Upload
others
View
3
Download
0
Embed Size (px)
Citation preview
Sebring Airport Authority
Board Meeting Agenda
Telephonic Technology - Conference Call
May 21, 2020
1:00p.m. Hendricks Field
Sebring Airside Center
1. OPENING ITEMS a) Call to Order
Executive Order No. 20-52, issued by the Office of Governor Ron Desantis on March
9, 2020, declared a state of emergency in Florida and that order remains in effect
today. Pursuant to Executive Order No. 20-69 issued by the Office of Governor Ron
Desantis on March 20, 2020, , as extended by Executive Order No. 20-112, local
government bodies may conduct meetings of their governing boards without having
a quorum of its members present physically or at any specific location, and utilizing
communications media technology such as telephonic or video conferencing, as
provided by Section 120.54(5)(b)2, Florida Statutes.
During this virtual meeting, please place your phone on mute when you are not
speaking, to minimize potential background noise.
The public will be afforded an opportunity to address this Board today on all items on
the agenda, but please do so only when I call for public input.
When you address the Board, please identify yourself so we can have a clear record
of today's meeting
b) Invocation c) Roll Call d) Identify Callers e) Set the Agenda f) Election of Officers g) Announcements
Upcoming Meetings & Events
Date Time Meeting/Event Location 6/18/2020 1:00pm SAA/CRA Board Meeting Virtual Meeting
Interested persons may attend that meeting by calling 754-837-9893 and entering the following conference code 148-135-115#.
2. CONSENT AGENDA a) Approve April Minutes b) Approve April Invoices
3. MISCELLANEOUS
4. ACTION ITEMS a) Aviation Consultant Service Contracts-AVCON, Atkins Global, AECOM and Amherst
Consulting Company b) RFP #20-01 Terminal HVAC Improvements - Recommendation and Contract - Johnson
Controls
c) Resolution 20-09 Approving Budget Amendment 520-05 d) SEF Track Reconstruction - RWSummers - Final Change Order #8
CONTINGENT ACTION ITEMS e) Lease Rent Deferrals f) Sebring Aviation Lease Amendment
5. EXECUTIVE DIRECTOR MONTHLY SUMMARY FBO Report - Jason Ali
6. BOARD OF DIRECTORS' BUSINESS
7. CONCERNS OF THE PUBLIC
8. EMERGENCY BUSINESS
9. ADJOURNMENT
If a person decides to appeal any decision made by the Board at any meeting or hearing, he will need a verbatim record of the proceedings. The record must include the testimony and
evidence upon which the appeal is to be based. Sebring Airport Authority also gives notice that the Chairman is authorized to cancel or postpone any scheduled meeting or hearing by directing the Executive Director to so inform all Board members and any other interested parties and the press. Sebring Airport Authority does not discriminate upon the basis of any individual's disability status. This non-discriminatory policy involves every aspect of the Board's functions, including one's access to, participation in, employment of, or treatment in its programs or activities. Anyone requiring reasonable accommodations as provided for in the Americans with Disabilities Act should contact Beverly K. Glarner, Sebring Airport Authority at 863-314-1301. IF HEARING OR VOICE IMPAIRED, PLEASE CALL THE EXECUTIVE OFFICES THROUGH FLORIDA RELAY SERVICE AT 711: (TTY) 1-800-955-8771, OR VOICE (V) 1-800-955-8770, VIA FLORIDA RELAY SERVICE.
SEBRING AIRPORT AUTHORITY BOARD MEETING
April 16, 2020
The Sebring Airport Authority Board of Directors held a scheduled Board Meeting on April I 6, 2020 at 1 :00 p.m. by telephone-=technology conference call. A quorum was met with the following in attendance:
Stanley Wells Chairman Craig Johnson Secretary Pete McDevitt Asst. Secretary Carl Cool Board Member Sid Valentine Board Member Mark Andrews Board Member
Also
Mike Willingham Executive Director Beverly G ia.mer Executive Assistant Colleen Polonsky Director of Finance Bob Swaine Swaine and Harris Jason Ali Volo Aviation Kevin McCauley Atkins Craig Sucich AVCON Tricia Fantinano Amhurst Consulting
1. OPENING ITEMS
A. Meeting was called to order at 1 :00 p.m.
B. Roll Call Craig Johnson, Stanley Wells, Mark Andrews, Sid Valentine, Carl Cool and Pete McDevitt were present for the meeting. Terrill Morris was absent.
C. The Invocation were led by Bob Swaine.
D. Set the Agenda Craig Johnson made a motion to set the Agenda with a second to the motion by Pete McDevitt. Bob Swaine asked the Chairman to please add Item n. Executive Director Mike Willingham ratification. Craig Johnson amended his motion to set the amended Agenda with a second to the amended motion by Pete McDevitt. The motion passed with aye votes from McDevitt, Andrews, Johnson Cool, Valentine and Wells.
E. Announcements Interested person may attend SAA/CRA Board Meeting by calling 754-837-9893 and entering conference code 148-135-1 I 5#.
2. CONSENT AGENDA Approve the Consent Agenda: There was a motion by Craig Johnson to approve the Consent Agenda and a second by Mark Andrews. The motion was passed with aye votes by Wells, McDevitt, Johnson, Valentine and Andrews. Cool abstained.
3. MISCELLANEOUS Presentation by Ju lie Fowler - Annual Audit
4. ACTION ITEMS A. Sebring Storm Water Facility - FOOT Grant Mike Willingham presented this item. Pete McDevitt made a motion to approve with a second to the motion by Mark Andrews. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
B. Declaration of Covenants Mike Willingham presented this item. Carl Cool made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool , Valentine and Johnson.
C. Project Assistance Agreement -Airfield marking Project (Runway 14-32 & 1-19) Mike Willingham presented this item. Craig Johnson made a motion to approve with a second to the motion by Mark Andrews. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool , Valentine and Johnson.
D. Volo Management Sebring, LLC Mike Willingham presented this item. Craig Johnson made a motion to approve with a second to the motion by Pete McDevitt. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
E. Resolution 20-03 Approving Budget Amendment S20-03 Colleen Plonsky presented this item. Pete McDevitt made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool , Valentine and Johnson.
F. SEF Track Reconstruction - Change Order #7 Mike Willingham presented thi s item. Pete McDevitt made a motion to approve with a second to the motion by Mark Andrews. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
G. Hancor-Advanced Drainage System - Lease Amendment #7 Mike Willingham presented this item. Craig Johnson made a motion to approve with a second to the motion by Pete McDevitt. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
H. RFQ 20-01 Webster Turn Reconstruction -Award Recommendation Mike Willingham presented this item. Carl Cool made a motion to approve with a second to the motion by Pete McDevitt. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
I. Resolution 20-04 Wauchula State Bank - Building 22 Bob Swaine presented this item. Pete McDevitt made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
J. Resolution 20-07 Approving Budget Amendment S20-04 Colleen Plonsky presented this item. Carl Cool made a motion to approve with a second to the motion by Mark Andrews. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
K. Apron Rehab Project - GLF - Final Change Order Craig Sucich presented this item. Pete McDevitt made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
L. Resolution 20-05 FAA Grants Electronic Execution Mike Willingham presented this item. Pete McDevitt made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
M. Resolution 20-06 FOOT Grants Electronic Execution Mike Willingham presented this item. Carl Cool made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool , Valentine and Johnson.
N. Executive Director - Signing Documents Bob Swaine presented this item. Because of the current COVID-19 virus situation, Staff requested the Board grant Mike Will ingham, Executive Director authorization to sign any and all documents related to any Airport business. This authorization will remain in effect until such time that the Board resumes in person meetings. Pete McDevitt made a motion to approve with a second to the motion by Craig Johnson. The motion passed with aye votes from Wells, McDevitt, Andrews, Cool, Valentine and Johnson.
Contingent Action Items
5. BOARD OF DIRECTOR'S BUSINESS Bob Swaine explained to the Board that the seat of Stanley Wells is expiring May 1, 2020. The Board needs to present at least two resumes to the City of Sebring for the expiring seat. The floor opened to receive nominations, Craig Johnson nominated Stanley Wells and Pete McDevitt nominated Gary Bagwell.
6. CONCERNS OF THE PUBLIC
7. EMERGENCY BUSINESS
8. ADJOURNMENT Chairman adjourned meeting at 1:44pm.
Mike Wi llinghan1, Executive Director 1
-s- I:;-; I .i IC,
Approved by Board
Invo
ices
Pai
d In
Apr
il 20
20 P
rese
nted
In M
ay 2
020
Boa
rd M
eetin
g D
ATE
SA
A/F
BO
-PA
ID IN
VOIC
ES
AM
OU
NT
DES
CR
IPTI
ON
04
/03/
20
Asc
ent -
Wor
ld F
uel
$25,
940.
57 F
BO:
1 DOL
L A
vGas
Fue
l at S
ebrin
q 04
/07/
20
Air
& El
ectri
cal S
ervi
ces,
Inc
$114
.37
SAA:
Rep
airs
to F
ixtu
re E
xhau
st F
an L
ight
Mot
or/T
rim in
Aer
omed
Bat
hroo
m;
Rep
lace
d Bu
lbs
to L
ED in
Tec
nam
04
/07/
20
Agilt
tech
Sol
utio
ns, L
LC
$177
.60
SAA:
Doc
umen
t Rem
edia
tion
Ser
vice
s fo
r AD
A C
ompl
ianc
e fo
r Jan
202
0 C
RA
& S
AA
Bu
dnet
Res
olut
ions
04
/07/
20
Aqili
tech
Sol
utio
ns,
LLC
$6
2.40
SAA
: D
ocum
ent R
emed
iatio
n Se
rvic
es fo
r AD
A C
omol
ianc
e -B
udae
t Am
endm
ents
04
/07/
20
Buqs
Bee
-War
e Ex
term
inat
inq,
Inc
$175
.00
SAA:
Pla
nt a
nd S
hrub
Car
e 04
/07/
20
Clif
ton
Lars
on A
llen
$9,5
20.0
0 SA
A: S
afet
v A
sses
smen
t 04
/07/
20
Cop
y Li
fe In
c.
$303
.21
SAA/
FBO
: Mar
ch 2
020
Con
ies
04/0
7/20
Ja
mi O
live
$130
.96
SAA:
Rei
mbu
rsem
ent f
or H
ome
Offi
ce S
unnl
ies
CO
VID
19
04/0
7/20
Ja
son
Ali
$65.
78 S
AA: T
rave
l/Mile
age
Rei
mbu
rsem
ent f
or T
rave
l Out
of T
own
to P
icku
p H
otsp
ots
-CO
VID
04
/07/
20
Leaf
Cao
ilal F
undi
na.
LLC
$3
76.7
1 SA
A/FB
O: L
ease
of C
anv
Mac
hine
s 04
/07/
20
RaP
id S
vste
ms
$495
.00
SAA/
FBO
: Mar
ch 2
020
Inte
rnet
Ser
vice
04
/07/
20
Sand
ra S
adie
$2
68.0
7 SA
A: L
ocal
Tra
vel E
xpen
ses
Jan
-Mar
ch 2
020
04/0
7/20
Te
ch H
ouse
: lnte
rara
ted
$116
.25
SAA:
Gen
eral
IT S
uono
rt: R
emot
e A
cces
s Q
uest
ions
Upd
ate
on G
4 Ite
ms
-CO
VID
19
04/0
7/20
Te
chH
ouse
:lnte
rgra
ted
$590
.00
SAA/
FBO
: Gen
eral
IT S
uppo
rt; I
ssue
s w
ith -
Voi
cem
ails
Rem
otel
y, S
plas
htop
, Pi
casa
, Te
ams
Trai
ninn
PD
F Fi
refo
x O
utlo
ok -
CO
VID
19
04/0
7/20
C
inta
s C
orpo
ratio
n $4
2.95
FBO
: Fi
rst A
id C
abin
et S
unol
v R
eple
nish
men
t .
04/0
7/20
G
ibso
n Av
iatio
n Se
rvic
es, I
nc
$3 1
66.4
0 FB
O:
Reb
uilt
Bla
ckm
er P
ump
on A
vGas
Tan
k at
Fue
l Far
m:
Incl
udes
Par
ts &
Lab
or
04/0
7/20
Lu
is P
ratts
$2
41.5
0 FB
O: T
rave
l/Mile
aqe
Rei
mbu
rsem
ent t
o A
PB
R
04/0
7/20
Sw
ift F
uels
, LL
C
$8 1
09.0
0 FB
O:
UL
94 A
vGas
Fue
l 04
/07/
20
Volo
Avi
atio
n Si
kors
ky,
LLC
$1
2,69
6.27
FBO
: In
stal
lmen
t #1
for G
ener
al L
iabi
litv
& W
orke
rs C
omp
Prem
ium
202
0 -
1/05
/20
-04
/07/
20
Vol
o Av
iatio
n S
ikor
skv
LLC
$4
687
.42
FBO
: Aor
il 20
20 M
edic
al &
Vis
ion
Cov
eraa
e 04
/07/
20
Volo
Avi
atio
n Si
kors
kv.
LLC
$2
62.9
3 FB
O: A
oril
2020
Ant
hem
Den
tal C
over
aae
04/0
7/20
Vo
lo A
viat
ion
Siko
rskv
. LL
C
$30.
60 F
BO:
Bene
fit A
dm in
Fee
s Th
ru 0
3.31
.202
0 04
/14/
20
Arom
a C
offe
e $1
49.6
5 SA
A/FB
O: C
offe
e &
Cle
anin
a Su
nnlie
s R
eole
nish
ed
04/1
4/20
Bu
as B
ee-W
are
Exte
rmin
atin
a. I
nc
$920
.00
SAA:
Bi-M
onth
lv L
awn
Car
e 4/
09/2
0 04
/14/
20
Jaso
n Al
i $4
8.99
SAA
: Tra
vel R
eim
burs
emen
t for
Mile
aae
04/1
4/20
R
anid
Svs
tem
s $4
24.2
8 SA
A: N
ew In
tern
et S
ervi
ce In
stal
l at E
x. A
ssis
tant
Hom
e -A
oril
& M
ay S
ervi
ce In
clud
ed
04/1
4/20
Te
ch H
ouse
: lnte
rgra
ted
$972
.50
SAA:
Gen
eral
IT S
uppo
rt; I
ssue
s -C
hrom
e, P
rinte
r, Lo
cked
Out
of C
ompu
ter,
Shar
ePoi
nt,
Adob
e Sc
anni
nN G
4S S
etun
Sca
nnin
n FB
O M
inra
tion
04/1
4/20
Pe
ttv C
ash
Rei
mbu
rsem
ent
$181
.96
FBO
Pem
, Cas
h Ao
ril 2
020
04/2
1/20
Er
ic T
. Zw
aver
Tax
Col
lect
or
$92.
95 S
AA:
Rea
istra
tion
Ren
ewal
for 2
014
Che
vrol
et
04/2
1/20
Pr
estia
e ae
rial S
ervi
ces
$100
.00
SAA:
Aer
ial V
ideo
& A
eria
l Pho
tos
of R
unw
av
04/2
1/20
S
WK
Tec
hnol
oaie
s $1
092
.50
SAA:
Rem
ote
Tech
nica
l Con
sult
for S
aae1
00/M
as90
04
/21/
20
Tota
l Adm
inis
trativ
e Se
rvic
es
$304
.29
SAA:
Qua
rterlv
FSA
Adm
inis
tratio
n Fe
es 0
4.01
.20
-06.
30.2
0 04
/21/
20
T ech
Hou
se:ln
terg
rate
d $6
82.5
0 SA
A: G
ener
al IT
Sup
port;
Iss
ues
-Wor
d, O
neD
rive,
Out
look
, M
icro
soft,
Spe
cial
Pro
ject
04
/21/
20
Tech
Hou
se:ln
tera
rate
d $2
99.5
0 SA
A/FB
O: M
ay 2
020
Mon
thlv
Rec
urrin
q So
ftwar
e Fe
es
04/2
1/20
U
NU
M L
ife In
sura
nce
$173
.02
FBO
: Apr
il 20
20 U
NU
M L
ife In
sura
nce
Polic
v 04
/21/
20
Volo
Avi
atio
n Si
kors
ky,
LLC
$7
1.93
FBO
: 1s
t Qua
rter A
dvis
orv
Fees
202
0 04
/28/
20
Bia
Mes
saae
s LL
C
$150
.00
SAA:
Afte
r Hou
rs T
elep
hone
Ans
wer
ina
Serv
ice
-Mav
202
0
Invo
ices
Pai
d In
Apr
il 20
20 P
rese
nted
In M
ay 2
020
Boa
rd M
eetin
g D
ATE
SA
A/F
BO
-PA
ID IN
VOIC
ES
AM
OU
NT
DES
CR
IPTI
ON
04
/28/
20
Cin
tas
Cor
pora
tion
$658
.93
SAA/
FBO
: Bi
-Wee
kly
Serv
ice;
Mat
s -L
ogo
& Sc
rape
r, A
ir D
isp/
Fres
hene
r, So
ap D
isp/
Soap
; Pa
per t
owel
s, T
oile
t Pap
er, S
aniti
zer/R
efill;
Uni
form
s fo
r all
Six
FBO
Em
ploy
ees
04/2
8/20
La
Gro
w lr
rioat
ion
$80.
00 S
AA: L
awn
lrrio
atio
n R
epai
r at T
erm
inal
04
/28/
20
Lotu
s D
esia
n LL
C
$270
.00
SAA:
Artw
ork
for E
xecu
tive
Offi
ce
04/2
8/20
R
isk
Man
agem
ent A
ssoc
iate
s In
c $4
10.0
0 SA
A: P
refe
rred
Gov
ernm
ent I
nsur
ance
Tru
st-A
dditi
onal
Equ
ipm
ent I
nsur
ed In
land
Mar
ine
-P
olic
"#P
K2F
L 102
8485
019-
16 1
0/01
/201
9 -1
0/01
/202
1 04
/28/
20
Ris
k M
anag
emen
t Ass
ocia
tes
Inc
$1,4
11.0
0 SA
A: G
loba
l Aer
ospa
ce-A
viat
ion
Liab
ility
-Add
FBO
Exp
osur
e -
Pol
icy#
150
0136
1 10
/01/
2017
-10
/01/
2020
04/2
8/20
S
WK
Tec
hnol
oaie
s $2
042
.50
SAA:
Rem
ote
Tech
nica
l Ass
ista
nce
-Liv
e U
nnra
de
04/2
8/20
G
ibso
n Av
iatio
n Se
rvic
es In
c $3
114.
76 F
BO: P
erfo
rmed
Pro
duct
Filt
er C
hanc
e on
Jet
-A T
ruck
& T
ank
at F
uel F
arm
04
/28/
20
Luis
Pra
tts
$69.
00 F
BO: T
rave
l/Mile
aae
Rei
mbu
rsem
ent t
o AP
BR
TOTA
L PA
ID IN
VOIC
ES:
$81,
293.
25
April
202
0 P-
Card
s
Purc
hase
Dat
e Ve
ndor
Nam
e A
mou
nt D
escr
iptio
n
3/6/
2020
D
OLL
AR
GE
NE
RA
L #1
7880
3/
6/20
20
SQ
BU
MP
ER
2 B
UM
PE
R
4/3/
2020
A
AR
ON
'S E
ZPA
Y
4/6/
2020
TR
IAN
GLE
HA
RD
WA
RE
4/
7/20
20
DIS
H N
ETW
OR
K-O
NE
TIM
E
4/7/
2020
IN
EB
RID
GE,
IN
C
4/7/
2020
R
EP
UB
LIC
SE
RV
ICE
S T
RA
SH
4/
7/20
20
SH
ELL
OIL
575
4251
7701
4/
7/20
20
WC
I SE
BR
ING
HA
ULI
NG
4/
8/20
20
CE
LLU
LAR
SA
LES
CF-
27
4/9/
2020
O
FFIC
E D
EP
OT
#236
2
4/10
/202
0 A
DO
BE
AC
RO
PR
O S
UBS
4/
12/2
020
TR T
AX
& A
CC
TG-P
RO
FES
SIO
4/
13/2
020
CO
LE A
UTO
SU
PP
LY IN
C
4/13
/202
0 R
AC
EW
AY
994
49
8099
40
4/15
/202
0 TH
E H
OM
E D
EP
OT
#634
0 4/
16/2
020
THE
BU
LB B
IN
4/16
/202
0 U
SPS
PO 1
1849
0087
0 4/
16/2
020
WW
W.S
EN
TRY
LIN
K.C
OM
4/
17/2
020
ALLE
N E
NTE
RP
RIS
ES
INC
4/
17/2
020
AM
ZN M
ktp
US
IL 1 H
C0l
13
4/17
/202
0 A
PE
X O
FFIC
E P
RO
DU
CTS
INC
4/
17/2
020
PD
F.FI
LLE
R
4/17
/202
0 V
ER
IZO
NW
RLS
S R
TCC
R V
B 4/
20/2
020
8072
EW
-SE
BR
ING
4/
21/2
020
AP
EX
OFF
ICE
PR
OD
UC
TS IN
C 4/
21/2
020
CE
LLU
LAR
SA
LES
CF-
27
4/21
/202
0 S
HE
LL O
IL 5
7542
5177
01
4/21
/202
0 W
M S
UP
ER
CE
NTE
R #
666
4/22
/202
0 A
MZN
Mkt
p U
S D
U7C
K05
63
4/22
/202
0 LO
OP
NE
T IN
C
4/22
/202
0 W
AL-
MA
RT
#066
6 4/
23/2
020
ALAN
JA
Y C
HE
VY
BU
ICK
GM
C
4/23
/202
0 C
INTA
S C
OR
P
4/23
/202
0 O
FFIC
E D
EP
OT
#236
2 4/
24/2
020
ALAN
JA
Y F
OR
D L
INC
OLN
4/
27/2
020
FLO
RID
A N
OTA
RY
AS
SO
CIA
TIO
N
$42.
14
$178
.00
$238
.99
$59.
75
$115
.73
$175
.00
$208
.23
$46.
00
$470
.00
$149
.99
$73.
96
$152
.91
$244
.00
$127
.01
$45.
50
$49.
00
$93.
00
$6.9
5 $9
9.75
$1
,023
.46
$405
.24
$59.
98
$96.
00
$760
.73
$276
.53
$46.
19
$248
.75
$50.
00
$62.
28
$41.
98
$104
.00
$126
.09
$54.
45
$1,5
30.0
0 $2
57.5
2 $1
88.8
5 $1
39.0
0
SAA:
San
itizi
ng W
ipes
and
Ble
ach
-CO
VID
-19
SAA:
Veh
icle
s W
ashe
d an
d D
etai
led
SAA:
Fur
nitu
re S
tagi
ng G
alle
ria R
ace
T-sh
irts
-Apr
il 20
20
FBO
: Var
ious
Dis
posa
ble
Glo
ves
Purc
hase
d fo
r Airp
ort S
taff
FBO
: M
onth
ly S
atel
lite
Serv
ice
for P
ilot's
Lou
nge
-Apr
il 20
20
SAA:
Mon
thly
Fee
for
Rec
ord
Ret
entio
n S
AA
/FB
O:
Mon
thly
Rec
yclin
g S
ervi
ce A
pril
2020
SA
A: F
uel f
or M
aint
enan
ce T
ruck
SA
A/FB
O:
Mon
thly
Was
te C
olle
ctio
n Se
rvic
e -A
pril
2020
SA
A: V
eriz
on 4
G L
TE M
obile
Hot
spot
Pur
chas
ed
SAA:
DVI
to H
DM
I Ada
pter
, U
SB
Cab
le to
Con
nect
Prin
ter,
Dis
play
Por
t to
HD
MI C
able
, H
DM
I A
dapt
er
SAA:
Mon
thly
Sub
scrip
tions
SA
A: F
ixes
Ass
et M
onth
ly S
ubsc
riptio
n SA
A: O
il an
d Fi
lters
for J
ohn
Dee
re G
ator
s, V
ehic
les
& G
ener
ator
s SA
A: F
uel f
or M
aint
enan
ce T
ruck
SA
A: L
ight
s an
d M
ater
ials
for X
Gen
erat
or R
epai
r SA
A: L
ight
Bul
bs fo
r Ter
min
al B
uild
ing
SAA:
Cer
tifie
d Le
tter M
aile
d fo
r Exe
cutiv
e O
ffice
SA
A: E
mpl
oyee
Bac
kgro
und
Che
cks
SAA:
Rep
lace
men
t fix
ture
s fo
r Run
way
Lig
htin
g &
Run
way
Lig
hts
SAA:
Rep
lace
men
t LED
s fo
r T-H
anga
r Flo
ods
& Bu
lbs
for T
erm
inal
Bui
ldin
g SA
A: 5
X9 a
nd 9
X 12
Env
elop
es w
ith C
lips
SAA:
E-s
ign
Doc
umen
ts P
rogr
am
SAA/
FBO
: M
onth
ly M
obile
Ser
vice
-Ap
ril 2
020
SAA:
Flo
od L
ight
s, L
ight
ing
for L
ands
cape
for a
roun
d Te
rmin
al B
uild
ing
SAA:
Env
elop
es 5
x9 w
ith C
lasp
s SA
A: C
ellp
hone
Cas
es,
3 Li
quid
Gla
ss S
cree
n P
rote
ctor
s SA
A: F
uel f
or M
aint
enan
ce T
ruck
FB
O: T
wo
Pho
ne C
ases
Pur
chas
ed;
Brus
h is
for C
lean
ing
Bat
hroo
m S
ink
SAA/
FBO
: H
eavy
Dut
y Ph
one
Cas
e's
SAA:
Onl
ine
SA
A R
ealty
Lis
ting
Com
pany
SA
A: P
urch
ase
of H
Q W
ebca
m a
nd H
Q M
icro
phon
e fo
r U
se in
Boa
rdro
om
SAA:
Oil
Cha
nge
for C
hevy
Tah
oe
SAA:
CO
VID
19
Cle
anin
g Su
pplie
s, G
love
s, S
aniti
zer
SA
A/F
BO
: PC
Spe
aker
, Wire
less
Key
boar
d/M
ouse
Com
bo S
ets;
Prin
ter I
nk fo
r Acc
ount
ing
SAA:
Ser
vice
and
Mai
nten
ance
on
Mai
nten
ance
Tru
ck
SAA:
Not
ary
Lice
nse
Dire
ctor
of F
inan
ce
April
202
0 P-
Card
s
Purc
hase
Dat
e Ve
ndor
Nam
e A
mou
nt D
escr
iptio
n
4/29
/202
0 5/
1/20
20
5/2/
2020
5/
3/20
20
HAR
BOR
FR
EIG
HT
TOO
LS 5
38
RA
CE
WA
Y 9
94
4980
9940
C
ELL
ULA
R S
ALES
CF-
27
AMZN
Mkt
p U
S 59
2WP
1IG
3
$11.
18
$46.
00
$69.
99
$352
.87
FBO
: El
ectri
cal T
ape
and
Wire
Bru
shes
Pur
chas
ed to
Mai
ntai
n FB
O e
quip
men
t SA
A: F
uel f
or M
aint
enan
ce T
ruck
SA
A: S
mar
t Pho
ne C
harg
er fo
r Fin
ance
Dire
ctor
SA
A: H
ome
Offi
ce D
esk
Org
aniz
er,
Lam
p, T
able
& D
esk
Tota
l: $8
,527
.00
-----
-----
-----
----------
----------
------------
Acc
ount
s Pa
yabl
e A
ged
Invo
ice
Rep
ort
Ope
n In
voic
es -
Age
d by
Invo
ice
Dat
e -A
s of
5/1
4/20
20
Seb
ring
Airp
ort A
utho
rity
(SAA
) In
voic
e N
umbe
r In
voic
e D
ate
Invo
ice
Bal
ance
30
D
ays
60
Day
s 90
Da
ys
120
Days
D
ue D
ate
Cur
rent
AR
OM
A A
rom
a C
offe
e 6/
6/20
20
540.
98
540.
98
0.00
0.
00
o4U
.98
---
540.
98
0.00
0.
00
5/30
/202
0 60
.00
60.0
0 0.
00
0.00
5/
29/2
020
3,10
0.00
0112
9041
0 5/
7/20
20
0.00
0.
00
SAA/
FBO
: Cof
fee
& C
lean
ing
Sup
plie
s R
esto
cked
Ve
ndor
AR
OM
A T
otal
s:
0.00
0.
00
ATK
INS
Atk
ins
1926
55H
I 4/
30/2
020
0.00
0.
00
SAA:
Hur
rican
e Irm
a Bl
dg.
#103
Eng
inee
ring
On-
Cal
l 19
2655
SF
4/29
/202
00.
000.
00SA
A: A
pril
2020
-S
tar F
arm
s -G
rant
Rei
mbu
rsem
ent
1926
642M
C
4/30
/202
0 19
2664
4CS
X 4/
30/2
020
5/30
/202
0 38
,726
.36
38,7
26.3
6 0.
00
0.00
0.
00
0.00
SA
A: A
pril
2020
CS
X T
rack
Rec
onst
ruct
ion
Line
Pac
kage
1
Adm
inis
tratio
n S
ervi
ces-
Gra
nt R
eim
burs
ed
75-1
9266
55
4/30
/202
0 5/
30/2
020
11,8
95.0
0 11
,895
.00
0.00
0.
00
0.00
0.
00
SAA:
Apr
il 20
20 O
n-C
all C
onsu
lting
Ser
vice
s Ve
ndor
ATK
INS
Tota
ls:
BEC
KER
Bec
ker &
Polia
koff,
P.A
. 41
4 795
8 4/
30/2
020
5/30
/202
0 40
0.00
40
0.00
0.
00
0.00
0.
00
0.00
SAA:
Apr
il 20
20 C
onst
ruct
ion
Cla
ims
with
Fra
sier
Con
tract
ing
Ve
ndor
BEC
KER
Tot
als:
40
0.00
40
0.00
0.
00
0.00
0.
00
0.00
CA
LEU
S M
athi
as H
utze
nlau
b 35
6 4/
30/2
020
5/30
/202
0 6,
242.
40
6,24
2.40
0.
00
0.00
0.
00
0.00
SA
A: A
pril
2020
Sec
urity
Ser
vice
s Ve
ndor
CA
LEU
S To
tals
: 6,
242.
40
6,24
2.40
0.
00
0.00
0.
00
0.00
C
INTA
S C
inta
s 40
4923
2951
4/
29/2
020
5/29
/202
0 10
9.80
10
9.80
0.
00
0.00
0.
00
0.00
SA
A/FB
O:
Han
d S
aniti
zer D
isp/
Soap
; Wee
kly
FBO
Uni
form
s fo
r All
Six
Em
ploy
ees
4049
8268
53
5/6/
2020
6/
5/20
20
677.
13
677.
13
0.00
0.
00
0.00
0.
00
SAA/
FBO
: B
i-Wee
kly
Serv
ice;
Log
o M
ats,
Scr
aper
Mat
s, A
ir Fr
eshe
ner/D
isp,
Soa
p/D
isp,
Ger
mx/
Dis
p, P
aper
tow
els,
Toi
let
Pace
r: W
eekl
v FB
O U
nifo
rms
for A
ll S
ix E
mol
ovee
s Ve
ndor
CIN
TAS
Tota
ls:
786.
93
786.
93
0.00
0.
00
0.00
0.
00
DIA
NA
RI
Dia
na R
ies
Des
igns
, Inc
. 13
295
4/30
/202
0 5/
30/2
020
1,82
3.00
1,
823.
00
0.00
0.
00
0.00
0.
00
SA
A/C
RA
/YA
Z: A
pril
2020
Web
site
Upd
ates
, D
irect
ors
Rep
ort,
Proj
ect S
uppo
rt Ve
ndor
DIA
NA
RI T
otal
s:
1,82
3.00
1,
823.
00
0.00
0.
00
0.00
0.
00
3,
100.
00
0.00
0.
00
5/30
/202
0 2,
464.
80
2,46
4.80
0.
00
0.00
0.
00
0.00
SA
A: A
pril
2020
Mas
ter P
lan
Upd
ate-
Gra
nt R
eim
burs
ed
56,2
46.1
6 56
,246
.16
0.00
0.
00
0.00
0.
00
--~~~
-------
-------
-------
--------
--------
--
------------
--------
--------
--------
----------
------------
Acc
ount
s Pa
yabl
e Ag
ed In
voic
e R
epor
t O
pen
Invo
ices
. A
ged
by In
voic
e D
ate.
As
of 5
/14/
2020
Se
brin
g A
irpor
t Aut
horit
y (S
AA)
Invo
ice
Invo
ice
Invo
ice
30
60
90
120
Num
ber
Dat
e D
ue D
ate
Bal
ance
C
urre
nt
Day
s Da
ys
Days
D
ays
G4S
G4S
Sec
ure
Inte
grat
ion,
LLC
87
62
5/8/
2020
6/
8/20
20
5,23
6.14
5,
236.
14
0.00
0.
00
0.00
0.
00
SA
A: S
oftw
are
Upg
rade
for S
ecur
ity G
ate
8780
5/
11/2
020
6/11
/202
0 2,
909.
66
2,90
9.66
0.00
0.
00
0.00
0.
00
SAA:
Mul
tiple
Ser
vice
Cal
ls fo
r Rep
airs
to S
ecur
ity G
ate
Ve
ndor
G4S
Tot
als:
8,
145.
80
8,14
5.80
0.
00
0.00
0.
00
0.00
JAC
KS
Jack
's L
awn
Serv
ice
MA
Y 2
020
5/1/
2020
5/
31/2
020
7,95
0.00
7,
950.
00
0.00
0.
000.
00
0.00
SA
A: M
ay 2
020
Law
n &
Land
scap
e C
are
Ve
ndor
JA
CK
S To
tals
: 7,
950.
00
7,95
0.00
0.
00
0.00
0.
00
0.00
PAYC
HEX
Pay
chex
of N
ew Y
ork
LLC
2171
2603
4/
30/2
020
5/15
/202
0 99
.00
99.0
0 0.
00
0.00
0.
00
0.00
SA
A: A
pril
2020
Mon
thly
Fee
for O
nlin
e Ti
mek
eepi
ng P
rogr
am
Vend
or P
AYC
HEX
Tot
als:
99
.00
99.0
0 0.
00
0.00
0.
00
0.00
SHU
TTS
Shut
ts &
Bow
en, L
LP
1449
143
4/30
/202
0 5/
30/2
020
1,25
0.00
1,
250.
00
0.00
0.
00
0.00
0.
00
SAA:
Apr
il 20
20 L
egal
Ser
vice
s . S
tar F
arm
s 14
4914
4 4/
30/2
020
5/30
/202
0 2,
817.
50
2,81
7.50
0.
00
0.00
0.
00
0.00
SA
A: A
pril
2020
Leg
al S
ervi
ces.
Wat
er Is
sues
14
4914
6 4/
30/2
020
5/30
/202
0 1,
782.
50
1,78
2.50
0.
00
0.00
0.
00
0.00
SA
A: A
pril
2020
Leg
al S
ervi
ces
• P
GIT
Insu
ranc
e P
olic
y C
over
age
Vend
or S
HU
TTS
Tota
ls:
5,85
0.00
5,
850.
00
0.00
0.
00
0.00
0.
00
STA
NLE
Y St
anle
y A
cces
s Te
chno
logi
es L
LC
9059
3122
6 4/
21/2
020
5/21
/202
0 67
0.00
67
0.00
0.
00
0.00
0.
00
0.00
S
AA
: Ann
ual P
reve
ntat
ive
Mai
nten
ance
. Aut
omat
ic S
lidin
g D
oors
. Te
rmin
al B
uild
ing
Vend
or S
TAN
LEY
Tota
ls:
670.
00
670.
00
0.00
0.
00
0.00
0
00
SWA
INE
Swai
ne, H
arris
& W
ohl,
P.A.
28
643
4/30
/202
0 5/
30/2
020
11,4
93.5
8 11
,493
.58
0.00
0.
00
0.00
0.
00
SAA:
Apr
il 20
20 L
egal
Ser
vice
s 28
644
4/30
/202
0 5/
30/2
020
384.
50
384.
50 ~ ~ ~ ~
SAA:
Apr
il 20
20 L
egal
Ser
vice
s .
Law
suit
Aga
inst
PG
IT
Vend
or S
WA
INE
Tota
ls:
11,8
78.0
8 11
,878
.08
0.00
0.
00
0.00
0.
00
TWC
SEV
TWC
Ser
vice
s 63
6285
4-1
4/29
/202
0 5/
29/2
020
248.
31
248.
31
0.00
0.
00
0.00
0.
00
SAA:
Ser
vice
Cal
l for
Ice
Mac
hine
-Fi
lter C
loQ
Rem
oved
Ve
ndor
TW
CSE
V To
tals
: 24
8.31
24
8.31
0.
00
0.00
0.
00
0.00
Rep
ort T
otal
s:
100,
880.
66
100,
880.
66
0.00
0.
00
0.00
0.
00
Acc
ount
s Pa
yabl
e A
ged
Invo
ice
Rep
ort
Ope
n In
voic
es -
Age
d by
Invo
ice
Dat
e - A
s of
5/1
3/20
20
Sebr
ing
Airp
ort A
utho
rity
(FB
O)
Invo
ice
Num
ber
Invo
ice
Dat
e D
ue D
ate
Invo
ice
Bal
ance
C
urre
nt
30
Dav
s 60
D
ays
90
Day
s 12
0 D
ays
CIN
TAS
Cin
tas
Cor
pora
tion
No. 2
dba
50
1708
8662
5/
11/2
020
6/10
/202
0 41
.61
41.6
1 0.
00
0.00
0.
00
0.00
FB
O: F
irst A
id C
abin
et S
uppl
y R
eple
nish
men
t Ve
ndor
CIN
TAS
Tota
ls:
41.6
1 41
.61
0.00
0.
00
0.00
0.
00
GIB
SON
Gib
son
Avi
atio
n Se
rvic
es In
c.
4396
4/
22/2
020
5/22
/202
0 5,
204.
73
5,20
4.73
0.
00
0.00
0.
00
0.00
FB
O: P
erfo
rmed
Pro
duct
Filt
er C
hang
e on
Jet
-A, A
vGas
, M
oGas
Tru
cks,
Jet
-A &
AvG
as T
anks
at F
uel F
arm
43
98
4/22
/202
0 5/
22/2
020
828.
13
828.
13
0.00
0.
00
0.00
0.
00
FBO
: P
erfo
rmed
Met
er C
alib
ratio
ns o
n Je
t-A
Tru
ck, A
vGas
Tr
uck.
Jet
-A T
ank
& A
vGas
Tan
ks
Vend
or G
IBSO
N T
otal
s:
6,03
2.86
6,
032.
86
0.00
0.
00
0.00
0.
00
LUIS
Lui
s A.
Pra
tts
5/8/
2020
5/
8/20
20
5/8/
2020
18
9.75
18
9.75
0.
00
0.00
0.
00
0.00
FB
O:
Trav
el/M
ileag
e R
eim
burs
emen
t to
AP
BR
Ve
ndor
LU
IS T
otal
s:
189.
75
189.
75
0.00
0.
00
0.00
0.
00
Rep
ort T
otal
s:
6,26
4.22
~6
,26<
1.22
0.
00
0.00
0.
00
0.00
SEBRING AIRPORT AUTHORITY AGENDA ITEM SUMMARY
MEETING DATE: May 21, 2020
PRESENTER: Mike Willingham
AGENDA ITEM: Aviation Consulting Services Contracts
BACKGROUND: Board approved Selection Committee's recommendation at its February 2020 Board Meeting to award contracts to Atkins Global, Avcon, AECOM and Amhurst Consulting Company. Staff now brings the contracts for these firms for board approval.
REQUESTED MOTION: Move to approve and authorize Mike Willingham to execute the same.
BOARD ACTION:
APPROVED ---___DENIED
DEFERRED ------OTHER
X
CONTRACT FOR CONTINUING SERVICES (Construction Projects & Study Activity)
This Contract is made by and between the SEBRING AIRPORT AUTHORITY, hereinafter referred to as the AUTHORITY, and AVCON, Inc. a Florida corporation, hereinafter referred to as the CONSUL TANT, whose address is 5555 East Michigan Street, Suite 200, Orlando, FL 32822. In consideration of the mutual promises contained herein, the AUTHORITY and the CONSULTANT agree:
The CONSUL TANT's responsibility under this Contract is to provide professional services related to tasks and projects hereinafter provided. These services may include aviation consulting, engineering, and other professional services as described in the response CONSUL TANT provided with respect to the Request for Qualifications 19-04. This Contract shall be deemed a "continuing contract" under Section 287.055, Florida Statutes.
The services performed by the CONSUL TANT under this Contract may include professional services for construction or study activity projects in which the estimated construction cost of each individual construction project or the fee of each individual study does not exceed the maximum amount permitted for a continuing contract pursuant to applicable law, including Section 287.055(2)(9), Florida Statutes, as may be amended.
Provisions of this Contract may be amended and updated periodically as deemed appropriate by the parties to reflect changes in professional business practices and general economic conditions without invalidating the effect of the nature of this Contract.
Significant tasks or projects shall be initiated by a separate Consultant Services Authorization (CSA) which will include a Scope of Services and Schedule of Payments. Each CSA shall identify whether it is a construction or study activity project, and shall include a duration during which the services shall be performed by the CONSUL TANT based on the nature of the work as approved by the AUTHORITY. General consulting work shall not require a separate CSA.
This Contract shall be effective upon the date of execution by all parties and shall continue thereafter until terminated in accordance with the General Terms and Conditions attached hereto.
The AUTHORITY shall pay the CONSULTANT for satisfactory performance, as specified, subject to additions and deletions by amendments as otherwise provided in this Contract.
Services of the CONSUL TANT shall be under the general direction of designated individuals, who shall act as the AUTHORITY's representative during the performance of this Contract. The CONSULTANT shall submit to the AUTHORITY a brief written report concerning the status of active projects.
This Contract shall include the following documents, which are attached to and hereby made a part of this Contract:
Attachment 1: General Terms and Conditions Attachment 2: Compensation Schedule
IN WITNESS WHEREOF, the AUTHORITY and CONSUL TANT have made and executed this Contract as of the ;21 day of l'.Y) 4 <-,
• I , 2020.
ATTEST: SEBRING AIRPORT AUTHORITY
~ By ______________
□ D
D. Craig Johnson, as its Secretary or □ D
Stanley H. 1/Vells, as its Chair er Peter H. McDevitt, as its Asst. Secretary T0frill Mu11 is, as its Vice Chair
)\,"I; k Lu; \ \ ,~., ~lk\,.. I q 1).", ( M
AVCON, Inc
Print N me: James A. Kriss Print Name: Sandeep Singh Print T tie: Secretary Print Title: President
2
ATTACHMENT 1
GENERAL TERMS AND CONDITIONS TO THE
CONTRACT FOR CONTINUING SERVICES BY AND BETWEEN
SEBRING AIRPORT AUTHORITY AND AVCON, INC
This Attachment contains the general terms and conditions for the Contract for Continuing Services (herein referred to as the "Contract") dated ' 2020, by and betweenthe SEBRING AIRPORT AUTHORITY, a body politic and corporate of the State of Florida (herein referred to as the "AUTHORITY") and AVCON, INC., a Florida corporation, (herein referred to as the "CONSUL TANT").
ARTICLE 1 - PAYMENTS TO CONSULTANT
----,---------------,--,-
The CONSUL TANT will bill the AUTHORITY at the amounts set forth in the Schedule of Payments for services satisfactorily rendered toward the completion of the Scope of Work on a monthly basis or as otherwise provided in a Consultant Services Authorization ("CSA") for specific services initiated pursuant to the Contract. The amounts billed shall be pursuant to the Compensation Schedule set forth in Attachment 2 of the Contract and shall represent the approximate completion of services outlined in the Scope of Work developed for each authorization.
ARTICLE 2 REIMBURSABLES
"Out-of-Pocket" expenses will be reimbursed in accordance with the list of the types of expenditures eligible for reimbursement. All requests for payment of "out-of-pocket" expenses eligible for reimbursement under the terms of this Contract shall include copies of paid receipts, invoices, or other documentation acceptable to the AUTHORITY. Such documentation shall be sufficient to establish that the expense was actually incurred and necessary in the performance of the applicable Scope of Work. Any travel, per diem, mileage, meals, or lodging expenses which may be reimbursable under the terms of this Contract will be paid in accordance with the rates and conditions set forth in Section 112.061, Florida Statutes.
ARTICLE 3 - PAYMENT OF INVOICES
Prior to payment, invoices received from the CONSUL TANT pursuant to the Contract will be reviewed and approved by the initiating department, indicating that services have been rendered in conformity with the Contract or applicable CSA. Invoices must reference the current purchase order number (if any). Payment shall be made in accordance with the CSA for specific projects.
ARTICLE 4- TRUTH-IN-NEGOTIATION CERTIFICATE
The signing of the Contract and any Consultant Services Authorization by the CONSUL TANT shall act as the execution of a truth-in-negotiation certificate certifying that the wage rates and costs used to determine the compensation provided for in the Contract and that CSA are accurate, complete and current as of the date of this Contract and that CSA.
The said rates and costs shall be adjusted to exclude any significant sums should the AUTHORITY determine that the rates and costs were increased due to the inaccurate, incomplete or noncurrent
May 21, 2020
wage rates or due to inaccurate representations of fees paid to outside consultants. The AUTHORITY shall exercise its rights under this "Certificate" within one year following final payment.
ARTICLE 5- TERMINATION
This Contract may be terminated by the CONSUL TANT upon 30 days prior written notice to the AUTHORITY in the event of substantial failure by the AUTHORITY to perform in accordance with the terms of this Contract through no fault of the CONSULTANT. It may also be terminated by the AUTHORITY with or without cause upon 30 days written notice to the CONSULTANT. Unless the CONSUL TANT is in breach of this Contract, the CONSUL TANT shall be paid for services rendered to the AUTHORITY through the date of termination. After receipt of a Termination Notice and except as otherwise directed by the AUTHORITY, the CONSUL TANT shall:
A. Stop work on the date and to the extent specified.
B. Terminate and settle all orders and subcontracts relating to the performance of terminated work.
C. Transfer all work in process, completed work, and other material related to the terminated work to the AUTHORITY.
D. Continue and complete all parts of the work that have not been terminated.
ARTICLE 6 - PERSONNEL
The CONSUL TANT represents that it has, or will secure at its own expense, all necessary personnel required to perform the services under this Contract. Such personnel shall not be employees of or have any contractual relationship with the AUTHORITY.
All of the services required hereunder shall be performed by the CONSUL TANT or under its supervision, and all personnel engaged in performing the services shall be fully qualified and, if required, authorized or permitted under state and local law to perform such services.
Any changes or substitutions in the CONSUL TANT's key personnel as may be listed herein must be made known to the AUTHORITY's representative and written approval granted by the AUTHORITY before said change or substitution can become effective.
ARTICLE 7 - KEY PERSONNEL ASSIGNMENT
The CONSUL TANT and the AUTHORITY agree to assign the following key personnel required to perform the services necessary under this Contract:
Contact Person for the Consultant: Sandeep Singh 5555 East Michigan Street Orlando, FL 32822-2779
Contact Person for Authority: Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
2
ARTICLE 8 - SUBCONTRACTING
For any specific project, the CONSULTANT reserves the right to select necessary subcontractors.
The AUTHORITY reserves the right to accept the use of a subcontractor or to reject the selection of a particular subcontractor and to inspect all facilities of any subcontractors in order to make a determination as to the capability of the subcontractor to perform properly under this Contract. The CONSUL TANT is encouraged to seek minority and women business enterprises for participation in subcontracting opportunities.
If a subcontractor fails to perform or make progress, as required by this Contract, and it is necessary to replace the subcontractor to complete the work in a timely fashion, the CONSUL TANT shall promptly do so, subject to acceptance of the new subcontractor by the AUTHORITY.
ARTICLE 9- FEDERAL AND STATE TAX
The AUTHORITY is exempt from Federal Tax and State Tax for Tangible Personal Property. The AUTHORITY will sign an exemption certificate submitted by the CONSUL TANT. The CONSUL TANT shall not be exempted from paying sales tax to its suppliers for materials to fulfill contractual obligations with the AUTHORITY, nor shall the CONSULTANT be authorized to use the AUTHORITY's Tax Exemption Number in obtaining such materials.
The CONSUL TANT shall be responsible for payment of its own taxes.
ARTICLE 10 -AVAILABILITY OF FUNDS
The obligations of the AUTHORITY under this Contract are subject to the availability of funds lawfully appropriated for its purpose by the Board of the Sebring Airport Authority.
ARTICLE 11 - INSURANCE
A. The CONSUL TANT shall not commence work under this Contract or any CSA unless it has all insurance required under this paragraph and that insurance has been approved by the AUTHORITY. In the event the insurance coverage expires prior to the completion of any Project, a renewal certificate shall be issued 30-days prior to said expiration date.
B. All insurance policies shall be issued by companies authorized or approved to do business under the laws of the State of Florida. The CONSUL TANT shall furnish Certificates of Insurance to the AUTHORITY prior to the commencement of work under this Contract. The Certificates shall clearly indicate that the CONSULTANT has obtained insurance of the type, amount, and classifications required for strict compliance with this Article. Compliance with the foregoing requirements shall not relieve the CONSUL TANT of its liability and obligations under this Contract.
C. The CONSUL TANT shall purchase and maintain professional liability or malpractice or errors or omissions insurance with minimum limits of $2,000,000 per occurrence and annual aggregate. If a claims made form of coverage is provided, the retroactive date of coverage shall be no later than the inception date of claims made coverage, unless the prior policy was extended indefinitely to cover prior acts. Coverage shall be extended beyond the policy year either by a supplemental extended reporting
3
period (ERP) of as great duration as available, and with no less coverage and with reinstated aggregate limits, or by requiring that any new policy provide a retroactive date no later than the inception date of claims made coverage.
D. The CONSUL TANT shall maintain, during the life of this Contract, comprehensive general liability insurance in the amount of $1,000,000 per occurrence to protect the CONSUL TANT from claims of bodily injury and property damages which may arise from any operations under this Contract whether such operations be by the CONSUL TANT or by anyone directly employed by or contracting with the CONSUL TANT.
E. The CONSUL TANT shall maintain, during the life of this Contract, comprehensive automobile liability insurance in the amounts of $1,000,000 combined single limit for bodily injury and property damage to protect the CONSUL TANT from claims for damages for bodily injury, including wrongful death, as well as from claims from property damage, which may arise from the ownership, use, or maintenance of owned and non-owned automobiles, including rented automobiles whether such operations be by the CONSUL TANT or by anyone directly or indirectly employed by the CONSULTANT.
F. The CONSUL TANT shall maintain, during the life of this Contract, adequate Workman's Compensation Insurance and Employer's Liability Insurance in at least such amounts as are required by law for all of its employees performing work for the AUTHORITY pursuant to this Contract.
G. All insurance, other than Professional Liability and Workman's Compensation, to be maintained by the CONSUL TANT shall specifically include the AUTHORITY as an "Additional Insured".
ARTICLE 12 - STANDARD OF CARE
The CONSUL TANT covenants that all services shall be performed by skilled and competent personnel to generally accepted professional standards under similar conditions.
ARTICLE 13- INDEMNIFICATION
Subject to limitations of Florida law, the CONSUL TANT shall indemnify and hold harmless the AUTHORITY, and its officers and employees, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys' fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the CONSUL TANT and other persons employed or utilized by the CONSULTANT in the performance of the Contract. CONSULTANT's liability for indemnification shall be limited to $2,000,000.00.
ARTICLE 14 - SUCCESSORS AND ASSIGNS
The AUTHORITY and the CONSUL TANT each binds itself and its partners, successors, executors, administrators and assigns to the other party of this Contract and to the partners, successors, executors, administrators and assigns of such other party, in respect to all covenants of this Contract. Neither the AUTHORITY nor the CONSUL TANT shall assign, convey or transfer its interest in the Contract without the written consent of the other, which shall not be unreasonably withheld. Nothing herein shall be construed as creating any personal liability on the part of any
4
officer or agent of the AUTHORITY which may be a party hereto, nor shall it be construed as giving any rights or benefits hereunder to anyone other than the AUTHORITY and the CONSULTANT.
ARTICLE 15 REMEDIES
This Contract shall be governed by the laws of the State of Florida. Any and all legal action necessary to enforce the Contract will be held in Highlands County, Florida, and the Contract will be interpreted according to the laws of the State of Florida. No remedy herein conferred upon any party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given hereunder or now or hereafter existing at law or by statute or otherwise. No single or partial exercise by any party of any right, power, or remedy hereunder shall preclude any other or further exercise thereof.
ARTICLE 16- CONFLICT OF INTEREST
The CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder, consistent with the intent and declaration of policy stated in Section 112.311, Florida Statutes. The CONSUL TANT further represents that no person having any interest shall be employed for said performance.
The CONSULTANT shall promptly notify the AUTHORITY in writing of potential conflicts of interest for any prospective business associations, interest or other circumstances which may influence or appear to influence the CONSUL TANT's judgment or quality of services being provided under a specific CSA. Such written notification shall identify the prospective business association, interest or circumstance, the nature of work that the CONSULTANT may undertake and request an opinion of the AUTHORITY as to whether the association, interest or circumstance would, in the opinion of the AUTHORITY, constitute a conflict of interest if entered into by the CONSUL TANT. The AUTHORITY agrees to notify the CONSUL TANT of its opinion by certified mail within 30 days of receipt of notification by the CONSULTANT. If, in the opinion of the AUTHORITY, the prospective business association, interest or circumstance would not constitute a conflict of interest by the CONSUL TANT, the AUTHORITY shall so state in the notification, and it shall be deemed not to be a conflict of interest with respect to services provided to the AUTHORITY by the CONSUL TANT under the terms of this Contract.
ARTICLE 17- EXCUSABLE DELAYS
The CONSULTANT shall not be considered in default by reason of any failure in performance if such failure arises out of causes reasonably beyond the CONSULTANT's control and without its fault or negligence. Such causes may include, but are not limited to: acts of God, the AUTHORITY's omissive and commissive failures; natural or public health emergencies; labor disputes; freight embargoes; and severe weather conditions. The CONSUL TANT shall be responsible for the timely completion of subcontractor's work.
Upon the CONSUL TANT's request, the AUTHORITY shall consider the facts and extent of any failure to perform the work and, if the CONSUL TANT's failure to perform was due to causes reasonably beyond the CONSUL TANT's control and without its fault or negligence, the Contract Schedule and/or other affected provision of this Contract shall be revised accordingly, subject to the AUTHORITY's rights to change, terminate, or stop any or all of the work at any time.
5
ARTICLE 18-ARREARS
The CONSUL TANT shall not pledge the AUTHORITY's credit or make the AUTHORITY a guarantor of payment or surety for any contract, debt, obligation, judgment, lien or any form of indebtedness. The CONSUL TANT further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Contract.
ARTICLE 19 - DISCLOSURE AND OWNERSHIP OF DOCUMENTS
The CONSUL TANT shall deliver to the AUTHORITY, if requested, reproducibles and computer files of all final documents and materials prepared by and for the AUTHORITY under this Contract and any CSA, including, but not limited to Project Specifications and Record Drawings. All documents provided by CONSUL TANT to AUTHORITY shall be delivered both in hard-copy and in digital, hyperlink formats.
All written and oral information not in the public domain or not previously known, and all information and data obtained, developed, or supplied by the AUTHORITY or at its expense will be kept confidential by the CONSUL TANT and will not be disclosed to any other party, directly or indirectly, without the AUTHORITY's prior written consent unless required by a law, notwithstanding that the CONSUL TANT will be permitted to disclose such information to the affected building trades. All drawings, maps, sketches, and other data developed, or purchased, under this Contract or at the AUTHORITY's expense shall be and remain its property and may be reproduced and reused at the direction of the AUTHORITY.
CONSUL TANT shall grant the AUTHORITY unlimited license to use all work product to complete any on-going projects, provided that use by the AUTHORITY of the work product is at the AUTHORITY's sole risk and without liability or legal exposure to CONSULTANT or anyone working by or through CONSULTANT and further provided that CONSULTANT is paid all undisputed monies due under the applicable project from which the work product was rendered.
ARTICLE 20 - INDEPENDENT CONSUL TANT RELATIONSHIP
The CONSUL TANT is, and shall be, in the performance of all work, services, and activities under this Contract an independent contractor, and not an employee, agent, or servant of the AUTHORITY. All persons engaged in any of the work or services performed pursuant to this Contract shall at all times, and in all places, be subject to the CONSUL TANT's sole direction, supervision, and control. The CONSUL TANT shall exercise control over the means and manner in which it and its employees perform the work, and in all respects the CONSUL TANT's relationship and the relationship of its employees to the AUTHORITY shall be that of an independent contractor and not as employees or agents of the AUTHORITY.
The CONSULTANT does not have the power or authority to bind the AUTHORITY in any promise, agreement or representation other than specifically provided for in this Contract or amendment thereto.
ARTICLE 21 - CONTINGENT FEES
The CONSULTANT represents that it has not employed or retained any company or person, other than a bona fide employee working solely for the CONSULTANT, to solicit or secure this Contract and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the CONSUL TANT, any fee, commission, percentage,
6
gift, or any other consideration contingent upon or resulting from the award or making of this Contract.
ARTICLE 22 - ACCESS AND AUDITS
The CONSUL TANT shall maintain adequate records to justify all charges, expenses, and costs incurred in performing work pursuant to this Contract for at least three (3) years after completion of this Contract. The AUTHORITY shall have access to such books, records, and documents as required in this section for the purpose of inspection or audit during normal business hours, at the AUTHORITY's cost, upon five (5) days written notice.
ARTICLE 23 - NONDISCRIMINATION
The CONSULTANT represents, to the best of its knowledge, that all of its employees are treated equally during employment without regard to race, color, religion, sex, age, national origin, handicap, or marital status.
ARTICLE 24- COMPLIANCE WITH DAVIS-BACON ACT REQUIREMENTS
The CONSULTANT hereby agrees, where required on Federal Grant assisted projects, to comply with applicable portions of the Davis-Bacon and related acts which regulate employee wages and benefits. The CONSUL TANT further acknowledges the possible necessity for amending the Contract in order to comply with Federal guidelines applicable to Grant Assisted projects which may be undertaken by the AUTHORITY.
ARTICLE 25- SURVIVAL
All covenants, agreements, and representations made herein, or otherwise made in writing by any party pursuant hereto, including but not limited to any representations made herein relating to disclosure or ownership or documents, shall survive the execution and delivery of this Contract and consummation of the transactions contemplated hereby.
ARTICLE 26 ENTIRETY OF CONTRACTUAL AGREEMENT
The AUTHORITY and the CONSUL TANT agree that this Contract sets forth the entire agreement between the parties, and that there are no promises or understandings other than those stated herein. None of the provisions, terms and conditions contained in this Contract may be added to, modified, superseded or otherwise altered, except by written instrument executed by the parties hereto.
ARTICLE 27 ENFORCEMENT COSTS
In any action brought by either party for the interpretation or enforcement of the obligations of the other party, including the establishment of a right to indemnification, the prevailing party shall be entitled to recover from the losing party all reasonable attorney's fees, paralegal fees, court and other costs, even if not taxable as court costs, whether incurred before or at trial, on appeal, in bankruptcy or in post judgment collections.
7
ARTICLE 28 - AUTHORITY TO PRACTICE
The CONSUL TANT hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business, that it will at all times conduct its business activities in a reputable manner, and that it will maintain for duration of this Contract a current certificate of registration required under Florida Statutes.
ARTICLE 29 - SEVERABILITY
If any term or provision of this Contract, or the application thereof to any person or circumstances shall, to any extent, be held invalid or unenforceable, the remainder of this Contract, or the application of such term or provision, to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected, and every other term and provision of this Contract shall be deemed valid and enforceable to the extent permitted by law.
ARTICLE 30 -AMENDMENTS AND MODIFICATION
No amendments and/or modifications of this Contract or any Consultant Services Authorization shall be valid unless in writing and signed by each of the parties.
The AUTHORITY reserves the right to make changes in the scope of work, including alterations, reductions therein or additions thereto. Upon receipt by the CONSULTANT of the AUTHORITY's notification of a contemplated change, the CONSULTANT shall, if requested by AUTHORITY: (1) provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the AUTHORITY of any estimated change in the completion date, and (3) advise the AUTHORITY in writing if the contemplated change shall effect the CONSUL TANT's ability to meet the completion dates or schedules of this Contract.
If the AUTHORITY so instructs in writing, the CONSUL TANT shall suspend work on the portion of the work affected by a contemplated change, pending the AUTHORITY's decision to proceed with the change.
If the AUTHORITY elects to make the change, the AUTHORITY shall issue a written amendment or Change Order and the CONSUL TANT shall not commence work on any such change until such written amendment or change order has been issued and signed by each of the parties.
ARTICLE 31 - CONSTRUCTION COST AND ESTIMATES
As to construction projects, the "Construction Cost" shall be the total cost or estimated cost to the AUTHORITY of all elements of the Project(s), including design costs, designed or specified by the CONSULTANT including costs of additives or deductive work items regardless of whether they are awarded for construction. It shall include the cost at current market rates of labor and materials furnished by the AUTHORITY and equipment designed, specified, selected or specially provided for by the CONSUL TANT, including a reasonable allowance of the Contractor's overhead and profit. In addition, a reasonable allowance for contingencies shall be included for market conditions at the time of bidding and for changes in the work during construction.
The ability to complete Projects at or under budget is of great importance to the AUTHORITY. Evaluations of individual Project budget(s), preliminary estimates of Construction Cost, and detailed estimates of Construction Cost prepared by the CONSULTANT, shall represent the CONSUL TANT's best judgment as a design professional familiar with the construction industry.
8
CONSUL TANT shall review the Project budget prior to undertaking substantive work on the Project. If CONSUL TANT initially determines that the Construction Cost will likely exceed the budget, CONSUL TANT shall promptly notify AUTHORITY in writing and suspend further work on the Project.
If CONSUL TANT initially believes that the Construction Cost of the proposed Project will likely not exceed the budget, CONSUL TANT shall proceed with its work until it has completed approximately thirty percent (30%) of the Project's overall professional services, at which point CONSUL TANT shall deliver to AUTHORITY a detailed written estimate of Construction Cost ("First Estimate"). The AUTHORITY shall review the First Estimate and provide a written directive to either continue or suspend work on the Project.
If AUTHORITY has directed CONSUL TANT to continue work on the Project, CONSUL TANT shall proceed with its work until it has completed approximately ninety percent (90%) of the Project's overall professional services, at which point CONSULTANT shall deliver to AUTHORITY another detailed written estimate of Construction Cost ("Second Estimate"). If the Second Estimate exceeds the First Estimate by more than five percent (5%), the CONSULTANT shall explain, in writing, the reason(s) for the increase. The AUTHORITY shall review the Second Estimate and provide a written directive to either continue or suspend work on the Project.
If the Second Estimate is exceeded by the lowest bona fide bid or negotiated proposal, the AUTHORITY shall:
31.1 give written approval of an increase in such fixed limit;
31.2 authorize rebidding or renegotiating of the project(s) within a reasonable time;
31.3 abandon the project(s); or
31.4 cooperate in revising the project(s) scope and quality as required to reduce the Construction Cost.
If the AUTHORITY chooses to proceed in accordance with either 31.2 or 31.4 above, the CONSULTANT shall, at its own expense, either a) modify the contract documents or plans, as necessary and subsequently approved by the Authority, or b) re-bid the Project to achieve a lower bona fide bid or negotiated proposal. If no such lower bid or proposal can be obtained after appropriate modification of the contract documents, AUTHORITY may proceed in accordance with 31.1, 31.3 or any other option that may be available to AUTHORITY in the AUTHORITY's discretion.
ARTICLE 32 -AUTHORITY'S RESPONSIBILITIES
Provided such information is reasonably required by the CONSULT ANT to perform its services under this Contract, the AUTHORITY shall:
1. Provide full information regarding requirements for the projects and tasks, including a program which shall set forth the AUTHORITY's objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems and site requirements.
9
2. Designate a representative authorized to act on the AUTHORITY's behalf with respect to the projects or tasks. The AUTHORITY or that authorized representative shall render decisions in a timely manner pertaining to documents submitted by the CONSUL TANT in order to avoid unreasonable delay in the orderly and sequential progress of the CONSUL TANT's services.
3. Furnish, to the extent in its possession, surveys describing available information on utility locations, written legal descriptions of the sites, easements, encroachments, zoning, deed restrictions, and other available information to assist the CONSUL TANT in developing proper scopes of service and fulfilling project or task objectives.
4. Assist in gaining access to and make all provisions for access required for the CONSUL TANT to enter upon public and private property as required for the CONSUL TANT to perform services under this Contract.
5. Examine all studies, reports, sketches, drawings, specifications, proposals and other documents presented by the CONSUL TANT and render decisions and comments regarding them within a reasonable time so as not to delay the services of the CONSULTANT.
6. Bear all reasonable costs incident to compliance with the requirements of this Article.
ARTICLE 33 - NOTICE
All notices required in this Contract shall be sent certified mail, return receipt requested, and if sent to the AUTHORITY shall be mailed to:
Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
and if sent to the CONSUL TANT shall be mailed to:
Sandeep Singh President AVCON, Inc. 5555 East Michigan Street Orlando, FL 32822-2779
ARTICLE 34 PUBLIC ENTITY CRIMES
A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017, Florida Statutes for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. By signing the Contract, CONSUL TANT certifies that it is
not subject to denial or revocation of the right to transact business with public entities pursuant to s. 287.133, Florida Statutes.
ARTICLE 35 - SCRUTINIZED COMPANIES
By signing the Contract, CONSUL TANT certifies that it is not ineligible, pursuant to Florida Statute 287.135, to bid on, submit a proposal for, or enter into or renew a contract pursuant to Florida Statute 287.135. AUTHORITY may terminate the Contract at its option if CONSULTANT is found to have submitted a false certification pursuant to section 287.135, F.S., been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or been engaged in business operations in Cuba or Syria. AUTHORITY may also terminate the Contract at its option if CONSULTANT is found to have been placed on the Scrutinized Companies that Boycott Israel List or is engaged in a boycott of Israel.
ARTICLE 36 - COMPLIANCE WITH ALL LAWS
In provision of services pursuant to the Contract, CONSULTANT shall comply with all applicable federal, state, and local laws, rules, and regulations.
ARTICLE 37 - PUBLIC RECORDS
AS REQUIRED BY § 119.0701{2)(a), FLORIDA STATUTES: IF CONSULTANT HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONSULTANT'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, Beverly K. Glarner AT 863-314-1301, EMAIL: [email protected] OR 128 AUTHORITY LANE, SEBRING, FLORIDA 33870.
CONSUL TANT shall:
37.1 Keep and maintain public records required by AUTHORITY to perform services.
37.2 Upon request from AUTHORITY's custodian of public records, CONSULTANT shall provide the AUTHORITY with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in Chapter 119, Florida Statutes, or as otherwise provided by law.
37.3 Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the Contract term and following completion of the Contract if CONSUL TANT does not transfer the records to the AUTHORITY.
37.4 Upon completion of the Contract, transfer, at no cost to the AUTHORITY, all public records in possession of CONSULTANT or keep and maintain public records required by AUTHORITY to perform the services. If the CONSUL TANT transfers all public records to the AUTHORITY upon completion of the Contract, CONSUL TANT shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If CONSULT ANT keeps and maintains public records upon completion of the Contract, CONSUL TANT shall meet all
II
applicable requirements for retaining public records. All records stored electronically must be provided to the AUTHORITY, upon request from the AUTHORITY's custodian of public records, in a format that is compatible with the information technology systems of the AUTHORITY.
-- END ATTACHMENT 1 --
12
AMctdN I : I I
APPENDIX B COMPENSATION SCHEDULE
2018 HOURLY BILLING RATES1
SEBRING REGIONAL AIRPORT
The following hourly rates include direct and indirect costs except direct expenses. Indirect costs include such items as overhead, profit and such statutory and customary fringe benefits as social security contributions, sick leave, unemployment, excise and payroll taxes, workmen's compensation, health and retirement benefits, bonuses, annual leave and holiday pay.
Hourly rates in effect on January 1, 2020 are:
CLASSIFICATION HOURLY RATE
Principal $220.00
QC Reviewer $220.00
Sr. Project Manager $220.00
Project Manager $185.00
Sr. Engineer/Planner $145.00
Project Engineer $110.00
Engineer/Planner $90.00
Sr. CADD Designer $95.00
CADD Designer $70.00
Administrative $65.00
Respectfully Submitted April 16, 2020
1Hourly rates are subject to annual adjustment for CPI increases.
CONTRACT FOR CONTINUING SERVICES (Construction Projects & Study Activity)
This Contract is made by and between the SEBRING AIRPORT AUTHORITY, hereinafter referred to as the AUTHORITY, and ATKINS NORTH AMERICA, INC., a Florida corporation, hereinafter referred to as the CONSULTANT, whose address is 4030 West Boy Scout Boulevard, Suite 700, Tampa, FL 33607. In consideration of the mutual promises contained herein, the AUTHORITY and the CONSULTANT agree:
The CONSULTANT’s responsibility under this Contract is to provide professional services related to tasks and projects hereinafter provided. These services may include aviation consulting, engineering, and other professional services as described in the response CONSULTANT provided with respect to the Request for Qualifications 19-04. This Contract shall be deemed a “continuing contract” under Section 287.055, Florida Statutes.
The services performed by the CONSULTANT under this Contract may include professional services for construction or study activity projects in which the estimated construction cost of each individual construction project or the fee of each individual study does not exceed the maximum amount permitted for a continuing contract pursuant to applicable law, including Section 287.055(2)(g), Florida Statutes, as may be amended.
Provisions of this Contract may be amended and updated periodically as deemed appropriate by the parties to reflect changes in professional business practices and general economic conditions without invalidating the effect of the nature of this Contract.
Significant tasks or projects shall be initiated by a separate Consultant Services Authorization (CSA) which will include a Scope of Services and Schedule of Payments. Each CSA shall identify whether it is a construction or study activity project, and shall include a duration during which the services shall be performed by the CONSULTANT based on the nature of the work as approved by the AUTHORITY. General consulting work shall not require a separate CSA.
This Contract shall be effective upon the date of execution by all parties and shall continue thereafter until terminated in accordance with the General Terms and Conditions attached hereto.
The AUTHORITY shall pay the CONSULTANT for satisfactory performance, as specified, subject to additions and deletions by amendments as otherwise provided in this Contract.
Services of the CONSULTANT shall be under the general direction of designated individuals, who shall act as the AUTHORITY’s representative during the performance of this Contract. The CONSULTANT shall submit to the AUTHORITY a brief written report concerning the status of active projects.
This Contract shall include the following documents, which are attached to and hereby made a part of this Contract:
Attachment 1: General Terms and Conditions Attachment 2: Compensation Schedule
1
IN WITNESS WHEREOF, the AUTHORITY and CONSUL TANT have made and executed this Contract as of the ,;).\ day of
ATTEST:
By ________ ______ ~nson, as its Secretary or D ~cDevitt, as its Asst. Secretary
ATTEST:
Print Name: C. Ernest Print Title: Secretary
VY A-'j ,2020.
SEBRING AIRPORT AUTHORITY
~ By -B □-
Stanley H. Wells, as its Chair or I emir-Morris, as its Vice Chair
Mike Willingham I
z.",c e~tivt D i ✓tc+-,,i_
ATKINS NORTH AMERICA, INC.
Print Name: Darin Larson Print Title: Vice President
2
ATTACHMENT 1
GENERAL TERMS AND CONDITIONS TO THE
CONTRACT FOR CONTINUING SERVICES BY AND BETWEEN
SEBRING AIRPORT AUTHORITY AND ATKINS NORTH AMERICA, INC.
This Attachment contains the general terms and conditions for the Contract for Continuing Services (herein referred to as the “Contract”) dated
May 20, 2020 _________________________, 2020, by and between
the SEBRING AIRPORT AUTHORITY, a body politic and corporate of the State of Florida (herein referred to as the “AUTHORITY”) and ATKINS NORTH AMERICA, INC., a Florida corporation, (herein r eferred to as the “CONSULTANT”).
ARTICLE 1 – PAYMENTS TO CONSULTANT
The CONSULTANT will bill the AUTHORITY at the amounts set forth in the Schedule of Payments for services satisfactorily rendered toward the completion of the Scope of Work on a monthly basis or as otherwise provided in a Consultant Services Authorization (“CSA”) for specific services initiated pursuant to the Contract. The amounts billed shall be pursuant to the Compensation Schedule set forth in Attachment 2 of the Contract and shall represent the approximate completion of services outlined in the Scope of Work developed for each authorization.
ARTICLE 2 – REIMBURSABLES
“Out-of-Pocket” expenses will be reimbursed in accordance with the list of the types of expenditures eligible for reimbursement. All requests for payment of “out-of-pocket” expenses eligible for reimbursement under the terms of this Contract shall include copies of paid receipts, invoices, or other documentation acceptable to the AUTHORITY. Such documentation shall be sufficient to establish that the expense was actually incurred and necessary in the performance of the applicable Scope of Work. Any travel, per diem, mileage, meals, or lodging expenses which may be reimbursable under the terms of this Contract will be paid in accordance with the rates and conditions set forth in Section 112.061, Florida Statutes.
ARTICLE 3 – PAYMENT OF INVOICES
Prior to payment, invoices received from the CONSULTANT pursuant to the Contract will be reviewed and approved by the initiating department, indicating that services have been rendered in conformity with the Contract or applicable CSA. Invoices must reference the current purchase order number (if any). Payment shall be made in accordance with the CSA for specific projects.
ARTICLE 4 – TRUTH-IN-NEGOTIATION CERTIFICATE
The signing of the Contract and any Consultant Services Authorization by the CONSULTANT shall act as the execution of a truth-in-negotiation certificate certifying that the wage rates and costs used to determine the compensation provided for in the Contract and that CSA are accurate, complete and current as of the date of this Contract and that CSA.
The said rates and costs shall be adjusted to exclude any significant sums should the AUTHORITY determine that the rates and costs were increased due to the inaccurate, incomplete or noncurrent
1
wage rates or due to inaccurate representations of fees paid to outside consultants. The AUTHORITY shall exercise its rights under this “Certificate” within one year following final payment.
ARTICLE 5 – TERMINATION
This Contract may be terminated by the CONSULTANT upon 30 days prior written notice to the AUTHORITY in the event of substantial failure by the AUTHORITY to perform in accordance with the terms of this Contract through no fault of the CONSULTANT. It may also be terminated by the AUTHORITY with or without cause upon 30 days written notice to the CONSULTANT. Unless the CONSULTANT is in breach of this Contract, the CONSULTANT shall be paid for services rendered to the AUTHORITY through the date of termination. After receipt of a Termination Notice and except as otherwise directed by the AUTHORITY, the CONSULTANT shall:
A. Stop work on the date and to the extent specified.
B. Terminate and settle all orders and subcontracts relating to the performance of terminated work.
C. Transfer all work in process, completed work, and other material related to the terminated work to the AUTHORITY.
D. Continue and complete all parts of the work that have not been terminated.
ARTICLE 6 - PERSONNEL
The CONSULTANT represents that it has, or will secure at its own expense, all necessary personnel required to perform the services under this Contract. Such personnel shall not be employees of or have any contractual relationship with the AUTHORITY.
All of the services required hereunder shall be performed by the CONSULTANT or under its supervision, and all personnel engaged in performing the services shall be fully qualified and, if required, authorized or permitted under state and local law to perform such services.
Any changes or substitutions in the CONSULTANT’s key personnel as may be listed herein must be made known to the AUTHORITY’s representative and written approval granted by the AUTHORITY before said change or substitution can become effective.
ARTICLE 7 – KEY PERSONNEL ASSIGNMENT
The CONSULTANT and the AUTHORITY agree to assign the following key personnel required to perform the services necessary under this Contract:
Contact Person for the Consultant: Kevin McCauley Atkins North America, Inc. 482 South Keller Road Orlando, FL 32810
Contact Person for Authority: Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
2
ARTICLE 8 - SUBCONTRACTING
For any specific project, the CONSULTANT reserves the right to select necessary subcontractors.
The AUTHORITY reserves the right to accept the use of a subcontractor or to reject the selection of a particular subcontractor and to inspect all facilities of any subcontractors in order to make a determination as to the capability of the subcontractor to perform properly under this Contract. The CONSULTANT is encouraged to seek minority and women business enterprises for participation in subcontracting opportunities.
If a subcontractor fails to perform or make progress, as required by this Contract, and it is necessary to replace the subcontractor to complete the work in a timely fashion, the CONSULTANT shall promptly do so, subject to acceptance of the new subcontractor by the AUTHORITY.
ARTICLE 9 – FEDERAL AND STATE TAX
The AUTHORITY is exempt from Federal Tax and State Tax for Tangible Personal Property. The AUTHORITY will sign an exemption certificate submitted by the CONSULTANT. The CONSULTANT shall not be exempted from paying sales tax to its suppliers for materials to fulfill contractual obligations with the AUTHORITY, nor shall the CONSULTANT be authorized to use the AUTHORITY’s Tax Exemption Number in obtaining such materials.
The CONSULTANT shall be responsible for payment of its own taxes.
ARTICLE 10 – AVAILABILITY OF FUNDS
The obligations of the AUTHORITY under this Contract are subject to the availability of funds lawfully appropriated for its purpose by the Board of the Sebring Airport Authority.
ARTICLE 11 – INSURANCE
A. The CONSULTANT shall not commence work under this Contract or any CSA unless it has all insurance required under this paragraph and that insurance has been approved by the AUTHORITY. In the event the insurance coverage expires prior to the completion of any Project, a renewal certificate shall be issued 30-days prior to said expiration date.
B. All insurance policies shall be issued by companies authorized or approved to do business under the laws of the State of Florida. The CONSULTANT shall furnish Certificates of Insurance to the AUTHORITY prior to the commencement of work under this Contract. The Certificates shall clearly indicate that the CONSULTANT has obtained insurance of the type, amount, and classifications required for strict compliance with this Article. Compliance with the foregoing requirements shall not relieve the CONSULTANT of its liability and obligations under this Contract.
C. The CONSULTANT shall purchase and maintain professional liability or malpractice or errors or omissions insurance with minimum limits of $2,000,000 per occurrence and annual aggregate. If a claims made form of coverage is provided, the retroactive date of coverage shall be no later than the inception date of claims made coverage, unless the prior policy was extended indefinitely to cover prior acts. Coverage shall be extended beyond the policy year either by a supplemental extended reporting
3
period (ERP) of as great duration as available, and with no less coverage and with reinstated aggregate limits, or by requiring that any new policy provide a retroactive date no later than the inception date of claims made coverage.
D. The CONSULTANT shall maintain, during the life of this Contract, comprehensive general liability insurance in the amount of $1,000,000 per occurrence to protect the CONSULTANT from claims of bodily injury and property damages which may arise from any operations under this Contract whether such operations be by the CONSULTANT or by anyone directly employed by or contracting with the CONSULTANT.
E. The CONSULTANT shall maintain, during the life of this Contract, comprehensive automobile liability insurance in the amounts of $1,000,000 combined single limit for bodily injury and property damage to protect the CONSULTANT from claims for damages for bodily injury, including wrongful death, as well as from claims from property damage, which may arise from the ownership, use, or maintenance of owned and non-owned automobiles, including rented automobiles whether such operations be by the CONSULTANT or by anyone directly or indirectly employed by the CONSULTANT.
F. The CONSULTANT shall maintain, during the life of this Contract, adequate Workman’s Compensation Insurance and Employer’s Liability Insurance in at least such amounts as are required by law for all of its employees performing work for the AUTHORITY pursuant to this Contract.
G. All insurance, other than Professional Liability and Workman’s Compensation, to be maintained by the CONSULTANT shall specifically include the AUTHORITY as an “Additional Insured”.
ARTICLE 12 - STANDARD OF CARE
The CONSULTANT covenants that all services shall be performed by skilled and competent personnel to generally accepted professional standards under similar conditions.
ARTICLE 13 – INDEMNIFICATION
Subject to limitations of Florida law, the CONSULTANT shall indemnify and hold harmless the AUTHORITY, and its officers and employees, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys’ fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the CONSULTANT and other persons employed or utilized by the CONSULTANT in t he performance of the Contract. CONSULTANT’s liability for indemnification shall be limited to $2,000,000.00.
ARTICLE 14 – SUCCESSORS AND ASSIGNS
The AUTHORITY and the CONSULTANT each binds itself and its partners, successors, executors, administrators and assigns to the other party of this Contract and to the partners, successors, executors, administrators and assigns of such other party, in respect to all covenants of this Contract. Neither the AUTHORITY nor the CONSULTANT shall assign, convey or transfer its interest in the Contract without the written consent of the other, which shall not be unreasonably withheld. Nothing herein shall be construed as creating any personal liability on the part of any
4
officer or agent of the AUTHORITY which may be a party hereto, nor shall it be construed as giving any rights or benefits hereunder to anyone other than the AUTHORITY and the CONSULTANT.
ARTICLE 15 – REMEDIES
This Contract shall be governed by the laws of the State of Florida. Any and all legal action necessary to enforce the Contract will be held in Highlands County, Florida, and the Contract will be interpreted according to the laws of the State of Florida. No remedy herein conferred upon any party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given hereunder or now or hereafter existing at law or by statute or otherwise. No single or partial exercise by any party of any right, power, or remedy hereunder shall preclude any other or further exercise thereof.
ARTICLE 16 – CONFLICT OF INTEREST
The CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder, consistent with the intent and declaration of policy stated in Section 112.311, Florida Statutes. The CONSULTANT further represents that no person having any interest shall be employed for said performance.
The CONSULTANT shall promptly notify the AUTHORITY in writing of potential conflicts of interest for any prospective business associations, interest or other circumstances which may influence or appear to influence the CONSULTANT’s judgment or quality of services being provided under a specific CSA. Such written notification shall identify the prospective business association, interest or circumstance, the nature of work that the CONSULTANT may undertake and request an opinion of the AUTHORITY as to whether the association, interest or circumstance would, in the opinion of the AUTHORITY, constitute a conflict of interest if entered into by the CONSULTANT. The AUTHORITY agrees to notify the CONSULTANT of its opinion by certified mail within 30 days of receipt of notification by the CONSULTANT. If, in the opinion of the AUTHORITY, the prospective business association, interest or circumstance would not constitute a conflict of interest by the CONSULTANT, the AUTHORITY shall so state in the notification, and it shall be deemed not to be a conflict of interest with respect to services provided to the AUTHORITY by the CONSULTANT under the terms of this Contract.
ARTICLE 17 – EXCUSABLE DELAYS
The CONSULTANT shall not be considered in default by reason of any failure in performance if such failure arises out of causes reasonably beyond the CONSULTANT’s control and without its fault or negligence. Such causes may include, but are not limited to: acts of God, the AUTHORITY’s omissive and commissive failures; natural or public health emergencies; labor disputes; freight embargoes; and severe weather conditions. The CONSULTANT shall be responsible for the timely completion of subcontractor’s work.
Upon the CONSULTANT’s request, the AUTHORITY shall consider the facts and extent of any failure to perform the work and, if the CONSULTANT’s failure to perform was due to causes reasonably beyond the CONSULTANT’s control and without its fault or negligence, the Contract Schedule and/or other affected provision of this Contract shall be revised accordingly, subject to the AUTHORITY’s rights to change, terminate, or stop any or all of the work at any time.
5
ARTICLE 18 – ARREARS
The CONSULTANT shall not pledge the AUTHORITY’s credit or make the AUTHORITY a guarantor of payment or surety for any contract, debt, obligation, judgment, lien or any form of indebtedness. The CONSULTANT further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Contract.
ARTICLE 19 – DISCLOSURE AND OWNERSHIP OF DOCUMENTS
The CONSULTANT shall deliver to the AUTHORITY, if requested, reproducibles and computer files of all final documents and materials prepared by and for the AUTHORITY under this Contract and any CSA, including, but not limited to Project Specifications and Record Drawings. All documents provided by CONSULTANT to AUTHORITY shall be delivered both in hard-copy and in digital, hyperlink formats.
All written and oral information not in the public domain or not previously known, and all information and data obtained, developed, or supplied by the AUTHORITY or at its expense will be kept confidential by the CONSULTANT and will not be disclosed to any other party, directly or indirectly, without the AUTHORITY’s prior written consent unless required by a law, notwithstanding that the CONSULTANT will be permitted to disclose such information to the affected building trades. All drawings, maps, sketches, and other data developed, or purchased, under this Contract or at the AUTHORITY’s expense shall be and remain its property and may be reproduced and reused at the direction of the AUTHORITY.
CONSULTANT shall grant the AUTHORITY unlimited license to use all work product to complete any on-going projects, provided that use by the AUTHORITY of the work product is at the AUTHORITY’s sole risk and without liability or legal exposure to CONSULTANT or anyone working by or through CONSULTANT and further provided that CONSULTANT is paid all undisputed monies due under the applicable project from which the work product was rendered.
ARTICLE 20 – INDEPENDENT CONSULTANT RELATIONSHIP
The CONSULTANT is, and shall be, in the performance of all work, services, and activities under this Contract an independent contractor, and not an employee, agent, or servant of the AUTHORITY. All persons engaged in any of the work or services performed pursuant to this Contract shall at all times, and in all places, be subject to the CONSULTANT’s sole direction, supervision, and control. The CONSULTANT shall exercise control over the means and manner in which it and its employees perform the work, and in all respects the CONSULTANT’s relationship and the relationship of its employees to the AUTHORITY shall be that of an independent contractor and not as employees or agents of the AUTHORITY.
The CONSULTANT does not have the power or authority to bind the AUTHORITY in any promise, agreement or representation other than specifically provided for in this Contract or amendment thereto.
ARTICLE 21 – CONTINGENT FEES
The CONSULTANT represents that it has not employed or retained any company or person, other than a bona fide employee working solely for the CONSULTANT, to solicit or secure this Contract and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the CONSULTANT, any fee, commission, percentage,
6
gift, or any other consideration contingent upon or resulting from the award or making of this Contract.
ARTICLE 22 – ACCESS AND AUDITS
The CONSULTANT shall maintain adequate records to justify all charges, expenses, and costs incurred in performing work pursuant to this Contract for at least three (3) years after completion of this Contract. The AUTHORITY shall have access to such books, records, and documents as required in this section for the purpose of inspection or audit during normal business hours, at the AUTHORITY’s cost, upon five (5) days written notice.
ARTICLE 23 – NONDISCRIMINATION
The CONSULTANT represents, to the best of its knowledge, that all of its employees are treated equally during employment without regard to race, color, religion, sex, age, national origin, handicap, or marital status.
ARTICLE 24 – COMPLIANCE WITH DAVIS-BACON ACT REQUIREMENTS
The CONSULTANT hereby agrees, where required on Federal Grant assisted projects, to comply with applicable portions of the Davis-Bacon and related acts which regulate employee wages and benefits. The CONSULTANT further acknowledges the possible necessity for amending the Contract in order to comply with Federal guidelines applicable to Grant Assisted projects which may be undertaken by the AUTHORITY.
ARTICLE 25 – SURVIVAL
All covenants, agreements, and representations made herein, or otherwise made in writing by any party pursuant hereto, including but not limited to any representations made herein relating to disclosure or ownership or documents, shall survive the execution and delivery of this Contract and consummation of the transactions contemplated hereby.
ARTICLE 26 – ENTIRETY OF CONTRACTUAL AGREEMENT
The AUTHORITY and the CONSULTANT agree that this Contract sets forth the entire agreement between the parties, and that there are no promises or understandings other than those stated herein. None of the provisions, terms and conditions contained in this Contract may be added to, modified, superseded or otherwise altered, except by written instrument executed by the parties hereto.
ARTICLE 27 – ENFORCEMENT COSTS
In any action brought by either party for the interpretation or enforcement of the obligations of the other party, including the establishment of a right to indemnification, the prevailing party shall be entitled to recover from the losing party all reasonable attorney’s fees, paralegal fees, court and other costs, even if not taxable as court costs, whether incurred before or at trial, on appeal, in bankruptcy or in post judgment collections.
7
ARTICLE 28 – AUTHORITY TO PRACTICE
The CONSULTANT hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business, that it will at all times conduct its business activities in a reputable manner, and that it will maintain for duration of this Contract a current certificate of registration required under Florida Statutes.
ARTICLE 29 - SEVERABILITY
If any term or provision of this Contract, or the application thereof to any person or circumstances shall, to any extent, be held invalid or unenforceable, the remainder of this Contract, or the application of such term or provision, to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected, and every other term and provision of this Contract shall be deemed valid and enforceable to the extent permitted by law.
ARTICLE 30 – AMENDMENTS AND MODIFICATION
No amendments and/or modifications of this Contract or any Consultant Services Authorization shall be valid unless in writing and signed by each of the parties.
The AUTHORITY reserves the right to make changes in the scope of work, including alterations, reductions therein or additions thereto. Upon receipt by the CONSULTANT of the AUTHORITY’s notification of a contemplated change, the CONSULTANT shall, if requested by AUTHORITY: (1) provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the AUTHORITY of any estimated change in the completion date, and (3) advise the AUTHORITY in writing if the contemplated change shall effect the CONSULTANT’s ability to meet the completion dates or schedules of this Contract.
If the AUTHORITY so instructs in writing, the CONSULTANT shall suspend work on the portion of the work affected by a contemplated change, pending the AUTHORITY’s decision to proceed with the change.
If the AUTHORITY elects to make the change, the AUTHORITY shall issue a written amendment or Change Order and the CONSULTANT shall not commence work on any such change until such written amendment or change order has been issued and signed by each of the parties.
ARTICLE 31 – CONSTRUCTION COST AND ESTIMATES
As to construction projects, the “Construction Cost” shall be the total cost or estimated cost to the AUTHORITY of all elements of the Project(s), including design costs, designed or specified by the CONSULTANT including costs of additives or deductive work items regardless of whether they are awarded for construction. It shall include the cost at current market rates of labor and materials furnished by the AUTHORITY and equipment designed, specified, selected or specially provided for by the CONSULTANT, including a reasonable allowance of the Contractor’s overhead and profit. In addition, a reasonable allowance for contingencies shall be included for market conditions at the time of bidding and for changes in the work during construction.
The ability to complete Projects at or under budget is of great importance to the AUTHORITY. Evaluations of individual Project budget(s), preliminary estimates of Construction Cost, and detailed estimates of Construction Cost prepared by the CONSULTANT, shall represent the CONSULTANT’s best judgment as a design professional familiar with the construction industry.
8
CONSULTANT shall review the Project budget prior to undertaking substantive work on the Project. If CONSULTANT initially determines that the Construction Cost will likely exceed the budget, CONSULTANT shall promptly notify AUTHORITY in writing and suspend further work on the Project.
If CONSULTANT initially believes that the Construction Cost of the proposed Project will likely not exceed the budget, CONSULTANT shall proceed with its work until it has completed approximately thirty percent (30%) of the Project’s overall professional services, at which point CONSULTANT shall deliver to AUTHORITY a detailed written estimate of Construction Cost (“First Estimate”). The AUTHORITY shall review the First Estimate and provide a written directive to either continue or suspend work on the Project.
If AUTHORITY has directed CONSULTANT to continue work on the Project, CONSULTANT shall proceed with its work until it has completed approximately ninety percent (90%) of the Project’s overall professional services, at which point CONSULTANT shall deliver to AUTHORITY another detailed written estimate of Construction Cost (“Second Estimate”). If the Second Estimate exceeds the First Estimate by more than five percent (5%), the CONSULTANT shall explain, in writing, the reason(s) for the increase. The AUTHORITY shall review the Second Estimate and provide a written directive to either continue or suspend work on the Project.
If the Second Estimate is exceeded by the lowest bona fide bid or negotiated proposal, the AUTHORITY shall:
31.1 give written approval of an increase in such fixed limit;
31.2 authorize rebidding or renegotiating of the project(s) within a reasonable time;
31.3 abandon the project(s); or
31.4 cooperate in revising the project(s) scope and quality as required to reduce the Construction Cost.
If the AUTHORITY chooses to proceed in accordance with either 31.2 or 31.4 above, the CONSULTANT shall, at its own expense, either a) modify the contract documents or plans, as necessary and subsequently approved by the Authority, or b) re-bid the Project to achieve a lower bona fide bid or negotiated proposal. If no such lower bid or proposal can be obtained after appropriate modification of the contract documents, AUTHORITY may proceed in accordance with 31.1, 31.3 or any other option that may be available to AUTHORITY in the AUTHORITY’s discretion.
ARTICLE 32 – AUTHORITY’S RESPONSIBILITIES
Provided such information is reasonably required by the CONSULTANT to perform its services under this Contract, the AUTHORITY shall:
1. Provide full information regarding requirements for the projects and tasks, including a program which shall set forth the AUTHORITY’s objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems and site requirements.
9
2. Designate a representative authorized to act on the AUTHORITY’s behalf with respect to the projects or tasks. The AUTHORITY or that authorized representative shall render decisions in a timely manner pertaining to documents submitted by the CONSULTANT in order to avoid unreasonable delay in the orderly and sequential progress of the CONSULTANT’s services.
3. Furnish, to the extent in its possession, surveys describing available information on utility locations, written legal descriptions of the sites, easements, encroachments, zoning, deed restrictions, and other available information to assist the CONSULTANT in developing proper scopes of service and fulfilling project or task objectives.
4. Assist in gaining access to and make all provisions for access required for the CONSULTANT to enter upon public and private property as required for the CONSULTANT to perform services under this Contract.
5. Examine all studies, reports, sketches, drawings, specifications, proposals and other documents presented by the CONSULTANT and render decisions and comments regarding them within a reasonable time so as not to delay the services of the CONSULTANT.
6. Bear all reasonable costs incident to compliance with the requirements of this Article.
ARTICLE 33 – NOTICE
All notices required in this Contract shall be sent certified mail, return receipt requested, and if sent to the AUTHORITY shall be mailed to:
Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
and if sent to the CONSULTANT shall be mailed to:
Darin R. Larson Atkins North America, Inc. 482 South Keller Road Orlando, FL 32810
ARTICLE 34 – PUBLIC ENTITY CRIMES
A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017, Florida Statutes for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. By signing the Contract, CONSULTANT certifies that it is
10
not subject to denial or revocation of the right to transact business with public entities pursuant to s. 287.133, Florida Statutes.
ARTICLE 35 – SCRUTINIZED COMPANIES
By signing the Contract, CONSULTANT certifies that it is not ineligible, pursuant to Florida Statute 287.135, to bid on, submit a proposal for, or enter into or renew a contract pursuant to Florida Statute 287.135. AUTHORITY may terminate the Contract at its option if CONSULTANT is found to have submitted a false certification pursuant to section 287.135, F.S., been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or been engaged in business operations in Cuba or Syria. AUTHORITY may also terminate the Contract at its option if CONSULTANT is found to have been placed on the Scrutinized Companies that Boycott Israel List or is engaged in a boycott of Israel.
ARTICLE 36 – COMPLIANCE WITH ALL LAWS
In provision of services pursuant to the Contract, CONSULTANT shall comply with all applicable federal, state, and local laws, rules, and regulations.
ARTICLE 37 – PUBLIC RECORDS
AS REQUIRED BY § 119.0701(2)(a), FLORIDA STATUTES: IF CONSULTANT HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONSULTANT’S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, Beverly K. Glarner AT 863-314-1301, EMAIL: [email protected] OR 128 AUTHORITY LANE, SEBRING, FLORIDA 33870.
CONSULTANT shall:
37.1 Keep and maintain public records required by AUTHORITY to perform services.
37.2 Upon request from AUTHORITY’s custodian of public records, CONSULTANT shall provide the AUTHORITY with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in Chapter 119, Florida Statutes, or as otherwise provided by law.
37.3 Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the Contract term and following completion of the Contract if CONSULTANT does not transfer the records to the AUTHORITY.
37.4 Upon completion of the Contract, transfer, at no cost to the AUTHORITY, all public records in possession of CONSULTANT or keep and maintain public records required by AUTHORITY to perform the services. If the CONSULTANT transfers all public records to the AUTHORITY upon completion of the Contract, CONSULTANT shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If CONSULTANT keeps and maintains public records upon completion of the Contract, CONSULTANT shall meet all
11
applicable requirements for retaining public records. All records stored electronically must be provided to the AUTHORITY, upon request from the AUTHORITY’s custodian of public records, in a format that is compatible with the information technology systems of the AUTHORITY.
-- END ATTACHMENT 1 --
12
APPENDIX A
SCHEDULE OF HOURLY RATES AND REIMBURSABLE EXPENSES
ATKINS
The Standard Hourly Rates and Reimbursable Expenses are subject to periodic review and adjustment annually.
The following hourly rates include direct and indirect costs except direct expenses. Indirect costs include such items as overhead,
profit and such statutory and customary fringe benefits as social security contributions, sick leave, unemployment, excise and
payroll taxes, workmen's compensation, health and retirement benefits, bonuses, annual leave and holiday pay.
Hourly rates in effect on the date of the Agreement (April 2020) are:
Classification Rates
ENGINEERING / ARCHITECTURAL / PLANNING SERVICES
Practice Manager
Sr. Project Manager
Project Manager
Sr. Eng/Arch/Planner IV
Sr. Eng/Arch/Planner III
Sr. Eng/Arch/Planner II
Sr. Eng/Arch/Planner I
Eng/Arch/Planner II
Eng/Arch/Planner I
$250.00
$220.00
$180.00
$245.00
$200.00
$180.00
$145.00
$125.00
$105.00
ENVIRONMENTAL / ECOLOGICAL SERVICES
Sr. Scientist I
Scientist II
Scientist I
Technician
$120.00
$100.00
$90.00
$80.00
CONSTRUCTION SERVICES
Sr. Construction Management Rep.
Construction Management Rep. II
Construction Management Rep. I
$155.00
$130.00
$110.00
DESIGN / DRAFTING / SUPPORT STAFF
Clerical/Administrative
Sr. Designer/CAD Technician
Designer/CAD Technician
$90.00
$115.00
$100.00
SURVEYING SERVICES
Sr. Surveyor
Survey Field Coordinator
Survey CADD Technician
$150.00
$110.00
$90.00
CONTRACT FOR CONTINUING SERVICES (Construction Projects & Study Activity)
This Contract is made by and between the SEBRING AIRPORT AUTHORITY, hereinafter referred to as the AUTHORITY, and Amherst Consulting Company, LLC. a Florida corporation, hereinafter referred to as the CONSULTANT, whose address is 2300 Maitland Center Parkway, Suite 106, Maitland, FL 32751. In consideration of the mutual promises contained herein, the AUTHORITY and the CONSULTANT agree:
The CONSULTANT’s responsibility under this Contract is to provide professional services related to tasks and projects hereinafter provided. These services may include aviation consulting, engineering, and other professional services as described in the response CONSULTANT provided with respect to the Request for Qualifications 19-04. This Contract shall be deemed a “continuing contract” under Section 287.055, Florida Statutes.
The services performed by the CONSULTANT under this Contract may include professional services for construction or study activity projects in which the estimated construction cost of each individual construction project or the fee of each individual study does not exceed the maximum amount permitted for a continuing contract pursuant to applicable law, including Section 287.055(2)(g), Florida Statutes, as may be amended.
Provisions of this Contract may be amended and updated periodically as deemed appropriate by the parties to reflect changes in professional business practices and general economic conditions without invalidating the effect of the nature of this Contract.
Significant tasks or projects shall be initiated by a separate Consultant Services Authorization (CSA) which will include a Scope of Services and Schedule of Payments. Each CSA shall identify whether it is a construction or study activity project, and shall include a duration during which the services shall be performed by the CONSULTANT based on the nature of the work as approved by the AUTHORITY. General consulting work shall not require a separate CSA.
This Contract shall be effective upon the date of execution by all parties and shall continue thereafter until terminated in accordance with the General Terms and Conditions attached hereto.
The AUTHORITY shall pay the CONSULTANT for satisfactory performance, as specified, subject to additions and deletions by amendments as otherwise provided in this Contract.
Services of the CONSULTANT shall be under the general direction of designated individuals, who shall act as the AUTHORITY’s representative during the performance of this Contract. The CONSULTANT shall submit to the AUTHORITY a brief written report concerning the status of active projects.
This Contract shall include the following documents, which are attached to and hereby made a part of this Contract:
Attachment 1: General Terms and Conditions Attachment 2: Compensation Schedule
1
ATTEST:
By _______ _______ 8 D. Craig Jotmson, as its Secretary or ~vitt, as its Asst. Secretary
ATTEST:
~m70anllim~D Print Title: Chief Operating Officer (COO)
ti6 os;()-0 7H) I
SEBRING AIRPORT AUTHORITY
'L~ By ___,,.,.-;..:-,;;;;---------□ ~ntey t=I. Wells, as its Chair or □-rernll Morns, as its Vice Chair
Mike Willingham I Z~ eC(...+ I1/f l) i'( t c-h✓
Amherst Consulting Company, LLC
Print Name: Todd N. Zimmerman, PE Print Title: President/CEO
2
ARTICLE 1 – PAYMENTS TO CONSULTANT
ATTACHMENT 1
GENERAL TERMS AND CONDITIONS TO THE
CONTRACT FOR CONTINUING SERVICES BY AND BETWEEN
SEBRING AIRPORT AUTHORITY AND Amhurst consulting Company, LLC
This Attachment contains the general terms and conditions for the Contract for Continuing Services (herein referred to as the “Contract”) dated May 21, 2020 _________________________, 2020, by and between the SEBRING AIRPORT AUTHORITY, a body politic and corporate of the State of Florida (hereinreferred to as the “AUTHORITY”) and Amhurst Consulting Company, LLC a Florida corporation, (herein r eferred to as the “CONSULTANT”).
The CONSULTANT will bill the AUTHORITY at the amounts set forth in the Schedule of Payments for services satisfactorily rendered toward the completion of the Scope of Work on a monthly basis or as otherwise provided in a Consultant Services Authorization (“CSA”) for specific services initiated pursuant to the Contract. The amounts billed shall be pursuant to the Compensation Schedule set forth in Attachment 2 of the Contract and shall represent the approximate completion of services outlined in the Scope of Work developed for each authorization.
ARTICLE 2 – REIMBURSABLES
“Out-of-Pocket” expenses will be reimbursed in accordance with the list of the types of expenditures eligible for reimbursement. All requests for payment of “out-of-pocket” expenses eligible for reimbursement under the terms of this Contract shall include copies of paid receipts, invoices, or other documentation acceptable to the AUTHORITY. Such documentation shall be sufficient to establish that the expense was actually incurred and necessary in the performance of the applicable Scope of Work. Any travel, per diem, mileage, meals, or lodging expenses which may be reimbursable under the terms of this Contract will be paid in accordance with the rates and conditions set forth in Section 112.061, Florida Statutes.
ARTICLE 3 – PAYMENT OF INVOICES
Prior to payment, invoices received from the CONSULTANT pursuant to the Contract will be reviewed and approved by the initiating department, indicating that services have been rendered in conformity with the Contract or applicable CSA. Invoices must reference the current purchase order number (if any). Payment shall be made in accordance with the CSA for specific projects.
ARTICLE 4 – TRUTH-IN-NEGOTIATION CERTIFICATE
The signing of the Contract and any Consultant Services Authorization by the CONSULTANT shall act as the execution of a truth-in-negotiation certificate certifying that the wage rates and costs used to determine the compensation provided for in the Contract and that CSA are accurate, complete and current as of the date of this Contract and that CSA.
The said rates and costs shall be adjusted to exclude any significant sums should the AUTHORITY determine that the rates and costs were increased due to the inaccurate, incomplete or noncurrent
1
wage rates or due to inaccurate representations of fees paid to outside consultants. The AUTHORITY shall exercise its rights under this “Certificate” within one year following final payment.
ARTICLE 5 – TERMINATION
This Contract may be terminated by the CONSULTANT upon 30 days prior written notice to the AUTHORITY in the event of substantial failure by the AUTHORITY to perform in accordance with the terms of this Contract through no fault of the CONSULTANT. It may also be terminated by the AUTHORITY with or without cause upon 30 days written notice to the CONSULTANT. Unless the CONSULTANT is in breach of this Contract, the CONSULTANT shall be paid for services rendered to the AUTHORITY through the date of termination. After receipt of a Termination Notice and except as otherwise directed by the AUTHORITY, the CONSULTANT shall:
A. Stop work on the date and to the extent specified.
B. Terminate and settle all orders and subcontracts relating to the performance of terminated work.
C. Transfer all work in process, completed work, and other material related to the terminated work to the AUTHORITY.
D. Continue and complete all parts of the work that have not been terminated.
ARTICLE 6 - PERSONNEL
The CONSULTANT represents that it has, or will secure at its own expense, all necessary personnel required to perform the services under this Contract. Such personnel shall not be employees of or have any contractual relationship with the AUTHORITY.
All of the services required hereunder shall be performed by the CONSULTANT or under its supervision, and all personnel engaged in performing the services shall be fully qualified and, if required, authorized or permitted under state and local law to perform such services.
Any changes or substitutions in the CONSULTANT’s key personnel as may be listed herein must be made known to the AUTHORITY’s representative and written approval granted by the AUTHORITY before said change or substitution can become effective.
ARTICLE 7 – KEY PERSONNEL ASSIGNMENT
The CONSULTANT and the AUTHORITY agree to assign the following key personnel required to perform the services necessary under this Contract:
Contact Person for the Consultant: Todd Zimmerman 2300 Maitland Center Parkway, Suite 106 Maitland, FL 32751
Contact Person for Authority: Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
2
ARTICLE 8 - SUBCONTRACTING
For any specific project, the CONSULTANT reserves the right to select necessary subcontractors.
The AUTHORITY reserves the right to accept the use of a subcontractor or to reject the selection of a particular subcontractor and to inspect all facilities of any subcontractors in order to make a determination as to the capability of the subcontractor to perform properly under this Contract. The CONSULTANT is encouraged to seek minority and women business enterprises for participation in subcontracting opportunities.
If a subcontractor fails to perform or make progress, as required by this Contract, and it is necessary to replace the subcontractor to complete the work in a timely fashion, the CONSULTANT shall promptly do so, subject to acceptance of the new subcontractor by the AUTHORITY.
ARTICLE 9 – FEDERAL AND STATE TAX
The AUTHORITY is exempt from Federal Tax and State Tax for Tangible Personal Property. The AUTHORITY will sign an exemption certificate submitted by the CONSULTANT. The CONSULTANT shall not be exempted from paying sales tax to its suppliers for materials to fulfill contractual obligations with the AUTHORITY, nor shall the CONSULTANT be authorized to use the AUTHORITY’s Tax Exemption Number in obtaining such materials.
The CONSULTANT shall be responsible for payment of its own taxes.
ARTICLE 10 – AVAILABILITY OF FUNDS
The obligations of the AUTHORITY under this Contract are subject to the availability of funds lawfully appropriated for its purpose by the Board of the Sebring Airport Authority.
ARTICLE 11 – INSURANCE
A. The CONSULTANT shall not commence work under this Contract or any CSA unless it has all insurance required under this paragraph and that insurance has been approved by the AUTHORITY. In the event the insurance coverage expires prior to the completion of any Project, a renewal certificate shall be issued 30-days prior to said expiration date.
B. All insurance policies shall be issued by companies authorized or approved to do business under the laws of the State of Florida. The CONSULTANT shall furnish Certificates of Insurance to the AUTHORITY prior to the commencement of work under this Contract. The Certificates shall clearly indicate that the CONSULTANT has obtained insurance of the type, amount, and classifications required for strict compliance with this Article. Compliance with the foregoing requirements shall not relieve the CONSULTANT of its liability and obligations under this Contract.
C. The CONSULTANT shall purchase and maintain professional liability or malpractice or errors or omissions insurance with minimum limits of $2,000,000 per occurrence and annual aggregate. If a claims made form of coverage is provided, the retroactive date of coverage shall be no later than the inception date of claims made coverage, unless the prior policy was extended indefinitely to cover prior acts. Coverage shall be extended beyond the policy year either by a supplemental extended reporting
3
period (ERP) of as great duration as available, and with no less coverage and with reinstated aggregate limits, or by requiring that any new policy provide a retroactive date no later than the inception date of claims made coverage.
D. The CONSULTANT shall maintain, during the life of this Contract, comprehensive general liability insurance in the amount of $1,000,000 per occurrence to protect the CONSULTANT from claims of bodily injury and property damages which may arise from any operations under this Contract whether such operations be by the CONSULTANT or by anyone directly employed by or contracting with the CONSULTANT.
E. The CONSULTANT shall maintain, during the life of this Contract, comprehensive automobile liability insurance in the amounts of $1,000,000 combined single limit for bodily injury and property damage to protect the CONSULTANT from claims for damages for bodily injury, including wrongful death, as well as from claims from property damage, which may arise from the ownership, use, or maintenance of owned and non-owned automobiles, including rented automobiles whether such operations be by the CONSULTANT or by anyone directly or indirectly employed by the CONSULTANT.
F. The CONSULTANT shall maintain, during the life of this Contract, adequate Workman’s Compensation Insurance and Employer’s Liability Insurance in at least such amounts as are required by law for all of its employees performing work for the AUTHORITY pursuant to this Contract.
G. All insurance, other than Professional Liability and Workman’s Compensation, to be maintained by the CONSULTANT shall specifically include the AUTHORITY as an “Additional Insured”.
ARTICLE 12 - STANDARD OF CARE
The CONSULTANT covenants that all services shall be performed by skilled and competent personnel to generally accepted professional standards under similar conditions.
ARTICLE 13 – INDEMNIFICATION
Subject to limitations of Florida law, the CONSULTANT shall indemnify and hold harmless the AUTHORITY, and its officers and employees, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys’ fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the CONSULTANT and other persons employed or utilized by the CONSULTANT in t he performance of the Contract. CONSULTANT’s liability for indemnification shall be limited to $2,000,000.00.
ARTICLE 14 – SUCCESSORS AND ASSIGNS
The AUTHORITY and the CONSULTANT each binds itself and its partners, successors, executors, administrators and assigns to the other party of this Contract and to the partners, successors, executors, administrators and assigns of such other party, in respect to all covenants of this Contract. Neither the AUTHORITY nor the CONSULTANT shall assign, convey or transfer its interest in the Contract without the written consent of the other, which shall not be unreasonably withheld. Nothing herein shall be construed as creating any personal liability on the part of any
4
officer or agent of the AUTHORITY which may be a party hereto, nor shall it be construed as giving any rights or benefits hereunder to anyone other than the AUTHORITY and the CONSULTANT.
ARTICLE 15 – REMEDIES
This Contract shall be governed by the laws of the State of Florida. Any and all legal action necessary to enforce the Contract will be held in Highlands County, Florida, and the Contract will be interpreted according to the laws of the State of Florida. No remedy herein conferred upon any party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given hereunder or now or hereafter existing at law or by statute or otherwise. No single or partial exercise by any party of any right, power, or remedy hereunder shall preclude any other or further exercise thereof.
ARTICLE 16 – CONFLICT OF INTEREST
The CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder, consistent with the intent and declaration of policy stated in Section 112.311, Florida Statutes. The CONSULTANT further represents that no person having any interest shall be employed for said performance.
The CONSULTANT shall promptly notify the AUTHORITY in writing of potential conflicts of interest for any prospective business associations, interest or other circumstances which may influence or appear to influence the CONSULTANT’s judgment or quality of services being provided under a specific CSA. Such written notification shall identify the prospective business association, interest or circumstance, the nature of work that the CONSULTANT may undertake and request an opinion of the AUTHORITY as to whether the association, interest or circumstance would, in the opinion of the AUTHORITY, constitute a conflict of interest if entered into by the CONSULTANT. The AUTHORITY agrees to notify the CONSULTANT of its opinion by certified mail within 30 days of receipt of notification by the CONSULTANT. If, in the opinion of the AUTHORITY, the prospective business association, interest or circumstance would not constitute a conflict of interest by the CONSULTANT, the AUTHORITY shall so state in the notification, and it shall be deemed not to be a conflict of interest with respect to services provided to the AUTHORITY by the CONSULTANT under the terms of this Contract.
ARTICLE 17 – EXCUSABLE DELAYS
The CONSULTANT shall not be considered in default by reason of any failure in performance if such failure arises out of causes reasonably beyond the CONSULTANT’s control and without its fault or negligence. Such causes may include, but are not limited to: acts of God, the AUTHORITY’s omissive and commissive failures; natural or public health emergencies; labor disputes; freight embargoes; and severe weather conditions. The CONSULTANT shall be responsible for the timely completion of subcontractor’s work.
Upon the CONSULTANT’s request, the AUTHORITY shall consider the facts and extent of any failure to perform the work and, if the CONSULTANT’s failure to perform was due to causes reasonably beyond the CONSULTANT’s control and without its fault or negligence, the Contract Schedule and/or other affected provision of this Contract shall be revised accordingly, subject to the AUTHORITY’s rights to change, terminate, or stop any or all of the work at any time.
5
ARTICLE 18 – ARREARS
The CONSULTANT shall not pledge the AUTHORITY’s credit or make the AUTHORITY a guarantor of payment or surety for any contract, debt, obligation, judgment, lien or any form of indebtedness. The CONSULTANT further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Contract.
ARTICLE 19 – DISCLOSURE AND OWNERSHIP OF DOCUMENTS
The CONSULTANT shall deliver to the AUTHORITY, if requested, reproducibles and computer files of all final documents and materials prepared by and for the AUTHORITY under this Contract and any CSA, including, but not limited to Project Specifications and Record Drawings. All documents provided by CONSULTANT to AUTHORITY shall be delivered both in hard-copy and in digital, hyperlink formats.
All written and oral information not in the public domain or not previously known, and all information and data obtained, developed, or supplied by the AUTHORITY or at its expense will be kept confidential by the CONSULTANT and will not be disclosed to any other party, directly or indirectly, without the AUTHORITY’s prior written consent unless required by a law, notwithstanding that the CONSULTANT will be permitted to disclose such information to the affected building trades. All drawings, maps, sketches, and other data developed, or purchased, under this Contract or at the AUTHORITY’s expense shall be and remain its property and may be reproduced and reused at the direction of the AUTHORITY.
CONSULTANT shall grant the AUTHORITY unlimited license to use all work product to complete any on-going projects, provided that use by the AUTHORITY of the work product is at the AUTHORITY’s sole risk and without liability or legal exposure to CONSULTANT or anyone working by or through CONSULTANT and further provided that CONSULTANT is paid all undisputed monies due under the applicable project from which the work product was rendered.
ARTICLE 20 – INDEPENDENT CONSULTANT RELATIONSHIP
The CONSULTANT is, and shall be, in the performance of all work, services, and activities under this Contract an independent contractor, and not an employee, agent, or servant of the AUTHORITY. All persons engaged in any of the work or services performed pursuant to this Contract shall at all times, and in all places, be subject to the CONSULTANT’s sole direction, supervision, and control. The CONSULTANT shall exercise control over the means and manner in which it and its employees perform the work, and in all respects the CONSULTANT’s relationship and the relationship of its employees to the AUTHORITY shall be that of an independent contractor and not as employees or agents of the AUTHORITY.
The CONSULTANT does not have the power or authority to bind the AUTHORITY in any promise, agreement or representation other than specifically provided for in this Contract or amendment thereto.
ARTICLE 21 – CONTINGENT FEES
The CONSULTANT represents that it has not employed or retained any company or person, other than a bona fide employee working solely for the CONSULTANT, to solicit or secure this Contract and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the CONSULTANT, any fee, commission, percentage,
6
gift, or any other consideration contingent upon or resulting from the award or making of this Contract.
ARTICLE 22 – ACCESS AND AUDITS
The CONSULTANT shall maintain adequate records to justify all charges, expenses, and costs incurred in performing work pursuant to this Contract for at least three (3) years after completion of this Contract. The AUTHORITY shall have access to such books, records, and documents as required in this section for the purpose of inspection or audit during normal business hours, at the AUTHORITY’s cost, upon five (5) days written notice.
ARTICLE 23 – NONDISCRIMINATION
The CONSULTANT represents, to the best of its knowledge, that all of its employees are treated equally during employment without regard to race, color, religion, sex, age, national origin, handicap, or marital status.
ARTICLE 24 – COMPLIANCE WITH DAVIS-BACON ACT REQUIREMENTS
The CONSULTANT hereby agrees, where required on Federal Grant assisted projects, to comply with applicable portions of the Davis-Bacon and related acts which regulate employee wages and benefits. The CONSULTANT further acknowledges the possible necessity for amending the Contract in order to comply with Federal guidelines applicable to Grant Assisted projects which may be undertaken by the AUTHORITY.
ARTICLE 25 – SURVIVAL
All covenants, agreements, and representations made herein, or otherwise made in writing by any party pursuant hereto, including but not limited to any representations made herein relating to disclosure or ownership or documents, shall survive the execution and delivery of this Contract and consummation of the transactions contemplated hereby.
ARTICLE 26 – ENTIRETY OF CONTRACTUAL AGREEMENT
The AUTHORITY and the CONSULTANT agree that this Contract sets forth the entire agreement between the parties, and that there are no promises or understandings other than those stated herein. None of the provisions, terms and conditions contained in this Contract may be added to, modified, superseded or otherwise altered, except by written instrument executed by the parties hereto.
ARTICLE 27 – ENFORCEMENT COSTS
In any action brought by either party for the interpretation or enforcement of the obligations of the other party, including the establishment of a right to indemnification, the prevailing party shall be entitled to recover from the losing party all reasonable attorney’s fees, paralegal fees, court and other costs, even if not taxable as court costs, whether incurred before or at trial, on appeal, in bankruptcy or in post judgment collections.
7
ARTICLE 28 – AUTHORITY TO PRACTICE
The CONSULTANT hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business, that it will at all times conduct its business activities in a reputable manner, and that it will maintain for duration of this Contract a current certificate of registration required under Florida Statutes.
ARTICLE 29 - SEVERABILITY
If any term or provision of this Contract, or the application thereof to any person or circumstances shall, to any extent, be held invalid or unenforceable, the remainder of this Contract, or the application of such term or provision, to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected, and every other term and provision of this Contract shall be deemed valid and enforceable to the extent permitted by law.
ARTICLE 30 – AMENDMENTS AND MODIFICATION
No amendments and/or modifications of this Contract or any Consultant Services Authorization shall be valid unless in writing and signed by each of the parties.
The AUTHORITY reserves the right to make changes in the scope of work, including alterations, reductions therein or additions thereto. Upon receipt by the CONSULTANT of the AUTHORITY’s notification of a contemplated change, the CONSULTANT shall, if requested by AUTHORITY: (1) provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the AUTHORITY of any estimated change in the completion date, and (3) advise the AUTHORITY in writing if the contemplated change shall effect the CONSULTANT’s ability to meet the completion dates or schedules of this Contract.
If the AUTHORITY so instructs in writing, the CONSULTANT shall suspend work on the portion of the work affected by a contemplated change, pending the AUTHORITY’s decision to proceed with the change.
If the AUTHORITY elects to make the change, the AUTHORITY shall issue a written amendment or Change Order and the CONSULTANT shall not commence work on any such change until such written amendment or change order has been issued and signed by each of the parties.
ARTICLE 31 – CONSTRUCTION COST AND ESTIMATES
As to construction projects, the “Construction Cost” shall be the total cost or estimated cost to the AUTHORITY of all elements of the Project(s), including design costs, designed or specified by the CONSULTANT including costs of additives or deductive work items regardless of whether they are awarded for construction. It shall include the cost at current market rates of labor and materials furnished by the AUTHORITY and equipment designed, specified, selected or specially provided for by the CONSULTANT, including a reasonable allowance of the Contractor’s overhead and profit. In addition, a reasonable allowance for contingencies shall be included for market conditions at the time of bidding and for changes in the work during construction.
The ability to complete Projects at or under budget is of great importance to the AUTHORITY. Evaluations of individual Project budget(s), preliminary estimates of Construction Cost, and detailed estimates of Construction Cost prepared by the CONSULTANT, shall represent the CONSULTANT’s best judgment as a design professional familiar with the construction industry.
8
CONSULTANT shall review the Project budget prior to undertaking substantive work on the Project. If CONSULTANT initially determines that the Construction Cost will likely exceed the budget, CONSULTANT shall promptly notify AUTHORITY in writing and suspend further work on the Project.
If CONSULTANT initially believes that the Construction Cost of the proposed Project will likely not exceed the budget, CONSULTANT shall proceed with its work until it has completed approximately thirty percent (30%) of the Project’s overall professional services, at which point CONSULTANT shall deliver to AUTHORITY a detailed written estimate of Construction Cost (“First Estimate”). The AUTHORITY shall review the First Estimate and provide a written directive to either continue or suspend work on the Project.
If AUTHORITY has directed CONSULTANT to continue work on the Project, CONSULTANT shall proceed with its work until it has completed approximately ninety percent (90%) of the Project’s overall professional services, at which point CONSULTANT shall deliver to AUTHORITY another detailed written estimate of Construction Cost (“Second Estimate”). If the Second Estimate exceeds the First Estimate by more than five percent (5%), the CONSULTANT shall explain, in writing, the reason(s) for the increase. The AUTHORITY shall review the Second Estimate and provide a written directive to either continue or suspend work on the Project.
If the Second Estimate is exceeded by the lowest bona fide bid or negotiated proposal, the AUTHORITY shall:
31.1 give written approval of an increase in such fixed limit;
31.2 authorize rebidding or renegotiating of the project(s) within a reasonable time;
31.3 abandon the project(s); or
31.4 cooperate in revising the project(s) scope and quality as required to reduce the Construction Cost.
If the AUTHORITY chooses to proceed in accordance with either 31.2 or 31.4 above, the CONSULTANT shall, at its own expense, either a) modify the contract documents or plans, as necessary and subsequently approved by the Authority, or b) re-bid the Project to achieve a lower bona fide bid or negotiated proposal. If no such lower bid or proposal can be obtained after appropriate modification of the contract documents, AUTHORITY may proceed in accordance with 31.1, 31.3 or any other option that may be available to AUTHORITY in the AUTHORITY’s discretion.
ARTICLE 32 – AUTHORITY’S RESPONSIBILITIES
Provided such information is reasonably required by the CONSULTANT to perform its services under this Contract, the AUTHORITY shall:
1. Provide full information regarding requirements for the projects and tasks, including a program which shall set forth the AUTHORITY’s objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems and site requirements.
9
2. Designate a representative authorized to act on the AUTHORITY’s behalf with respect to the projects or tasks. The AUTHORITY or that authorized representative shall render decisions in a timely manner pertaining to documents submitted by the CONSULTANT in order to avoid unreasonable delay in the orderly and sequential progress of the CONSULTANT’s services.
3. Furnish, to the extent in its possession, surveys describing available information on utility locations, written legal descriptions of the sites, easements, encroachments, zoning, deed restrictions, and other available information to assist the CONSULTANT in developing proper scopes of service and fulfilling project or task objectives.
4. Assist in gaining access to and make all provisions for access required for the CONSULTANT to enter upon public and private property as required for the CONSULTANT to perform services under this Contract.
5. Examine all studies, reports, sketches, drawings, specifications, proposals and other documents presented by the CONSULTANT and render decisions and comments regarding them within a reasonable time so as not to delay the services of the CONSULTANT.
6. Bear all reasonable costs incident to compliance with the requirements of this Article.
ARTICLE 33 – NOTICE
All notices required in this Contract shall be sent certified mail, return receipt requested, and if sent to the AUTHORITY shall be mailed to:
Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
and if sent to the CONSULTANT shall be mailed to:
Todd Zimmerman Amhurst Consulting Company, LLC 2300 Maitland Center Parkway #106 Maitland, FL 32751
ARTICLE 34 – PUBLIC ENTITY CRIMES
A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017, Florida Statutes for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. By signing the Contract, CONSULTANT certifies that it is
10
not subject to denial or revocation of the right to transact business with public entities pursuant to s. 287.133, Florida Statutes.
ARTICLE 35 – SCRUTINIZED COMPANIES
By signing the Contract, CONSULTANT certifies that it is not ineligible, pursuant to Florida Statute 287.135, to bid on, submit a proposal for, or enter into or renew a contract pursuant to Florida Statute 287.135. AUTHORITY may terminate the Contract at its option if CONSULTANT is found to have submitted a false certification pursuant to section 287.135, F.S., been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or been engaged in business operations in Cuba or Syria. AUTHORITY may also terminate the Contract at its option if CONSULTANT is found to have been placed on the Scrutinized Companies that Boycott Israel List or is engaged in a boycott of Israel.
ARTICLE 36 – COMPLIANCE WITH ALL LAWS
In provision of services pursuant to the Contract, CONSULTANT shall comply with all applicable federal, state, and local laws, rules, and regulations.
ARTICLE 37 – PUBLIC RECORDS
AS REQUIRED BY § 119.0701(2)(a), FLORIDA STATUTES: IF CONSULTANT HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONSULTANT’S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, Beverly K. Glarner AT 863-314-1301, EMAIL: [email protected] OR 128 AUTHORITY LANE, SEBRING, FLORIDA 33870.
CONSULTANT shall:
37.1 Keep and maintain public records required by AUTHORITY to perform services.
37.2 Upon request from AUTHORITY’s custodian of public records, CONSULTANT shall provide the AUTHORITY with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in Chapter 119, Florida Statutes, or as otherwise provided by law.
37.3 Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the Contract term and following completion of the Contract if CONSULTANT does not transfer the records to the AUTHORITY.
37.4 Upon completion of the Contract, transfer, at no cost to the AUTHORITY, all public records in possession of CONSULTANT or keep and maintain public records required by AUTHORITY to perform the services. If the CONSULTANT transfers all public records to the AUTHORITY upon completion of the Contract, CONSULTANT shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If CONSULTANT keeps and maintains public records upon completion of the Contract, CONSULTANT shall meet all
11
-- --
applicable requirements for retaining public records. All records stored electronically must be provided to the AUTHORITY, upon request from the AUTHORITY’s custodian of public records, in a format that is compatible with the information technology systems of the AUTHORITY.
END ATTACHMENT 1
12
ATTACHMENT 2Compensation Schedule for Sebring Airport Authority
Amherst Consulting Company, LLC Typical Prime Consultant Billing Rates
2020
FUNCTION 2020 HOURLY BILLING RATE
Principal $235.00
Project Director $200.00
Sr. Project Manager $185.00
Project Manager $155.00
Sr. Engineer/Planner II $155.00
Sr. Engineer/Planner I $140.00
Engineer/Planner II $120.00
Engineer/Planner I $105.00
Sr. Designer/CAD Technician II $125.00
Sr. Designer/CAD Technician I $105.00
Designer/CAD Technician II $95.00
Designer/CAD Technician I $80.00
Sr. Administrative Assistant $85.00
Administrative Assistant $70.00
Sr. Construction Manager $180.00
Construction Manager $150.00
Sr. Construction RPR $110.00
Construction RPR $90.00
Expenses Per Project
Per Diem (RPR) Per Project
Note: Billing rates are specific to function, not necessarily individual employees
13
CONTRACT FOR CONTINUING SERVICES (Construction Projects & Study Activity)
This Contract is made by and between the SEBRING AIRPORT AUTHORITY, hereinafter referred to as the AUTHORITY, and AECOM Technical Services, Inc., a California corporation, hereinafter referred to as the CONSULTANT, whose address is 7650 W. Courtney Campbell Causeway, Tampa, Florida 33607. In consideration of the mutual promises contained herein, the AUTHORITY and the CONSULTANT agree:
The CONSULTANT’s responsibility under this Contract is to provide professional services related to tasks and projects hereinafter provided. These services may include aviation consulting, engineering, and other professional services as described in the response CONSULTANT provided with respect to the Request for Qualifications 19-04. This Contract shall be deemed a “continuing contract” under Section 287.055, Florida Statutes.
The services performed by the CONSULTANT under this Contract may include professional services for construction or study activity projects in which the estimated construction cost of each individual construction project or the fee of each individual study does not exceed the maximum amount permitted for a continuing contract pursuant to applicable law, including Section 287.055(2)(g), Florida Statutes, as may be amended.
Provisions of this Contract may be amended and updated periodically as deemed appropriate by the parties to reflect changes in professional business practices and general economic conditions without invalidating the effect of the nature of this Contract.
Significant tasks or projects shall be initiated by a separate Consultant Services Authorization (CSA) which will include a Scope of Services and Schedule of Payments. Each CSA shall identify whether it is a construction or study activity project, and shall include a duration during which the services shall be performed by the CONSULTANT based on the nature of the work as approved by the AUTHORITY. General consulting work shall not require a separate CSA.
This Contract shall be effective upon the date of execution by all parties and shall continue thereafter until terminated in accordance with the General Terms and Conditions attached hereto.
The AUTHORITY shall pay the CONSULTANT for satisfactory performance, as specified, subject to additions and deletions by amendments as otherwise provided in this Contract.
Services of the CONSULTANT shall be under the general direction of designated individuals, who shall act as the AUTHORITY’s representative during the performance of this Contract. The CONSULTANT shall submit to the AUTHORITY a brief written report concerning the status of active projects.
This Contract shall include the following documents, which are attached to and hereby made a part of this Contract:
Attachment 1: General Terms and Conditions Attachment 2: Compensation Schedule
1
-
IN WITNESS WHEREOF, the AUTHORITY and CONSULTANT have made and executed this Contract as of the _±L_ day of (v\ ~
ATTEST:
By __::::~:;.-:.,~---=- - -------□ 97-Craig Johnson, as its Secretary or □ Pet~as its Asst. Secretary
, 2020.
SEBRING AIRPORT AUTHORITY
By □ 0 --
Stafiley t=t. Well57as its Chair or 'fetrill Mo11 is, as its Vice Chair
Mike WIiiingham , ~x r C:U'ti ~
AECOM Technical ervices, Inc.
' I
Print Name: Steven G. Print Title: Vice Presid
2
ATTACHMENT 1
GENERAL TERMS AND CONDITIONS TO THE
CONTRACT FOR CONTINUING SERVICES BY AND BETWEEN
SEBRING AIRPORT AUTHORITY AND AECOM TECHNICAL SERVICES, INC.
This Attachment contains the general terms and conditions for the Contract for Continuing Services (herein referred to as the “Contract”) dated May 20, 2020 _________________________, 2020, by and between the S EBRING AIRPORT AUTHORITY, a body politic and c orporate of the State of Florida (herein referred to as the “AUTHORITY”) and AECOM TECHNICAL SERVICES, INC., a California corporation, (herein r eferred to as the “CONSULTANT”).
ARTICLE 1 – PAYMENTS TO CONSULTANT
The CONSULTANT will bill the AUTHORITY at the amounts set forth in the Schedule of Payments for services satisfactorily rendered toward the completion of the Scope of Work on a monthly basis or as otherwise provided in a Consultant Services Authorization (“CSA”) for specific services initiated pursuant to the Contract. The amounts billed shall be pursuant to the Compensation Schedule set forth in Attachment 2 of the Contract and shall represent the approximate completion of services outlined in the Scope of Work developed for each authorization.
ARTICLE 2 – REIMBURSABLES
“Out-of-Pocket” expenses will be reimbursed in accordance with the list of the types of expenditures eligible for reimbursement. All requests for payment of “out-of-pocket” expenses eligible for reimbursement under the terms of this Contract shall include copies of paid receipts, invoices, or other documentation acceptable to the AUTHORITY. Such documentation shall be sufficient to establish that the expense was actually incurred and necessary in the performance of the applicable Scope of Work. Any travel, per diem, mileage, meals, or lodging expenses which may be reimbursable under the terms of this Contract will be paid in accordance with the rates and conditions set forth in Section 112.061, Florida Statutes.
ARTICLE 3 – PAYMENT OF INVOICES
Prior to payment, invoices received from the CONSULTANT pursuant to the Contract will be reviewed and approved by the initiating department, indicating that services have been rendered in conformity with the Contract or applicable CSA. Invoices must reference the current purchase order number (if any). Payment shall be made in accordance with the CSA for specific projects.
ARTICLE 4 – TRUTH-IN-NEGOTIATION CERTIFICATE
The signing of the Contract and any Consultant Services Authorization by the CONSULTANT shall act as the execution of a truth-in-negotiation certificate certifying that the wage rates and costs used to determine the compensation provided for in the Contract and that CSA are accurate, complete and current as of the date of this Contract and that CSA.
3
The said rates and costs shall be adjusted to exclude any significant sums should the AUTHORITY determine that the rates and costs were increased due to the inaccurate, incomplete or noncurrent wage rates or due to inaccurate representations of fees paid to outside consultants. The AUTHORITY shall exercise its rights under this “Certificate” within one year following final payment.
ARTICLE 5 – TERMINATION
This Contract may be terminated by the CONSULTANT upon 30 days prior written notice to the AUTHORITY in the event of substantial failure by the AUTHORITY to perform in accordance with the terms of this Contract through no fault of the CONSULTANT. It may also be terminated by the AUTHORITY with or without cause upon 30 days written notice to the CONSULTANT. Unless the CONSULTANT is in breach of this Contract, the CONSULTANT shall be paid for services rendered to the AUTHORITY through the date of termination. After receipt of a Termination Notice and except as otherwise directed by the AUTHORITY, the CONSULTANT shall:
A. Stop work on the date and to the extent specified.
B. Terminate and settle all orders and subcontracts relating to the performance of terminated work.
C. Transfer all work in process, completed work, and other material related to the terminated work to the AUTHORITY.
D. Continue and complete all parts of the work that have not been terminated.
ARTICLE 6 - PERSONNEL
The CONSULTANT represents that it has, or will secure at its own expense, all necessary personnel required to perform the services under this Contract. Such personnel shall not be employees of or have any contractual relationship with the AUTHORITY.
All of the services required hereunder shall be performed by the CONSULTANT or under its supervision, and all personnel engaged in performing the services shall be fully qualified and, if required, authorized or permitted under state and local law to perform such services.
Any changes or substitutions in the CONSULTANT’s key personnel as may be listed herein must be made known to the AUTHORITY’s representative and written approval granted by the AUTHORITY before said change or substitution can become effective.
ARTICLE 7 – KEY PERSONNEL ASSIGNMENT
The CONSULTANT and the AUTHORITY agree to assign the following key personnel required to perform the services necessary under this Contract:
Contact Person for the Consultant: Kelli Piercy, PE AECOM Technical Services, Inc. 7650 W. Courtney Campbell Causeway Tampa, FL 33607
4
Contact Person for Authority: Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
ARTICLE 8 - SUBCONTRACTING
For any specific project, the CONSULTANT reserves the right to select necessary subcontractors.
The AUTHORITY reserves the right to accept the use of a subcontractor or to reject the selection of a particular subcontractor and to inspect all facilities of any subcontractors in order to make a determination as to the capability of the subcontractor to perform properly under this Contract. The CONSULTANT is encouraged to seek minority and women business enterprises for participation in subcontracting opportunities.
If a subcontractor fails to perform or make progress, as required by this Contract, and it is necessary to replace the subcontractor to complete the work in a timely fashion, the CONSULTANT shall promptly do so, subject to acceptance of the new subcontractor by the AUTHORITY.
ARTICLE 9 – FEDERAL AND STATE TAX
The AUTHORITY is exempt from Federal Tax and State Tax for Tangible Personal Property. The AUTHORITY will sign an exemption certificate submitted by the CONSULTANT. The CONSULTANT shall not be exempted from paying sales tax to its suppliers for materials to fulfill contractual obligations with the AUTHORITY, nor shall the CONSULTANT be authorized to use the AUTHORITY’s Tax Exemption Number in obtaining such materials.
The CONSULTANT shall be responsible for payment of its own taxes.
ARTICLE 10 – AVAILABILITY OF FUNDS
The obligations of the AUTHORITY under this Contract are subject to the availability of funds lawfully appropriated for its purpose by the Board of the Sebring Airport Authority.
ARTICLE 11 – INSURANCE
A. The CONSULTANT shall not commence work under this Contract or any CSA unless it has all insurance required under this paragraph and that insurance has been approved by the AUTHORITY. In the event the insurance coverage expires prior to the completion of any Project, a renewal certificate shall be issued 30-days prior to said expiration date.
B. All insurance policies shall be issued by companies authorized or approved to do business under the laws of the State of Florida. The CONSULTANT shall furnish Certificates of Insurance to the AUTHORITY prior to the commencement of work under this Contract. The Certificates shall clearly indicate that the CONSULTANT has obtained insurance of the type, amount, and classifications required for strict compliance with this Article. Compliance with the foregoing
5
requirements shall not relieve the CONSULTANT of its liability and obligations under this Contract.
C. The CONSULTANT shall purchase and maintain professional liability or malpractice or errors or omissions insurance with minimum limits of $2,000,000 per occurrence and annual aggregate. If a claims made form of coverage is provided, the retroactive date of coverage shall be no later than the inception date of claims made coverage, unless the prior policy was extended indefinitely to cover prior acts. Coverage shall be extended beyond the policy year either by a supplemental extended reporting period (ERP) of as great duration as available, and with no less coverage and with reinstated aggregate limits, or by requiring that any new policy provide a retroactive date no later than the inception date of claims made coverage.
D. The CONSULTANT shall maintain, during the life of this Contract, comprehensive general liability insurance in the amount of $1,000,000 per occurrence to protect the CONSULTANT from claims of bodily injury and property damages which may arise from any operations under this Contract whether such operations be by the CONSULTANT or by anyone directly employed by or contracting with the CONSULTANT.
E. The CONSULTANT shall maintain, during the life of this Contract, comprehensive automobile liability insurance in the amounts of $1,000,000 combined single limit for bodily injury and property damage to protect the CONSULTANT from claims for damages for bodily injury, including wrongful death, as well as from claims from property damage, which may arise from the ownership, use, or maintenance of owned and non-owned automobiles, including rented automobiles whether such operations be by the CONSULTANT or by anyone directly or indirectly employed by the CONSULTANT.
F. The CONSULTANT shall maintain, during the life of this Contract, adequate Workman’s Compensation Insurance and Employer’s Liability Insurance in at least such amounts as are required by law for all of its employees performing work for the AUTHORITY pursuant to this Contract.
G. All insurance, other than Professional Liability and Workman’s Compensation, to be maintained by the CONSULTANT shall specifically include the AUTHORITY as an “Additional Insured”.
ARTICLE 12 - STANDARD OF CARE
The CONSULTANT covenants that all services shall be performed by skilled and competent personnel to generally accepted professional standards under similar conditions.
ARTICLE 13 – INDEMNIFICATION
Subject to limitations of Florida law, the CONSULTANT shall indemnify and hold harmless the AUTHORITY, and its officers and employees, from liabilities, damages, losses, and costs, including, but not limited to, reasonable attorneys’ fees, to the extent caused by the negligence, recklessness, or intentionally wrongful conduct of the CONSULTANT and other persons
6
employed or utilized by the CONSULTANT in the performance of the Contract. CONSULTANT’s liability for indemnification shall be limited to $2,000,000.00.
ARTICLE 14 – SUCCESSORS AND ASSIGNS
The AUTHORITY and the CONSULTANT each binds itself and its partners, successors, executors, administrators and assigns to the other party of this Contract and to the partners, successors, executors, administrators and assigns of such other party, in respect to all covenants of this Contract. Neither the AUTHORITY nor the CONSULTANT shall assign, convey or transfer its interest in the Contract without the written consent of the other, which shall not be unreasonably withheld. Nothing herein shall be construed as creating any personal liability on the part of any officer or agent of the AUTHORITY which may be a party hereto, nor shall it be construed as giving any rights or benefits hereunder to anyone other than the AUTHORITY and the CONSULTANT.
ARTICLE 15 – REMEDIES
This Contract shall be governed by the laws of the State of Florida. Any and all legal action necessary to enforce the Contract will be held in Highlands County, Florida, and the Contract will be interpreted according to the laws of the State of Florida. No remedy herein conferred upon any party is intended to be exclusive of any other remedy, and each and every such remedy shall be cumulative and shall be in addition to every other remedy given hereunder or now or hereafter existing at law or by statute or otherwise. No single or partial exercise by any party of any right, power, or remedy hereunder shall preclude any other or further exercise thereof.
ARTICLE 16 – CONFLICT OF INTEREST
The CONSULTANT represents that it presently has no interest and shall acquire no interest, either direct or indirect, which would conflict in any manner with the performance of services required hereunder, consistent with the intent and declaration of policy stated in Section 112.311, Florida Statutes. The CONSULTANT further represents that no person having any interest shall be employed for said performance.
The CONSULTANT shall promptly notify the AUTHORITY in writing of potential conflicts of interest for any prospective business associations, interest or other circumstances which may influence or appear to influence the CONSULTANT’s judgment or quality of services being provided under a specific CSA. Such written notification shall identify the prospective business association, interest or circumstance, the nature of work that the CONSULTANT may undertake and request an opinion of the AUTHORITY as to whether the association, interest or circumstance would, in the opinion of the AUTHORITY, constitute a conflict of interest if entered into by the CONSULTANT. The AUTHORITY agrees to notify the CONSULTANT of its opinion by certified mail within 30 days of receipt of notification by the CONSULTANT. If, in the opinion of the AUTHORITY, the prospective business association, interest or circumstance would not constitute a conflict of interest by the CONSULTANT, the AUTHORITY shall so state in the notification, and it shall be deemed not to be a conflict of interest with respect to services provided to the AUTHORITY by the CONSULTANT under the terms of this Contract.
ARTICLE 17 – EXCUSABLE DELAYS
7
The CONSULTANT shall not be considered in default by reason of any failure in performance if such failure arises out of causes reasonably beyond the CONSULTANT’s control and without its fault or negligence. Such causes may include, but are not limited to: acts of God, the AUTHORITY’s omissive and commissive failures; natural or public health emergencies; labor disputes; freight embargoes; and severe weather conditions. The CONSULTANT shall be responsible for the timely completion of subcontractor’s work.
Upon the CONSULTANT’s request, the AUTHORITY shall consider the facts and extent of any failure to perform the work and, if the CONSULTANT’s failure to perform was due to causes reasonably beyond the CONSULTANT’s control and without its fault or negligence, the Contract Schedule and/or other affected provision of this Contract shall be revised accordingly, subject to the AUTHORITY’s rights to change, terminate, or stop any or all of the work at any time.
ARTICLE 18 – ARREARS
The CONSULTANT shall not pledge the AUTHORITY’s credit or make the AUTHORITY a guarantor of payment or surety for any contract, debt, obligation, judgment, lien or any form of indebtedness. The CONSULTANT further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Contract.
ARTICLE 19 – DISCLOSURE AND OWNERSHIP OF DOCUMENTS
The CONSULTANT shall deliver to the AUTHORITY, if requested, reproducibles and computer files of all final documents and materials prepared by and for the AUTHORITY under this Contract and any CSA, including, but not limited to Project Specifications and Record Drawings. All documents provided by CONSULTANT to AUTHORITY shall be delivered both in hard-copy and in digital, hyperlink formats.
All written and oral information not in the public domain or not previously known, and all information and data obtained, developed, or supplied by the AUTHORITY or at its expense will be kept confidential by the CONSULTANT and will not be disclosed to any other party, directly or indirectly, without the AUTHORITY’s prior written consent unless required by a law, notwithstanding that the CONSULTANT will be permitted to disclose such information to the affected building trades. All drawings, maps, sketches, and other data developed, or purchased, under this Contract or at the AUTHORITY’s expense shall be and remain its property and may be reproduced and reused at the direction of the AUTHORITY.
CONSULTANT shall grant the AUTHORITY unlimited license to use all work product to complete any on-going projects, provided that use by the AUTHORITY of the work product is at the AUTHORITY’s sole risk and without liability or legal exposure to CONSULTANT or anyone working by or through CONSULTANT and further provided that CONSULTANT is paid all undisputed monies due under the applicable project from which the work product was rendered.
ARTICLE 20 – INDEPENDENT CONSULTANT RELATIONSHIP
The CONSULTANT is, and shall be, in the performance of all work, services, and activities under this Contract an independent contractor, and not an employee, agent, or servant of the AUTHORITY. All persons engaged in any of the work or services performed pursuant to this Contract shall at all times, and in all places, be subject to the CONSULTANT’s sole direction, supervision, and control. The CONSULTANT shall exercise control over the means and
8
manner in which it and its employees perform the work, and in all respects the CONSULTANT’s relationship and the relationship of its employees to the AUTHORITY shall be that of an independent contractor and not as employees or agents of the AUTHORITY.
The CONSULTANT does not have the power or authority to bind the AUTHORITY in any promise, agreement or representation other than specifically provided for in this Contract or amendment thereto.
ARTICLE 21 – CONTINGENT FEES
The CONSULTANT represents that it has not employed or retained any company or person, other than a bona fide employee working solely for the CONSULTANT, to solicit or secure this Contract and that it has not paid or agreed to pay any person, company, corporation, individual, or firm, other than a bona fide employee working solely for the CONSULTANT, any fee, commission, percentage, gift, or any other consideration contingent upon or resulting from the award or making of this Contract.
ARTICLE 22 – ACCESS AND AUDITS
The CONSULTANT shall maintain adequate records to justify all charges, expenses, and costs incurred in performing work pursuant to this Contract for at least three (3) years after completion of this Contract. The AUTHORITY shall have access to such books, records, and documents as required in this section for the purpose of inspection or audit during normal business hours, at the AUTHORITY’s cost, upon five (5) days written notice.
ARTICLE 23 – NONDISCRIMINATION
The CONSULTANT represents, to the best of its knowledge, that all of its employees are treated equally during employment without regard to race, color, religion, sex, age, national origin, handicap, or marital status.
ARTICLE 24 – COMPLIANCE WITH DAVIS-BACON ACT REQUIREMENTS
The CONSULTANT hereby agrees, where required on Federal Grant assisted projects, to comply with applicable portions of the Davis-Bacon and related acts which regulate employee wages and benefits. The CONSULTANT further acknowledges the possible necessity for amending the Contract in order to comply with Federal guidelines applicable to Grant Assisted projects which may be undertaken by the AUTHORITY.
ARTICLE 25 – SURVIVAL
All covenants, agreements, and representations made herein, or otherwise made in writing by any party pursuant hereto, including but not limited to any representations made herein relating to disclosure or ownership or documents, shall survive the execution and delivery of this Contract and consummation of the transactions contemplated hereby.
ARTICLE 26 – ENTIRETY OF CONTRACTUAL AGREEMENT
The AUTHORITY and the CONSULTANT agree that this Contract sets forth the entire agreement between the parties, and that there are no promises or understandings other than those stated herein. None of the provisions, terms and conditions contained in this Contract
9
may be added to, modified, superseded or otherwise altered, except by written instrument executed by the parties hereto.
ARTICLE 27 – ENFORCEMENT COSTS
In any action brought by either party for the interpretation or enforcement of the obligations of the other party, including the establishment of a right to indemnification, the prevailing party shall be entitled to recover from the losing party all reasonable attorney’s fees, paralegal fees, court and other costs, even if not taxable as court costs, whether incurred before or at trial, on appeal, in bankruptcy or in post judgment collections.
ARTICLE 28 – AUTHORITY TO PRACTICE
The CONSULTANT hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business, that it will at all times conduct its business activities in a reputable manner, and that it will maintain for duration of this Contract a current certificate of registration required under Florida Statutes.
ARTICLE 29 - SEVERABILITY
If any term or provision of this Contract, or the application thereof to any person or circumstances shall, to any extent, be held invalid or unenforceable, the remainder of this Contract, or the application of such term or provision, to persons or circumstances other than those as to which it is held invalid or unenforceable, shall not be affected, and every other term and provision of this Contract shall be deemed valid and enforceable to the extent permitted by law.
ARTICLE 30 – AMENDMENTS AND MODIFICATION
No amendments and/or modifications of this Contract or any Consultant Services Authorization shall be valid unless in writing and signed by each of the parties.
The AUTHORITY reserves the right to make changes in the scope of work, including alterations, reductions therein or additions thereto. Upon receipt by the CONSULTANT of the AUTHORITY’s notification of a contemplated change, the CONSULTANT shall, if requested by AUTHORITY: (1) provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the AUTHORITY of any estimated change in the completion date, and (3) advise the AUTHORITY in writing if the contemplated change shall effect the CONSULTANT’s ability to meet the completion dates or schedules of this Contract.
If the AUTHORITY so instructs in writing, the CONSULTANT shall suspend work on the portion of the work affected by a contemplated change, pending the AUTHORITY’s decision to proceed with the change.
If the AUTHORITY elects to make the change, the AUTHORITY shall issue a written amendment or Change Order and the CONSULTANT shall not commence work on any such change until such written amendment or change order has been issued and signed by each of the parties.
ARTICLE 31 – CONSTRUCTION COST AND ESTIMATES
10
As to construction projects, the “Construction Cost” shall be the total cost or estimated cost to the AUTHORITY of all elements of the Project(s), including design costs, designed or specified by the CONSULTANT including costs of additives or deductive work items regardless of whether they are awarded for construction. It shall include the cost at current market rates of labor and materials furnished by the AUTHORITY and equipment designed, specified, selected or specially provided for by the CONSULTANT, including a reasonable allowance of the Contractor’s overhead and profit. In addition, a reasonable allowance for contingencies shall be included for market conditions at the time of bidding and for changes in the work during construction.
The ability to complete Projects at or under budget is of great importance to the AUTHORITY. Evaluations of individual Project budget(s), preliminary estimates of Construction Cost, and detailed estimates of Construction Cost prepared by the CONSULTANT, shall represent the CONSULTANT’s judgment as a design professional familiar with the construction industry.
CONSULTANT shall review the Project budget prior to undertaking substantive work on the Project. If CONSULTANT initially determines that the Construction Cost will likely exceed the budget, CONSULTANT shall promptly notify AUTHORITY in writing and suspend further work on the Project.
If CONSULTANT initially believes that the Construction Cost of the proposed Project will likely not exceed the budget, CONSULTANT shall proceed with its work until it has completed approximately thirty percent (30%) of the Project’s overall professional services, at which point CONSULTANT shall deliver to AUTHORITY a detailed written estimate of Construction Cost (“First Estimate”). The AUTHORITY shall review the First Estimate and provide a written directive to either continue or suspend work on the Project.
If AUTHORITY has directed CONSULTANT to continue work on the Project, CONSULTANT shall proceed with its work until it has completed approximately ninety percent (90%) of the Project’s overall professional services, at which point CONSULTANT shall deliver to AUTHORITY another detailed written estimate of Construction Cost (“Second Estimate”). If the Second Estimate exceeds the First Estimate by more than five percent (5%), the CONSULTANT shall explain, in writing, the reason(s) for the increase. The AUTHORITY shall review the Second Estimate and provide a written directive to either continue or suspend work on the Project.
If the Second Estimate is exceeded by the lowest bona fide bid or negotiated proposal, the AUTHORITY shall:
31.1 give written approval of an increase in such fixed limit;
31.2 authorize rebidding or renegotiating of the project(s) within a reasonable time;
31.3 abandon the project(s); or
31.4 cooperate in revising the project(s) scope and quality as required to reduce the Construction Cost.
If the AUTHORITY chooses to proceed in accordance with either 31.2 or 31.4 above, the CONSULTANT shall, at its own expense, either a) modify the contract documents or plans, as necessary and subsequently approved by the Authority, or b) re-bid the Project to achieve a
11
lower bona fide bid or negotiated proposal. If no such lower bid or proposal can be obtained after appropriate modification of the contract documents, AUTHORITY may proceed in accordance with 31.1, 31.3 or any other option that may be available to AUTHORITY in the AUTHORITY’s discretion.
ARTICLE 32 – AUTHORITY’S RESPONSIBILITIES
Provided such information is reasonably required by the CONSULTANT to perform its services under this Contract, the AUTHORITY shall:
1. Provide full information regarding requirements for the projects and tasks, including a program which shall set forth the AUTHORITY’s objectives, schedule, constraints and criteria, including space requirements and relationships, flexibility, expandability, special equipment, systems and site requirements.
2. Designate a representative authorized to act on the AUTHORITY’s behalf with respect to the projects or tasks. The AUTHORITY or that authorized representative shall render decisions in a timely manner pertaining to documents submitted by the CONSULTANT in order to avoid unreasonable delay in the orderly and sequential progress of the CONSULTANT’s services.
3. Furnish, to the extent in its possession, surveys describing available information on utility locations, written legal descriptions of the sites, easements, encroachments, zoning, deed restrictions, and other available information to assist the CONSULTANT in developing proper scopes of service and fulfilling project or task objectives.
4. Assist in gaining access to and make all provisions for access required for the CONSULTANT to enter upon public and private property as required for the CONSULTANT to perform services under this Contract.
5. Examine all studies, reports, sketches, drawings, specifications, proposals and other documents presented by the CONSULTANT and render decisions and comments regarding them within a reasonable time so as not to delay the services of the CONSULTANT.
6. Bear all reasonable costs incident to compliance with the requirements of this Article.
ARTICLE 33 – NOTICE
All notices required in this Contract shall be sent certified mail, return receipt requested, and if sent to the AUTHORITY shall be mailed to:
Mike Willingham Executive Director Sebring Airport Authority 128 Authority Lane Sebring, FL 33870
and if sent to the CONSULTANT shall be mailed to:
12
Steven G. Henriquez, PE AECOM Technical Services, Inc. 7650 W. Courtney Campbell Causeway Tampa, FL 33607
ARTICLE 34 – PUBLIC ENTITY CRIMES
A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided in s. 287.017, Florida Statutes for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list. By signing the Contract, CONSULTANT certifies that it is not subject to denial or revocation of the right to transact business with public entities pursuant to s. 287.133, Florida Statutes.
ARTICLE 35 – SCRUTINIZED COMPANIES
By signing the Contract, CONSULTANT certifies that it is not ineligible, pursuant to Florida Statute 287.135, to bid on, submit a proposal for, or enter into or renew a contract pursuant to Florida Statute 287.135. AUTHORITY may terminate the Contract at its option if CONSULTANT is found to have submitted a false certification pursuant to section 287.135, F.S., been placed on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or been engaged in business operations in Cuba or Syria. AUTHORITY may also terminate the Contract at its option if CONSULTANT is found to have been placed on the Scrutinized Companies that Boycott Israel List or is engaged in a boycott of Israel.
ARTICLE 36 – COMPLIANCE WITH ALL LAWS
In provision of services pursuant to the Contract, CONSULTANT shall comply with all applicable federal, state, and local laws, rules, and regulations.
ARTICLE 37 – PUBLIC RECORDS
AS REQUIRED BY § 119.0701(2)(a), FLORIDA STATUTES: IF CONSULTANT HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONSULTANT’S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS, Beverly K. Glarner AT 863-314-1301, EMAIL: [email protected] OR 128 AUTHORITY LANE, SEBRING, FLORIDA 33870.
CONSULTANT shall:
13
37.1 Keep and maintain public records required by AUTHORITY to perform services.
37.2 Upon request from AUTHORITY’s custodian of public records, CONSULTANT shall provide the AUTHORITY with a copy of the requested records or allow the records to be inspected or copied within a reasonable time at a cost that does not exceed the cost provided in Chapter 119, Florida Statutes, or as otherwise provided by law.
37.3 Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for the duration of the Contract term and following completion of the Contract if CONSULTANT does not transfer the records to the AUTHORITY.
37.4 Upon completion of the Contract, transfer, at no cost to the AUTHORITY, all public records in possession of CONSULTANT or keep and maintain public records required by AUTHORITY to perform the services. If the CONSULTANT transfers all public records to the AUTHORITY upon completion of the Contract, CONSULTANT shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. If CONSULTANT keeps and maintains public records upon completion of the Contract, CONSULTANT shall meet all applicable requirements for retaining public records. All records stored electronically must be provided to the AUTHORITY, upon request from the AUTHORITY’s custodian of public records, in a format that is compatible with the information technology systems of the AUTHORITY.
ARTICLE 38 – PURSUANT TO FLORIDA STATUTES, SECTION558.0035, AN INDIVIDUAL EMPLOYEE OR AGENT OFCONSULTANT MAY NOT BE HELD INDIVIDUALLY LIABLEFOR NEGLIGENCE.
-- END ATTACHMENT 1 --
14
EXHIBIT A AECOM TECHNICAL SERVICES, INC.
SEBRING AIRPORT AUTHORITY / SEBRING REGIONAL AIRPORT
PROPOSED HOURLY RATES FOR CALENDAR YEAR 2020
Job Classification Billable Rate ($ / hour)
Vice President / Principal $290.00
Project Manager $185.00
Senior Architect $175.00
Project Architect $140.00
Construction Manager $155.00
Senior Construction Inspector $115.00
Project Construction Inspector $85.00
Senior Civil Engineer $165.00
Project Civil Engineer $140.00
Civil Engineer $110.00
Senior Electrical Engineer $165.00
Project Electrical Engineer $135.00
Electrical Engineer $110.00
Senior Environmental Engineer $160.00
Project Environmental Engineer $125.00
Environmental Engineer $100.00
Senior Geotechnical Engineer $175.00
Project Geotechnical Engineer $155.00
Geotechnical Engineer $105.00
Senior Structural Engineer $180.00
Project Structural Engineer $145.00
Structural Engineer $110.00
Page 1 of 2
EXHIBIT A AECOM TECHNICAL SERVICES, INC.
SEBRING AIRPORT AUTHORITY / SEBRING REGIONAL AIRPORT
PROPOSED HOURLY RATES FOR CALENDAR YEAR 2020
Senior Environmental Scientist $160.00
Project Environmental Scientist $125.00
Senior Water Resources Engineer $175.00
Project Water Resources Engineer $135.00
Water Resources Engineer $110.00
Senior Engineer $175.00
Project Engineer $140.00
Engineer $110.00
Senior Planner $180.00
Project Planner $140.00
Senior Landscape Architect $155.00
Landscape Architect $105.00
Senior Geologist $140.00
Project Geologist $105.00
Senior GIS Specialist $130.00
Project GIS Specialist $95.00
Field Technician $85.00
Senior Designer $140.00
Drafter / CADD Operator $105.00
Operations Specialist $95.00
Fiscal / Accounting $75.00
Administrative / Clerical $75.00
Page 2 of 2
RESOLUTION SAA 20-09
A RESOLUTION OF THE SEBRING AIRPORT AUTHORITY TO APPROVE AMENDMENT S20-05 TO THE 2019-2020 BUDGET.
WHEREAS, The Sebring Airpo11 Authority is req uired to have an operating budget; and
WHEREAS, said budget is to be used as a tool to project revenues, expenses and reserves; and
WHEREAS, said budget is to be used as a control of costs and expenditures; and
WHEREAS, said budget can be amended from time to time by action of the Sebring Airpo11 Authority Board of Directors;
NOW, THEREFORE, BE IT RESOLVED BY A MAJORITY OF THE MEMBERS OF THE SEBRING AIRPORT AUTHORITY AS FOLLOWS:
SECTION 1. The Sebring Airport Authority hereby approves the 2019-2020 Budget Amendment S20-05 as presented.
SECTION 2. This Resolution shall take effect immediately upon its adoption.
PASSED AND ADOPTED this 21st day of May 2020.
SEBRING AIRPORT AUTHORITY
By /J/~Mike W&-Hngharn, Ex. Director
(SEAL)
SE
BR
ING
AIR
PO
RT
AU
TH
OR
ITY
B
UD
GE
T A
ME
ND
ME
NT#
S20
-05
EFF
EC
TIV
E A
CC
OU
NTI
NG
PE
RIO
D: M
arch
202
0
5 121
/202
0 S
UB
MIT
TED
BY:
S
UB
MIT
TED
BY:
RE
VE
NU
E C
EN
TER
A
CC
OU
NT
AC
CO
UN
T N
AM
E
PRI
OR
BU
DG
ET
AS
O
F 2/
29/2
0 IN
CR
EA
SE
D
EC
RE
AS
E
RE
VIS
ED
B
UD
GE
T R
easo
n:
SA
A
360-
800-
SA
A
INS
UR
AN
CE
CLA
IM P
RO
CE
ED
S
s $
637,
398.
00 .
$
637,
398.
00 .
Unb
udge
ted
s $
$ $
$ $
s s
_$ $
$ '.
s s
s $
s s
$ To
tal R
even
ue ln
crea
~e/D
ecre
ase
$ s
637,
398.
00 .
s
637,
398.
00
CO
ST
CE
NTE
R (e
xpen
ses)
S
AA
S
AA
FB
O
512-
030-
SA
A
512-
061-
S~
51
2-05
1-FB
O
_SA
A O
PE
RA
TIN
G E
XP
EN
SE
S
SM
CO
MP
UTE
R A
CC
ES
SO
RIE
S
. FB
O O
FFIC
E S
UP
PLI
ES
$ 47
.000
.00
$ 20
.0Q_
0._00
. s
7.00
0.00
$
3.00
0.00
s
600.
00 _
_$
500.
00
s $
-$
67.0
00.0
0, s
10
.000
.00
$ 1.
100.
00$
Bu
d_ge
t Und
erst
ated
1 '
~
--
Bud
get U
nd.e
rsta
ted
- .B
udge
t Und
erst
ated
s s s $ s $ s 54
,600
.00
$ $ $ s s $ $ 23
,500
.00
$ s s s $ $ $ 78
,100
.00
-•
Tota
l Exp
ense
s ln
crea
~e/
Dec
reas
e .
Cap
ital E
xpen
ditu
res
Adj
ustm
ents
Pri
or M
onth
B
udge
ted
Ope
ratin
g R
eser
ve
Cur
rent
Mon
th
Rev
enue
-ln
c/(D
ec)
Cur
rent
Mon
th
Exp
ense
-ln
c/(O
ec)
Rev
ised
B
udge
ted
Ope
ratin
g
S12,
114,
655.
69_S
63
7,39
8.00
. $
23
,500
.00
S12
f28,
553.
69
RE
QU
ES
T#:
S20-
05
BO
AR
D
AP
PR
OV
AL:
TRA
NS
FER
TY
PE
: □ x x
ITEM
TO
ITEM
O
PE
RA
TIN
G R
ES
ER
VE
Gt
iai11
11a1
1 of
vlci
i-Cha
h111
aEic
e ~
ut
]>N
c.(.+4
r,.
;\.\ i'1
--t w
j \ \
'"--
'\ h
~
BY
RE
SO
LUTI
ON
# S
AA
20-
-09
Sec
reta
ry o
r Ass
t Sec
reta
ry
SEBRING AIRPORT AUTHORITY AGENDA ITEM SUMMARY
MEETING DA TE:
PRESENTER:
AGENDA ITEM:
May 21, 2020
Mike Willingham
SEF Track Reconstruction - RWSummers - Change Order #8
BACKGROUND: Change Order #08 is a credit to the contract and includes the deduction of the Change Order #05 work associated with the Turf care pit system that was not required. This change order will also reconcile the final contract amount for the Project.
REQUESTED MOTION:
BOARD ACTION:
APPROVED DENIED
---___
DEFERRED OTHER
---
---
Move to approve and authorize Mike Willingham to execute the same.
X
--
Change Order
Change Order
PROJECT: FOOT FPN: 444395-1-94-01
SEfSllmgNrport Au1tl0111y
T,..d< Rec:omlUCllon - Padcage 1
CONTRACT INFORMATION: CCnndlor: SEF Sc:t>ri'Jg Akp«1 Alll>a1l'j
gig/2019
CHANGE ORDER INFO:
O.ngeOro..-No.: 3
Dato< 6/11/2020
OWNER; Mike~-El(8(u1M) OlreQor
12B~Lare
Stl>r'llg. ~ 33670
OWNER'S REPRESENTATIVE: 151' l!toeclwi,v. &Jlle202
Fart My,n. Fl33001
CONTRACTOR: RW&lrnmers. Inc. J693!:estGantfyRold
8"'10#, Fl 33830
THECONTRACT IS CHANGED AS FOU.OWS:
The onginal (Cootred Sum) (Guarantood maximum Price) was
Netchange by previously alfhOrized Change on!OIS
Tho (Contract Sum) (G.Jerant~ maximum Price) prior to !hi&O>Mge order was
The new (Conlnact Sum) (Guaranteed maximum Prioe) lnduding tHs Change orderw1n ba
$ 2,774,979.66 -------5 __2_70..;.,0_1_4_68__
s _ __,;3._044_.;...994_ .34__
$ 3,041,546.12
CHANGE ORDER DETAILS • CONTRACT FINAL EARTHWORK QUANTITY RECONCll.lATION Thi&Q\angeOrd« is for the final reconciliation of wor1c for Ille project ba,;odon final oompleled wak
1) DeductChange Order #05 due to WDfk onIha exisllng Turfcere Pit OOI being n,quired. $ - ---- --2) Raconcillallon to a,rmct Anal Cortract Amount. $
TheCortracl Sum WWI ba 1ncr&a$8d by this Olenge oroer in the amourt of $ -----TheCottract Time w,11 be (ooehanged) byThe date ofSub5tantlalCanpletlon asof the daloor this ChengeOrder therefore is
HOT VALID UlfTl SIGNfD Ill' TH~ R~PRf:S!NTATIVE, CONTRACTOR ANO OWNER.
Alldns NMh America RW S ummers, Inc. Seb<lf111 AJrpo,t Authority OWNER'S REPRESENTATIVE CONTI!ACTOR
_.,;,,-,,,,,.~ r?'~ SIGNATURE SIGNATURE
Kellin McCauley MikeWlRlnghamC.L~~ LJ[(t PRINTED N!UIE PRINTI:O NAME PRINTED NAIIIE
5/11/2020 f1. l'l Lo1.o DATE DATE ~ DATE