year. 8.2 Invoice
8.2.1 The Power Producer shall invoice Procurer on third Business Day of each month
(“Metering Date”) in respect of energy generated the immediately preceding month.
RESCO Power Purchase Agreement
However, the last monthly invoice pursuant to this PPA shall include energy generated only
till the Expiration Date of this PPA.
8.2.2 The Invoice to the Procurer shall include:
a) Gross energy generated for a net metered Project b) Supporting data, documents and calculations in accordance with this PPA;
8.3 Due Date
8.3.1 If there is no dispute on an Invoice, Procurer shall pay all amounts due under the Invoice
within fifteen (15) Business Days after the date of the receipt of the invoice in Procurer‟s office (“Due Date”) through e-mail or/ and FAX.
8.4 Method of Payment
8.4.1 Procurer shall make all payments under the PPA by cheque or electronic funds transfer of immediately available funds to the designated bank account. All payments made hereunder shall be non-refundable, subject to the applicable tax deduction at source, and be made
free and clear of any other tax, levy, assessment, duties or other charges and not subject to reduction, set-off, or adjustment of any kind. If the Procurer deducts any tax at source, the Procurer will issue a tax credit certificate as per law.
8.5 Late Payment
8.5.1 Save for provisions in for disputed bills, in case payment against any Invoice is delayed by
the Procurer beyond its Due Date, a Late Payment Surcharge shall be payable by Procurer to the Power Producer at the rate of 1.5% per month (“Late Payment Surcharge”) calculated on the amount of outstanding payment, calculated on a Day to Day basis for each Day of the delay beyond the Due Date, compounded on monthly basis. Late Payment Surcharge shall be claimed by the Power Producer through its subsequent Invoice.
8.6 Rebate
8.6.1 Save for any dispute, Procurer shall be eligible for rebate of 1% on the amount of outstanding payment, for payment of any Bill within first seven (7) Business Daysfrom the
Metering Date, calculated on a Day to Day basis for each Day of the.
8.6.2 In case of any disputed bill, the rebate shall be allowed on only that payment which is made
within first seven (7) days of Metering Date, irrespective of the outcome of final settlement of the dispute.
8.6.3 No Rebate shall be payable on the Bills raised on account of Change in Law relating to
taxes, duties and cess etc.
8.7 Disputed Bill 8.7.1 If the Procurer does not dispute a Monthly Bill or a Supplementary Bill raised by Power
Producer by the Due Date, such Bill shall be taken as conclusive.
8.7.2 If the Procurer disputes the amount payable under a Monthly Bill or a Supplementary Bill, as the case may be, it shall within seven (7) Days of receipt of such Bill, issue a notice (the
"Bill Dispute Notice") to the Power Producer setting out:
a) the details of the disputed amount; b) its estimate of what the coGovt. Sectt.t amount should
be; and c) all written material in support of its claim.
8.7.3 If the Power Producer agrees to the claim raised in the Bill Dispute Notice issued pursuant
to Article8.7.2, the Power Producer shall revise such Bill and present along with the next
Monthly Bill.
8.7.4 If the Power Producer does not agree to the claim raised in the Bill Dispute Notice issued
pursuant to Article8.7.2, it shall, within seven (7) Days of receiving the Bill Dispute Notice,
furnish a reply to Bill Dispute Notice to the Procurer providing:
a) its reasons against dispute;
b) its estimate of what the coGovt. Sectt.t amount should be; and c) all written material in
support of its counter claim.
8.7.5 Upon receipt of the reply to Bill Dispute Notice from Power Producer, by Procurer, under Article8.7.4, authorized representative(s) or a director of the board of directors/ member of board of the Procurer and Power Producer shall meet and make best endeavours to
amicably resolve such dispute within seven (7) Days of receipt of the reply to the Bill Dispute Notice.
RESCO Power Purchase Agreement
8.7.6 If the Parties do not amicably resolve the Dispute within seven (7) Days of receipt of reply
to the Bill Dispute Notice pursuant to Article8.7.4, the matter shall be referred to Dispute
resolution in accordance with ARTICLE 16:.
8.7.7 For the avoidance of doubt, it is clarified that despite a Dispute regarding an Invoice, Procurer shall, without prejudice to its right to Dispute, be under an obligation to make
payment of 100% of the undisputed amount of the concerned Monthly Bill, and 90% of disputed amount under protest within fifteen (15) Business Days after the date of the
receipt of the invoice. Once the dispute is settled, the coGovt. Sectt.tion amount shall be
adjusted with the monthly interest rate of 1.50% computed on daily basis;
8.8 Payment Security Mechanism
8.8.1 Procurer shall provide to the Power Producer, in respect of payment of its Monthly Bills
and/or Supplementary Bills, a monthly unconditional, revolving and irrevocable letter of credit (“Letter of Credit”), opened and maintained which may be drawn upon by the Power Producer in accordance with this Article.
8.8.2 Not later than one (1) Month before the SCOD, including the extension granted, if any, Procurer through a scheduled bank at [Identified Place] open a Letter of Credit in favour of the Power Producer, to be made operative from a date prior to the Due
Date of its first Monthly Bill under this PPA.
8.8.3 The Letter of Credit shall have a term of twelve (12) Months and shall be renewed annually, for an amount:
a) for the first Operational Year, equal to one hundred twenty percent (120%) of the estimated
average monthly billing; b) for each subsequent Operational Year, equal to one hundred and twenty percent (120%) of
the average of the monthly billing of the previous Operational Year.
8.8.4 Provided that the Power Producer shall not draw upon such Letter of Credit prior to the end
of 30thDay from the Due Date of the relevant Monthly Bill and/or Supplementary Bill, and
shall not make more than one drawal in a Month. 8.8.5 Provided further that if at any time, such Letter of Credit amount falls short of the amount
specified in Article8.8.2 due to any reason whatsoever, Procurer shall restore such shortfall within seven (7) Business Days.
8.8.6 If the Power Producer draws from the Letter of Credit, the amount corresponding to the
drawn amount shall be deposited in the designated bank account.
8.8.7 Procurer shall cause the scheduled bank issuing the Letter of Credit to intimate the Power Producer, in writing regarding establishing of such irrevocable Letter of Credit.
8.8.8 Procurer shall ensure that the Letter of Credit shall be renewed not later than thirty (30) Business Days prior to its expiry.
8.8.9 All costs relating to opening, maintenance of the Letter of Credit shall be borne by Procurer.
8.8.10 Where necessary, the Letter of Credit may also be substituted by an
8.8.10.1 unconditional and irrevocable bank guarantee;
8.8.10.2 Fixed Deposit Receipt with DOP;
8.8.10.3 Cash receipt with DOP Govt. Secretariat;
8.8.10.4 Guarantee/Assurance of the concerned Department.
8.8.11 If Procurer fails to pay a Monthly Bill or Supplementary Bill or part thereof within and
including the 30th day from the Due Date, then, subject to Article8.8.7, the Power Producer may draw upon the Letter of Credit, and accordingly the bank shall pay without any
reference or instructions from Procurer, an amount equal to the shortfall of the payment made towards such Monthly Bill or Supplementary Bill or part thereof, if applicable, in
accordance with Article8.5 above, by presenting to the scheduled bank issuing the Letter of Credit, the following documents:
a) a copy of the Monthly Bill or Supplementary Bill which has remained unpaid to Power Producer and;
b) a certificate from the Power Producer to the effect that the bill at item a) above, or specified
part thereof, is in accordance with the PPA and has remained unpaid beyond the Due
Date;
8.9 Quarterly and Annual Reconciliation
RESCO Power Purchase Agreement
8.9.1 The Parties acknowledge that all payments made against Monthly Bills and Supplementary
Bills shall be subject to quarterly reconciliation within 30 Days of the end of the quarter of each Operational Year and annual reconciliation at the end of each Operational Year within
thirty (30) Days of the end of the Operational Year to take into account the Energy
Accounts, payment adjustments, Tariff rebate, Late Payment Surcharge, or any other reasonable circumstance provided under this PPA.
8.9.2 The Parties, therefore, agree that as soon as all such data in respect of any quarter of anOperational Year or a full Operational Year, as the case may be, has been finally verified
and adjusted, the Power Producer and Procurer shall jointly sign such reconciliation
statement. Within fifteen (15) Days of signing of a reconciliation statement, the Power Producer shall make appropriate adjustments in the next Monthly Bill. Late Payment Surcharge/ interest shall be payable in such a case from the date on which such payment had been made to the Power Producer or the date on which any payment was originally
due, as may be applicable. Any Dispute with regard to the above reconciliation shall be
dealt with in accordance with the provisions of ARTICLE 16:
8.10 Payment of Supplementary Bill
8.10.1 Procurer/ Power Producer may raise a ("Supplementary Bill") for payment on account of:
a) Adjustments required by the Energy Accounts (if applicable); or b) Change in Law as provided in ARTICLE 11:;
8.10.2 Procurer shall remit all amounts due under a Supplementary Bill raised by the Power Producer to the Power Producer's Designated Account by Due Date. Similarly, the Power Producer shall pay all amounts due under a Supplementary Bill raised by Procurer by the
Due Date to Procurer's designated bank account and notify such Procurer of such payment on the same Day.
8.10.3 In the event of delay in payment of a Supplementary Bill by the Power Producer beyond its
Due Date or by Procurer beyond the end of 30th Day from the Due Date, as the case may
be, a Late Payment Surcharge shall be payable at the same terms applicable to the
Monthly Bill in Article8.5.
RESCO Power Purchase Agreement
ARTICLE 9: INSURANCES
9.1 Insurance
9.1.1 The Power Producer shall maintain at its own costs, throughout the Term of PPA and any
extensions thereof all mandatory insurance coverage for adequate amount including but not restricted to, theft, damages, comprehensive general liability insurance covering the
Project and accidental losses, bodily harm,injury,death of all individuals employed/assigned
by the Power Producer to perform the services required under this PPA.
9.2 Application of Insurance Proceeds
9.2.1 Save as expressly provided in this PPA or respective Insurances, the proceeds of any
insurance claim made due to loss or damage to the Project or any part of the Project shall be first applied to reinstatement, replacement or renewal or making good of such loss or damage of the Project.
9.2.2 If a Force Majeure Event renders the Project no longer economically and technically viable
and the insurers under the respective Insurances make payment on a “total loss” or equivalent basis, Procurer shall have no claim on such proceeds of such Insurance.
9.3 Effect on liability of Procurer
9.3.1 Notwithstanding any liability or obligation that may arise under this PPA, any loss, damage, liability, payment, obligation or expense which is insured or not or for which the Power Producer can claim compensation, under any Insurance shall not be charged to or payable
by Procurer. ARTICLE 10: FORCE MAJEURE
10.1 Definitions
10.1.1 In this Article, the following terms shall have the following meanings: Affected Party 10.1.2 An affected Party means Procurer or the Power Producer whose performance has been
affected by an event of Force Majeure.
10.1.3 An event of Force Majeure affecting the Discom, which has affected the interconnection
facilities, shall be deemed to be an event of Force Majeure affecting the Power Producer.
10.1.4 Any event of Force Majeure affecting the performance of the Power Producer‟s contractors, shall be deemed to be an event of Force Majeure affecting Power Producer only if the
Force Majeure event is affecting and resulting in:
a) late delivery of plant, machinery, equipment, materials, spare parts, fuel, water or consumables for the Project; or
b) a delay in the performance of any of the Power Producer‟s contractors for other works associated with Project.
Force Majeure 10.1.5 A „Force Majeure‟ means any event or circumstance or combination of events those stated
below that wholly or partly prevents or unavoidably delays an Affected Party in the
performance of its obligations under this PPA, but only if and to the extent that such events
or circumstances are not within the reasonable control, directly or indirectly, of the Affected
Party and could not have been avoided if the Affected Party had taken reasonable care: a) Act of God, including, but not limited to lightning, drought, fire and explosion (to the
extent originating from a source external to the site), earthquake, volcanic eruption, landslide, flood, cyclone, typhoon or tornado, or exceptionally adverse weather conditions which are in excess of historical statistical measures, act of war, terrorist attack, public disorders, civil disturbances, riots, insuGovt. Sectt.tion, sabotage, rebellion, blockade, embargo ;
b) A Force Majeure Event shall not be based on the Economic hardship of either Party. In
case of any damage because of force majeure event, the Project shall be repaired / commissioned at its own cost by the Power Producer.
c) the unlawful, unreasonable or discriminatory revocation of, or refusal to renew, any
Consent required by the Power Producer or any of the Power Producer‟s contractors to perform their obligations under the Project documents or any unlawful, unreasonable or discriminatory refusal to grant any other consent required for the development/ operation of the Project. Provided that an appropriate court of law declares the
RESCO Power Purchase Agreement
revocation or refusal to be unlawful, unreasonable and discriminatory and strikes the
same down.
d) radioactive contamination or ionising radiation originating from a source in India or resulting from another Force Majeure Event mentioned above excluding circumstances
where the source or cause of contamination or radiation is brought or has been brought into or near the Project by the Affected Party or those employed or engaged by the Affected Party.
e) Industry wide strikes and labour disturbances having a nationwide impact in India.
10.2 Force Majeure Exclusions
10.2.1 Force Majeure shall not include (i) any event or circumstance which is within the
reasonable control of the Parties and (ii) the following conditions, except to the extent that they are consequences of an event of Force Majeure:
a) Inability to obtain permission from discom
b) Inability to obtain commissioning certificate from discom
c) Unavailability, late delivery, or changes in cost of the plant, machinery, equipment, materials, spare parts, fuel or consumables for the Project;
d) Delay in the performance of any contractor, sub-contractor or their agents excluding the
conditions as mentioned in Article10.1.5;
e) Non-performance resulting from normal wear and tear typically experienced in power generation materials and equipment;
f) Strikes at the facilities of the Affected Party;
g) Insufficiency of finances or funds or the PPA becoming onerous to perform; and
h) Non-performance caused by, or connected with, the Affected Party‟s: i. Negligent or intentional acts, errors or omissions;
ii. Failure to comply with an Indian Law; oriii. Breach of, or default under this PPA. 10.3 Notification of Force Majeure Event
10.3.1 The Affected Party shall give notice to the other Party of any event of Force Majeure as
soon as reasonably practicable, but not later than seven (7) Days after the date on which
such Party knew or should reasonably have known of the commencement of the event of Force Majeure. If an event of Force Majeure results in a breakdown of communications
rendering it unreasonable to give notice within the applicable time limit specified herein, then the Party claiming Force Majeure shall give such notice as soon as reasonably
practicable after reinstatement of communications, but not later than three (3) Days after such reinstatement.
10.3.2 Provided that such notice of Force Majeure shall be a pre-condition to the Affected Party‟s entitlement to claim relief under this PPA. Such notice shall include full particulars of the
event of Force Majeure, its effects on the Party claiming relief and the remedial measures
proposed. The Affected Party shall give the other Party regular (weekly or monthly basis, as communicated and agreed upon between the Parties in writing) reports on the existence
Force Majeure and/ or progress of those remedial measures and such other information as
the other Party may reasonably request about the Force Majeure Event.
10.3.3 The Affected Party shall give notice to the other Party of (i) the cessation of the relevant event of Force Majeure; and (ii) the cessation of the effects of such event of Force Majeure
on the performance of its rights or obligations under this PPA, as soon as practicable, but not later than seven (7) Days after becoming aware of each of these cessations.
10.3.4 In case of delay in Payment due to Force Majeure, Affected Party shall have to inform the
other Party and make payment as soon as effect of Force Majeure shall be ended on
Affected Party payment obligation.
10.4 Duty to Perform and Duty to Mitigate
10.4.1 To the extent not prevented by a Force Majeure Event pursuant to Article10.3, the Affected
Party shall continue to perform its obligations pursuant to this PPA. The Affected Party
shall use its reasonable efforts to mitigate the effect of any Force Majeure Event as soon
as practicable.
10.5 Available Relief for a Force Majeure Event
10.5.1 Subject to this ARTICLE 10:
RESCO Power Purchase Agreement
a) no Party shall be in breach of its obligations pursuant to this PPA except to the extent that the performance of its obligations was prevented, hindered or delayed due to a
Force Majeure Event; b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard
to its obligations, including but not limited to those specified under Article4.17; c) For avoidance of doubt, none of either Party‟s obligation to make payments of money
due and payable prior to occurrence of Force Majeure events under this PPA shall be
suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
d) Provided that no payments shall be made by either Party affected by a Force Majeure
Event for the period of such event on account of its inability to perform its obligations
due to such Force Majeure Event.
ARTICLE 11: CHANGE IN LAW
11.1 Definitions
In this Article, the following terms shall have the following meanings:
11.1.1 "Change in Law" means the occurrence of any of the following events after the Bid
Submission Date resulting into any additional recurring/ non-recurring expenditure by the
Power Producer or any income to the Power Producer:
a) the enactment, coming into effect, adoption, promulgation, amendment, modification or repeal (without re-enactment or consolidation) in India, of any Law, including rules and
regulations framed pursuant to such Law; b) change in the interpretation or application of any Law by any Indian Governmental
Instrumentality having the legal power to interpret or apply such Law, or any Competent Court of Law;
c) the imposition of a requirement for obtaining any Consents, Clearances and Permits which was not required earlier;
d) change in any Consents, approvals or licenses available or obtained for the Project, otherwise than for default of the Power Producer, which results in any change in any cost of or revenue from the business of selling electricity by the Power Producer to Procurer under the terms of this PPA;
e) a change in the terms and conditions prescribed for obtaining any Consents or the
inclusion of any new terms or conditions for obtaining such Consents; except due to any
default of the Power Producer; f) any change in taxes, duties and cess or introduction of any taxes, duties and cess made
applicable for generation and sale/ supply of power by Power Producer as per the terms of this PPA but shall not include: (i) any change in any withholding tax on income or dividends
distributed to the shareholders of the Power Producer, or (ii) any change on account of regulatory measures by the Appropriate Commission or (iii) change in the rates of existing
taxes applicable to the Power Producer or (iv) change in income taxes applicable for the
Power Producer
11.2 Notification of Change in Law
11.2.1 If the Power Producer is affected by a Change in Law in accordance with this ARTICLE 11: and wishes to invoke a Change in Law provision, it shall give notice to Procurer of such
Change in Law as soon as reasonably practicable after becoming aware of the same or should reasonably have known of the Change in Law.
11.2.2 Notwithstanding Article11.2.1, the Power Producer shall be obliged to serve a notice to
Procurer if it is beneficially affected by a Change in Law. Without prejudice to the factor of materiality or other provisions contained in this PPA, the obligation to inform Procurer contained herein shall be material. However, in case the Power Producer has not provided
such notice, Procurer shall have the right to issue such notice to the Power Producer.
11.2.3 Any notice served pursuant to Change in Law shall provide, amongst other things, precise
details of:
a) the Change in Law; and
RESCO Power Purchase Agreement
b) the effects on the Power Producer of the matters relevant for Construction Period and the
operation period for the Project.
11.3 Relief for Change in Law
11.3.1 The aggrieved Party shall be required to approach the State DOPfor seeking appropriate
relief under Change in Law.
11.3.2 The decision of the State DOPto acknowledge a Change in Law and the date from
which it will become effective and relief provided for the same shall be final and
binding on both the Parties. Principle that the purpose of compensating the Party affected
by such Change in Law, is to restore through monthly bill payment, to the extent contemplated in this Article 10, the affected Party to the same economic position as if such
Change in Law has not occurred.
ARTICLE 12: EVENTS OF DEFAULT AND TERMINATION
12.1 Power Producer’s Event of Default
12.1.1 The occurrence and continuation of any of the following events, unless any such event occurs as a result of a Force Majeure Event or a breach by Procurer of its obligations under this PPA, shall constitute a Power Producer Event of Default:
a) the failure to achieve COD for the PPA Capacity, within the definite time period, as defined
under RFP and PPA, or any extension granted by DOP and/or Procurer; b) if
i. the Power Producer assigns, mortgages or charges or purports to assign, mortgage or charge any of its assets or rights related to the Project in contravention of the provisions
of this PPA; or
ii. the Power Producer transfers or novates any of its rights and/ or obligations under this PPA, in a manner contrary to the provisions of this PPA; except where such transfer.
a. is in pursuance of a Law; and does not affect the ability of the transferee to perform, and such transferee has the financial capability to perform, its obligations under this
PPA or b. is to a transferee who assumes such obligations under this PPA and the PPA remains
effective with respect to the transferee; or
c) If
i. the Power Producer becomes voluntarily or involuntarily the subject of any bankruptcy
or insolvency or winding up proceedings and such proceedings remain uncontested for a period of thirty (30) Days, or
ii. any winding up or bankruptcy or insolvency order is passed against the Power Producer, or
iii. the Power Producer goes into liquidation or dissolution or has a receiver or any similar officer appointed over all or substantially all of its assets or official liquidator is
appointed to manage its affairs, pursuant to Law; or
iv. Provided that a dissolution or liquidation of the Power Producer will not be a Power Producer Event of Default if such dissolution or liquidation is for the purpose of a
merger, consolidation or reorganization and where the resulting company retains
creditworthiness similar or more than the Power Producer and expressly assumes all obligations of the Power Producer under this PPA and is in a position to perform them; or
v. the Power Producer fails to make any payment (i) of an amount exceeding Rupees Five
(5) Lakh required to be made to Procurer under this PPA, within three (3) Months after the Due Date of an undisputed invoice /demand raised by Procurer on the Power Producer; or
vi. any of the representations and warranties made by the Power Producer in PPA being
found to be untrue or inaccurate. Further, in addition to the above, any of representations made or the undertakings submitted by the Power Producer at the time
of submission of the Bid being found to be breached or inaccurate, including but not limited to undertakings from its parent company/ affiliates related to the minimum equity
RESCO Power Purchase Agreement
obligation; Provided however, prior to considering any event specified under this sub- Article to be an Event of Default, Procurer shall give a notice to the Power Producer in
writing of at least thirty (30) Days; or
vii. the Power Producer repudiates this PPA and does not rectify such breach within a
period of thirty (30) Days from a notice from Procurer in this regard; or
viii. except where due to Procurer‟s failure to comply with its material obligations, the Power Producer is in breach of any of its material obligations pursuant to this PPA, and such
material breach is not rectified by the Power Producer within thirty (30) Days of receipt of first notice in this regard given by Procurer.
ix. the Power Producer fails to complete/ fulfil the activities/conditions specified in
Article4.2, beyond a period of twenty (20) weeks from the period SCOD and Article4.19
right of termination under this PPA can be invoked by Procurer; or x. The Power Producer fails to maintain the C-PBG in accordance with PPA and RFP; or xi. change in controlling shareholding before the specified time frame as mentioned in
Article4.4.1 of this PPA; or
xii. occurrence of any other event which is not specified in this PPA to be a material breach/ default of the Power Producer;
xiii. Power Producer generates solar power lower than 10% CUF on a monthly basis
continuously for 6 months.
12.2 Procurer’s Event of Default
12.2.1 The occurrence and the continuation of any of the following events, unless any such event occurs as a result of a Force Majeure Event or a breach by the Power Producer of its
obligations under this PPA, shall constitute the Event of Default on the part of defaulting
Procurer:
a) Procurer fails to set up a Payment Security Mechanism in accordance with Article8.8.2 at least one (1) Month before the SCOD or the newly determined SCOD based on extension
granted by DOP/Procurer; or b) Procurer fails to pay (with respect to a Monthly Bill or a Supplementary Bill), as per
ARTICLE 8:, for a period of ninety (90) Days after the Due Date and the Power Producer is
unable to recover the amount outstanding to the Power Producer through the Payment Security Mechanism; or
c) Procurer repudiates this PPA and does not rectify such breach even within a period of thirty (30) Days from a notice from the Power Producer in this regard; or
d) except where due to the Power Producer‟s failure to comply with its obligations under PPA and RFP, Procurer is in material breach of any of its obligations pursuant to this PPA and
RFP, and such material breach is not rectified by Procurer within thirty (30) Days of receipt of notice in this regard from the Power Producer; or
e) occurrence of any other event which is not specified in this PPA but leading to a material breach or default by Procurer.
12.3 Procedure for cases of Power Producer Event of Default
12.3.1 Upon the occurrence and continuation of any Power Producer Event of Default under
Article 12.1 Procurer shall have the right to deliver to the Power Producer, with a copy to
the lenders of the Power Producer with whom the Power Producer has executed the
Financing agreement with a copy to the DOP, a notice stating its intention to terminate this PPA (“Procurer Preliminary Default Notice”), which shall specify in reasonable
detail, the circumstances giving rise to the issue of such notice.
12.3.2 Following the issue of a Procurer Preliminary Default Notice, the Consultation Period of sixty (60) Days or such longer period as the Parties may agree, shall apply and it shall be
the responsibility of the Parties to discuss as to what steps shall be taken with a view to
mitigate the consequences of the relevant Event of Default having regard to all the
circumstances.
12.3.3 During the Consultation Period, the Parties shall continue to perform their respective
obligations under this PPA & RFP.
12.3.4 Within a period of seven (7) Days following the expiry of the Consultation Period unless the
Parties shall have otherwise agreed to the contrary or the Power Producer Event of Default
RESCO Power Purchase Agreement
giving rise to the Consultation Period shall have ceased to exist or shall have been
remedied, the Lenders shall have the right to seek the substitution of the Power Producer by a Selectee for the residual period of this PPA for the purpose of performing obligations
of the Power Producer. Such substitution of the Power Producer by a Selectee shall be as
per the procedure prescribed in this PPA and with prior approval of Procurer, provided
Selectee as aforesaid shall have the required qualification and experience as prescribed
under the RFP.
12.3.5 In the event the Lender‟s total debt obligations have been completely satisfied at the time
of issue of Procurer‟s Preliminary Default Notice and upon the occurrence and continuation of Power Producer Default and the failure by the Power Producer to rectify such default within the applicable Consultation Period specified in this ARTICLE 12:Procurer will have
the option of owing the Project at the fees determined as per below formula and later Procurer may terminate this PPA by serving a fifteen (15) Days‟ notice to the Power Producer (“Procurer Termination Notice”).
After COD
Termination payment = Net Asset Value X 50% [After COD]
Net Asset Value = Normative Project Cost X (1 –(4%X No of Operational Years))
The handover of full assets shall be without any encumbrance/liability along with warranties
and insurances in force.
In such case the termination payment shall be deposited in the Procurer‟s designated bank account
There will be no Termination Payment to Power Producer if the termination happens
because of the reasons mentioned below:
Termination before the Project COD or;
event of default occurs due to cause mentioned in 12.1.1
12.3.6 The Power Producer is obligated to perform all duties mentioned in PPA and pay the
Termination Payment, in case of Power Producer Event of Default, on or before the last Day of Procurer Termination Notice.
In situations where there is no transfer of asset based on the above clauses then the Power Producer should return the rooftop/project premises in the original condition existing
before the start of this Project. This has to be undertaken at Power Producers cost without any liability to Procurer.
12.4 Procedure for cases of Procurer Event of Default
12.4.1 Upon the occurrence and continuation of any Procurer Event of Default specified in
Article12.2 the Power Producer shall have the right to deliver to Procurer, a Power Producer Preliminary Default Notice, which shall specify in reasonable detail the
circumstances giving rise to its issue.
12.4.2 Following the issue of a Power Producer Preliminary Default Notice, the Consultation
Period of sixty (60) Days or such longer period as the Parties may agree, shall apply and it shall be the responsibility of the Parties to discuss as to what steps shall be taken with a
view to mitigate the consequences of the relevant Event of Default having regard to all the
circumstances.
12.4.3 During the Consultation Period, the Parties shall continue to perform their respective
obligations under this PPA.
12.4.4 After a period of seven (7) Days following the expiry of the Consultation Period and unless
the Parties shall have otherwise agreed to the contrary or Procurer Event of Default giving
rise to the Consultation Period shall have ceased to exist or shall have been remedied. Upon the occurrence and continuation of Power Producer Default and the failure by the
Procurer to rectify such default within the applicable Consultation Period specified in this
ARTICLE 12:. the Power Producer shall take the termination payment, to be paid by
Procurer at the end of PPA termination, calculated as per below formula, and later Power Producer may terminate this PPA by serving a fifteen (15) Day‟s notice to the Procurer (“Power Producer Termination Notice”).
Termination payment = Net Asset Value
Net Asset Value = Normative Project Cost X (1 –(4%X No of Operational Years))
In such case the termination payment shall be deposited on Power Producer‟s designated
bank account.
RESCO Power Purchase Agreement
If the Power Producer exercises his right to remove the assets from the premises, then the
termination payment would be as below:-
Termination payment= 10% of Net Assets Value (as defined above).
12.4.5 Procurer obligated to perform all duties mentioned in PPA and pay the termination fees, in
case of Procurer Event of Default, on or before the last Day of Power Producer Termination
Notice.
12.4.6 In situations where there is no transfer of asset based on the above clauses then the
Power Producer should return the rooftop/project premises in the original condition existing
before the start of this Project. This has to be undertaken at Power Producers cost without any liability to Procurer.
12.5 Termination due to Force Majeure
If the Force Majeure Event or its effects continue to be present beyond the period as
specified in Article4.17.3, either Party shall have the right to cause termination of the
PPA. In such an event, this PPA shall terminate on the date of such Termination Notice. 12.6 Termination on request of the Procurer
12.6.1 Procurer may, on giving at least 6 months written notice to the Project Developer with a
copy marked to the Lenders, terminate the PPA only after the completion of 5 Operational Years. Following the issue of a “Default Notice”, a Conciliation Period of sixty
(60) days or such longer period as the parties may agree, shall apply and it shall be the
responsibility of the parties to discuss as to what steps shall be taken with a view to
mitigate the consequences of the relevant solar power developer / Procurer Event of Default having regard to all the circumstances.
12.6.2 However after the expiry of the default notice if both parties can‟t reach to an amicable solution, In such case the Procurer shall pay to Power Producer a sum as per formula
given hereunder:
Termination payment = Net Asset Value
Net Asset Value = Normative Project Cost X (1- (2% X No of Operational Years)) for first 15 Operational Years;
OR
Net Asset Value = Normative Project Cost (1- (4% X No of Operational Years)) after 15 Operational Years
In such case the termination payment shall be deposited on Power Producer‟s designated
bank account.
The Parties shall promptly execute all documents necessary to cause title to the
Project to pass to Procurer on the date of termination free and clear of all liens and
assign all vendor warranties for the Project to the Procurer. Upon execution of the
documents and payment of the applicable purchase price in each case as described in
the preceding sentence, the agreement shall stand terminated and the Procurer shall become the owner of the Project. The transfer of Project will be without any
encumbrances, no assignments.
Upon such termination, the Power Producer may offer' its operations and maintenance
("O&M") services to the Purchaser and the Parties may enter into an O&M agreement in this regard. The terms and conditions of the O&M agreement will be negotiated in
good faith between the Parties.
12.6.3 Notwithstanding Terminations, both Power Producer and Procurer shall ensure full and
final settlement of respective rights and obligations pursuant to terms and conditions of this
RFP and Agreement/ PPA, so that neither would have to carry and bear the burden of the
other‟s rights and obligations. Towards fulfilment of this provision, an affidavit on a non- judicial stamp paper shall have to be furnished by both Power Producer and Procurer to
each other at the time of termination.
ARTICLE 13: LIABILITY AND INDEMNIFICATION
13.1 Indemnity
13.1.1 The Power Producer shall indemnify, defend and hold Procurer harmless against:
RESCO Power Purchase Agreement
a. any and all third party claims against Procurer for any loss of or damage to property of such
third party, or death or injury to such third party, arising out of a breach by the Power Producer of any of its obligations under this PPA; and
b. any and all losses, damages, costs and expenses including legal costs, fines, penalties and
interest actually suffered or incurred by Procurer from third party claims arising by reason
of a breach by the Power Producer of any of its obligations under this PPA or any of the
representations or warranties of the Power Producer under this PPA being found to be
inaccurate or untrue. c. Notwithstanding any liability or obligation that may arise under this PPA, any loss, damage,
liability, payment, obligation or expense which is insured or not or for which the Procurer can claim compensation under any insurance policy, shall not be charged to or payable by
the Procurer. d. However, this ARTICLE 13: shall not apply to such breaches by the Power Producer, for
which specific remedies have been provided for under this PPA)
13.2 Procedure for claiming Indemnity
13.2.1 Third party claims a. Where the indemnified Party is entitled to indemnification from the indemnifying Party
pursuant to Article13.1.1a, the indemnified Party shall promptly notify the indemnifying
Party of such claim referred to in to Article13.1.1a in respect of which it is entitled to be
indemnified. Such notice shall be given as soon as reasonably practicable after the
indemnified Party becomes aware of such claim. The indemnifying Party shall be liable to
settle the indemnification claim within thirty (30) Days of receipt of the above notice. However, if: i. the Parties choose to refer the dispute before the Arbitrator in accordance with
Article16.3; and ii. the claim amount is not required to be paid/ deposited to such third party pending the
resolution of the Dispute; b. the indemnifying Party shall become liable to pay the claim amount to the indemnified Party
or to the third party, as the case may be, promptly following the resolution of the Dispute, if such Dispute is not settled in favour of the indemnifying Party.
c. An indemnifying Party may, at its own expense, assume control of the defence of any
proceedings brought against it by the indemnified Party.
13.3 Indemnifiable Losses
13.3.1 Where an indemnified Party is entitled to indemnifiable losses from the indemnifying Party
pursuant to Article13.1.1b, the indemnified Party shall promptly notify the Indemnifying
Party of the indemnifiable losses actually incurred by the indemnified Party. The
indemnifiable losses shall be reimbursed by the indemnifying Party within thirty (30) Days
of receipt of the notice seeking indemnifiable losses by the indemnified Party. In case of non-payment of such losses after a valid notice under this Article, such event shall constitute a payment default under ARTICLE 12:.
13.4 Limitation on Liability
13.4.1 Except as expressly provided in this PPA, neither the Power Producer nor its/ their respective officers, directors, agents, employees or affiliates (or their officers, directors, agents or employees), shall be liable or responsible to the other Party or its affiliates, officers, directors, agents, employees, successors or permitted assigns or their respective
insurers for incidental, indirect or consequential damages, connected with or resulting from
performance or non-performance of this PPA, or anything done in connection herewith, including claims in the nature of lost revenues, income or profits (other than payments
expressly required and properly due under this PPA), any increased expense of, reduction
in or loss of power generation or equipment used therefore, irrespective of whether such
claims are based upon breach of warranty, tort (including negligence, the Power Producer or others), strict liability, contract, breach of statutory duty, operation of law or otherwise.
13.4.2 Procurer shall have no recourse against any officer, director or shareholder of the Power Producer or any affiliate of the Power Producer or any of its officers, directors or shareholders for such claims excluded under this Article. The Power Producer shall have
no recourse against any officer, director or shareholder of Procurer, or any affiliate of
RESCO Power Purchase Agreement
Procurer or any of its officers, directors or shareholders for such claims excluded under this
Article.
13.4.3 Notwithstanding anything to the contrary contained elsewhere in this PPA, the provisions of this ARTICLE 13: shall apply mutatis mutandis to any claim against Procurer under ARTICLE 13:.
13.5 Duty to Mitigate
13.5.1 The Parties shall endeavour to take all reasonable steps so as mitigate any loss or damage
which has occurred under this ARTICLE 13:. ARTICLE 14: GENERAL COVENANTS
14.1 Power Producer’s Covenants
14.1.1 The Power Producer covenants and agrees to the following: a) Notice of Damage or Emergency: The Power Producer shall (a) promptly notify Procurer
if it becomes aware of any damage to or loss of the use of the Project or that could
reasonably be expected to adversely affect the Project, (b) immediately notify Procurer once it becomes aware of any event or circumstance that poses an imminent risk to human
health, the environment, the Project or the Premises. b) Project Condition: The Power Producer shall take all actions reasonably necessary to
ensure that the Project is capable of generation and delivery of solar energy at agreed rate
as per PPA & RFP. Subject to there being no Procurer Default, the Power Producer shall provide 24X7 onsite / offsite monitoring and maintenance of the Project throughout the
period of this PPA at no additional cost. c) Consents and Approvals: While providing the installation work, solar power and system
operations, the Power Producer shall obtain and maintain and secure all Consents and
Approvals required to be obtained and maintained and secured by the Power Producer and
to enable the Power Producer to perform such obligations as required under PPA and RFP. d) Interconnection with Discom: The interconnection of the Project with the network of the
distribution licensee shall be made as per the technical standards for connectivity of distributed generated resources regulations as may be notified by the competent authority. The interconnection of the Project shall be as per the contracted Load and/or respective
voltage level applicable to the Procurer as per the provisions of the guidelines issued by
the competent authority. e) Health and Safety: The Power Producer shall take all necessary and reasonable safety
precautions with respect to providing the installation work, solar energy, and system
operations that shall comply with all Applicable Laws pertaining to the health and safety of persons and real and personal property.
14.2 Power Producer’s Representatives
14.2.1 During the subsistence of this PPA, the Power Producer undertakes to respond to all questions, concerns and complaints of the Procurer regarding the Project in a prompt and
efficient manner. The Power Producer designates the following individual as its
representative pertaining to performance of this PPA for the period from Effective date till the COD:
Name: Telephone: E-mail:
14.2.2 The Power Producer designates the following individual as its representative and primary
point of contact pertaining to performance of this PPA following the COD till Expiry Date:
Name: – Project Manager
Telephone: +91
E-mai
RESCO Power Purchase Agreement
14.3 Procurer’s Covenants
14.3.1 Procurer covenants and agrees to the following:
a) Notice of Damage or Emergency: Procurer shall (a) promptly notify the Power Producer if it becomes aware of any damage to or loss of the use of the Project or that could
reasonably be expected to adversely affect the Project; (b) immediately notify the Power Producer once it becomes aware of any event or circumstance that poses an imminent risk
to human health, the environment, the Project or the Premises. b) Consents: The Procurer shall cooperate with the Power Producer to obtain such
approvals, permits, rebates or other financial incentives including those required for installation of Project at the Premises and to draw/ consume/ sell solar energy. However, it would be sole responsibility of Power Producer to obtain such approvals, permits, rebates
or other financial incentives including those required for installation of Project at the
Premises and to draw/ consume/ sell solar energy. The Procurer should grant similar access/grants/licenses to the Lenders and Lenders Representative to enable them smooth access to the site for site inspection.
c) In cases, where the Procurer and Building Owner are different, then similar undertaking for access to premises in favour of Lenders has to be provided by the Building Owner.
d) Access to Premises, Grant of Licenses: Procurer hereby grants to the Power Producer a license co-terminus with the Term of PPA, containing all the rights necessary for the Power Producer to use and occupy portions of the Premises for the installation, operation and
maintenance of the Project pursuant to the terms of this PPA, including ingress and egress
rights to the Premises for the Power Producer and its employees, agents, contractors and
subcontractors and access to electrical panels and conduits to interconnect or disconnect the Project with the Premises‟ electrical wiring with the consent and approval of the Procurer‟s authorized representative identified by the Procurer.
e) Security: Procurer shall be responsible for maintaining the physical security of the
Premises. Procurer will not conduct activities on, in or about the Premises that have a
reasonable likelihood of causing damage, impairment or otherwise adversely affecting the
Project. f) Regardless of whether Procurer is owner of the Premises or leases the Premises from a
building owner, Procurer hereby covenants that (a) the Power Producer shall have access
to the Premises and Project during the Term of this PPA and for so long as needed after termination to remove the Project pursuant to the applicable provisions herein, and (b) neither Procurer nor Procurer‟s owner will interfere or handle any of the Power Producer‟s equipment or the Project without written authorization from the Power Producer.
g) Temporary storage space during installation or removal:Procurer shall provide sufficient space at the Premises for the temporary storage and staging of tools, materials
and equipment and for the parking of construction crew vehicles and temporary
construction trailers and facilities reasonably necessary during the installation work, Project operations or Project removal, and access for rigging and material handling.
h) Storage space during O &M period: Procurer shall provide some space, if required, for keeping minimum tools and tackles compulsory for O &M activities, from the Initial Part Commissioning to Expiry Date. Also, if required, minimum necessary equipment shall be
kept at or near the Premises, with due permission from Procurer. i) Sunlight Easements: Procurer will take all reasonable actions as necessary to prevent
other buildings, structures or flora from overshadowing or otherwise blocking access of sunlight to the Project, including but not limited to such actions as may be reasonably
necessary to obtain a solar access easement for such purpose. i. In the event that the Procurer fails to ensure adequate space for solar equipment to
ensure that other structures within his premises do not partially or wholly shade any
part of the Project and if such shading occurs, the Power Producer may apply for Deemed Generation furnishing the calculation for loss in revenue due to such
shading supported by the relevant data, which shall be approved by Procurer within
one month of submission failing which the Power Producer shall claim provisional Deemed Generation till the issue is finally settled. In case, Procurer requested to
shift the Project within the Premises to reduce/minimize the impact of shading then
RESCO Power Purchase Agreement
complete cost of shifting shall be borne by the Procurer. The costing would be as
per latest Standard of Rates (SOR) published by concerned distribution utility for similar works;
ii. In the event that the Procurer fails to ensure adequate space for solar equipment to
ensure that other structures outside his premises do not partially or wholly shade
any part of the Project and if such shading occurs, the Power Producer may apply
for 80% of Deemed Generation furnishing the calculation for loss in revenue due to
such shading supported by the relevant data, which shall be approved by Procurer within one month of submission failing which the Power Producer shall claim
provisional Deemed Generation till the issue is finally settled. In case, Procurer requested to shift the Project within the Premises to reduce/minimize the impact of shading then 80% of cost of shifting shall be borne by the Procurer and remaining
will be borne by Power Producer. The costing would be as per latest Standard of Rates (SOR) published by concerned distribution utility for similar works
j) Evacuation: Procurer shall offtake 100% of the solar energy generated, as per PPA
Capacity as agreed under this PPA, from the Delivery Point(s), and pay all invoices raised
by the Power Producer under this PPA by the Due Date and pay interest on delayed
payments, if any, as per this PPA. k) Water: Power Producer shall arrange water, as per the requirements of the Power
Producer, for periodic cleaning of the solar panels. The raw water connection point may be
provided by Procurer at site but water bill or charges against such connection shall be
borne by Power Producer and to be mutually agreed between the Parties. 14.4 Procurer’s Representatives
14.4.1 During the subsistence of this PPA, the Procurer undertakes to respond to all questions, concerns and complaints of the Power Producer regarding the Project in a prompt and
efficient manner. The Procurer designates the following individual as its representative
pertaining to performance of this PPA during the Term of PPA:
Name: Telephone: E-mail
ARTICLE 15: ASSIGNMENTS AND CHARGES 15.1 Assignments
15.1.1 This PPA shall be binding upon, and inure to the benefit of the Parties and their respective
successor and permitted assign. This PPA shall not be assigned by any Party other than by
mutual consent between the Parties to be provided and evidenced in writing.
15.1.2 Provided that, respective successor or permitted assign shall meet eligibility criteria as per RFP and shall not be inferior, in any respect, to the concerned Party.
15.1.3 Provided that, Procurer shall permit assignment of any of Power Producer‟s rights and obligations under this PPA in favour of lenders of the Power Producer, if required under the
Financing agreement.
15.1.4 Provided that, such consent shall not be withheld if Procurer seeks to transfer to any
transferee all of its rights and obligations under this PPA.
15.1.5 Provided further that any successor or permitted assign identified after mutual PPA
between the Parties may be required to execute a new PPA on the same terms and
conditions as are included in this PPA.
15.2 Permitted Charges
15.2.1 Power Producer shall not create or permit to subsist any encumbrance over all or any of its
rights and benefits under this PPA, other than as set forth in ARTICLE 15:. ARTICLE 16: GOVERNING LAW AND DISPUTE RESOLUTION
16.1 Governing Law
16.1.1 This PPA shall be governed by and construed in accordance with the Laws of India. Any
legal proceedings in respect of any matters, claims or disputes under this PPA shall be
under the jurisdiction of appropriate courts in Jaipur.
16.2 Amicable Settlement
RESCO Power Purchase Agreement
16.2.1 Either Party is entitled to raise any claim, dispute or difference of whatever nature arising
under, out of or in connection with PPA or RFP (“Dispute”) by giving a written notice (Dispute Notice) to the other Party, which shall contain:
a) a description of the Dispute; b) the grounds for such Dispute; and c) all written material in support of its claim
16.2.2 The other Party shall, within thirty (30) Days of issue of Dispute Notice issued under Article16.2.1, furnish:
a) counter-claim and defences, if any, regarding the Dispute; and
b) all written material in support of its defences and counter-claim.
16.2.3 Within thirty (30) Days of issue of Dispute Notice by any Party pursuant to Article16.2.1if the other Party does not furnish any counter claim or defence under Article16.2.2 or thirty
(30) Days from the date of furnishing counter claims or defence by the other Party, both the
Parties to the Dispute shall meet amicably to settle such Dispute. If the Parties fail to
resolve the Dispute amicably within thirty (30) Days from the later of the dates mentioned in
this Article16.2.3, the Dispute shall be referred for dispute resolution in accordance with
Article16.3.
16.3 Dispute Resolution
16.3.1 In case of dispute with Discom related to Net-Meter, Power Producer shall seek
Appropriate Commission help and other parties will extend their full support in getting
favourable decision;
16.3.2 In case of Disputed Bills, it shall be open to the aggrieved Party to approach the DOPor Courtfor dispute resolution in accordance with settled Law and also for interim orders
protecting its interest and the Parties shall be bound by the decision of the DOP.
Dispute Resolution by the DOP Govt. Secretariat
16.3.3 DOPcan be approached by either Party for settlement of a dispute:
a) Where any Dispute (i) arises from a claim made by any Party for any matter related to
Tariff or claims made by any Party which partly or wholly relate to any change in the
Tariff or determination of any of such claims could result in change in the Tariff, or (ii) relates to any matter agreed to be referred to the DOP, such Dispute shall be submitted
to the DOP Govt. Secretariat. Dispute Resolution through Arbitration
16.3.4 Dispute shall be resolved by arbitration under the provisions of the “The Arbitration and Conciliation Act 1996“, as amended, as under, provided not settled amicably as per this
ARTICLE 16:. In such events, any party to such Dispute may refer the matter to registrar under the Rules of the Indian Council of Arbitration:
a) The Arbitration Tribunal shall consist of three (3) Arbitrators. Each party shall appoint one Arbitrator within 30 Days of the receipt of request for settlement of dispute by
Arbitration. The two appointed Arbitrators shall within 30 Days of their appointment, appoint a third Arbitrator who shall act as presiding Arbitrator. In case the party fails to
appoint an Arbitrator within 30 Days from the date of receipt of request or the two
appointed Arbitrator fails to agree on third Arbitrator within 30 Days of their appointment, the appointment of Arbitrator, as the case may be, shall be made in
accordance with the Indian Arbitration and Conciliation Act, 1996. b) The place of arbitration shall be Jaipur. The language of the arbitration shall be English. c) The Arbitration Tribunal‟s award shall be substantiated in writing. The Arbitration
Tribunal shall also decide on the costs of the arbitration proceedings and the allocation thereof.
d) The provisions of this Article shall survive the termination of this PPA for any reason
whatsoever. e) The award shall be of majority decision. If there is no majority, the award will be given
by the presiding Arbitrator. f) Procurer shall be entitled to co-opt Discom(s) as a supporting party in such arbitration
proceedings.
16.4 Parties to Perform Obligations
RESCO Power Purchase Agreement
16.4.1 Notwithstanding the existence of any Dispute and difference referred to the Arbitration
Tribunal as provided in Article16.3 and save as the Arbitration Tribunal may otherwise
direct by a final or interim order, the Parties hereto shall continue to perform their respective obligations (which are not in dispute) under this PPA or RFP.
ARTICLE 17: SUBSTITUTION RIGHTS OF LENDERS
17.1 Substitution of the Power Producer
17.1.1 Subject to the terms of the PPA, upon occurrence of an Power Producer Event of Default under the PPA, the Lenders shall, have the right to seek substitution of the Power Producer by a Selectee, meeting or exceeding eligibility criteria as per PPA or/ and RFP, for the
residual period of the PPA, for the purposes of securing the payments of the Total Debt Amount from the Power Producer and performing the obligations of the Power Producer, in
accordance with the provisions of this Article.
17.1.2 The Lenders may seek to exercise right of substitution by an amendment or novation of the
PPA and other Project Documents executed between Procurer and the Power Producer in
favour of the Selectee, Procurer and the Power Producer shall cooperate with the Lenders
to carry out such substitution.
17.2 Procurer Preliminary Default Notice
17.2.1 Procurer shall, simultaneously to delivering a Procurer Preliminary Default Notice to the Power Producer, also issue a copy of it to the Lenders.
17.3 Substitution Notice
17.3.1 In the event of failure of the Power Producer to rectify the Event of Default giving rise to
Procurer Preliminary Default Notice, the lenders, upon receipt of a written advice from
Procurer confirming such failure, either on their own or through its representative (“the Lenders‟ Representative) shall be entitled to notify Procurer and the Power Producer of the
intention of the Lenders to substitute the Power Producer by the Selectee, meeting or exceeding eligibility criteria as per PPA or/ and RFP, for the residual period of the PPA (the
“Substitution Notice”).
17.4 Interim operation of Project
17.4.1 On receipt of a Substitution Notice, no further action shall be taken by any Party to
terminate the PPA, except under and in accordance with the terms of this Article of this
PPA.
17.4.2 On issue of a Substitution Notice, the Lenders shall have the right to request Procurer to
enter upon and takeover the Project for the interim and till the substitution of the Selectee is
complete and to otherwise take all such steps as are necessary for the continued operation
and maintenance of the Project, including levy, collection and appropriation of payments
there under, subject to, the servicing of monies owed in respect of the Total Debt Amount as per the Financing agreements and the Power Producer shall completely cooperate in
any such takeover of the Project by Procurer. If Procurer, at its sole and exclusive
discretion agrees to enter upon and takeover the Project, till substitution of the Selectee in
accordance with this PPA, Procurer shall be compensated for rendering such services in
accordance with Article17.8 herein.
17.4.3 If Procurer refuses to take over the Project on request by the Lenders in accordance with
Article17.4.2 above, the Power Producer shall have the duty and obligation to continue to
operate the Project in accordance with the PPA till such time as the Selectee is finally
substituted under Article17.6.10 hereof. 17.4.4 The Lenders and Procurer shall, simultaneously have the right to commence the process of
substitution of the Power Producer by the Selectee in accordance with these terms and the
Power Producer hereby irrevocably consents to the same.
17.5 Process of Substitution of Power Producer
17.5.1 The Lenders‟ Representative may, on delivery of a Substitution Notice notify Procurer and
the Power Producer on behalf of all the Lenders about the Lenders‟ decision to invite and negotiate, at the cost of the Lenders, offers from third parties to act as Selectee, either through private negotiations or public auction and / or a tender process, for the residual period of the PPA. Subject to and upon approval of, such Selectee shall be entitled to
receive all the rights of the Power Producer and shall undertake all the obligations of the
Power Producer under the PPA and other Project Documents executed between the Power Producer and Procurer, in accordance with these terms of substitution.
RESCO Power Purchase Agreement
17.5.2 The Lenders and the Power Producer shall ensure that, upon Procurer approving the
Selectee, the Power Producer shall transfer absolutely and irrevocably, the ownership of the Project to such Selectee simultaneously with the amendment or novation of the PPA
and other Project Documents executed between the Power Producer and Procurer in
favour of the Selectee as mentioned in Article17.1.2.
17.6 Modality for Substitution
Criteria for selection of the Selectee:
17.6.1 The Lenders and / or the Lenders‟ Representative shall in addition to any other criteria that they may deem fit and necessary, apply the following criteria in the selection of the
Selectee:
a) if the Power Producer is proposed to be substituted during the Construction Period, the
Selectee shall possess the financial capability used to pre-qualify bidders in the RFQ stage
(including the methodology prescribed therein) to perform and discharge all the residual duties, obligations and liabilities under the PPA. If the Power Producer is proposed to be
substituted during the Operation Period, this criterion shall not be applicable. b) the Selectee shall have the capability and shall unconditionally consent to assume the
liability for the payment and discharge of dues, if any, of the Power Producer to Procurer under and in accordance with the PPA and also payment of the Total Debt Amount to the
Lenders upon terms and conditions as agreed to between the Selectee and the Lenders; c) the Selectee shall have not been in breach of any PPA between the Selectee and any
Bank or any Lender or between the Selectee and Procurer, involving sums greater than
Rupees fifty (50) lakhs at any time in the last two (2) Operational Years as on the date of the substitution of the Power Producer.
d) any other appropriate criteria, whereby continuity in the performance of the Selectee‟s obligations under the PPA is maintained and the security in favour of the Lenders under the
Financing agreements is preserved.
Modalities
The following modalities shall be applicable to any substitution of the Power Producer by the Selectee pursuant to this PPA: 17.6.2 The Lenders‟ Representative shall on behalf of the Lenders propose to Procurer (the
“Proposal”) pursuant to Article17.6.3 below, the name of the Selectee for acceptance, seeking:
a) grant of all the rights and obligations under the PPA and the other Project Documents
executed between Procurer and the Power Producer, to the Selectee (as substitute for the
Power Producer); b) amendment of the PPA and the other Project Documents executed between Procurer and
the Power Producer, to the effect that the aforementioned grant to the Selectee, shall be
such that the rights and obligations assumed by the Selectee are on the same terms and
conditions for the residual period of the PPA as existed in respect of the Power Producer under the original PPA and the other Project Documents executed between Procurer and
the Power Producer; and c) the execution of new PPAs as necessary, by the proposed Selectee for the residual period
of the PPA on the same terms and conditions as are included in this PPA.
17.6.3 The Proposal shall contain the particulars and information in respect of the Selectee the
data and information as any of Procurer may reasonably require. Procurer may intimate
any additional requirement within thirty (30) Days of the date of receipt of the Proposal.
17.6.4 The Proposal shall be accompanied by an unconditional undertaking by the Selectee that it shall, upon approval by Procurer of the Proposal:
a) observe, comply, perform and fulfil the terms, conditions and covenants of the PPA and all Project Documents executed between Power Producer and Procurer or a new power purchase PPA or respective Project Document (in the case of the novation thereof), which
according to the terms therein are required to be observed, complied with, performed and
fulfilled by the Power Producer, as if such Selectee was the Power Producer originally
named under the PPA; or the respective Project Document; and b) be liable for and shall assume, discharge and pay the Total Debt Amount or then
outstanding dues to the Lenders under and in accordance with the Financing agreements
RESCO Power Purchase Agreement
or in any other manner agreed to by the Lenders and Procurer as if such Selectee was the
Power Producer originally named under such Financing agreements.
17.6.5 At any time prior to taking a decision in respect of the Proposal received under Article17.6, Procurer may require the Lender / Lenders‟ Representative to satisfy it as to the eligibility of the Selectee. The decision of Procurer as to acceptance or rejection of the Selectee, shall be made reasonably and when made shall be final, conclusive and binding on the Parties.
17.6.6 Procurer shall convey its approval or disapproval of such Proposal to the Lender / Lender‟s Representative. Such decision shall be made by Procurer at their reasonably exercised
discretion within twenty one (21) Days of:
a) the date of receipt of the Proposal by the Procurers; or b) the date when the last of further and other information and clarifications in respect of any
data, particulars or information included in the Proposal requested by any of Procurer under Article17.6 above is received;whichever is later. If there is no decision ismade within twenty one (21) Days, it shall be considered as
deemed approval.
17.6.7 Notwithstanding anything to the contrary mentioned in this PPA, the approval of the Procurer for the Selectee shall not be withheld in case the Selectee meets the criteria
mentioned in Article17.6.
17.6.8 Upon approval of the Proposal and the Selectee by Procurer, the Selectee mentioned in
the Proposal shall become the Selectee hereunder.
17.6.9 Following the rejection of a Proposal, the Lenders and/or the Lenders‟ Representative shall have the right to submit a fresh Proposal, proposing another Selectee (if the rejection was
on the grounds of an inappropriate third party proposed as Selectee) within sixty (60) Days
of receipt of communication regarding rejection of the Selectee previously proposed. The
provisions of this Article shall apply mutatis mutandis to such fresh Proposal.
17.6.10 The substitution of the Power Producer by the Selectee shall be deemed to be complete
upon the Selectee executing all necessary documents and writings with or in favour of the
Power Producer, Procurer and the Lenders so as to give full effect to the terms and
conditions of the substitution, subject to which the Selectee has been accepted by the
Lenders and Procurer and upon transfer of ownership and complete possession of the
Project by Procurer or the Power Producer, as the case may be, to the Selectee. Procurer shall novate all the Project Documents, which they had entered in to with the Power Producer in order to make the substitution of the Power Producer by the Selectee effective. The quantum and manner of payment of the consideration payable by the Selectee to the
Power Producer towards purchase of the Project and assumption of all the rights and
obligations of the Power Producer under the PPA and the Project Documents as mentioned
in this PPA shall be entirely between the Power Producer, Selectee and the Lenders and
Procurer shall in no way be responsible to bear the same.
17.6.11 Upon the substitution becoming effective pursuant to Article17.6.10 above, all the rights of the Power Producer under the PPA shall cease to exist:
Provided that, nothing contained in this Article shall prejudice any pending / subsisting
claims of the Power Producer against a Procurer or any claim of Procurer against the
erstwhile Power Producer or the Selectee.
17.6.12 The Selectee shall, subject to the terms and conditions of the substitution, have a period
of ninety (90) Days to rectify any breach and / or default of the Power Producer subsisting
on the date of substitution and required to be rectified and shall incur the liability or consequence on account of any previous breach and / or default of the Power Producer.
17.6.13 The decision of the Lenders and Procurer in the selection of the Selectee shall be final and binding on the Power Producer and shall be deemed to have been made with the
concurrence of the Power Producer. The Power Producer expressly waives all rights to
object or to challenge such selection and appointment of the Selectee on any ground
whatsoever.
17.6.14 The Lenders shall be solely and exclusively responsible for obtaining any and all consents/approvals or cooperation, which may be required to be obtained from the Power Producer under this PPA and Procurer shall not be liable for the same.
RESCO Power Purchase Agreement
17.6.15 All actions of the Lenders‟ Representative hereunder shall be deemed to be on behalf of the Lenders and shall be binding upon them. The Lenders‟ Representative shall be authorised to receive payment of compensation and any other payments, including the
consideration for transfer, if any, in accordance with the Proposal and the Financing agreements and shall be bound to give valid discharge on behalf of all the Lenders.
17.7 Power Producer’s Waiver
17.7.1 The Power Producer irrevocably agrees and consents (to the extent to which applicable
law may require such consent) to any actions of the Lenders, the Lender‟s Representative and Procurer or exercise of their rights under and in accordance with these terms.
17.7.2 The Power Producer irrevocably agrees and consents (to the extent to which applicable
law may require such consents) that from the date specified in Article17.6, it shall cease to
have any rights under the PPA or the Financing agreements other than those expressly
stated therein.
17.7.3 The Power Producer warrants and covenants that any PPA entered into by it, in relation to
the Project, shall include a legally enforceable clause providing for automatic novation of such PPA in favour of the Selectee, at the option of the Lenders or Procurer. The Power Producer further warrants and covenants that, in respect of any PPAs which have already
been executed in relation to the Project and which lack a legally enforceable clause
providing for automatic novation of such PPA, the Power Producer shall procure an
amendment in the concluded PPA to incorporate such clause.
17.8 Interim Protection of Service and Preservation of Security
Appointment of a Receiver 17.8.1 In every case of the Lenders issuing a Substitution Notice and Procurer refusing to take
over the Project and the Power Producer failing to operate the Project in accordance with
Article17.4 above and Procurer not electing to act as Receiver as per Article17.8 below, the
Lenders may institute protective legal proceedings for appointment of a receiver (the
“Receiver”) to maintain, preserve and protect the assets held as security by the Lenders if such right is granted under the terms of the Financing agreements.
17.8.2 Provided that in event of Procurer refusing to take over the Project and the Power Producer failing to operate the Project in accordance with Article17.4 above, and if the assets of the
Project are, in the opinion of Procurer, necessary and required for the operation and
maintenance of the Project, Procurer shall be entitled to elect to act as the Receiver for the
purposes of this Article and be entitled to maintain, preserve and protect the said assets by
engaging an operator/service provider to act on their behalf and the Lenders and Power Producer hereby consent and agree to the same. Upon Procurer so intimating the Power Producer and the Lender‟s representative their desire to act as Receiver, the Power Producer and the Lender‟s representative shall co-operate with Procurer to facilitate the
same.
17.8.3 Upon appointment of the Court appointed Receiver or Procurer acting as Receiver, all the
Receivables received by such Receiver shall be deposited by the Receiver in the bank
account jointly designated by PROCURER and the Lenders. The Receiver shall be
responsible for protecting the assets in receivership and shall render a true and proper account of the receivership to the lenders in accordance with the terms of its appointment.
17.8.4 When acting as a Receiver or operator in accordance with this Article17.8 or Article17.4, Procurer shall be entitled to be remunerated for such services as may be determined by
Central Electricity Regulatory Commission. Furthermore, when acting as a Receiver, Procurer shall not be liable to the Lenders, the Lenders‟ Representative, Power Producer or any third party for any default under the PPA, damage or loss to the Power Station or for any other reason whatsoever, except for wilful default of Procurer.
17.9 Substitution Consideration
17.9.1 The Lenders and Procurer shall be entitled to appropriate any consideration received for the substitution of the Power Producer as hereinabove provided, from the Selectee towards
the payment of Lenders‟ and Procurer‟s respective dues, to the exclusion of the Power Producer.
17.9.2 The Power Producer shall be deemed to have nominated, constituted and appoints the
Lenders‟ Representative as its constituted attorney for doing all acts, deeds and things as
RESCO Power Purchase Agreement
may be required to be done for the substitution of the Power Producer by the Selectee
pursuant to these terms.
17.10 Change in Lenders
17.10.1 The Parties hereto acknowledge that during the subsistence of the PPA, it is
possible that any Lender may cease to remain as a Lender by reason of repayment of the
debt or otherwise. Further it may possible that any Lender may be substituted or a new
Lender may be added. In the event of any Lender ceasing to be a party to the PPA or Financing agreement respectively, the term and conditions as prescribed in this Articleshall cease to automatically apply to such Lender as the case may be. Further, upon any entity
being added as a Lender and in the event such entity is given the right to substitute the
Power Producer under the Financing agreement and then the contents of this Article shall be applicable to the exercise of such right by the said new entity.
ARTICLE 18: REPRESENTATIONS & WARRANTIES
18.1 Representations and Warranties of Procurer
18.1.1 Procurer hereby represents and warrants to and agrees with the Power Producer as
follows and acknowledges and confirms that the Power Producer is relying on such
representations and warranties in connection with the transactions described in this PPA:
18.1.2 Procurer has all requisite powers authorising and has been duly authorised to execute and
consummate this PPA;
18.1.3 This PPA is enforceable against Procurer in accordance with its terms;
18.1.4 The consummation of the transactions contemplated by this PPA on the part of Procurer will not violate any provision of nor constitute a default under, nor give rise to a power to
cancel any charter, mortgage, deed of trust or lien, lease, PPA, license, permit, evidence of indebtedness, restriction, or other contract to which Procurer is a party or to which Procurer is bound, which violation, default or power has not been waived;
18.1.5 Procurer is not insolvent and no insolvency proceedings have been instituted, nor threatened or pending by or against Procurer;
18.1.6 There are no actions, suits, claims, proceedings or investigations pending or, to the best of Procurer‟s knowledge, threatened in writing against Procurer at law, in equity, or otherwise, and whether civil or criminal in nature, before or by, any court, commission, arbitrator or governmental agency or authority, and there are no outstanding judgements, decrees or orders of any such courts, commission, arbitrator or governmental agencies or authorities, which materially adversely affect its ability to comply with its obligations under this PPA.
18.1.7 Procurer makes all the representations and warranties above to be valid as on the date of this PPA.
18.2 Representations and Warranties of the Power Producer
18.2.1 The Power Producer hereby represents and warrants to and agrees with Procurer as
follows and acknowledges and confirms that Procurer is relying on such representations
and warranties in connection with the transactions described in this PPA.
18.2.2 The Power Producer has all requisite power authorising and has been duly authorised to
execute and consummate this PPA;
18.2.3 This PPA is enforceable against the Power Producer in accordance with its terms;
18.2.4 The consummation of the transactions contemplated by this PPA on the part of the Power Producer will not violate any provision of nor constitute a default under, nor give rise to a
power to cancel any charter, mortgage, deed of trust or lien, lease, PPA, license, permit, evidence of indebtedness, restriction, or other contract to which the Power Producer is a
party or to which the Power Producer is bound which violation, default or power has not been waived;
18.2.5 The Power Producer is not insolvent and no insolvency proceedings have been instituted, or not threatened or pending by or against the Power Producer;
RESCO Power Purchase Agreement
18.2.6 There are no actions, suits, claims, proceedings or investigations pending or, to the best of Power Producer‟s knowledge, threatened in writing against the Power Producer at law, in
equity, or otherwise, and whether civil or criminal in nature, before or by, any court, commission, arbitrator or governmental agency or authority, and there are no outstanding
judgements, decrees or orders of any such courts, commission, arbitrator or governmental agencies or authorities, which materially adversely affect its ability to execute the Project or to
comply with its obligations under this PPA.
18.2.7 The Power Producer makes all the representations and warranties above to be valid as on
the date of this PPA.
ARTICLE 19: MISCELLANEOUS PROVISIONS
19.1 Amendment
19.1.1 This PPA may only be amended or supplemented by a written PPA between the Parties or their successor and permitted assign and after duly obtaining the approval of the
Appropriate authority, if necessary and relevant.
19.2 Third Party Beneficiaries
19.2.1 This PPA is solely for the benefit of the Parties and their respective successors and
permitted assigns and shall not be construed as creating any duty, standard of care or any
liability to, any person not a party to this PPA.
19.3 Industry Standard
19.3.1 Except as otherwise set forth herein, for the purpose of the PPA the normal standards of performance within the solar photovoltaic power generation industry in the relevant market shall be the measure of whether a Party‟s performance is reasonably and timely. Unless expressly defined herein, words having well-known technical or trade meaning or under popular market practice at the time of execution of PPA or meaning under Law shall be so
construed.
19.4 Waiver 19.4.1 No waiver by either Party of any default or breach by the other Party in the performance of
any of the provisions of this PPA shall be effective unless in writing duly executed by an
authorised representative of such Party.
19.4.2 Neither the failure by either Party to insist on any occasion upon the performance of the terms, conditions and provisions of this PPA nor time or other indulgence granted by one Party to
the other Parties shall act as a waiver of such breach or acceptance of any variation or the relinquishment of any such right or any other right under this PPA, which shall remain
in full force and effect.
19.5 Entirety
19.5.1 This PPA and the Schedules/ Annexures are intended by the Parties as the final expression of their PPA and are intended also as a complete and exclusive statement of the terms of their PPA.
19.5.2 Except as provided in this PPA, all prior written or oral understandings, offers or other communications of every kind pertaining to this PPA or the sale or purchase of solar energy under this PPA to Procurer by the Power Producer shall stand superseded and
abrogated.
19.6 Confidentiality 19.6.1 The Parties undertake to hold in confidence this PPA and not to disclose the terms and
conditions of the transaction contemplated hereby to third parties, except: a) to their professional advisors; b) to their officers, contractors, employees, agents or representatives, financiers, who
need to have access to such information for the proper performance of their activities; or c) disclosures required under Law. d) without the prior written consent of the other Party.
19.6.2 Provided that the Power Producer agrees and acknowledges that Procurer may at any
time, disclose the terms and conditions of the PPA and the Project Documents to any
person, to the extent stipulated under the Law.
RESCO Power Purchase Agreement
19.7 Affirmation
19.7.1 The Power Producer and Procurer, each affirm that:
a) neither it nor its respective directors, employees, or agents has paid or undertaken to
pay or shall in the future pay any unlawful commission, bribe, pay-off or kick-back; and b) it has not in any other manner paid any sums, whether in Indian currency or foreign
currency and whether in India or abroad to the other Party to procure this PPA, and the
Power Producer and Procurer hereby undertake not to engage in any similar acts
during the Term of PPA.
19.8 Severability
19.8.1 The invalidity or unenforceability, for any reason, of any part of this PPA shall not prejudice or affect the validity or enforceability of the remainder of this PPA, unless the part held
invalid or unenforceable is fundamental to this PPA or remainder of this PPA.
19.9 No Partnership
19.9.1 None of the provisions of this PPA shall constitute a partnership or agency or any such
similar relationship between the Power Producer and Procurer.
19.10 Notices
19.10.1 All notices or other communications which are required to be given under this PPA shall be in writing and in the English language.
19.10.2 If to the Power Producer, all notices or other communications which are required must be
delivered personally or by registered post or facsimile or any other method duly
acknowledged to the address(es) below:
Address : Attention : Email : Fax. No. : Telephone No. : 19.10.3 If to Procurer, all notices or communications must be delivered personally or by
registered post or facsimile or any other mode duly acknowledged to the address(es) below:
Address : Attention : Email : Fax. No. :Telephone No. : 19.10.4 All notices or communications given by e-mail or facsimile shall be confirmed by sending a
copy of the same via post office in an envelope properly addressed to the appropriate Party
for delivery by registered mail. All notices shall be deemed validly delivered upon receipt evidenced by an acknowledgement of the recipient, unless the Party delivering the
notice can prove in case of delivery through the registered post that the recipient refused to
acknowledge the receipt of the notice despite efforts of the postal authorities.
19.10.5 Any Party may by notice of at least fifteen (15) Days to the other Party change the
address and/or addresses to which such notices and communications to it are to be
delivered or mailed.
19.11 Language
19.11.1 All correspondence and communications between the Parties relating to this PPA and all other documentation to be prepared and supplied under the PPA shall be written in
English, and the PPA shall be construed and interpreted in accordance with English
language convention and practice.
19.11.2 If any of the correspondence, communications or documents is prepared in any language
other than English, the English translation of such correspondence, communications or documents shall prevail in matters of interpretation.
19.12 Breach of Obligations
19.12.1 The Parties acknowledge that a breach of any of the obligations contained herein would
result in injuries as per Law. The Parties further acknowledge that the amount of the
Liquidated Damages or the method of calculating the Liquidated Damages specified in
this PPA is a genuine and reasonable pre-estimate of the damages that may be suffered
by the non-defaulting party in each case specified under this PPA.
19.13 Nomination Restriction
RESCO Power Purchase Agreement
19.13.1 Notwithstanding anything contained to the contrary in this PPA, wherever a reference is
made to the right of a Procurer to nominate a third Party to receive benefits under this
PPA, such third party shall have a financial standing comparable to that of Procurer.
19.14 Commercial Acts
19.14.1 Procurer and Power Producer unconditionally and irrevocably agree that the execution, delivery and performance by each of them of this PPA to which it is a Party constitute private
and commercial acts rather than public or governmental acts.
19.15 Restriction of Shareholders / Owners’ Liability
19.15.1 Parties expressly agree and acknowledge that none of the shareholders of the Parties hereto
shall be liable to the other Parties for any of the contractual obligations of the concerned
Party under this PPA. Further, the financial liabilities of the shareholder/s of each Party to
this PPA, in such Party, shall be restricted to the extent provided in Section 426 of the Indian Companies Act, 1956 as amended or replaced.
19.15.2 The provisions of this Article19.15 shall supersede any other prior PPA or understanding, whether oral or written, that may be existing between Procurer, Power Producer, shareholders/ owners of the Power Producer or shareholders/ owners of Procurer before the
date of this PPA, regarding the subject matter of this PPA. 19.16 No Consequential or Indirect Losses
19.16.1 The liability of the Power Producer and Procurer shall be limited to that explicitly provided in
this PPA. Provided that notwithstanding anything contained in this PPA, under no
event shall Procurer or the Power Producer claim from one another any indirect or consequential losses or damages.
19.17 Independent Entity
19.17.1 The Power Producer shall be an independent entity performing its obligations pursuant to
the PPA or/ and RFP.
19.17.2 Subject to the provisions of the PPA or/ and RFP, the Power Producer shall be solely
responsible for the manner in which its obligations under this PPA or/ and RFP are to be
performed. All employees and representatives of the Power Producer or contractors
engaged by the Power Producer in connection with the performance of the PPA or/ and RFP
shall be under the complete control of the Power Producer and shall not be deemed to be
employees, representatives, contractors of Procurer and nothing contained in the PPA or/ and RFP or in any PPA or contract awarded by the Power Producer shall be construed to
create any contractual relationship between any such employees, representatives or contractors and Procurer.
19.18 Taxes and Duties
19.18.1 The Power Producer shall bear and promptly pay all statutory taxes, duties, levies and
cess, assessed/ levied on the Power Producer, contractors or their employees, which are
required to be paid by the Power Producer as per the Law in relation to the execution of the PPA or/ and RFP and for generation/ supply/ sale of solar energy as per the terms of this
PPA or/ and RFP.
19.18.2 Procurer shall be indemnified and held harmless by the Power Producer against any
claims that may be made against Procurer in relation to the matters set out in
Article19.18.1.Procurer shall not be liable for any payment of, taxes, duties, levies, cess
whatsoever for discharging any obligation of the Power Producer by Procurer on behalf of Power Producer.
19.18.3 The financial bid should include all taxes and duties etc., if any. Power Producer shall be
entirely responsible for all taxes, duties, license fees, etc. However, if any new change in
tax/duty and cess is effected in the period after the Financial Bid Submission Deadline
and any time during the period of Agreement, the same will be passed on by the Power Producer to the Procurer as determined by the Competent Authority.
To evaluate impact of any change of laws in future, the rates applicable for each
component shall be considered as:-
Material Component in the capital cost- 80% of the Benchmark capital cost as
notified by MNRE for the year 2020-21. This will include the cost of Solar Cells
as 26% of the above referred benchmark capital cost
Erection, Installation and Commissioning (I&C) component- 20% of the
RESCO Power Purchase Agreement
Benchmark capital cost and
Yearly operational cost will be considered as 3% of the Benchmark capital cost
The Quoted Tariff would be adjusted as below based on the variations in the capital cost and operational cost on account of change in taxes. Adjustment shall be allowed
only if the extent of variation in taxes is beyond the deviations specified in table below:
Variation due
to change in
taxes
Proportionate
adjustments to
the tariff
Effective Timelines
Capital Cost
(Adjustments will be
considered only if the change is more
than 2.5%)
+ X%
+ 0.8 X%
If the relevant change is
notified after Financial Bid
submission deadline till 3
months prior to the
Scheduled Completion date
as per the terms of PPA
Operational Cost (Adjustments will be
made only if change is more
than 5%)
+ Y%
+ 0.1 Y%
If the relevant change is
notified after Financial Bid
submission deadline, adjustments in tariff shall be
provided till the time such
change is in force.
19.19 Compliance with Law
19.19.1 Despite anything contained in this PPA but without prejudice to this Article, if any
provision of this PPA shall be in deviation or inconsistent with or repugnant to the
provisions contained in the Electricity Act, 2003, or any rules and regulations made there
under, such provision of this PPA shall be deemed to be amended to the extent required
to bring it into compliance with the aforesaid relevant provisions as amended from time to
time. IN WITNESS WHEREOF the Parties have caused the PPA to be executed through their duly
authorized representatives as of the date and place set forth above.
For and on behalf of [Procurer]
For and on behalf of [Power Producer]
Name: Designation: Address:
Name: Designation: Address:
Signature with seal
Witness:
1.
2.
Signature with seal
Witness:
1.
2.
RESCO Power Purchase Agreement
SCHEDULE1:SCOPEOFWORK
1. DETAILS OF WORKS: 1.1. Designing, engineering, supply, installation, testing and Commissioning of various capacities of
Project as per standard design and specifications and connecting up to existing Mains /ACDB and
interfacing internal electrical loads of Project with licensee’s network/electrical loads with
Comprehensive O&M for period of twenty five (25) Operational Years for Sale of Solar Power.
Power Producer would have to take approval for the interfacing the Project with
Grid/Electrical Loads of every location from distribution licensee/ CEIG, as applicable.
Comprehensive O&M for twenty five (25) Operational Year shall be required for each of the
Project. Bidder shall be responsible for all the works related to Commissioning and operation for
twenty five (25) Operational Years of Project. In no case, DOP Govt Secretariat shall be
responsible to pay or increase in tariff for any work related to Project. It is clarified that the projects awarded under this RFP would not include energy storage with
rooftop solar project. However, if DOP desires to have such arrangement, it would need to pay
separately for the battery storage, and associated change in design and civil and electrical works.
Such arrangement would not affect the tariff discovered for sale of power under this RFP. 1.2. THE SCOPE OF WORK SHALL ALSO INCLUDE THE FOLLOWING:
A layout plan of the site should be submitted to the Inspecting Authority clearly indicating the
identified location for installation of SPV modules & control room, where control panels shall be
installed. The Power Producer shall also submit (a) The mode in which the system will operate is in accordance with the provisions of Rajasthan
Electricity Regulatory Commission (Connectivity and Net Metering for Rooftop and Small Solar
Grid Interactive Systems) Regulations 2015 issued by RERC vide Notification Dated: 26-02-
2015 as amended from time to time;
(b) Detailed planning of time bound smooth execution of Project;
(c) Performance testing of the Completion and Successful Commissioning of the
Project;
(d) Comprehensive O & M of the Project for twenty five (25) Operational Year to assure
faultless operation, and inventory maintenance;
(e) Supply of Power from Commissioning to Termination or for twenty five (25) Operational
Years;
(f) Coverage of risk liability of all personnel associated with implementation and realization of the
Project;
(g) The Power Producer shall maintain sufficient inventory of the spare parts to ensure that
the Project is functional during the term of PPA;
(h) The Power Producer shall done sun path analysis of the whole project and submit the sun path
analysis DOP in soft and hard copy for approval.
(i) The Power Producer is responsible for the waterproofing of the roof disturbed/
pierced for installation of Project for the Comprehensive O&M period of first 5 Operational Years. The Power Producer should immediately take necessary action to repair any damage to the water proofing. However, in such situations, Power Producer shall bear any loss or damage to Project and rectify the same within reasonable time frame but any generation loss in such eventualities shall not be . If Power Producer fails to do required water proofing within 7 days from the day of identification of issue, DOP may get the same done at prevailing market rate and Power Producer shall reimburse the same to DOP. If the Power Producer fails to reimburse the expenses to the DOP then such expenses shall be adjusted by the DOP from the energy bills of the next months.
RESCO Power Purchase Agreement
Power Producer shall be responsible for O &M of the Project from the first Part Commissioning
or SCOD, whichever is earlier, to the completion of twenty five (25) Operational Years.
(j) The solar plant on the North west parking shall be installed at roof top on super structure not
less that 8 feet in height as per site requirement. The cost of super structure shall be included
in the project, no extra payment shall be done for super structure.
The solar structure on North West parking building should be designed in a way that the vehicles
parked on the roof are protected from exposure to water in rainy days and sunlight. The power
producer shall use fiber sheet below solar panel for water protection.
Power Producer shall intimate the DOP the total weight of the solar system to be installed at site
for determining roof load bearing feasibility including the weight of super structure.
1.3. INTERNAL ELECTRIFICATION: Inspection of the existing electrical network of each of the Project site;
Inspection of the Project in respect of its interfacing with licensee network/
identified electrical load;
Preparation and submission of electrical drawing for the site with quantity of material
required;
Obtaining prior approval of the work and drawing from Inspecting Authority; Execution of the
work in accordance with the norms and regulation directives for testing and completion of the
Project to the satisfaction of the DOP Govt Secretariat.
Solar plant will be installed on the following buildings:-
7. North west parking roof
8. SSO building roof.
9. Food building roof.
10. Minister block roof.
11. Archieve block roof.
12. Library block roof.
If solar plant capacity of 970 KWp will not fulfill on these area then Main building roof
will be used.
The Power Producer shall take care necessary precaution of already installed various
equipment on the roof for installing solar plant, If any damage to installed equipment will
be done by Power Producer then its cost will be recovered from power producer.
The Power producer shall check incoming cable & switch gear size at the point of
solar plant connectivity, If incoming cable & switch gear size is not sufficient as per solar plant
capacity then power producer shall intimate the DOP for insufficient size of the incomer cable
& switch gear and DOP shall provide the suitable size incomer cable & switch gear at site.
On the SSO building old unusable solar plant of 25 KW is already installed at roof,
power producer shall dismental old plant and deposit old material in DOP before new
installation.
In the CMO building 25 KW solar power plant is already working from last 3 years.
1.4. GRID CONNECTION: The Power Producer shall be responsible for synchronization of the Project with licensee’s network
under Rajasthan Electricity Regulatory Commission
(Connectivity and Net Metering for Rooftop and Small Solar Grid Interactive Systems)
Regulations 2015 issued by RERC vide Notification Dated: 26-02-2015 as amended from time
to time.
1 . 5 METERING AND GRID CONNECTIVTY:
Metering and grid connectivity of the Projects would be the responsibility of the Power
Producer in accordance with the prevailing guidelines of the concerned distribution licensee and /
or CEA and net metering provisions in the state of Rajasthan. DOP Govt Secretariat may
facilitate in the process; however t he entire responsibility lies only with the Power Producer. The
cost of required meters shall be borne by Successful Bidder (Power Producer).This includes
purchase of net meters under Rajasthan Electricity Regulatory Commission(Connectivity and Net
RESCO Power Purchase Agreement
Metering forRooftop and Small Solar Grid Interactive Systems) Regulations 2015 issued by
RRECL vide Notification Dated: 26-02-2015 as amended from time to time.
The Power Producer shall install the Generation Meter separately near the output of Inverter
and Net-Meter shall be located in place of present discom’s metering system. There are two 33
KV HT connection in the secretariat, and the present installed meters are leading power factor
blocking meters, The Power Producer shall install leading power factor blocking Net Meter for
both the connections.
Meters and metering equipment shall be tested as per provision of RERC and as per IS 14697
at CPRI or at any NABL accredited/distribution licensee lab before installation at site on the cost
of power producer and should be properly sealed in the presence of designated authority from
DOP at the time of installation.
The accuracy class, current rating and certifications of the net meter and generation
meter shall confirm with the standards for net meter and standards for generation meter as provided
by Rajasthan Electricity Regulatory Commission (Connectivity and Net Metering for Rooftop
and Small Solar Grid Interactive Systems) Regulations 2015 issued by RERC vide Notification
Dated: 26-02-2015 as amended from time to time. 1.6. INSURANCE:
The Power Producer shall also take insurance for third party liability covering loss of human
life, engineers and workmen and also covering the risks of damage, theft of material/ equipment/
properties after completion of the work(s). Before commencement of the work, the Power
Producer shall ensure that all its employees and representatives are covered by suitable
insurance against any damage, loss, injury or death arising out of the execution of the
work. Liquidation, Death, Bankruptcy etc., shall be the responsibility of Power
Producer.
1.7. WARRANTY AND GUARANTEES: The Bidder shall warrant that the goods supplied under this Agreement are new, unused, of the most
recent or latest technology and incorporate all recent improvements in design and materials as per
standards specified in the technical specifications of this RFP.
The Power Producer shall provide warranty covering the rectification of any and all defects in the
design of equipment, materials and workmanship including spare parts for a period of twenty
five (25) Operational Years.
The responsibility of operation of warranty and guarantee clauses and claims/ settlement of issues
arising out of said clauses shall be responsibility of the Power Producer and DOP will not be
responsible in any way for any claims whatsoever on account of the above. 1.8. TYPE AND QUALITY OF MATERIALS AND WORKMANSHIP:
The design, engineering, manufacture, supply, installation, testing, commissioning
and performance of the equipment shall be in accordance with latest/ appropriate IEC/Indian
Standards as detailed in the technical specifications of this RFP or its subsequent amendments.
Where appropriate Indian Standards and Codes are not available, other suitable standards and
codes as approved by the MNRE/ CEA/ electricity regulators/ DOP Govt Secretariat shall be
used. the
relevant test certifications must be kept valid up to one (1) Year from the COD of the Project.
The specifications of the components should meet the technical specifications mentioned
in this RFP or its subsequent amendments. Any supplies which have not been specifically mentioned in this RFP but which are
necessary during construction or Comprehensive O&M period of the Project shall be
provided by the Power Producer without any extra cost and within the time schedule for
efficient and smooth construction and Comprehensive O &M of the Project.
1.9. CONSTRUCTION OF CONTROL ROOM ETC. Construction of control room or any other relative civil work essential for
Commissioning of Project; 1.10. ADDITIONAL WORKS
RESCO Power Purchase Agreement
Any Additional civil, structural or electrical works required for completion of installation of solar
panel power plant will be in the scope of the bidder.
1.11. PROVISION OF SIGN BOARD Power Producer will have to provide sign board of dimension 6’x4’ s ize (M.S. sheet) of 16
gauge, o n M.S. angle o f s i z e 40x40x5 mm with essential bracing & adequate grouting
with PCC 1:3:6 i/c painting & writing) at each site with complete specification & matter
will be installed at site with PPA. 1.12. COMPLETION AND COMMISSIONING 1.12.1.1. Part Commissioning is allowed for all the Project.
1.12.1.2. Power Producer, in coordination with the Discom, shall submit Commissioning certificate,
issued by the concerned Discom, in accordance with all applicable regulations/policies.
1.12.1.3. Further, DOP shall issue the Commissioning Certificate for the capacity of the Project
Completed on issuance of Completion Certificate for capacity.
1.12.1.4. In case of Part Commissioning, Power Producer shall be required to submit all the above
mentioned requisites with submission of every Part Commissioning of capacity. For the
purpose of obtaining Completion certificate following documents shall be required: (a) Inspection Report of the Work(s) for all equipments/material
(b) CEIG Approval for the PPA Capacity or part thereof, if applicable;
In case of part Completion, Power Producer shall be required to submit all the above
mentioned requisites with request for every part capacity Completion.
RESCO Power Purchase Agreement
SCHEDULE 2: TECHNICAL SPECIFICATIONS
AS PROVIDED IN RFP DOCUMENT
SCHEDULE 3: TARIFF SCHEDULE
Operational Year
Financial Bid for Project (INR/kWh)
1 to 25 Years LCoE = Rs. per kWh(Quoted Fixed Tariff)
1. Quoted Fixed Tariff must be applicable for sale of Solar Power to Procurer from Initial Part
Commissioning to twenty-five (25) Operational Years, Bidder to provide the Quoted Fixed
Tariff up to 4 decimal places.
2. Quoted Fixed Tariff shall remain fixed for twenty-five (25) Operational Years of the Project.
3. The above Quoted Fixed Tariff is inclusive of any applicable taxes. However, if any new
change in tax/duty is effected in the period after the Bid Deadline and any time during the
period of Agreement, the same will be passed on by the Power Producer to the Procurer.
4. Further, for clarification, PPA shall be signed for individual Projects and Quoted Fixed Tariff
shall remain the same for all Projects. However, it shall be applicable in accordance with
respective dates of COD.
SCHEDULE 4: COD SCHEDULE
COD Schedule from the Date of Signing of PPA
S. No.
Milestone (Activity to be Performed)
Day
1.
Fulfilment of Condition Precedent
T
2.
T + [1 Month]
3.
T + [2 Month]
4.
T + [3 Month]
5.
T + [4 Month]
6.
T + [5 Month]
7.
T + [6 Month]
8.
T + [7 Month]
9.
T + [8 Month]
10.
COD
T + [9 Month]
Note: The COD should be within overall period of 05 months from the date of issuance of
LoA by the DOP.
RESCO Power Purchase Agreement
ANNEXURE 1: LETTER FROM DOP CONFIRMING THE CAPACITY
RESCO Power Purchase Agreement
FORMAT-1: FULFILLMENT CERTIFICATE This is to certify that, Power Producer has installed a kWp Part Capacity/ PPA Capacity
of Project on the Premise of the Procurer in accordance with the RFP and executed PPA dated
. The key features of the Part Capacity/ PPA Capacity is as follows:
S. No
Parameter
Description
1.
System Size Installed
kWp
2.
Expected Annual Energy Generation
3.
Module Type
No. of Module installed:
Module Supplier Name:
Capacity (kWp):
4.
Inverter Type & Rating
No. of Inverter:
Supplier Name:
Capacity (kW or kVA)
5.
Combiner Box
Number:
Supplier:
6.
Electrical Parameter for interconnection
7.
Mounting type
8.
Surface Azimuth Angle
9.
Tilt Angle
10.
Wind Resistance
11.
Remote Monitoring System
12.
Net Metering, if required for that part of
capacity
13.
Sign Board
14.
Danger Board
15.
Internal wiring upto use points, if required
16.
Any additional work done, please specify
The Power Producer shall provide a Remote Monitoring System (RMS) to DOP/ Procurer as
prescribed in RFP and/or PPA.
RESCO Power Purchase Agreement
FORMAT 2: FORMAT FOR CONSTRUCTION PERFORMANCE BANK GUARANTEE
(To be on non-judicial stamp paper of Minimum Rs. 1000/-)
In consideration of the [Insert name
of the Bidder] (hereinafter referred to as (Bidder) submitting the response to Request for Proposal
(RFP) for Selection of Bidders for Implementation of Grid Connected Roof Top Solar PV Projects for
Sale of Solar Power aggregating to about kWp under RESCO Model at various locations in
the state of Rajasthan in response to the RFP against NIT TN:05/2019-20 dated 05.09.2019 and this
PPA issued by Joint Secretary, DOP (B), Govt. Secretariat Jaipur (hereinafter referred to as
DOP) and Nodal Agency considering such response to the RFP of
[insert the name of the
Power Producer] (which expression shall unless repugnant to the context or meaning thereof include
its executers, administrators, successors and assignees) and selecting the Project of the Power
Producer and issuing LICA No. to
(Insert Name of Power Producer) as per
terms of RFP and the same having been accepted by the selected Project Company, M/s
{a Special Purpose Vehicle
(SPV) formed for this purpose}, if applicable]. As per the terms of the RFP, the
[insert
name & address of bank] hereby agrees unequivocally, irrevocably and unconditionally to pay to
DOPat [Insert Name of the Place from the address of the DOP
Govt. Secretariat] forthwith on demand in writing from DOP Govt. Secretariat, or any officer
authorized by it in this behalf, any amount upto and not exceeding Rupees
[Rupees (Total Value in
words)] only, on behalf of M/s [Insert name of the Power Producer / Project Company].This
guarantee shall be valid and binding on this Bank up to and including _and shall not
be terminable by notice or any change in the constitution of the Bank or the term of Agreement or by
any other reasons whatsoever and our liability hereunder shall not be impaired or discharged by any
extension of time or variations or alternations made, given, or agreed with or without our knowledge
or consent, by or between parties to the respective Agreement.
Our liability under this Guarantee is restricted to Rupees _(both in numbers
and words)
This Bank Guarantee shall remain in force until fourteen (14) months from the date of its issue.
DOPshall be entitled to invoke this Guarantee with an additional claim period of six (6) months. This
BANK GUARANTEE may be extended as deemed necessary. The Guarantor Bank hereby
agrees and acknowledges that DOPshall have a right to invoke this BANK GUARANTEE in part or
in full, as it may deem fit.
The Guarantor Bank hereby expressly agrees that it shall not require any proof in addition to the
written demand by DOP, made in any format, raised at the above mentioned address of the
Guarantor Bank, in order to make the said payment to DOP Govt. Secretariat.
The Guarantor Bank shall make payment hereunder on first demand without restriction or
conditions and notwithstanding any objection by [Insert name of the Power Producer. The
Guarantor Bank shall not require DOP Govt. Secretariat to justify the invocation of this
BANK GUARANTEE, nor shall the Guarantor Bank have any recourse against DOP in respect of
any payment made hereunder.
This BANK GUARANTEE shall be interpreted in accordance with the laws of
India and the courts at Jaipur shall have exclusive jurisdiction.
The Guarantor Bank represents that this BANK GUARANTEE has been
established in such form and with such content that it is fully enforceable in
accordance with its terms as against the Guarantor Bank in the manner provided
herein.
This BANK GUARANTEE shall not be affected in any manner by
reason of merger, amalgamation, restructuring or any other change in the
constitution of the Guarantor Bank.
This BANK GUARANTEE shall be a primary obligation of the Guarantor Bank
and accordingly DOPshall not be obliged before enforcing this BANK
GUARANTEE to take any action in any court or arbitral proceedings against the
selected Power Producer / Project Company, to make any claim against or any
demand on the Power Producer or to give any notice to the Power Producer /
Project Company or to enforce any security held by DOP Govt. Secretariat or to
exercise, levy or enforce any distress, diligence or other process against the
Power Producer / Project Company.
Notwithstanding anything contained hereinabove, our liability under this
Guarantee is restricted to Rupees (Rupees
only) and it shall remain in force until we are liable to pay the guaranteed amount
or any part thereof
under this Bank Guarantee only if DOP Govt. Secretariat serves upon us a written claim or demand.
Signature
Name
Power of Attorney No. For
[Insert Name of the Bank]
Banker's Stamp and Full Address. Dated this day of _, 20
Witness:
Signature
Name and Address_
Signature
Name and Address_
jktLFkku ljdkj dkfeZd ¼[k&3½ foHkkx
dzekad% i- 01¼08½ dkfeZd@[k&3@xzhfclS@2018 t;iqj] fnukad %& vk;qDr] lwpuk ,oa tu&lEidZ vk;qDrky;] t;iqjA fo"k; %& fufonk izdkf'kr djk, tkus ckcrA egksn;] funsZ'kkuqlkj vuqjks/k gS fd layXu fufonk lwpuk dks fu;ekuqlkj nSfud lekpkj i=ksa esa rRdky izdkf'kr djokdj izdkf'kr lekpkj i= dh ,d izfr bl foHkkx dks fHktokus dh O;oLFkk djkosa] lkFk gh fufonk lwpuk] fufonk izi= ,oa 'krksZ dks osc lkbZV ij izdk'ku gsrq lkWQ~V dkWih Hkh layXu dj Hksth tk jgh gSA layXu % nks izfr;kWa ,oa lkWQ~V dkWihA Hkonh; la;qDr 'klu lfpo izfrfyfi %& 1- vo/kkrk] 'kklu lfpoky;] t;iqj dks uksfVl cksMZ ij yxk, tkus gsrq izsf"kr gSA 2- ,ukfyLV de izksxzkej ¼mi funs'kd] dEI;wVj½ dkfeZd foHkkx dks foHkkxh; osclkbZV ij fufonk lwpuk]
fufonk izi= ,oa 'krksZ dks izdkf'kr fd, tkus gsrq [email protected] Hkst fn;k x;k gSA
3- jkT; yksd mikiu iksVZy (http://sppp.raj.nic.in) ij fufonk lwpuk] fufonk izi= ,oa 'krksZ ds izdkf'kr fd, tkus gsrq e; lkWQ~V dkWih esa izsf"kr gSA
iath;d