Upload
others
View
10
Download
0
Embed Size (px)
Citation preview
Walchand College of Engineering, SangliRs. 1500.00/-
Date: - Bidder Director(Employer)
Tender Form for Civil Work
Department of Planning
Name of the Work- - 1. Asphalting of Road works2. Allied Works3. Solar street lights
in College Campus
Name of the Bidder: -_________________________
Address: -_________________________
_________________________
_________________________
Phone No.: -______________
Mobile: -______________
Email: -_______________
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 1
Invitation of tenders for 1. Asphalting of Road works 2. Allied Works 3. Solarstreet lights in College Campus
Ref. No.: - WCE/PD/ HOSTEL/ Date: - 05/05/2014
To____________________________________________________________________________________________________________________________________________
Dear Sirs,
Sub: Letter of invitation for tenders for 1. Asphalting of Road works 2. AlliedWorks 3. Solar street lights in College Campus.
1. You are invited to submit your most competitive tender for the following work:-
2. To assist you in the preparation of your tender, we are enclosing the following:
i. Detailed Bill of Quantities with estimated rates;ii. Instructions to Bidders (in two sections as Section-A & Section-B).iii. Draft Contract Agreement format for finalizing the agreement for this
Contract.
3. Tender form can be downloaded from www.walchandsangli.ac.in. The cost of suchdownloaded forms shall be attached as D.D. along with D.D. of earnestmoney.
Brief Description of the Works Period of Completion
1. Asphalting of Road works2. Allied Works3. Solar street lights
in College Campus
30 days from the date of letter ofacceptance cum notice by thecollege to proceed with the workorder
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 2
4. Amount paid towards cost of tender form is Non refundable.
5. You are requested to provide your offer latest by 03:30 p.m. on Tuesday 16th
December 2014.
6. Tenders will be opened (in the presence of Bidders or their representatives whochoose to attend) at 04:30 pm on Tuesday 16th December 2014 in the office of theDirector Walchand College of engineering, Sangli.
7. Pre bid meeting is arranged at 3:30 pm at conference hall of main building onMonday 15th December 2014.
8. The contractors may quote separately for Part -1, Part-2 or Part-3. They mayalso quote for all the three parts.
9. We look forward to receiving your tenders.
Employer: DirectorWalchand College of engineering,Vishrambag, Sangli 416405
Tel. No.: (0233) 2300383Fax No.: 91-233-2300831
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 3
Instructions to Bidders
SECTION - A
1. Scope of Works
The Director Walchand College of engineering, Sangli 416415 (Employer) invitestenders for the construction of work as detailed in the table given below
Brief Description of the Works Period of Completion1. Asphalting of Road works2. Allied Works3. Solar street lights
in College Campus
30 days from the Date of letter ofacceptance cum notice to proceed withwork
The successful bidder will be expected to complete the works by the intendedcompletion period specified above.
2. Qualification of the bidder: The bidder shall provide qualification information,which shall include: -
(a) Total monetary value of construction works performed for each year of thelast 3 years, which exceed estimated cost of present work.
(b) Income tax clearance certificate from the concerned IT circle;(c) Report on his financial standing; and(d) Details of any litigation, current or during the last 3 years in which the
bidder is involved, the parties concerned and disputed amount in each case.
3. To qualify for award of the contract the bidder: -
Should have satisfactorily completed as a prime Bidder at least one work of valuenot less than Rs.15,00,000/- in the last three years;(Xerox copy of the certificatefrom the concerned about satisfactory completion of work to be attached)
4. Bid Price
a) The contract shall be for the whole works as described in the Bill ofquantities, drawings and technical specifications. Corrections, if any, shallbe made by crossing out, initialing, dating and rewriting.
b) All duties, taxes and other levies payable by the Bidder under the contractshall be including in the total price.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 4
c) The rates quoted by the bidder shall be fixed for the duration of the contractand shall not be subject to adjustment on any account.
d) The rates should be quoted in Indian Rupees only.
5. Submission of Tenders
5.1 The bidder is advised to visit the site of work at his own expense and obtain allinformation that may be necessary for preparing the tender.
5.2 Each bidder shall submit only one tender. Submission of more than one tender forthe same work by the same bidder shall automatically lead to disqualification forthe bid.
5.3 The tender submitted by the bidder shall comprise of two sub envelopes sealed inone main envelopeSub Envelope No 1: - (Technical bid): - Shall consist of D.D. of Rs. 45000/- forpart –I, 5000/- for Part –II and 4000/- part –III towards earnest money,Bidders Qualification information. (Xerox copies of - filled up tender pages no 8 to30 along with documental proofs)Sub Envelope no 2: - (Financial bid): -Shall consists of duly stamped and signedtender form as completed tender bid (pages 1 to 30, drawing and covering page)by the bidder.
5.4 The bidder shall seal the tender in main envelope. The envelope will also bear thefollowing identification: -
(a) Address to “The Director, Walchand College of Engineering, Sangli”Write at top of envelope “Tender for 1. Asphalting of Road works 2. AlliedWorks 3. Solar street lights in College Campus” WHICHEVER IS VALIDFOR THEIR OFFER.
(b) Do not open before 04:30 pm on Tuesday 16th December 2014.(c) Name, Address and mobile number of bidder.
5.5 Tenders must be received in the office of the Director Walchand College ofengineering, Sangli (Employer) not later than the time and date given in the letterof invitation. If the specified date is declared a holiday, tenders shall be received upto the appointed time on the next working day.
5.6 Any tender received by the Director, Walchand College of engineering, Sangli(Employer) after the deadline for submission of tenders will be rejected.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 5
6. Validity of Tender
Tender shall remain valid for a period of 30 days.
7. Opening of Tenders
Tenders will be opened in the presence of bidders or their representatives whochoose to attend on the date and time and at the place specified in the letter ofinvitation.
8. Information relating to evaluation of tenders and recommendations for the award ofcontract shall not be disclosed to bidders or any other persons not officiallyconcerned with the process until the award to the successful bidder by letter ofacceptance.
9. Evaluation of Tenders
The Employer will evaluate and compare the tenders determined to be substantiallyresponsive i.e. which
(a) Meet the qualification criteria specified in clause 2 & 3 above;
(b) Are properly stamped and signed; and
(c) Conform to the terms and conditions, specifications and drawings withoutmaterial deviations.
10. Award of contract
The Employer will award the contract to the bidder whose tender has beendetermined to be substantially responsive and who has offered the feasible lowestevaluated tender price and who meets the specified qualification criteria andrelevant clauses in section A & B.
10.1 Notwithstanding the above, the Employer reserves the right to accept or reject anytenders and to cancel the bidding process and reject all tenders at any time prior tothe award of contract.
10.2 Notwithstanding the above, the Employer reserves the right to omit any item/workfrom the tender at any time without giving any reasons.
10.3 The bidder whose bid is accepted will be notified of the award of contract by theEmployer prior to expiration of the tender validity period.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 6
11. Performance Security
Within 5 days of receiving letter of acceptance, the successful bidder shall deliverto the Director Walchand College of engineering, Sangli (Employer) paymenttowards performance security (5% of tendered cost) by bank draft in favor of theEmployer or will be deducted from first bill. The Performance Security shall bevalid till the expiry of the period of maintenance of the work, specified in clause12.
12. Period of Maintenance:
The “Period of Maintenance” for the work is 12 months from the date of takingover possession. During the period of maintenance, the Bidder will be responsiblefor rectifying any defects in work, free of cost to the Employer.
13. Purchase of all construction materials as cement, steel, sand, Bitumen, grit,aggregate of all sizes etc. as per the specifications and to the satisfaction of theengineer incharge, shall be the responsibility of the Bidder. The Bidder shall getthe material tested by paying appropriate testing fees in Walchand College ofengineering, Sangli, Applied mechanics/Civil department and shall submit the testresults to the employer.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 7
Instructions to BiddersSECTION - B
1. Format for Qualification Information.
2. Format for Submission of Tender.
3. Format of Letter of Acceptance.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 8
QUALIFICATION INFORMATION FOR BIDDER(to be supplied by the bidder along with bid document)
1 Name of bidder:______________________________
1.1 Address of bidder:______________________________
1.2 Total value of Civil Engineering 2011-2012 ____________________Construction work performed in the last 2012-2013 ____________________Three years (in Rs. Lakhs) 2013-2014 ____________________
1.3 Work performed as prime Bidder (in the same name) on works of a similar natureover the last three years.
ProjectName
Name ofEmployer
Descriptionof work
Value ofcontract(Rs.Lakhs)
Date ofissue ofworkorder
Stipulatedperiod ofcompletion
Actual dateofcompletion*
Remarksexplainingreasons fordelay andworkcompleted
* Completion Certificate from engineer shall be attached
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 9
Information about Existing commitments and on-going works:
ProjectName
Name ofEmployer
Descriptionof work
Value ofcontract(Rs.Lakhs)
Date ofissue ofworkorder
Stipulatedperiod ofcompletion
Value oftotalworkcompleted*
Remarksexplainingreasons fordelay andworkcompleted
* Certificate from engineer shall be attached
1.4 Proposed subcontracts and firms involved in the present work.
Sections of theworks
Value of Sub-contract
Sub-Bidder (name& address)
Experience insimilar work
1.5 Evidence of access to financial resources to meet the requirements of workingcapital: cash in hand, lines of credit, etc. List them below and attach copies ofsupport documents.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 10
1.6 Name, address, and telephone, telex, and fax numbers of the Bidders’ bankers whomay provide references if contacted by the Employer.
1.7 Information on litigation history in which the Bidder is involved.
Name of theparty Cause of dispute Amount
involvedRemarks showingpresent status
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 11
FORMAT OF SUBMISSION OF TENDER
(To be completed by the bidder)
Description of the Works: 1. Asphalting of Road works 2. Allied Works 3. Solarstreet lights in College Campus
To: The Director,Walchand College of Engineering,Vishrambag, Sangli 416415
Subject : Tender for 1. Asphalting of Road works 2. Allied Works 3. Solarstreet lights in College Campus
Reference :- Letter No WCE/PD/ROADS/ dated 10/12/2014from Director W.C.E., Sangli.
Sir,
We offer to execute the Works described in your letter referred to above inaccordance with the Conditions of Contract enclosed there with at Rs---- ---------- as perbill of quantities i.e. for a total Contract Price of -Rs. _________________________________________________ [ in figures ]Rs. _________________________________________________ [ in words ].
This tender and your written acceptance of it shall constitute a binding contractbetween us. We understand that you are not bound to accept the lowest or any tender youreceive.
We hereby confirm that this tender is valid for 30 days as required in Clause 6 ofthe Instructions to Bidders.
Yours faithfully,
Authorized Signature : Date: ______________
Name of Signatory : _______________________________________Name of Bidder/Firm : _______________________________________Address : _______________________________________
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 12
DRAFT LETTER OF ACCEPTANCECUM NOTICE TO PROCEED WITH THE WORK
Dated: ____________________________
To : _________________________________ [Name and address of the Bidder]__________________________________________________________________
Dear Sirs,
This is to notify you that your Tender dated ____________________ for executionof the _____________________________________________________________ for thecontract price of Rupees __________________________________________ [amount inwords and figures], is hereby accepted by us.
You are hereby requested to furnish part performance security for an amount of 5%of contract value in the form of Bank draft in favor of Director W.C.E., Sangli (Employer)within 5 days of the receipt of this letter. This part Performance Security shall be valid tillthe expiry of the period of maintenance. Failure to furnish the Performance Security willentail cancellation of the award of contract and forfeitation of earnest money.
You are also requested to sign the agreement form on court stamp value of Rs100/- stamp on the day of furnishing performance security and proceed with the work notlater than 3 (three) days from signing the agreement under the instructions of the Engineer, and ensure its completion within the contract period.
With the issuance of this acceptance letter, furnishing the part PerformanceSecurity and signing the agreement, contract for the above said work stands concluded.
Yours faithfully,
DirectorWalchand College of Engineering, Sangli
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 13
Draft Agreement formARTICLES OF AGREEMENT
(On a stamp of Rs. 100.00/-)
This deed of agreement is made in the form of agreement on ________ day_______________ month ____________ 2014, between the_____________________________ (Employer) or his authorized representative(hereinafter referred to as the first party) and _____________________ (Name of theBidder), S/O _______________ resident of ______________ (hereinafter referred to asthe second party), to execute the work of ______________________ (hereinafter referredto as works) on the following terms and conditions.
2. Cost of the Contract
The total cost of the works (hereinafter referred to as the “total contract price”) isRs. -________________ as reflected in Annexure – 1 (Bill of Quantities).
3.1 Payments under its contract:The first party will release payments to the second party for the construction work
in the following manner: -
Payment within 7 days on completion of approx. 25 % of the total work (After submissionby second party of certified R.A. bill signed by engineer to first party)Payment within 7 days on completion of approx. 50 % of the total work (After submissionby second party of certified R.A. bill signed by engineer to first party)Payment within 7 days on completion of approx. 75 % of the total work (After submissionby second party of certified R.A. bill signed by engineer to first party)Payment within 15 days on completion of approx. 100 % of the total work (Aftersubmission by second party of certified Final bill & completion certificate of work to firstparty)
4. Notice by Bidder to Engineer
The second party, on the works reaching each stage of construction, shall submit aR.A. bill along with a notice to the Engineer nominated by the first party (who isresponsible for supervising the Bidder, administering the contract, certifying thepayments due to the Bidder, issuing and valuing variations to the contract,awarding extensions of time etc.), to visit the site for certification of stagecompletion and RA. Bill. Within 5 days of the receipt of such R.A. Bill, theengineer nominated by it, will ensure issue of stage completion certificate after due
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 14
verification. Within 15 days of the receipt of final bill, the engineer/I/C worknominated by it, will ensure issue of completion certificate and final billcertification after due verification.
5. Completion time
The works should be completed in 30 days from the date of letter of acceptance. Inexceptional circumstances, the time period stated in this clause may be extended inwriting by mutual consent of both the parties.
6. If any of the compensation events mentioned below would prevent the work beingcompleted by the intended completion date, the first party will decide on theintended completion date being extended by a suitable period:
a) The first party does not give access to the site or a part thereof by theagreed period.
b) The first party orders a delay or does not issue completed drawings,specifications or instructions for execution of the work on time.
c) Ground conditions are substantially more adverse than could reasonablyhave been assumed before issue of letter of acceptance and frominformation provided to second party or from visual inspection of the site.
d) Payments due to the second party are delayed without reason.
e) Certification for stage completion of the work is delayed unreasonably.
7. Any willful delay on the part of the second party in completing the constructionwithin the stipulated period will render him liable to pay liquidated damages.@ Rs. 1000/- per day, this will be deducted from payments due to him. The firstparty may cancel the contract and take recourse to such other action as deemedappropriate once the total amount of liquidated damages exceeds 2 % of thecontract amount.
8. Duties and responsibilities of the first party
8.1 The first party shall be responsible for providing regular and frequent supervisionand guidance to the second party for carrying out the works as per specifications.This will include written guidelines and regular site visit of the authorizedpersonnel of the first party, for checking quality of material and construction toensure that it is as per the norms.
8.2 The first party shall supply 2 sets of drawings wherever necessary, specificationsand guidelines to the second party for the proposed works.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 15
8.3 Possession of the site will be handed over to the second party within 3 days ofsigning of the agreement.
8.4 The Engineer or such other person as may be authorized by the first party shallhold meeting once in a week where the second party or his representative at sitewill submit the latest information including progress report and difficulties if any,in the execution of the work. The whole team may jointly inspect the site on aparticular day to take stock of activities.
8.5.1 The Engineer shall record his observations/instructions at the time of his site visitin a site register maintained by the second party. The second party will carry outthe instructions and promptly rectify any deviations pointed out by the engineer. Ifthe deviations are not rectified, within the time specified in the Engineer notice, thefirst party as well as the engineer nominated by it, may instruct stoppage orsuspension of the construction. It shall thereupon be open to the first party or theengineer to have the deviations rectified at the cost of the second party.
9. Duties and responsibilities of the second party
9.1 The second party shall:
a) Take up the works and arrange for its completion within the time periodstipulated in clause 5;
b) Employ suitable skilled persons to carry out the works;
c) Regularly supervise and monitor the progress of work;
d) Abide by the technical suggestions / direction of supervisory personnelincluding engineer etc. regarding building construction;
e) Be responsible for bringing any discrepancy to the notice of therepresentative of the first party and seek necessary clarification:
f) Ensure that the work is carried out in accordance with specifications,drawings and within the total of the contract amount without any costescalation;
g) Keep the first party informed about the progress of work;
h) Be responsible for all security and watch and ward arrangements at site tillhanding over of the building to the first party; and
i) Maintain necessary insurance against loss of materials/cash, etc. orworkman disability compensation claims of the personnel deployed on theworks as well as third party claims.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 16
f) Pay all duties, taxes and other levies payable by construction agencies asper law under the contract (First party will effect deduction from runningbills in respect of such taxes as may be imposed under the law).
10. Variations / Extra Items
The second party in accordance with the approved drawings and specificationsshall carry out the works. However, if, on account of site conditions or any otherfactors, variations are considered necessary, the following procedure shall befollowed:-
a) The second party shall provide the Engineer with a tender for carrying outthe Variation when requested to do so by the Engineer. The Engineer shallassess the tender, which shall be given within seven days of the requestbefore the Variation is ordered.
b) The tender given by the second party is will be technically assessed byengineer/ Construction committee and financial feasibility will also bechecked. The first party has all right to alter the tender on technical realisticgrounds.
On mutual approval of altered tender the content price shall be varied andfirst party at the mutually accepted tender/ rate shall execute the work.
c) If the alteration in the tender is net acceptable to second party, the firstparty has every right to deploy the other agency to get executed thedeviated/ extra item and for which no claim of first party will beentertained. In the said situation the first party will cooperate the otheragency to complete the whole of the work in stipulated time period.
11. Securities
The Performance Security shall be provided to the Employer no later than the datespecified in the Letter of Acceptance and shall be issued in an amount and formand by a bank or surety acceptable to the Employer. The Performance Securityshall be valid until period of maintenance from the date of issue of the Certificateof Completion in the case of a Bank Guarantee.
12. Termination
12.1 The Employer may terminate the Contract if the other party causes afundamental breach of the Contract.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 17
12.2 Fundamental breaches of Contract including, but shall not be limited to thefollowing:
(a) The Bidder stops work for 7 days and the stoppage has not beenauthorized by the Engineer;
(b) The Bidder has become bankrupt or goes into liquidation other thanfor a reconstruction or amalgamation;
(c) The Engineer gives Notice that failure to correct a particular Defectis a fundamental breach of Contract and the Bidder fails to correct itwithin a reasonable period of time determined by the Engineer/I/Cwork;
(d) The Bidder does not maintain a security, which is required;
12.3 Notwithstanding the above, the Employer may terminate the Contract forconvenience.
12.4 If the Contract is terminated the Bidder shall stop work immediately, makethe Site safe and secure and leave the Site as soon as reasonably possible.
13. Payment upon Termination
13.1 If the Contract is terminated because of a fundamental breach of Contractby the Bidder, the Engineer shall issue a certificate for the value of thework done less advance payments received up to the date of the issue of thecertificate, less other recoveries due in terms of the contract, less taxes dueto be deducted at source as per applicable law.
13.2 If the Contract is terminated at the Employer’s convenience, the Engineershall issue a certificate for the value of the work done, the reasonable costof removal of Equipment, repatriation of the Bidder’s personnel employedsolely on the Works, and the Bidder’s costs of protecting and securing theWorks and less advance payments received up to the date of the certificate,less other recoveries due in terms of the contract and less taxes due to bededucted at source as per applicable law.
14. Dispute settlement
If over the works, any dispute arises between the two parties, relating to anyaspects of this Agreement, the parties shall first attempt to settle the disputethrough mutual and amicable consultation.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 18
In the event of agreement not being reached, the matter will be referred forarbitration by a Sole Arbitrator not below the level of retired SuperintendingEngineer, PWD to be appointed by the first party. The Arbitration will beconducted in accordance with the Arbitration and Conciliation Act, 1996. Thedecision of the Arbitrator shall be final and binding on both the parties.
Special Terms and conditions
1. If rain does not allow for execution of few of the items, the items will be executedimmediately after rainy season without claiming any additional charges.
2. In the scope of the tender for the bill of the quantities brief specifications isincluded for the understanding of the tenderer, however the detailed PWDspecifications of the respective item is applicable for the execution and in general.
3. Your tender should be addressed to the Director, Walchand College ofEngineering, Vishrambag, Sangli - 416 415 (Maharashtra State).
4. All duties, taxes, octroi and other levies etc. as applicable are payable by thecontractor under the contract and shall be included in the total price.
5. Proper measures/ precautions are to be taken on site during the execution ofworks.
6. Accidental loss of any kind will be borne by contractor.7. Rights to change quantity, any clause fully or partially in the terms and conditions
mentioned above and right to cancel any Tender without giving any reason isreserved with Director, Walchand College of Engineering, Sangli.
8. The work may also be awarded to one or more agencies.
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 19
Annexure I
BILL OF QUANTITIES
Sr.No.
Description ofWork
Qty. Unit Estimated Cost Amount
In figure(Rs.)
In Words
As per Separatesheet of B.O.Qattached
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 20
Annexure – 2
Format of certificate
To,The Director,W.C.E., Sangli.
Subject: - About R.A/Final bill of 1. Asphalting of Road works 2. Allied Works 3. Solarstreet lights in College Campus.
Certified that the works of Rs.___________________________ in respect of 1.Asphalting of Road works 2. Allied Works 3. Solar street lights in College Campus, atWalchand College of Engineering, Sangli have been executed in accordance with thescope of work and technical specifications
Signature
Engineer
Place:Date:
Office seal
WCE-PD/ROADS
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 21
Walchand College Of Engineering, SangliBill of Quantities
Annexure – 1NAME OF WORK: - 1. Asphalting of Road works2. Allied Works3. Solar street lights in College Campus
Part I : Asphalting of Road works(Approx. Quantity and Abstract sheet)
Sr.No.
Item No L B D Qty Rate Per Amount
Item1
Providing necessary labour for giving line out of roads, removing thorny shrubs,trees and plants, grit, aggregate on road and similar etc complete as directed byEngineer in charge.
Job - - - L/S 2500.0
Job 2500.00
Item2
Excavation for road foundation in all types of soil, murum including removingexcavated material up to distance of 50 m, watering, ramming etc complete asdirected by engineer in charge REF: 2a/23MORTH301ABCGHIJKL
182.0244.0132.0
1.02.03.0
0.150.150.15
27.30
73.20
59.40
Total Quantity 159.9
150.0
Cum
23985.0
Item3
Supplying Hard murum at the college site, including conveying and stackingcomplete (for Road Shoulders) REF: 20/23MORTH 408GCN 215.0 3.0 0.1 64.5
0
Total quantity 64.50
550.0
Cum
35475.0
Item4
Spreading Hard murum including sectioning complete. REF: 22/23 MORTH 408GCN 215.0 3.0 0.1 64.5 39 Cu 2515.50
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 22
0 m
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 23
Sr.No.
Item No
L B D Qty Rate Per Amount
Item5
Transporting soft murum from item no 2 to the college road widening sites withincampus including stacking complete.ABCGHIJKL
182.0
244.0
132.0
1.02.03.0
0.150.150.15
27.30
73.20
59.40
Total quantity 159.9
200.0
Cum
31980.0
Item6
Spreading soft murum from item No 5 including sectioning complete .REF: 22/23MORTH 408ABCGHIJKL
182.0244.0132.0
1.02.03.0
0.150.150.15
27.3073.2059.40
Total quantity 159.9
39.00
Cum
6236.10
Item7
Compacting the subgrade / gravel / size metal (100mm loose) layers with powerroller including necessary, labour, materials and artificial watering complete REF:24/23 MORTH 408ABCGHII to PhysicsNOPQCentral gate to H
182.0244.0215.0252.0132.0
1.02.03.03.03.0
-----
182.0488.0645.0756.0396.0
Total quantity 2467
5.00 Sqm
12335.0
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 24
Sr.No.
Item No L B D Qty Rate Per
Amount
Item8
Providing and laying bituminous bound macadam surface 75 millimeter thickincluding supplying all materials spreading trap metal layers and key aggregateheating and spraying bitumen at the rate of 200 kg/100 sq.mt. and compaction withpower roller including brooming, applying tack coat at 50 kg. per 100 sq.mt. etc.complete (without seal coat) excluding 20 mm metal etc. complete as per line outand site cleaning as directed by Engineer-in-chargeABCGHIGCNOVparking areaJKL
182.0244.0215.0252.058.00132.0
4.02.0/23.03.044.03.0
------
728.0244.0645.0756.02552396.0
Total Quantity 5321 250 Sq.m.
1330250
Item9
Providing and laying bituminous bound macadam surface 12 to 20 mm thickaggregate for patch work including supplying all materials spreading trap metallayers and key aggregate heating and spraying bitumen at the rate of 200 kg/100Sqm and compaction with power roller including brooming, applying tack coat at50 kg per 100 sq.mt. etc. complete (without seal coat) excluding 20 mm metal etc.complete as per line out and site cleaning as directed by Engineer-in-chargeABCDECNNQJKL
350.0170.0255.0120.0
1.0/21/21/21/2
----
175.085.00127.560.00
Total Quantity 477.5
200 Sqm
95500
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 25
Sr.No.
Item No L B D Qty Rate Per Amount
Item10
Providing 20 mm thick premix bituminous carpet supplying all materials preparingand cleaning the base, heating bitumen, brooming applying tack coat, mixing hotbitumen and chips, laying the carpet layer and compacting using Bulk Bitumengrade 60/70 etc complete as per line out and site cleaning as directed by Engineer-in-chargeABCCDEFGHII to PhysicsNOPQJRU, RS, STGCNCentral gate to HD to KJKLL to Vartak Hall
182.0233.0244.0286.0248.0135.0215.059.0090.00132.0139.0385.0
4.03.03.04.03.02.03.05.06.706.015.02.0
------------
728.0699.0732.01144744.0270.0645.0295.0603.0792.02085770.0
Total Quantity 9507 230 Sqm
2186610
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 26
Sr.No.
Item No L B D Qty Rate Per Amount
Item11
Laying bituminous liquid seal coat to black top surface including preparing theexisting road surface, heating and applying bitumen and spreading stone dustcomplete. Using Bulk Bitumen grade 60/70, etc complete as per line out and sitecleaning as directed by Engineer-in-charge97ai/23 MORTH 513ABCCDEFGHII to PhysicsNOPQJRU, RS, STGCNCentral gate to HD to KJKLL to Vartak Hall
18223324428624813521559.090.00132139385
4.03.03.04.03.02.03.05.06.706.015.02.0
-------
----
728.0699.0732.01144744.0270.0645.0295.0603.0792.02085770.0
Total Quantity 9507 80.00
Sqm
760560
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 27
Sr.No.
Item No L B D Qty Rate Per Amount
Item12
Providing and applying Hot applied Road Marking Thermoplastic compound 2 mmthick Paint on bituminous surface for Lines, zebra crossing, arrows etc. complete asdirected by engineer inchargeABCCDEFGHII to PhysicsNOPQJRU, RS, STGCNOVCentral gate to Hparking areaD to KJKLL to Vartak HallAll internalDepartment
182.0233.0244.0286.0248.0135.0215.0252.059.0058.0090.00132.0139.0385.0
2.02.02.02.02.02.02.02.02.044.02.02.02.02.0
0.100.100.100.100.100.100.100.100.100.100.100.100.100.10
36.446.648.857.249.627.043.050.411.825518.026.427.877.077520*1.1
Total Quantity 852.72 150 Sqm
127908
Item13
Providing and laying cement concrete pipe of I.R.S. NP-3 class of 450 mmdiameter in proper line level and slope for CD works including necessaryexcavation, laying and back filling of trench, providing and fixing collars in cm 1:2curing etc complete as directed by engineer incharge
10 6.0 - - 60.00
1500
m 90000
TOTAL Rs. 4705855.00Say Rs. Forty Seven Lac Six Thousand only 4706000.00
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 28
Part II: Allied Works (Approx. Quantity and Abstract sheet)
Sr.No.
Item No L B D Qty Rate Per Amount
Item1
Providing & constructing Brick Masonry Inspection Chamber 60 cm x 75 cm x90cm including 1:4:8 cement concrete foundation 1:2:4 cement concrete channels,Brick Masonry, plastering from inside/ outside and with frame fixed in cementconcrete with R.C.C. Cover, all side rough Shahabad covering curing etc completeas directed by engineer incharge.
2 - - - 2 6000.0
No. 12000.0
Item2
Providing and laying channelized gutter in RCC of size 0.45 at top and 0.30 atbottom and height 0.45 m, with necessary excavation, removing and replacingPaving blocks with necessary slope etc. complete as directed by Engineer inCharge.
350.0
- - 350
Total Quantity 350 1000 m 35000Item3
Providing uncoursed rubble masonry of trap/ granite/ quartzite/ gneiss stones incement mortar 1:6 in foundation and plinth of inner walls/in plinth of externalwalls including bailing out water, striking joints on un exposed faces and wateringcomplete.
2 16 0.75 1.20 28.80
Total quantity 28.80
3000 Cum
86400.0
Item4
Providing and constructing masonry in precast solid concrete Block (Grade D-50As per I.S. 2185, Part- 1, 1974, Reframed 1987) having compresive strength 5-00N/mm2) of size ( 300 x 200 x 150 mm) in cement mortar 1:6 for super structureincluding striking joins on unexposed faces racking out joints on exposed faces,watering, curing and scaffolding etc. complete as directed by Engineer in charge.2 25 0.20 0.6 6 2800 Cu
m16800
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 29
Sr.No.
Item No L B D Qty Rate Per Amount
Item5
Providing and fixing electronic boom each with length of 4.5 m , automaticoperated etc. complete as directed by Engineer in charge.3 4.5 - - -
Total quantity 3 65000 No.
195000
Item6
Providing, supplying and installing Portable Prefabricated Cabin of model ItemCode: B-UC-1042-OT or equivalent Portable cabin having size: 2.45m (length) x2.45 m Width x 2.2 m Height used mainly for security Cabins connected withFiber Reinforced Plastic: 5 mm thickness Panels, door arrangement for entry & 3openings of sliding glass windows which are fitted in powder quoted aluminumsections and properly arranged for the ventilation. Canopy of the Cabins made upFRP Structure make well finished & good attractive color combination etccomplete as directed by engineer in charge.
Total quantity 1 50000 No.
50000.0
Item7
Providing and planting ornamental plants with necessary red soil , and necessarygardeners work etc complete as directed by engineer incharge.
200 200 50 No.
10000.0
Total quantity 200 50 No.
10000.0
Item9
Providing and fixing SWR 100 mm dia stabilizer pipe/ soil vent/waste pipe andwith necessary fixtures and fitting such as bends, tees, single junctions, slottedvent, clamps etc. complete as directed by Engineer in charge.
10 - - 10 250.0 No. 2500.0Item10
Providing and fixing convex type reflecting mirrors at junctions of roads includingadequate back, and stand etc complete as directed by engineer incharge.3 - - - 3 1000
0No 30000
Total Quantity 3 30000
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 30
Sr.No.
Item No L B D Qty Rate Per Amount
Item11
Providing and spreading river bank red soil for lawn plantation, with necessarybrick bats bedding, compost, fertilizers, and slabs of jumping lawn, 0.45 mretaining wall with sand faced plaster etc. complete as directed by engineerincharge.
20 15 - 300
Total quantity 300 1000 Sqm
30000
Total Amount: Rs. Four lac Ninety three thousand only 492700.00Item12
Providing necessary labour and material, cutting and welding plant etc. to widenthe main gate by 1.5 m, including removing existing pillars, steel structure,providing necessary repairs, re-erecting pillars with concrete foundation, providingand fixing 1.5 m X 2.0 m emblem as per design in MS structure, coloring etc.complete as directed by engineer incharge.
- - - 1.0
Total quantity 25000 Job
25000
Total Amount: Rs. Four lac Ninety three thousand only 492700.00
Walchand College of Engineering, Sangli
Date: - Bidder DirectorPage 31
Part III: Solar Street Light Works(Approx. Quantity and Abstract sheet)
(Main gate to Physics lab and MSEB gate to Ganpati temple)
Sr.No.
Item No L B D Qty Rate Per Amount
Item1
Providing & fixing solar street light with PV Module 12 V, 37 Wp; MonoCrystalline silicon type; Battery 12V, 40 Ah; Sealed Maintenance Free Battery;Light Source ; Super bright White LED with working dusk to dawn (Automaticoperation) and minimum warranty of one year etc . complete as directed byengineer incharge.
20 - - - 20 20000 No. 400000TOTAL: Rs. Four lac Only
We agree to execute the above mentioned items/works in accordance with theapproved drawings and technical Specifications at,
1. ------------ % above/below for part –I2. ------------ % above/below for part –II3. ------------ % above/below for part –IIIto the estimated cost of equipments/works as mentioned in above bill of
quantities .
Signature of Bidder
WA
LCH
AN
D C
OLLEG
E OF EN
GIN
EERING
, SAN
GLI.
40
GO
VERN
MEN
T CO
LONY RO
AD
GO
VERN
MEN
T CO
LON
Y ROA
D
M.S.E.B.
DRN
BY- Prof. N. N. Kam
ble
Dra
inag
e W
ellD
raina
ge
Well
Dra
inag
e W
ell
Main Build
ing
PG
LabPELab
Chem
istryLab
Meta
llurgy
Lab
Electrical Deptt
Mecha
nical Lab
Mecha
nical W
orkshop
Mecha
nical Deptt
Civil
Deptt
Hyd Lab
Civil D
rg Hall
Quad
rangleTilak Hall
Vartak Hall
Law
n Tennis
Gun W
all
Gym
khana
Ca
nteen
Physics
Maths
Vision O
ffice
ExamC
ell
Toilet
Ajit G
ulabchand
Central Lib
rary
Ganapati
Sump
SumpSociety
Cyb
er Hostel Watchm
an
Director Bunglow
Ladies M
essM
edicalO
ld Rector O
ffice
Ladies M
ess
Faculty Qua
rter
Rector Office
Faculty Qua
rter
D1D2
D3D4
D8
D7
D6D5
Old
Mess
Hot Bath
Hot Bath Q
uarters
ME Hostels
ME Hostels
New
Mess
Rainbow
Staff Q
uaters
Wad
ar Well Staff Q
uarters
Agricultura
l Staff Quarters
Ganesh Staff Q
uarters
Bara Staff Quarters
Staff Q
uarter
Staff Q
uartersC
omm
unity Polytechnic
Green
Faculty Qua
rters
Staff Q
uarter
Staff Q
uarter
Bank
Staff Q
uarter
Smithy W
orkshop
Hyd
Well
Wad
ar Well
N
SCA
LE 1 :1000
College Roads
AB
CE
DF
HI
KL
M
NO
PQ
G
Ro
adW
idth
Rem
arksE
xisitin
gP
rop
osed
AB
C3
.04
.0W
ide
nin
g b
y 1 m
C
DEF
3.0
3.0
Asp
ha
lting
& w
ide
nin
g n
ot possib
le du
e to a
dju
stan
t structu
resG
HI
3.0
3.0
Asp
ha
lting
for ro
ad
wid
th an
d V
IP p
arking
a
rea w
ith p
erma
na
nt p
arking
layout
Ma
in g
ate
to P
hysics
4.0
Asp
ha
lting
with
pro
vision
of storm w
ater d
rain
ag
e, W
atch
ma
n cab
in w
ith A
utom
atic b
oo
mso
n e
ither sid
eN
OP
Q3
.03
.0A
sph
altin
gJR
U, R
S, S
T 3.0
3.0
Asp
ha
lting
GC
N3
.03
.0A
sph
altin
g w
ith P
ark
ing
lot 2 m
wid
e, G
utte
r pro
vision
be
hin
d m
echan
ical and
civil d
ep
artmen
tO
V3
.05
.0W
BM
Wid
en
ing
by 2
m
Cen
tral gate to
H5
.0A
sph
altin
gFou
r wh
eele
r pa
rkin
g area
Asp
ha
lting
with
pe
rman
ant p
arking
layout
Ma
in b
uild
ing
to K6
.70
Asp
ha
lting
with
pro
vision
of storm
water d
rainag
eJK
L3
.06
.0W
ide
nin
g b
y 3 m
an
d A
sph
alting
with
p
rovisio
n o
f storm
water d
rainag
e and
p
erm
an
an
t ma
rkin
gs fo
r path
of procession
d
urin
g G
radu
ation
aw
ard
sL to
Va
rtak Hall
15
.0A
sph
altin
g an
d p
erm
anan
t ma
rkin
gs for
pa
th o
f pro
cessio
n a
nd
flag h
oisting
stand
ing
a
rran
ge
me
nt, stro
m w
ater is to be
harve
sted a
t adja
cen
t borew
ells
All
Dep
artm
ent
Asp
ha
lting
Roa
ds
3.0
3.0
RS T
U J
V
ESR
Watchm
an
Watchm
an
Lifton Tea 2
Lifton Tea 1Tra
nsformer Room
2
Transform
er Room 1
Full Asphalting a
rea for parking
Central G
ate
PRODUCED BY AN AUTODESK EDUCATIONAL PRODUCTPR
OD
UC
ED B
Y A
N A
UTO
DES
K E
DU
CA
TIO
NA
L PR
OD
UC
TPRODUCED BY AN AUTODESK EDUCATIONAL PRODUCT
PRO
DU
CED
BY A
N A
UTO
DESK
EDU
CA
TION
AL PR
OD
UC
T
Tender for Renovation of Roads in college campus.pdfcollege road plan.pdf