Upload
doanthu
View
216
Download
0
Embed Size (px)
Citation preview
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 1 of 69
UCO BANK, Department of Information Technology
Request for Proposal (RFP) For “Implementation of Bharat Bill Payment System to operate as a Bharat Bill Payment Operating Unit RFP Ref No : UCO/DIT/1003/2016-17 Date 31-08-2016”Pre-Bid Responses/ Clarifications
to Queries raised by the Bidder(s), Amendments, Addendums and Corrigendum’s
SL No
Page no Clause Clause as per RFP Description of Query/Clarification
sought by Bidder Bank Response
1. 9 Section 1.6
Earnest Money Deposit (EMD)
of Rs. 10,00,000
We wish to decrease the EMD to Rs. 1,00,000 (Rs. One Lakh)
Clause 1.6 of the RFP has been modified as “Earnest
Money Deposit (EMD) of Rs.
5,00,000.”
2.
13
Section 2.1 –
Eligibility Criteria
Point 2
The bidder should have an annual turnover of at least Rs.
10 Crores per annum for last 3
financial years (i.e. 2013-14, 2014-15, and 2015-16)
The Bidder should have registered
an annual turnover of at least Rs. 5 Crores per annum for last 3 financial
years (i.e 2013-14, 2014-15 and 2015-
16).
Clause of the RFP has been
modified as “The Bidder
should have registered an
annual turnover of at least Rs.
5 Crores per annum for last 3
financial years (i.e 2013-14,
2014-15 and 2015-16).”
3.
22
Section 5.4 –
Performance Bank
Guarantee
The selected bidder, within 15 days from the date of
purchase order will have to
furnish a Performance Bank Guarantee, format as
Annexure I , issued by any
The selected bidder, within 15 days from the date of purchase order will
have to furnish a Performance Bank
Guarantee, format as Annexure I , issued by any scheduled
commercial bank equal to 5% of
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 2 of 69
scheduled commercial bank
equal to 10% of the order
value valid for 39 months from the date of purchase order.
Upon furnishing the
Performance Bank Guarantee, the EMD of the selected
bidder shall be returned.
the order value valid for 39 months
from the date of purchase order.
Upon furnishing the Performance Bank Guarantee, the EMD of the
selected bidder shall be returned.
4.
19 4.5
*Note: Phase-2 is required if
Bank wants to be Biller OU also.
In case, Bank has opted only to be Customer OU then
Phase-2 is not required.
1) Request the Bank to clarify if Bank wants to be Biller OU since overall
implementation timelines and
planning can be impacted if Bank decides to be Biller OU after
completion of Phase 1.
2) How many existing Merchants
does the Bank currently have?
Request the Bank to specify the nature of integration with these
Merchants. If the Bank is not able to
provide the information, request the Bank to consider merchant on-
boarding an operational activ ity in
Phase2.
Bank will act as Biller OU post
Phase 1. As and when the merchant tie up will happen
with the Bank, vendor has to
integrate the merchant in the BBPS environment.
5 20 4.6
Standard API‟s For Interface
With Alternate Delivery Channels
Request the Bank to clarify whether
payment channel API 's will be
provided by the Bank for the Bidder
to consume for Integration
Payment channel API 's will be
provided by the Bank
6
Can the Bank please clarify the year
on year volumes it is expecting for
the contract period? This will be helpful in hardware sizing
estimation.
Please refer scope of work,
point no-14.First year-50 to 75
lacs,2nd year 75-1.25 cr,3rd 1.25-2cr approx. volume of
transaction.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 3 of 69
7 18 4.2 SMS/Email Integration
Request the Bank to clarify if existing vendors for SMS / Email are present
with the Bank for Integration?
Bank has its SMS/Email
vendor. The required
information will be shared with the selected bidder.
8
13 2.1 Eligibility Criteria
We understand that bank is looking
forward for a partner with some experience of Bill payment system
to ensure successful implementation
of BBPOU platform hence we
request bank to consider adding of below eligibility qualification:
1) The bidder should have successfully completed sand box
testing with NPCI for BBPOU
integration.
Clause stands as per RFP.
9
13 2.1 Eligibility Criteria
We understand that bank is looking
forward for a partner with some
experience of Bill payment system to ensure successful implementation
of BBPOU platform hence we
request bank to consider adding of below eligibility qualification:
1) The bidder should be implementing / implemented
hosted BBPOU platform for at least
one bank in India. Formal go ahead
email / Purchase order should be submitted as proof of this.
Yes. Clause stands as per RFP.
10
14
PART –I I / 2.1
Eligibility
Criteria/4.
The Bidder should own the
intellectual property rights of the solution or should have
rights from the owner. I f not,
the Bidder should have in place proper tie-ups,
As the proposed system is in-house
developed can the bidder can give an undertaking to this effect. The
intellectual property rights solely rest
with the vendor.
Yes
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 4 of 69
commercial agreements &
authorized implementation
partnership for deployment/resale/customizati
on of software with the
product OSD whose software products are offered.
11 14
PART –I I / 2.1 Eligibility
Criteria/5.
The bidder should be an OEM or their authorized
representative.
As the proposed system is in-house developed can the bidder can give
an undertaking to this effect.
Yes
12 14
PART –I I / 2.1 Eligibility
Criteria/6.
Bidder should have experience
of minimum 1 years as on 30th
September, 2016 in providing such type of solutions or
carrying out activ ities/projects
like Payment Gateway/ATM Switch/IMPLS/Biller Integration
& reconciliation of the
RBI/NPCI/PSB.
I f the vendor has implemented
payment gateway solution to one
of the banks will it suffice the requirements? We need more clarity
on Biller Integration & reconciliation
of the RBI/NPCI/PSB
Clause of the RFP has been
modified as “Bidder should
have experience of minimum 1 years as on 30th
September, 2016 in providing
such type of solutions or carrying out
activ ities/projects like
Payment Gateway/ATM Switch/IMPS/Biller Integration
& reconciliation of the
RBI/NPCI/PSB.”
13 48
Annexure-E
Commercial Bid Format
Table-4
Request the bank to provide the
approximate number of
transactions for each year for quoting reconciliation charges.
Bidders are not privy to the changes
in tax structure introduced by respective regulatory authorities
from time to time.(Eg. Introduction
of GST and its impact is unknown so far).
Bidder has to quote bid with
existing tax in place.
However, payment will be made based on the
prevailing tax at the time of
invoice.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 5 of 69
Accordingly almost RFP‟s in India so
far have excluded taxes from the
Ambit of commercial calculations. We request the bank to please
consider the base price of
components and exclude all taxes and lev ies from the gamut of
commercial evaluation.
14
General
Submission of Bid documents
Request the bank to consider 2
weeks time for submission of bid documents from the date the pre-
bid clarifications is published in the
bank‟s website.
Date of Submission of bid is
extended upto 13/10/2016.
15 13 2.1. (3)
The Bidder should be a profit
making entity (profit after tax) in any two of the last three
financial years i.e. 2013-14,
2014-15, and 2015-16.
Usually for IT Companies banks
prefer Eligibility Criteria as "Profit
making in last 3 financial years OR having Positive Networth in last 3
financial years".
Suggest to amend.
Clause stands as per RFP.
16 17 3 (iii)
Prov ide mobile app in
android/windows/blackberry/iOS for customer payment
Bank has its own Mobile Banking
Application. APIs can be shared with the Mobile
Banking Vendor for integration with
BBPOU. Does Bank want to have separate
Mobile App for BBPOU. Please
clarify.
Yes , For BBPPOU Bank wants
separate Mobile App.
17 18 19
The proposed Bharat Bill
Payment system application
must be implemented in scheduled languages (22) of
the India.
We understand this requirement is from the perspective that Customer
accessing the Web Portal of Bank
for using bank BBPS system. In such case Bank web portal vendor need
to provide this facility.
In case if Bank wants to provide
BBPS vender has to provide required web portal for BBPS,
which should be available in
22 languages
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 6 of 69
separate portal then bidder will
have to provide it.
Please clarify.
18 18 4.2 Phase 1
(1)
Portal for bill payment through
BBPS
Does Bank want to provide dedicated portal for customer to
access Bank BBPS.
Please clarify.
Yes
19 18 4.2 Phase 1
(2)
Integration with Core Banking
Application
Bank to arrange APIs for integration. Any charges for API by CBS vendor
should be borne by Bank.
Yes
20 18 4.2 Phase 1
(10)
Complaint management
system [CMS] i. Complaint messages to
BBPCU
ii. The complete Complaint
management system should be available.
As per the BBPS technical specification the Compliant
Management System (CMS) &
Dispute Management System (DMS)
is in the scope of BBPCU (NPCI).
The scope of work should be as per the guidelines of NPCI.
The selected bidder has to in
line with NPCI to the any
changes/updation/modification of the proposed system
and it will be the responsibility
of the selected bidder.
21 19 4.2 Phase 1
(11) Integration with existing Bill
payment platform of the bank Please share the details
Required information will be
shared with the selected
bidder
22 18 16 Option for RRBs to be available in the solution for future
requirement
RRBs will be operating under the same BBPOU License of Bank OR
RRBs will be having indiv idual BBPOU
License issued by RBI . Please clarify.
In case if RRBs will not be operating
under Bank BBPOU License, then Bank BBPS application cannot
accommodate RRBs.
As and when if RRB gets
license for OU they have the right to discuss and negotiate
the price with the selected
bidder to implement the BBPS. I f they wish they can
operate under Bank like
agent.
23 20 4.7
Facility Management Serv ices : End to end facility
management serv ices
including Database,
Bank will be paying for 3 Support
persons for facility management
24x7x365. Please confirm.
Bank needs support for 24x7x365 basis. Selected
bidder has to decide number
of support person deployed
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 7 of 69
Application & Hardware will be
provided by the vendor for
24x7x365 from the day of Go-live of the project.
and their shift to meet the
SLA.
24 21 4.8
Support Hours: The Vendor
shall provide support to business user maintenance
and monitoring of the solution,
hardware, software &
database and it should be available 24 X 7 X 365.
These support hours are considered
under the FM Serv ices. Please
confirm.
RFP Clause is self-explanatory
25 23 5.6
The AMC, ATS, FM cost would
be paid quarterly in arrears after submitting all the
required documents/serv ices.
Request to amend payment on Monthly basis.
Clause stands as per RFP
26 23 5.8 (3)
Penalty : Uptime 99.90 monthly basis
98.90% to 99.90% Rs 5 Lakhs
97.90% to 98.90% Rs 10 Lakhs 96.90 to 97.90% Rs 20 Lakhs
95.90% to 96.90% Rs 30 Lakhs
I s Bank going to charges penalty of Rs. 5/10/20/30 Lacs on monthly
basis?
The Penalty charges are exorbitantly on higher side.
Request to reduce the same.
Uptime requirement 99.90% monthly basis:
98.90% to 99.90% - 1% of FM
97.90% to 98.90% - 3% of FM 95.00% to 97.90% - 5% of FM
Below 95.00% - 10% of FM
I f the uptime 3-4 times comes below 95.00%, the contract
may be terminated.
27 48 Annexure E
Table 3
* Note- Charges for SL no- 10 &
11 will start from 2nd year
SL No 10 & 11 are not found. Please
amend the note to reflect correct Sl. No.
* Note- Charges for SL no- 2 &
3 will start from 2nd year
28 17 Section 4.1
Point 3) iii
Prov ide mobile app in android/windows/blackberry/
iOS for customer payment
NPCI does not provide support for
Blackberry. RS would be able to
support Blackberry once NPCI provides the common library for
Blackberry.
Clause stands as per RFP.
29 18 Section 4.1
Point 12
PCI DSS Compliance
We are the technology partners for NPCI for the development of BBPS.
We are already working with banks
RFP clause stands. Letter to be submitted with in time line
maximum before phase-1
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 8 of 69
like SBI , PNB to name a few, for the
implementation of BBP-OU.
We request that this criterion be
removed.
implementation or payment
will be held on. Bidder can
submit the acceptable time line for doing the same.
30 17 Section 4.1
point 5
As the Customer OU, it is imperative that the bank will
not impact its existing
arrangement with the biller
aggregators for the on-us bill payment on immediate basis.
This solution approach must
keep this in consideration and create the provision for
integration with existing bill
payment system without impacting the customer
experience in the negative
way
Please share the details of your
existing bill payment system and
what are the expectations in terms of integration.
I t will be shared with the
selected bidders. I t is direct
integration/through payment aggregator etc.
31 18 Section 4.1
point 10
In-built Fraud Risk Mitigation
Procedures.
The BBPOU software does not have
a Fraud and Risk Mitigation Feature.
BBPOU can link to bank‟s FRM system, if required.
Solution must have some in
built capabilities to check for
risk mitigation. I ts integration with Bank‟s FRM is advisable.
32 18 Section 4.1 point 13
Integration of new biller if he is
not able to provide desired
format
I t would be possible to do so with
additional effort which will be
provided on a case to case basis.
Clause stands as per RFP.
33 18 Section 4.1 point 16
Option for RRBs to be available
in the solution for future
requirement
Please clarify what is meant by this.
Would the RRBs function as Agents
or Agent Institutions
As and when if RRB gets
license for OU they have the
right to discuss and negotiate
the price with the selected bidder to implement the
BBPS. I f they wish they can
operate under Bank like agent.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 9 of 69
34 23 Section 5.6.3
Payment
terms
30% of the TCO (excluding Phase-2) will be paid on
delivery, successful installation,
commissioning of the hardware.
I t is requested that the cost of the hardware and system software be
released completely on the
installation of the hardware and system software
Clause of RFP the modified as
“30% of the item value
(excluding Phase-2) will be paid on delivery, successful
installation, commissioning of
the hardware.”
35 24
5.9
Liquidated damages
Liquidated damages
I t is requested that only the BBPOU
solution cost be included for
calculation of the damages. The
hardware, system software cost, AMC cost and support be removed
for calculating the damages./
Request to provide an overall cap on LD up to 10% of the total annual
contract value as the RFP is silent on
this matter.
Clause of the RFP modified as
“Notwithstanding the Bank‟s
right to cancel the order ,liquidated damages at 0.5%
of the item price per week
will be charged for every weeks‟ delay in
implementation.”
36 12
1.16
A Recipient will, by responding to Bank RFP, be
deemed to have accepted
the terms as stated in the RFP
The RFP is silent regarding the right
for negotiation of terms by the
Bidder. Request to delete this clause as this will curb interest of the bidder
and there would be several terms in
the RFP that would require negotiations and clarifications.
Clause stands as per RFP.
37 12 1.21
The total liability of the
selected bidder shall not exceed the total cost of the
order value
Request to limit the total liability of
the bidder equal to last 12 month's fees paid to the Bidder under this project.
Clause stands as per RFP.
38 16 3.6
The contract period will be
for
a period of Three (03) Years from the date of
Agreement. Bank at its own discret ion may extend the
contract for a further period
Request the Bank to clarify if the infra inputs are to be provided
considering 3 years or 5 years
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 10 of 69
of 2 years.
39 16 3.6
The performance of the selected bidder shall be
rev iewed every quarter and
the Bank reserves the right to terminate the contract at its
sole discretion by giving two
month’s notice without assigning any reasons.
Termination without reason is not acceptable, unless a mutually
agreed termination fees is paid by
the Bank for such termination without reason.
The Bank reserves the right to terminate the contract at its
sole discretion by giv ing 90
day’s notice without assigning any reason.
40 17 4.1 (3.vi) Provide BBPOU Cert ification Support
Request the bank to confirm what is
expected from supplier towards
certification.
Selected bidder has to
provide necessary support for
certification from NPCI.
41 17 4.1 (V)
Provide a bill processing
portal or integrate with bank‟s
exist ing portal
Does bidder needs to provide a separate
bill processing portal as part of the
solution or can bidder use the existing bank portal.
Bidder needs to provide a separate bill processing
portal as part of the solution
and Integration with Existing portals and other medium.
42 17 4.1 (VII)
Provide Annual
Maintenance
Support
Requesting bank to provide more
clarity on this clause. Kindly clarify the items which need to be
covered under this clause.
AMC for all the Hardware items.
43 17 4.1 (VII)
Solut ion must provide OTP via
SMS as 2-factor authentication
solut ion, considering that
BBPS is a mass deployment.
Request the Bank to clarify if bidder needs to provide 2nd factor
authentication solution also as part
of the solution. I f so, kindly confirm the count of users for 2FA.
The RFP doesn‟t have any
commercial line item mentioning this requirement.
SMS gateway will be provided by the Bank.
44 17 4.1 (VII I) Availability of Audit logs
Which all types of logs will be
considered for Audit purpose , kindly confirm
I t may cover any type of logs and matter may be discussed
during implementation.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 11 of 69
45 17 4.1 (VII I) MIS as per the requirement
of the Bank
What is the MIS requirement of the bank? Kindly provide more clarity.
To be discussed with selected bidder.
46 17 4.1 (IX)
The Application will be built
to collect and send application related logs to
the Security Operations
Centre (SOC) of Bank as well to the NPCI.
Our understanding is customer will provide the links and network WAN
devices to send the application logs
to SOC, kindly confirm. Also, logger appliance at the bank
DC and DR location will be
provided by customer, kindly confirm.
SOC setup and SIEM tool along with
perimeter security is not in scope of
supplier, kindly confirm.
SOC setup and SIEM will be
provided by the bank along
with the N/w link.
47 18 4.1 (X) In-built Fraud Risk Mit igation
Procedures.
Kindly provide the scope of the
fraud risk mitigation procedures
Solution must have some in
built capabilities to check for
risk mitigation. I ts integration with Bank‟s FRM is desired.
48 17 4.1 (X) Reconciliat ion of t ransactions.
Bidder will provide the recon reports
and transaction dumps to the bank. Request bank to take care of
dispute management with BBPCU/
NPCI as the customers are bank facing.
Clause stands as per RFP.
49 18 4.1 (15) Storage should be able to keep data in online mode
for whole contract period.
Request the Bank to confirm if
bidder needs to provide data in
online mode for period of 5 years.
Clause stands as per RFP.
50 18 4.2 (4-I I) Raw data reports Request the Bank to confirm why the raw data report is required by
bank
Clause stands as per RFP.
51 18 4.2 (7)
i. Customer on-boarding
ii. Agent on-boarding iii. Agent Inst itut ion On-
boarding
The actual on boarding of agents
will be bank's responsibility. Please
confirm.
Yes
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 12 of 69
52 18 4.2 (10-i) Complaint management
system [CMS]
Kindly provide more clarity more on this requirement
Clause stands as per RFP.
53 19 4.3 (3-ii) User access management
Does supplier need to provide user access management platform like
IDAM, kindly confirm.
I f yes , please provide sizing details of number of users
Approx. 4000 users
54 19 4.3 (5)
Clearing and Sett lement
system
I. Reconciliat ion
Bidder will provide the recon reports
and transaction dumps to the bank.
Request bank to take care of dispute management with BBPCU/
NPCI as the customers are bank
facing.
Clause stands as per RFP.
55 19 4.5
Phase-1: the solut ion should
be implemented within 8
weeks from the date of issue of Purchase Order/LOI
Phase-2: 4 weeks*
Request bank to consider 5 months
of go
live for phase 1 as BBPS is a new initiative and testing and
certification will take time
Clause stands as per RFP.
56 19 4.5
The vendor must be
responsible for cert ification with NPCI implementation,
maintenance during the
contract period.
Certification is bank's responsibility.
Kindly confirm
Clause stands as per RFP.
57 19 4.5
The vendor must be responsible for cert ification
with NPCI implementation,
maintenance during the contract period.
The firewall / encryption in transport mechanism will be provided by
customer, kindly confirm.
Clause stands as per RFP.
58 20 4.5 (I)
The indicative nature of work is as under.
I . BBPOU Integration Manager
Kindly provide the scope of the
BBPOU integration manager
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 13 of 69
59 20 4.5 (V)
V. Implementation Support
at onsiteVI. 24x7 onsite
support during the contract period
Kindly provide the number of
resources required to provide
implementation support Also kindly confirm the count of resources to be
deployed at bank's DC & DR
separately for this serv ice.
Bidder to decide on this to meet the SLA.
60 20 4.6
Standard API‟s For Interface
With Alternate Delivery Channels
I . Bank Web Portal
I I . ATM II I . Internet Banking
IV. Mobile Banking
V. Financial Inclusion gateway
VI. Mult i-Function Kiosks VII. Remittance agencies
VII I . MIS/Report ing System
IX. Customized Reports X. UPI
Bank web portal - Please confirm if
the feature will be enabled in the web portal and backend serv ices
need to be provided by bidder.
Please confirm what is the interface required with the Financial Inclusion
gateway, Remittance agencies, Multi function kiosks.
Clause stands as per RFP.
61 20 4.6 (VII I ,IX) MIS/Report ing System Customized Reports
Bidder will provide standard reports
to the bank. Customized report will be provided when the need arises, and upon request from the bank to
the bidder. Please confirm.
Clause stands as per RFP.
62 General
Request bank to provide number of
customers, number of active
customers, volumes expected, volume projections and Y-o-Y
growth over the next 5 years. This
will help the bidder to size the solution and provide cost inputs.
Please refer scope of work,
point no-14.First year-50 to 75 lacs, 2nd year 75-1.25 cr,3rd
1.25-2cr approx. volume of
transaction.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 14 of 69
63 21 5.2 Compliance with Applicable laws
Request to modify the clause to
capture that the Bidder shall be
responsible only for compliance of laws that is applicable to it as a
serv ice provider. The laws
applicable for the Bank and its operations which relates to the
bidder's obligation under the RFP
shall be intimated to the bidder by
the Bank, which shall only be incorporated by the bidder in its
solution. Indemnification is
acceptable only for the non-compliance of law which is
applicable to the bidder as a
serv ice provider.Request to appreciate that the bidder is an IT
solution provider and is not in a
position to be well versed with the banking laws to advice the bank in
this aspect.
Clause stands as per RFP.
64 22 5.3
Necessary assistance for
any DR drill or Benchmarking exercise must be rendered
by the Bidder for the contractual period, at no
addit ional cost to the Bank.
Kindly provide the scope of support
and frequency of DR drill in a year
DR drill will be atleast once in
a quarter/as per the bank‟s
requirement. Solution must work in a normal way during
operations from DR .
65 22 5.4
Further, the Bank reserves the right to invoke the
Performance Bank Guarantee in case the
Prime Vendor is not able to
fulfill any or all condit ions specified in the document
Bank already has remedy by way of
LD for delays/non-completion of
project and it is not acceptable to agree for invoking the PBG for
bidder's failure to fulfil 'any or all
conditions' which is very generic statement. This would require further
negotiation during contract stage.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 15 of 69
or is unable to complete the project within the st ipulated
t ime. This is independent of
the LD on Delivery and installat ion of hardware &
software
66 23 5.8
Bank will have right to
recover any opportunity loss
or monetary loss incurred by the Bank due to malfunction
of software/application
faults/system failure/negligence of bidder
etc.Penalty structure
Recovery of opportunity loss
tantamount to an indirect loss & hence is requested to be removed
from the clause.The indiv idual
penalties proposed under the RFP are way too high as per existing
standards and hence, request to
consider negotiation during contract stage. Further, the RFP
does not contain an overall cap on
penalties, which is proposed as 10% of the total annual contract value.
Clause stands as per RFP.
67 25 5.13
Order Cancellat ion
-Delay in commissioning / implementation / test ing
beyond the specified
period.
-Serious discrepancy in the quality of service expected
during the implementation,
rollout and subsequent maintenance process
The Bank already has remedy by
way of charging LD for delays,
hence request to remove
'Serious discrepancy' is a relative
term, request to modify as 'material breach'
Clause stands as per RFP.
68 25-
26 5.14 Indemnity
All indemnities sought under the
clause is not acceptable to us like indemnification for commission of
errors, omissions, etc. as the
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 16 of 69
threshold is very less for
indemnification. Bank already has
remedies by way of penalty for this purpose. Indemnification for 'any'
breach of terms of RFP is also not
acceptable as it is general indemnity. Further, use of
deliverables or serv ices is also very
generic. Further, request to limit the
indemnity at last 12 month's fees paid to the bidder. Request to
consider negotiation for exceptions
to this limitation during contract stage.
69 26 5.15 Publicity Request to make this clause mutual. Clause stands as per RFP..
70 28 5.20 Exit option & contract re-negotiat ion
Serious discrepancy' is a relative
and subjective term and will lead to
ambiguity. Further, Bank gets the option to charge LD for delayed
delivery. Request to remove this
clause. Alternatively, suggest to capture triggering points like ' if the LD crosses 10% of the total annual
contract value, if the penalty crosses a threshold of 10% of the
total annual contract value, etc.
Further, it is not acceptable to enter into price re-negotiation as the
prices offered are already
competitive and shall be fixed for
the duration of the contract.Further, request to delete the clauses
related to procurement from a third
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 17 of 69
party as it affects our forecasts basis
which pricing is done.
71 30 5.22
The Bank shall be entit led to
terminate the agreement with the selected bidder at
any t ime by giving ninety
(90) days prior written notice to the selected bidder
Termination at any time is acceptable only if a mutually
agreed termination fees is paid by
the bank.
Clause stands as per RFP.
72 30 5.23
The Bank shall make such prorated payment for
services rendered by the selected bidder and
accepted by the Bank at
the sole discret ion of the Bank in the event of clause
of termination, provided
that the selected bidder is in compliance with its
obligations t ill such date. However, no payment for
“costs incurred, or
irrevocablycommitted to, up to the effective date of
such termination” will be applicable to selected
Bidder. There shall be no
termination compensation payable to the selected
bidder.
Request to modify the clause as the
bidder needs to be paid for the serv ices / obligations provided till
the effective date of termination,
irrespective of the cause of termination.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 18 of 69
73 Gen
eral - -
Crucial legal terms like termination
rights for the bidder, indemnification
of the bidder, IPR of bidder, etc are not captured in the RFP which
needs to be negotiated during
contract stage.
74 44 Annexure D
(7.1) Fall Clause
Request the bank to remove this
clause
Clause stands as per RFP.
75 47
annex-E
(Table1-SN. 4)
Anti-Virus , patch
management
Can bank let us know which Anti-
v irus tool is currently used for server protection?
Is it possible to procure the same
antiv irus agent license and bank will allow to manage the new servers
through their existing AV
management server
Clause stands as per RFP.
76 48 Table 4 Reconciliat ion Charges
Request the Bank to clarify the
inputs which are required to be
provided as part of this table. Bidder will only provide the recon
reports and transaction dumps to
the bank.
Clause stands as per RFP.
77 51 Annexure H PROFORMA FOR DEED OF
INDEMNITY
Request the bank to clarify if this is
to be submitted by all the bidders
participating in the RFP or by the selected vendor by the bank to
implement the BBPS
Deed of Indemnity will be
submitted by the selected bidders
78 General
Does supplier need to provide
security devices like firewall and nips/hips ; encryption and masking
for database ; FIM , etc. or existing
security setup at bank's DC and DR location can be used for the same,
kindly confirm.
Existing security setup at
bank's DC and DR location
can be used for the same
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 19 of 69
Will banks existing security serv ices
provider manage the server and
perimeter security requirements for new BBPOU , kindly confirm
79 1, 11
& 12
1.11, 1.12,
1.17
1.11 Confidentiality
The RFP document is confidential and is not to be
reproduced, transmitted, or
made available by the
Recipient to any other party. The RFP document is provided
to the Recipient on the basis of
the undertaking of confidentiality given by the
Recipient to Bank. Bank may
update or rev ise the RFP document or any part of it. The
Recipient acknowledges that
any such rev ised or amended document is received subject
to the same terms and
conditions as this original and subject to the same
confidentiality undertaking.
The Recipient will not disclose or discuss the contents of the
RFP document with any officer,
employee, consultant,
director, agent, or other person associated or affiliated
in any way with Bank or any of
its customers, suppliers, or agents without the prior written
consent of Bank.
1.12 Disclaimer:
FSS requests that the contents of the
proposal be treated confidential
and be subject to relevant confidentiality restrictions as
appropriate.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 20 of 69
Subject to any law to the
contrary, and to the maximum
extent permitted by law, Bank and its officers, employees,
contractors, agents, and
advisers disclaim all liability from any loss or damage
(whether foreseeable or not)
suffered by any person acting
on or refraining from acting because of any information,
including forecasts,
statements, estimates, or projections contained in this
RFP document or conduct
ancillary to it whether or not the loss or damage arises in
connection with any
negligence, omission, default, lack of care or
misrepresentation on the part
of Bank or any of its officers, employees, contractors,
agents, or advisers.
1.17. RFP response
All submissions will become the
property of Bank. Recipients shall be deemed to license,
and grant all rights to, Bank to
reproduce the whole or any
portion of their submission for the purpose of evaluation, to
disclose the contents of the
submission to other Recipients who have registered a
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 21 of 69
submission and to disclose
and/or use the contents of the
submission as the basis for any resulting RFP process,
notwithstanding any copyright
or other intellectual property right that may subsist in the
submission or Banking
documents.
80 12 1.16
1.16 Acceptance of Terms A Recipient will, by responding
to Bank RFP, be deemed to
have accepted the terms as stated in the RFP.
FSS would wish to clarify that any binding terms and conditions
including the RFP terms and the
Contract be binding between upon the parties upon mutual agreement
that is considerate to the comments
mentioned herein.
Clause stands as per RFP.
81 12 1.21. 5.14
1.21 Indemnity and 5.14
The bidder shall indemnify the
Bank and be liable for any loss or damage suffered by the
Bank due to malfunctioning of
the system as supplied and installed by them. The total
liability of the selected bidder
shall not exceed the total cost of the order value.
Bidder would like to clarify that
Bidder will indemnify the Bank for
any infringement of third party IP rights for the solution provided by
the Bidder to the Bank.
Bidder further is willing to indemnify
for breach of confidentiality, IP and
applicable laws. Bidder is also willing to indemnify the Bank for any acts
or omissions of gross negligence and
willful misconduct.
Clause stands as per RFP.
82 16 3.6
3.6 Contract Period The selected bidder need to
execute a Serv ice Level
Agreement (SLA) with UCO Bank covering all terms and
conditions of this RFP. SLA will
cover performance and availability of the solution
FSS would wish to clarify that any
terms and conditions of the contract be binding upon the
parties upon mutual agreement.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 22 of 69
deployed. The contract period
will be for a period of Three
(03) Years from the date of Agreement. Bank at its own
discretion may extend the
contract for a further period of 2 years.
The performance of the
selected bidder shall be rev iewed every quarter and
the Bank reserves the right to
terminate the contract at its sole discretion by giv ing two
month‟s notice without
assigning any reasons. Any offer falling short of the
contract validity period is liable
for rejection.
83 16 4.1
4.1 Scope of Work
The scope of the work must be
as per the Bharat Bill Payment System – BBPOU Technical
Specification issued by the
NPCI from time to time. The selected bidder must adhere
to guidelines issued by the
NPCI on Bharat Bill Payment
System with no extra cost from the Bank. The bidder has to
provide required Hardware,
Software, Database & any other application for the
implementation of BBPOU. The
solution will be implemented in DC/ DR concept at our
Bidder would like to discuss on the
aspect of the additional costs
involved and would request that the
same be mutually agreed between the parties.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 23 of 69
Kolkata Disaster Recovery
Centre & Bangalore Data
Centre.
84 25 5.12
5.12 Acceptance Testing The Bank will carry out the
acceptance tests as per
Scope of work supplied & implemented by the selected
bidder as a part of the Project.
The Vendor shall assist the Bank in all acceptance tests to be
carried out by the Bank. The
provisioned items will be
deemed accepted only on successful acceptance of
those products and the vendor
would need to provision insurance of those items till
successful acceptance. The
Bank at its‟ discretion may modify, add or amend the
acceptance tests which then
will have to be included by the vendor. The Vendor shall
arrange for the tests at the
relevant sites in the presence of the officials of the Bank. The
Vendor should ensure that the
tests will involve trouble-free operation of the complete
system apart from physical
verification and testing and
that there shall not be any additional charges payable by
the Bank for carrying out this
Bidder requests that any
acceptance under the contract be
in accordance with set acceptance criteria and
procedures as laid out in the
relevant work order/ SOW. Bidder further requests that a clause on
acceptance period and deemed
acceptance be introduced in the contract.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 24 of 69
acceptance test.
In case of any discrepancy in
the hardware / software supplied, the Bank reserve the
right to terminate the entire
agreement in case the Vendor does not rectify or replace the
supplied hardware/software
and the Vendor shall take
back Vendor equipment at Vendor‟s costs and risks. The
Bank have the right to reject
the „Vendor Supplied Equipment‟ and to seek free
replacement or repair of the
equipment or defective components thereof till the
completion of acceptance
test and obtaining final acceptance certificate from
the Bank.
85 1.11
1.11 Confidentiality FSS requests that the confidentiality provisions be amended and be
made mutual to include the
confidentiality obligations of the Bank, as well.
Clause stands as per RFP.
86
25, 28,
29
5.13, 5.20
5.13 Order Cancellation
The Bank reserve its right to
cancel the order in the event of one or more of the following
situations, that are not
occasioned due to reasons solely and directly attributable
to the Bank alone:
• Delay in commissioning / implementation / testing
FSS request that any termination under this agreement be for cause
with a 30 day cure period.
FSS requests that the costs be borne
by the Bank or FSS procures such products and serv ices.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 25 of 69
beyond the specified period.
• Serious discrepancy in the
quality of serv ice expected during the implementation,
rollout and subsequent
maintenance process. • In case of cancellation of
order, any payments made by
the Bank to the Vendor would
necessarily have to be returned to the Bank, further
the Vendor would also be
required to compensate the Bank for any direct loss
suffered by the Bank due to
the cancellation of the contract/purchase order and
any additional expenditure to
be incurred by the Bank to appoint any other Vendor. This
is after repaying the original
amount paid. • Vendor should be liable
under this section if the
contract/ purchase order has been cancelled in case sum
total of penalties and
deliveries equal to exceed 10% of the TCO.
• Please also refer 5.19 herein
below.
5.20 Exit Option and Contract
Re-Negotiation and 5.22
Termination
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 26 of 69
87 26 5.15
5.15 Publicity
Any publicity by the selected
bidder in which the name of the Bank is to be used should
be done only with the explicit
written permission of the Bank.
FSS requests that this clause be made mutual.
Clause stands as per RFP.
88 28,
31
5.19, 5.24,
5.25
5.19 Resolution of Disputes
This RFP document shall be
governed and construed in
accordance with the laws of India. The courts of Kolkata
alone and no other courts shall
be entitled to entertain and try any dispute or matter relating
to or arising out of this RFP
document. Notwithstanding the above, the Bank shall have
the right to initiate appropriate
proceedings before any court of appropriate jurisdiction,
should it find it expedient to do
so.
5.24 Arbitration and
5.25 Applicable law &
Jurisdiction of court.
Bidder requests that the venue of
arbitration be Chennai under the
exclusive jurisdiction of the courts at Chennai, India.
Clause stands as per RFP.
89
New clauses required to be
included in the Contract
FSS requires inclusion of the following
clauses, without limitation.
1) LIABILITY
FSS requests that FSS‟s aggregate liability be capped and liability for
indirect damages be excluded
under the contract.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 27 of 69
2) Non-solicitation etc.
90 44 7.1
7. Fall Clause 7.1 The BIDDER undertakes that
it has not supplied/is not
supplying similar product/systems or subsystems
at a price lower than that
offered in the present bid in respect of any other
Ministry/Department of the
Government of India or PSU
and if it is found at any stage that similar product/systems or
sub systems was supplied by
the BIDDER to any other Ministry/Department of the
Government of India or a PSU
at a lower price, then that very price, with due allowance for
elapsed time, will be
applicable to the present case and the difference in the cost
would be refunded by the
BIDDER to the BUYER, if the contract has already been
concluded.
Bidder would like to discuss the
provisions of the integrity pact with the Bank. Bidder also requests that
this fall clause be deleted.
Clause stands as per RFP.
91 50
Annexure-H PROFORMA FOR DEED OF INDEMNITY
Bidder is willing to provide indemnities under the contract to
be agreed between the parties.
Bidder requests that this deed be
withdrawn.
Please note that Deed of Indemnity will be submitted
by the selected bidders
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 28 of 69
92 17 4.1
9) The Application will be built
to collect and send
application related logs to the Security Operations Centre
(SOC) of Bank as well to the
NPCI.
What is Security Operations Centre?
How to communicate to them what
format
SOC is the security operator
centre WHICH collects the
logs of the various modules and analyse them to protect
the infrastructure from any
cyber attack.
93 18 4.1
DR details- RTO (90 Minutes) &
RPO (15 Minutes) to be
defined
DR details- RTO (90 Minutes) & RPO (15 Minutes) to be defined? - By
whom / when?+
RFP Clause is self explanatory
94 15
3.4
Commercial Evaluation
3.4.2 The Bidder needs to
provide Unit costs for components and serv ices; unit
rates with applicable taxes
would be considered for the TCO purposes.
Request Bank to evaluate the
commercials excluding all taxes
Clause stand as per RFP
95 23
5.6 Payment
Terms
-30% of the TCO (excluding
Phase-2) will be paid on delivery, successful installation,
commissioning of the
hardware. - 40% of the TCO (excluding
Phase-2) will be paid after
successfully implementation of Phase-1.
-Rest 30% of the TCO
(excluding Phase-2) will be paid after 03 months from the
date of successful running/go
live of the solution (Phase-1).
Request bank to consider separate
payments terms for hardware and other software‟s with 90% payment
on installation and balance 10% on
Go Live
30% of item value( excluding
phase – 2) will be paid on delivery, successful
installation, commissioning of
the hardware.
96 23
5.6 Payment Terms
The AMC, ATS, FM cost would be paid quarterly in arrears
after submitting all the
required documents/serv ices. The charges of the AMC ATS &
FM will starts from the date of
Request bank to consider payment of AMC/ATS annually in advance as
per industry practices
Clause stand as per RFP
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 29 of 69
go-live of the solution.
97 23
5.6 Payment Terms
Ø The AMC, ATS, FM cost would be paid quarterly in
arrears after submitting all the
required documents/serv ices. The charges of the AMC ATS &
FM will starts from the date of
go-live of the solution.
Request bank to consider payment of FM cost monthly in arrears as
bidder will incur monthly cost to
deploy the resources
Clause stand as per RFP
98 23
5.8 Penalty General We assume the total Penalty will be restricted to 10% of the contract
value as indicated in clause 5.13.
Request Bank to confirm
Clause stands as per RFP.
99 23
5.8 Penalty 1% of the total cost delay in
project
implementation/execution on per week
Clause 5.9 covers for LD due to delayed implementation. Request
Bank to remove the penalties as
mentioned in 5.8 for implementation delays as it is duplicated with 5.9
Modified penalty term given
as annex.
100 24
5.9
Liquidated
Damage
5.9 Liquidated Damage
Notwithstanding the Bank‟s
right to cancel the order, liquidated damages at 0.5% of
the contract price per week
will be charged for every week‟s delay in
implementation
We assume the total liquidated damages will be restricted to 10% of
the contract value as indicated in
clause 5.13. Request Bank to confirm
LD term is modified as 5% of
(hardware cost +
implementation) per week that will be charged for every
week‟s delay in
implementation. LD will be maximum of 10% of
(hardware cost +
implementation).
101 25
5.13 Order
Cancellation
In case of cancellation of
order, any payments made by
the Bank to the Vendor would necessarily have to be
returned to the Bank, further
the Vendor would also be
Request bank to restrict the
repayment for the undelivered
portion of contract.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 30 of 69
required to compensate the
Bank for any direct loss
suffered by the Bank due to the cancellation of the
contract/purchase order and
any additional expenditure to be incurred by the Bank to
appoint any other Vendor. This
is after repaying the original
amount paid.
102 25
5.13 Order
Cancellation
In case of cancellation of
order, any payments made by
the Bank to the Vendor would necessarily have to be
returned to the Bank, further
the Vendor would also be required to compensate the
Bank for any direct loss
suffered by the Bank due to the cancellation of the
contract/purchase order and
any additional expenditure to be incurred by the Bank to
appoint any other Vendor. This
is after repaying the original amount paid.
The bidder is not privy to the commercials agreed between the
Bank and the new supplier. Hence
request Bank to limit the liability of the bidder to the value of the
undelivered portion of the contract.
Clause stands as per RFP.
103 28
5.20 Exit
Option and
Contract Re-Negotiation
The Bank will reserve a right to
re-negotiate the price and
terms of the entire contract with the Selected Bidder at
more favourable terms in case
such terms are offered in the industry at that time for
projects of similar and
comparable size, scope and quality.
We understand that the L1 bidder
will be selected based on the
evaluations. Hence request bank to remove the clause
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 31 of 69
104 47
Annexure-E
Commercial
Bid Format- Table 1
Applicable taxes Request Bank to clarify if Tax value is
to be entered or the bidder needs
to indicate relevant tax % applicable
Clause stands as per RFP.
Provide the data as per the
format.
105 47
Annexure-E
Commercial Bid Format-
Table 1
Applicable taxes We assume that taxes will be paid
at the then prevailing rates at actuals as stipulated by the
Government. Request Bank to
confirm
Clause stands as per RFP.
Provide the data as per the format.
106 47
Annexure-E Commercial
Bid Format-
Table 1
Applicable taxes We assume that if any new taxes are introduced or new taxes
replace existing taxes, the same will
be borne by the bank. Request Bank to confirm
Clause stands as per RFP.
107 47
Annexure-E
Commercial Bid Format-
Table 1
Total Amount (`) Request Bank to clarify if the total is
including taxes
Clause stands as per RFP.
Provide the data as per the format.
108 16
3.6 Contract Period
The performance of the selected bidder shall be
rev iewed every quarter and
the Bank reserves the right to terminate the contract at its
sole discretion by giv ing two
months‟ notice without
assigning any reasons. Any offer falling short of the
contract validity period is liable
for rejection
We understand that cancellation of contract or termination will be
performed as per clause 5.13 and
5.22. Request bank to align clause 3.6 with 5.13 and 5.22 and remove
termination as per convenience
RFP clause MODIFIED AS “The performance of the selected
bidder shall be rev iewed
every quarter and the Bank reserves the right to terminate
the contract at its sole
discretion by giv ing 90 DAYS
notice without assigning any reasons. Any offer falling short
of the contract validity period
is liable for rejection.”
109 48
Annexure-E
Commercial
Bid Format- Table-3
* Note- Charges for SL no- 10 &
11 will start from 2nd year We assume the note relates to SL 2 and 3 of table 3. Request Bank to
clarify
* Note- Charges for SL no- 2 &
3 will start from 2nd year
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 32 of 69
110 48
Annexure-E
Commercial
Bid Format- Table-4
Reconciliation Charges Request clarity from the bank on the
basis for providing the commercials
for reconciliation charges (fixed fee basis, transaction basis etc)
Fixed fee per transactional
basis.
111 48
Annexure-E
Commercial Bid Format-
Total Cost of ownership
(A+B+C+D): We assume the Total cost of
ownership is Cost inclusive of all
taxes
Yes
112 47
Annexure-E
Commercial
Bid Format-
Table-2
Phase 2 Request bank to provide further clarity on the scope of phase 2 as
the scope seems similar to phase 1
The detailed scope of Phase
2 will be shared at the time of
implementation and as per
the guidelines of NPCI.
113 47
Annexure-E
Commercial
Bid Format- Table-2
Phase 2 Request bank to provide
placeholder to quote for
application cost for Phase 2 in Table 4
Software cost if any can be
placed in SL no-2 of table 4
114
17/4.1(3) iv
Integrate with other systems of
the bank like payment gateway, Net Banking
platform, Mobile application,
ATM, UPI , SMS and email systems.
Clarification requested :Will the UI
for different channels will be developed by respective channel
and utilize the serv ice of BBP
exposed by the BBPOU engine provided by TCS
Integration of BBPS with the
different channels is to be done by the selected bidder.
115
17/4.1(3) v i
Provide BBPOU Certification
Support Clarification requested: What
type/level of support is expected?
Clause stands as per RFP.
116
17/4.1(3) v iii
MIS as per the requirement of
the Bank Clarification requested: Will the
report generation will be in scope?
Clause stands as per RFP.
117
17/4.1(3) x
Reconciliation of transactions Clarification requested: Will the
report generation suffice the reconciliation purpose?
Clause stands as per RFP.
118
17/4.1(5)
As the Customer OU, it is
imperative that the bank will not impact its existing
arrangement with the biller
Clarification requested: Will the UI
look & feel related code and Interface to integrate existing
system will be shared
Required API will be shared
by the Bank.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 33 of 69
aggregators for the on-us bill
payment on immediate basis.
This solution approach must keep this in consideration and
create the provision for
integration with existing bill payment system without
impacting the customer
experience in the negative
way.
119
19/4.2 Phase -2
Clarification requested: is on
boarding of biller is bidder's
responsibility?
Biller on boarding will be
done by Bank.
120
1.16 Acceptance of Terms Following modification proposed in the section:
A Recipient will, by responding to
Bank RFP, be deemed to have accepted the terms as stated in the
RFP, subject to the clarifications and
deviations submitted by the Recipient.
Clause stands as per RFP.
121
1.21 Indemnity Recipient propose that they shall not indemnify the Bank from the loss or damage suffered by the Bank due to malfunctioning of the system as supplied and installed by them, instead Recipient proposes that the below suggested clauses shall apply and shall be made part of the RFP and/or contract: The Recipient further clarifies that 'malfunctioning' as referred to in the RFP shall be defined to mean a material non-conformance with the agreed corresponding specifications.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 34 of 69
Bidder warrants that as delivered by it and at the time of acceptance by Bank, each deliverable provided pursuant to the Agreement will conform to its corresponding specifications. I f the Recipient is in breach of such warranty in respect of a given Deliverable due to reasons solely attributable to the Recipient, then the Recipient shall, at its own cost, re-perform such Deliverables as are necessary to rectify that breach or replace the Deliverables that provides substantially similar functionality and then re-submit that Deliverables. I f however both parties subsequently mutually determine that such remedies are not practicable, the Bank's exclusive remedy shall be to require the Recipient to refund/return all payment of fees allocable to that part of the nonconforming Deliverables made by the Bank to the Recipient (if already paid by the Bank). This warranty shall not apply in the event that failure of the Deliverable to conform to its corresponding specifications has resulted from: (a) modification of the Deliverable after delivery by Recipient if such modification was not made by or on behalf of the Recipient, (b) use of the Deliverable in combination/ operation with other products or systems which are not approved by the Recipient and operation of the
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 35 of 69
Deliverables on incompatible hardware and/or software not recommended by Recipient or (c) if the Deliverables has been used otherwise than in accordance with the relevant documentation and/or otherwise than for the purpose for which they have been developed or supplied, or (d) defects in components or materials provided to Recipient by Bank in connection with the preparation of the Deliverable. All the hardware, software, equipments, etc. provided to the
Bank by the Recipient as well as any
deliverables, customizations, modifications, etc. to the afore-
stated provided pursuant to the RFP
scope shall be solely subject to the terms and conditions including warranty, indemnity, maintenance and support, AMC/ATS etc. as provided in the respective hardware, software, firmware, equipment etc. vendor's and/or OEM's underlying terms and conditions. All provisions in the RFP which refer to such hardware, software, equipments, etc. shall be deemed to incorporate the provisions of this clause therein. Except as set forth in this section, Bidder makes no warranties to the Bank, express or implied, with respect to any serv ices or deliverables provided hereunder,
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 36 of 69
including, without limitation, any implied warranties of merchantability or fitness for a particular purpose. All such other warranties are hereby disclaimed by the Bidder. The Bank warrants that all software, information, data, materials, and other assistance ("Bank Materials") provided by it to the Bidder will not infringe the intellectual property rights of any third parties. Further, Bank has the rights and is otherwise authorized to deliver the Bank Material and to grant the rights and licenses to the Bidder as contemplated in this RFP and/or contract. Liability: The Bidder clarifies that the provision on liability inserted in the text of the RFP in this section shall be modified as under and form part of the RFP and/or contract: Liability: i) The total cumulative liability of the selected bidder arising from or relating to the RFP and/or Agreement shall not exceed the fees paid to the Bidder in the preceding twelve months under the applicable indiv idual order during that gives rise to such liability (as of the date the liability arose).
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 37 of 69
ii)Neither party shall be liable to the other for any special, indirect, incidental, consequential (including loss of profit or revenue, loss of good will, loss of data), exemplary or punitive damages whether in contract, tort or other theories of law, even if such party has been advised of the possibility of such damages. iii) The Bidder shall be excused and not be liable or responsible for any delay or failure to perform the Serv ices or failure of the Serv ices or a Deliverable under this RFP and/or Agreement to the extent that such delay or failure has arisen as a result of any delay or failure by the Bank or its employees or agents or third party serv ice providers to perform any of its duties and obligations as set out in this RFP and/or Agreement. In the event that the Bidder is delayed or prevented from performing its obligations due to such failure or delay on the part of or on behalf of the Bank, the Bidder shall be allowed an additional period of time to perform its obligations and unless otherwise agreed the additional period shall be equal to the amount of time for
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 38 of 69
which vendor is delayed or prevented from performing its obligations due to such failure or delay on the part of or on behalf of the Bank. Subject to mutual agreement with the Bank, the Bidder shall take such actions as may be
necessary to correct or remedy the
failures or delays. The Bidder shall be entitled to invoice the Bank for
additional costs incurred in
connection with correction or
remedy as above at agreed rate card.
122
1.23 Authorized Signatory The Bidder clarifies that not all the
Bidder employees involved in the discussions and negotiations may
also be authorized signatories of the
Bidder but the Bidder can confirm that such employees are authorized
to discuss and negotiate on behalf
of the Bidder.
Clause stands as per RFP.
123
3.6 Contract Period The Bidder requests that Bank and
the Bidder shall mutually agree
upon any extension of the contract. Further, termination by the Bank
under this section shall be subject to
payment of termination charges including reasonable wind down
costs of the Bidder.
Clause stands as per RFP.
124
4.1 Scope of Work The Bidder clarifies that the scope of
work shall be agreed between the Parties under the contract upfront.
Any change to the scope of work
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 39 of 69
shall be subject to the change
control procedure agreed between
the Parties.
125
5.2 Compliance with all Applicable Laws
Para 1: The Bidder clarifies that each party i.e. Bank and Bidder shall be responsible and liable for its own compliance with laws which are applicable to such party. The Bidder will not be responsible for Bank's compliance with applicable laws. Further, notifying the Bank about laws applicable to the Bidder shall not be mandatory and nor shall failure to notify lead to any consequences for the Bidder. This shall be removed from the clause. Further, the scope of the indemnification obligation in this section shall be made mutually applicable and shall be limited to third party claims only. The Bidder clarifies that mere failure or omission by a Party to abide by the applicable laws shall not give rise to indemnification obligation, unless there is any third party claim or demand arising there from. Thus the clause shall be modified accordingly. Para 2: The Bidder clarifies that Para 2 shall be modified as under: The vendor shall promptly and timely obtain all such consents, permissions, approvals, licenses, etc., as may be necessary or required for the vendor in the capacity of a services provider to perform this project or for the
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 40 of 69
conduct of their own business under any Law, Government Regulation/Guidelines applicable to the vendor and shall keep the same valid and in force during the term of the project, and in the event of any failure or omission to do so, shall indemnify, keep indemnified, hold harmless, defend the Bank and its employees/ officers/ staff/ personnel/ representatives/agents from and against all claims or demands of liability and all consequences that may occur or arise for any default or failure on its part to conform or comply with the above and all other statutory obligations arising there from and the Bank will immediately notify the vendor of any such claim or demand of liability. Para 3: The Bidder clarifies that indemnity shall not cover damages,
loss or liabilities suffered by the bank
arising out of claims made by its customers and/or regulatory
authorities.
126
5.3.1 Warranty & Maintenance The Bidder clarifies that all hardware, software, equipments,
etc. provided to the Bank by the
Recipient as well as any deliverables of customizations, modifications,
etc. to the afore-stated provided
pursuant to the RFP scope shall be
solely subject to the terms and conditions including warranty,
maintenance and support,
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 41 of 69
AMC/ATS etc. as provided in the
respective hardware, software,
equipment etc. vendor's and/or OEM's underlying terms and
conditions.
127
5.4 Performance Bank Guarantee
The format of the Performance Bank Guarantee is subject to the
changes or deviations suggested
below by the Bidder to Annexure 1.
Further, forfeiture of the Performance Bank Guarantee shall
be subject to parties agreeing to
specific trigger events.
Clause stands as per RFP.
128
5.5.1 Delivery of Equipment The Bidder clarifies that the time
frame shall be agreed upon
between the parties.
Clause stands as per RFP.
129
5.5.2 Delivery of Equipment The Bidder clarifies that all fees and costs payable to Bidder are
exclusive of any sales, use, value
added tax, serv ice taxes or taxes of a similar nature as applicable, and
Bank shall be responsible to pay or
reimburse Bidder the amount of such taxes, and thus the section
shall be amended to reflect the
above.
Clause stands as per RFP.
130
5.6.1 Payment Terms Will the period until such
commissioning not be included
under the contract period? Kindly
clarify. Further, Bidder clarifies that
successful commissioning shall
mean commissioning of hardware, software etc. as agreed under the
contract, and thus the section be
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 42 of 69
amended accordingly.
131
5.6.2 Payment Terms The Bidder clarifies that the Bank shall not withhold payment of fees in case of delays or defaults by the Bidder and the section shall be amended accordingly. There are many other remedies available under the RFP and/or contract for delay or default of the Bidder. Additional clauses to be included in this section of the RFP and/or contract as under: 5.6.4: Bidder shall submit invoices to Bank as per the agreed payment milestones specified in the applicable contract detailing the amounts payable by Bank there under. Bank shall remit payment to Bidder within thirty (30) days following its receipt of each such invoice. For any amounts not paid when due, Bidder shall impose late payment charges at the rate of one and one half percent (1.50%) per month until the delayed payment is paid in full. Without prejudice to the other rights available, Bank also reserves the right to withhold the provision of Serv ices till such time all the payments due to it under this Agreement/contract have been made by Bank and any such withholding by the Bidder shall not be treated as breach by it of the provisions of this RFP and/or
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 43 of 69
Agreement/contract. 5.6.5:
The price for serv ices and all fees payable to Bidder are exclusive of
any sales, use, value added tax,
serv ice taxes or taxes of a similar nature measured by the Serv ices,
Deliverables or charges thereon,
imposed by any applicable taxing jurisdiction and where such taxes
are applicable, Bank shall be
responsible to pay or reimburse Bidder the amount of such taxes.
Where applicable, Bidder shall
invoice such taxes as a separate
line item in applicable invoices and shall pay such amount of tax to the
appropriate taxing authority upon
receipt of such amount from the Bank. Each party is responsible for its
own income taxes, corporate taxes
and franchise taxes.
132
5.7 Paying Authority The Bidder clarifies that the clause shall be amended to reflect that payment of bills will be released in accordance within 30 days of receipt of Invoice by the Bank. I t shall not be dependent on Bank's internal process of receiv ing confirmations, reports etc. as proposed in the RFP. The Parties will agree to payment milestones and the Bidder will raise invoices upon reaching such milestones, so there is no need for further Confirmations.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 44 of 69
This section shall be amended to
reflect the above.
133
5.8 Penalty The Bidder clarifies that the first para of this section shall be replaced as under: The penalty charges listed in this section below will be applicable only if and to the extent the default and/or delay is due to reasons solely attributable to the Bidder. Notwithstanding anything to the contrary, the aggregated penalty charges payable by Bidder under this section and under the RFP and contract shall not exceed 1% of the total contract value. Apart from FM services, the selected bidder should provide onsite support when required within same day if agreed under the contract. The Bidder clarifies that any uptime requirements under the RFP and/or contract shall be subject to standard downtime provisions as listed below: The time lost due to any of the following reasons are taken into account while calculating the availability/ uptime requirement: (a) Time lost due to power or environmental failures; (b) Time taken to recover the system because of power or environmental failures; (c) Time lost due to damage or malfunction in the system or any units thereof due to causes attributable to Purchaser such as attachment of additional
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 45 of 69
devices, making alteration to the system, maintenance of the system, etc. without Bidder's consent and/ or failure to maintain the site as required by the Bidder; (d) Time taken for scheduled maintenance/ troubleshooting either for preventive purposes or improvement in function or other purposes; (e) Time taken for reconfiguration or other planned downtime situations; (f) Scheduled shutdowns as required by Purchaser; (Bidder may also request Purchaser for a shutdown for maintenance purpose, which request will not be denied unreasonably by Purchaser); (g) Time taken for booting the system (h) Time lost due to unavailability of links. The penalty set forth against the uptime requirement in the table below shall be as mutually agreed. Penalty Description of Work Turn Around Penalty Charge time (TAT)/ s: SL Serv ice Level 1 Project Project 0.1% of the total cost
Execution/Implementation
implementation of the delayed ionon time: As milestone in
project
per the implementation/exec timeline ution on per week
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 46 of 69
provided in and a maximum of the scope of 0.5% of the delayed work milestone 2 FM Support 24X7 till 0.1% per day of the three years total cost of the FM from the day support upto a of live of maximum of 0.5% of project the FM support cost 3 Uptime requirement 99.90% 98.90% to 99.90% monthly basis .................................................................. (To Be Discussed 'TBD') 97.90% to 98.90% TBD... 96.90 to 97.90% ..TBD... 95.90% to 96.90% .TBD.. (The penalty will be calculated on monthly basis), if the uptime falls below 95.90%, the
contract may be terminated, subject to prior written notice and a cure period of 30 days being provided to the Bidder. 4 Resolution of As per the 0.1 % per day of the cost customer Level corresponding to such delayed serv ice defined in serv ice under the project upto complaints the scope a maximum of 0.5% of such cost corresponding to such delayed serv ice
134
5.9 Liquidated Damages The Bidder clarifies that there are
already penalty charges set forth in
the above section for delay in implementation, so levying
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 47 of 69
liquidated damages in addition to
such penalties appears
unreasonable and thus this section shall be removed from the RFP
and/or contract.
135
5.12 Acceptance Testing The Bidder clarifies that section shall be modified to reflect the following:
Para 1:
The Bank will carry out the acceptance tests as per Scope of work supplied & implemented by the selected bidder as a part of the Project. The Vendor shall assist the Bank in all acceptance tests to be carried out by the Bank. The provisioned items will be deemed accepted: i) upon successful acceptance of those provisioned items within the agreed acceptance period i.e. the provisioned items substantially meeting the corresponding agreed specifications and/or agreed acceptance criteria, as the case may be; or ii) if the Bank (a) fails to provide the list of non-conformities within the acceptance period, (b) fails to notify the acceptance of the provisioned items in terms of this clause within the period agreed for the same, or (c) starts using the provisioned item in a live production environment (other than as part of agreed review and acceptance testing procedure, such as UAT). Unless agreed otherwise the
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 48 of 69
acceptance period shall be seven working days from the date of delivery of the provisioned item by the Bidder. Further reworking/ remedy of defects shall be at the cost of Bidder, provided the non-conformities are solely and entirely attributable to the Bidder. In all other cases, reworking/ remedy of non-conformities shall be at the cost of Bank. The vendor clarifies that it shall not be required to provision insurance of those items till successful acceptance. The Bank and Bidder may mutually
agree to modify, add or amend the acceptance tests which then will
have to be included by the vendor.
The Vendor shall arrange for the tests at the relevant sites in the
presence of the officials of the
Bank. The Vendor should ensure that the tests will be based on the
acceptance criteria as agreed for the provisioned items apart from physical verification and testing and that there shall not be any additional charges payable by the Bank for carrying out this acceptance test, unless agreed otherwise. Para 2: In case of any discrepancy in the hardware / software supplied due to
reasons entirely attributable to the Bidder, the Bank reserve the right to
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 49 of 69
terminate the affected order
executed under the agreement in
case the Vendor does not rectify or replace the supplied
hardware/software and the Vendor
shall take back Vendor equipment at Vendor's costs and risks. The Bank
have the right to reject the 'Vendor
Supplied Equipment' and to seek
free replacement or repair of the equipment or defective
components thereof till the
completion of acceptance test and obtaining final acceptance
certificate from the Bank, subject to
the respective underlying terms and conditions governing such
hardware/software.
136
5.13
Order Cancellation
The Bidder clarifies that "cancellation" shall be substituted by "termination" throughout this section. Further, the Bidder clarifies that the rights of the Bank under this section shall be invoked and exercised only if the situations set forth in this section have arisen due to reasons entirely attributable to the Bidder. The situations set forth in the section shall be modified as under: Delay in commissioning / implementation / testing beyond the specified period, which has an adverse impact on the overall project.
agreed under the contract for the
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 50 of 69
implementation, rollout and subsequent maintenance process. □ In case of cancellation of order, any payments made by the Bank to the Vendor would necessarily have to be returned to the Bank, further the Vendor would also be required to compensate the Bank for any direct loss suffered by the Bank due to the cancellation of the contract/purchase order and any additional expenditure to be incurred by the Bank to appoint any other Vendor. This is after repaying the original amount paid. The Bank may raise a claim for direct damages under the liability regime.
Vendor should be liable under this
section if the contract/ purchase order has been terminated in case sum total of penalties and deliveries equal to exceed 10% of the TCO.
Please also refer 5.20 herein
below Bidder's clarifications to section 5.20 have been submitted in the subsequent sections of this table.
137
19 5.14
Indemnity
The Bidder clarifies that it shall indemnify the Bank as under and thus this section of the RFP and/or contract shall be amended to reflect the below: The first para of this section shall be deleted from the RFP, except the last line provided that the last line shall be made mutually applicable i.e. there
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 51 of 69
shall be mutual indemnity for loss or damage to a party's premises or property, loss of life, etc., due to the acts of other party's employees or representatives, unless caused by the negligence or misconduct of the indemnified party/it's personnel. Further, the scope of third party IPR infringement indemnity set forth in second para of this section shall be as set forth below: The Vendor shall indemnify the Bank against any third party claims, damages, costs and expenses (including reasonable attorney fees), arising out of claims of infringement of such third-party's copyright, patents, or other intellectual property rights on the Bank arising from the use by the Bank of the Bidder provided deliverables and/or serv ices in accordance with the contract. The standard exceptions to indemnity for infringement of third party IPR shall be included in the RFP and/or contract. Further, in the event that Bank is enjoined or otherwise prohibited, or is reasonably likely to be enjoined or otherwise prohibited, from using any Deliverable as a result of or in connection with the above stated IPR infringement claims for which Bidder is required to indemnify the Bank
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 52 of 69
according to a final decision of the courts or in the v iew of Bidder, Bidder, may at its own expense and option: (i) procure for Bank the right to continue using such Deliverable; (ii) modify the Deliverable so that it becomes non-infringing without materially altering its capacity or performance; (iii) replace the Deliverable with work product that is equal in capacity and performance but is non-infringing; or (iv) I f such measures do not achieve the desired result and if the infringement is established by a final decision of the courts or a judicial or extrajudicial settlement, the Bidder shall refund the Bank the fees effectively paid for that Deliverable by the Bank subject to depreciation for the period of use, on a straight line depreciation over a 5 year period basis. The foregoing provides for the entire liability of the Bidder and the exclusive remedy of the Bank in matters related to infringement of third party intellectual property rights.
The below para of this section shall be removed from the RFP document as indemnification for non-compliance with laws is already covered under section 5.2 and third party IPR infringement claims indemnification has been set forth in this section above. The Bidder does not agree to provide the additional
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 53 of 69
indemnities set forth in this RFP section. The vendors should indemnify the Bank (including its employees, directors or representatives) from and against claims, losses, and liabilities arising from:
Non compliance of the vendor with Laws / Governmental Requirements IP infringement
Negligence and misconduct of the Vondor, its employees, and agents Breach of any terms of RFP, Representation or Warranty Act or omission in performance of serv ice
The Bidder clarifies that indemnity shall not cover damages, loss or liabilities suffered by the Bank arising out of claims made by its customers. However, Bidder accepts that indemnity shall cover direct damages suffered by the Bank arising out of claims of competent regulatory authorities
The below para of this section shall be modified as under:
The vendor shall not indemnify the Bank for
(i) Any loss of profits, revenue,
contracts, or anticipated savings or
(ii)Any consequential or indirect loss or damage however caused, provided that the claims against
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 54 of 69
customers, users and serv ice providers of the Bank would be considered as a "direct" claim
Further, Bidder clarifies that the Bank shall defend, indemnify and hold harmless the selected bidder from and against any third party suit, proceedings damages, judgments, cost and expenses (including reasonable attorney fees) relating to any infringement claim by a third party to the extent based on any Bank materials prov ided to selected bidder by or on behalf of Bank or the access and use by selected bidder of any Bank provided software or material in connection with selected bidder's performance of serv ices.
138
5.16 Privacy and
Security safeguards
The Bidder clarifies that in the following situations the restrictions set forth in this section shall not apply and the section be amended to include the same: I f such details and information is (i) already known to the Bidder or its
subcontractors free of any restriction
at the time it is obtained from the Bank, (ii) subsequently learned from
an independent third party free of
any restriction and without breach of this provision; (iii) is or becomes
publicly available through no
wrongful act of the Bidder or any
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 55 of 69
third party; (iv) is independently
developed by the Bidder without
reference to or use of any information of the Bank; or (v) is
required to be disclosed pursuant to
an applicable law, rule, regulation, government requirement or court
order, or the rules of any stock
exchange.
139
5.18 Guarantees The Bidder clarifies that it does not provide any guarantees with
respect to the serv ices and
deliverables under the RFP and/or contract. The Bidder confirms that it
will provide serv ices and
deliverables in accordance with the agreed parameters under the
contract.
Clause stands as per RFP.
140
5.19 Resolution of disputes The last line of the last para to this section shall be modified as under:
Notwithstanding the above, either
party shall have the right to initiate appropriate proceedings before
any court of appropriate jurisdiction
for any interim relief such as injunction, etc.
Clause stands as per RFP.
141
5.20 Exit Option & Contract Renegotiation
The Bidder clarifies that the term 'cancel" shall be substituted by the term "terminated" throughout this section and be construed accordingly. Further, rather than having the RFP provided isolated events as basis of termination, the Bidder clarifies that the RFP and/or contract shall reflect that if there is a material breach of the RFP and/or
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 56 of 69
contract by either party, the other party shall notify such breach. The Party in breach shall be given a cure period of 30 days or such agreed period to rectify such breach, and if the party fails to rectify such breach, the other party shall be entitled to terminate the contract.
The Bank shall not encash the Bid Security/Performance Guarantee to appropriate damages in this context. Further, if the Bank procures the equipment directly from a third
party, it is not clear how the
obligations in that respect will still remain with the Bidder. Kindly
clarify.
The Bidder clarifies that there be objective milestones defined under
the reverse transition plan and
mechanism and the achievement
of such milestones be conclusive of whether the reverse transition has
been achieved or not. The Bidder
does not agree to leave the decision on completion and
compliance with reverse transition
plan to the Bank's sole discretion.
142
5.22 Termination Further, the termination for breach shall be made mutually applicable and be invoked only when there is material breach of significant obligations by a party. The successor vendor shall be subjected to confidentiality
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 57 of 69
obligations towards the Bidder which are no less restrictive than those between the Bank and the Bidder. Bank shall initiate arbitration proceedings and not approach any court in the context of this clause. The dispute resolution set forth above shall apply.
143
5.23 Effect of Termination The Bidder clarifies that provision of maintenance serv ices by the Bidder to the Bank post termination shall be subject to a separate agreement which may contain different terms and conditions including commercials and rates, depending upon the scope, volumes, locations, etc. as the case may be. Further, it is clarified that the Bidder shall be paid for all the serv ices
rendered upto the effective date of
termination and prorated payment, if any, shall be agreed upon
between the parties. Termination
charges, may apply, if agreed
between the parties.
144
5.26 and 5.27
Performance Measurements
and Serv ice Levels
The Bidder clarifies that the
performance measurements and
serv ice level audits shall be conducted as per agreed
frequency, and a third party, if any,
used by the Bank in conducting the same, shall not be a competitor to
the Bidder. Such third parties and/or
Bank's representatives shall be subject to confidentiality obligations
towards the Bidder.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 58 of 69
145
Additio nal
clause to be
added
Non-
solicitation
The Bidder request that following clause shall be added to the RFP and/or contract: Bidder and Bank each agree that
during the term the Bidder
personnel or Bank employee is associated with the Serv ices
hereunder and for a period of two
years after such person ceases to be so associated, neither Bidder nor
Bank shall, directly or indirectly,
solicit for hire or knowingly hire or retain such personnel of the other party as an employee or
independent contractor, except with prior written consent of the
other party.
Not applicable.
146
Additional
clause to be added
Intellectual
Property Rights
The Bidder requests that following clauses shall be added to the RFP and/or contract: i) Bank acknowledges and agrees that this agreement is not intended to be used for licensing of any Bidder's proprietary software or tools. I f Bidder and Bank mutually agree that the Bidder provides to Bank any proprietary software or tools of Bidder or of a third party, the pertinent parties shall negotiate and set forth the applicable terms and conditions in a separate license agreement and the provisions of this section shall not apply to any
Not applicable
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 59 of 69
deliverables related to customization or implementation of any such proprietary software or products of Bidder or of a third party. ii) Further, the Bank acknowledges that in performing Serv ices under this Agreement, Bidder may use Bidder proprietary materials including without limitation any software (or any part or component thereof), tools, methodology, processes, ideas, know-how and technology that are or were developed or owned by Bidder prior to or independent of the Serv ices performed hereunder or any improvements, enhancements, modifications or customization made thereto as part of or in the course of performing the Serv ices hereunder, ("Bidder Pre-Existing IP"). Bidder agrees that except with prior consent of Bank, Bidder shall not embed or incorporate any Bidder Pre-Existing IP. Notwithstanding anything to the contrary contained in this Agreement, Bidder shall continue to retain all the ownership, the rights title and interests to all Bidder Pre-Existing IP and nothing contained herein shall be construed as preventing or restricting Bidder from using Bidder Pre-Existing IP in any manner. To the extent that any Bidder Pre-Existing IP or a portion
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 60 of 69
thereof is incorporated or contained in a Deliverable under a Statement of Work under this Agreement, Bidder hereby grants to BANK a non-exclusive, perpetual, royalty free, fully paid up, irrevocable license, with the right to sublicense through multiple tiers, to use, copy, install, perform, display, modify and create derivative works of any such Bidder Pre-Existing IP in connection with the Deliverables and only as part of the Deliverables in which they are incorporated or embedded. The foregoing license does not authorizes BANK to (a) separate Bidder Pre-Existing IP from the Deliverable in which they are incorporated for creating a stand alone product for marketing to others; (b) independently sell, lease, exchange, mortgage, pledge, license, sub license, assign or in any other way convey, transfer or alienate the Bidder Pre-Existing IP in favour of any person (either for commercial consideration or not (including by way of transmission), and/or (c) except as specifically and to the extent permitted by the Bidder in the relevant Statement of Work, reverse compile or in any other way arrive at or attempt to arrive at the source code of the Bidder Pre-Existing IP. iii) Residuary Rights. Each Party shall be entitled to use in the normal
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 61 of 69
course of its business and in providing same or similar serv ices or development of similar deliverables for its other clients, the general knowledge and experience gained and retained in the unaided human memory of its personnel in the performance of this Agreement and Statement of Work(s) hereunder. For the purposes of clarity the Bidder shall be free to provide any services or design any deliverable(s) that perform functions same or similar to the Deliverables being provided hereunder for the BANK, for any other client or customer of the Bidder (including without limitation any affiliate, competitor or potential competitor of the BANK). Nothing contained in this Section shall relieve either party of its confidentiality obligations with respect to the proprietary and confidential information or material of the other party. iv) Third Party Components. Any
third-party software, tools, products
or
materials required for performing the Serv ices or for being
incorporated
into or provided in connection with the serv ices or deliverables are
referred
to as "Third-Party Components". Unless otherwise agreed, BANK shall
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 62 of 69
be
responsible for obtaining any and all
appropriate consents and licenses for
such Third Party Components, at
BANK's costs and expenses, including
applicable license fee. Bidder shall
be responsible for providing
reasonable assistance to BANK for securing all such licenses required
from third parties for BANK's use of
any such Third-Party Components.
147
Additional clause to be added
Entire Agreement Bidder requests the insertion of an
entire agreement clause which
states that the Agreement sets forth the entire understanding of the
parties with respect to the subject
matter hereof and supersedes all prior or simultaneous
representations, discussions,
negotiations, letters, proposals, agreements and understandings
between the parties.
Not applicable
148
Additional clause to be
added
Tata Code of Conduct Bidder requests that the Bank notify the Bidder of any breach of the
Tata Code of Conduct by any
Bidder personnel relating to the
Agreement. Bidder in turn, undertakes that it will maintain
confidentiality of all communication
received.
Not applicable
149
Additional
clause to be
added
Confidential Information The Bidder suggests that the parties
shall agree to include a mutually
applicable regime on confidential information as part of the contract.
Not applicable
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 63 of 69
150
Annexure B Undertaking The Bidder clarifies that the below clause of the Annexure shall be modified as under: I f our bid is accepted, we are
responsible for the due
performance as per the scope of work and terms & conditions as per
mentioned in RFP, subject to the
deviations and clarifications submitted by the Bidder.
Clause stands as per RFP.
151
Annexure C Format of Bank
Guarantee (EMD)
The Bidder clarifies that the amount stated in para 4 of the Annexure shall be rectified to state RUPEES TEN LAKHS as against "RUPESS TWENTY LAKHS" stated in the RFP Annexure document. Further, the Guarantee can be invoked if the contingencies stated in the guarantee occur and shall not refer to the situations stated in the RFP document. The Bidder clarifies that at the before of the paragraph starting with "Notwithstanding any other term....", the below provisions shall be added: "This Bank Guarantee issued by Bank, on behalf of Bidder in favor of
Bank is in respect of a new
Contract dated . As communicated by Bidder, on the
date of execution of this Bank
Guarantee an amount of Rupees (Rupees
only) is outstanding and payable to Bidder by Bank, in respect of perv ious
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 64 of 69
contracts between Bidder and Bank. As communicated by Bidder on the date of execution of this Bank Guarantee, there are no outstanding disputes related to any previous contracts between Bidder and Bank." Also after the present Not
withstanding clause following to be
added : Unless the demand/claim under this
guarantee is served upon us in
writing before all the rights
of Bank under this guarantee shall stand automatically forfeited and
we shall be relieved and discharged
from all liabilities mentioned hereinabove.
152
Annexure D Pre contract Integrity Pact The Bidder clarifies that the Bidder does not offer any stores as referred in para 2 of the "General" para of the Annexure. The Bidder provides serv ices and deliverables as agreed under the contract. The Bidder clarifies as under: Section 6.1 (iv) shall be deleted from the document. Section 6.1 (v i) The Bidder's liability shall be subject to the liability cap set forth in the contract. Section 7.1 shall be removed from the document. The pricing provided in each deal will depend on the nature of serv ices, volumes, volume commitments, location of serv ices performance, etc. and thus this clause is not reasonable.
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 65 of 69
The Bidder requests removal of the
letter from the OEM as required in
the format on page 46 of the RFP document due to administrative
constraints
153
Annexure F Undertaking to be given by the Bidders
The Bidder clarifies that the below clause of the Annexure shall be
modified as under:
We having registered
office at do hereby confirm that we will provide the serv ices as per
scope of work mentioned in the RFP
Document, subject to the deviations
and clarifications submitted by the
Bidder.
Clause stands as per RFP.
154
Annexure G Non Disclosure Agreement The Bidder clarifies that the Annexure shall be modified to include the following clauses as under: i) The obligations set forth in the Annexure shall not apply to the extent, that such information is (i) already known to the Bidder free of any restriction at the time it is obtained from the Bank, (ii) subsequently learned from an independent third party free of any restriction and without breach of this provision; (iii) is or becomes publicly available through no wrongful act of the Bidder or any third party; (iv) is independently developed by the Bidder without reference to or use of any information of
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 66 of 69
the Bank; or (v) is required to be disclosed pursuant to an applicable law, rule, regulation, government requirement or court order, or the rules of any stock exchange. ii) Equivalent obligations of confidentiality shall apply to Bank with respect to the Bidder's information and material. iii) The confidentiality obligations
set forth in the Annexure shall survive for a period of two years from the
time of disclosure of such
information.
155
Annexure H Proforma of Deed of Indemnity Section 5. 14 of the RFP document (subject to Bidder's clarifications suggested above) already deals with the indemnities that the Bidder shall provide the Bank with, in relation to the RFP and/or contract. I t is our understanding that an additional deed of indemnity for the same purpose is not required and hence Bidder suggests that the same be removed from the RFP document. Kindly clarify and confirm. Bidder reserves its right to comment on the deed of indemnity based on
the response received from the
Bank on this front.
Clause stands as per RFP.
156
Annexure I Proforma for Performance
Guarantee
The Bidder clarifies that at the before section 7 of the Annexure , the below provisions shall be added:
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 67 of 69
This Bank Guarantee issued by
Bank, on behalf of Bidder in favor of
Bank is in respect of a new Contract dated .
As communicated by Bidder, on the date of execution of this Bank Guarantee an amount of Rupees (Rupees
only) is outstanding and payable to Bidder by Bank, in respect of perv ious contracts between Bidder and Bank. As communicated by Bidder on the date of execution of this Bank
Guarantee, there are no
outstanding disputes related to any previous contracts between Bidder
and Bank
Also section 7 iii) shall be modified as under : iii) We are liable to pay the guaranteed amount or any part thereof under this Bank Guarantee only and only if you serve upon us a written claim or demand on or before .......................................................(date of expiry of Guarantee including claim period), after which all the rights of
Bank under this guarantee shall
stand automatically forfeited and
we shall be relieved and discharged from all liabilities mentioned
hereinabove.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 68 of 69
157
Annexure J Manufacturer Authorization Form
The Bidder requests removal of the
Annexure J as required from the
OEM in the format on page 56 of the RFP document due to
administrative constraints.
Clause stands as per RFP.
158
Annexure K Tender offer forwarding letter
The Bidder clarifies that the below clauses of the Annexure shall be modified as under: With reference to the above RFP, having examined and understood the instructions including all annexure, terms and conditions forming part of the Bid, we hereby enclose our offer for Implementation of Bharat Bill Payment System as per approved Design & Specification of the Bank mentioned in the RFP document forming Technical as well as Commercial Bids being parts of the above referred Bid, subject to the deviations and clarifications submitted by the Bidder. In the event of acceptance of our Technical as well as Commercial Bids by the bank we undertake to Implementation of Bharat Bill Payment System as per your purchase orders, subject to the deviations and clarifications submitted by the Bidder as well as any reservations to such purchase orders. In the event of our selection by the Bank for Implementation of Bharat
Bill Payment System as per
approved Design & Specification of the Bank, we will submit a
Clause stands as per RFP.
RFP Ref No. UCO/DIT/1003/2016-17 Date 31-08-2016 Page 69 of 69
Performance Guarantee for a sum
equivalent to10% of the project cost
for a period of 39 (Thirty Nine) months effective from the month of
execution of the Agreement in favor
of UCO Bank. We agree to abide by the terms and conditions of this
tender offer till 180 days from the
date of commercial bid opening
and our offer shall remain binding upon us which may be accepted
by the Bank any time before expiry
of 180 days, subject to the
deviations and clarifications submitted by the Bidder. Until a
formal contract is executed, this tender offer, together with the
Bank's written acceptance thereof
and Bank's notification of award,
subject to the deviations and
clarifications submitted by the Bidder, shall constitute a binding contract between us.