Upload
others
View
11
Download
0
Embed Size (px)
Citation preview
िनिवदा पूछताछTENDER ENQUIRY
[वेब िनिवदा][WEB TENDER]
िनिवदा सं./Tender No 6000001275�य अिधकारी/Purchase Exec. MOHAMED ASRAFF Bसेवा म� /To
दूरभाष सं./Telephoneफै� स सं./Faxई-मेल/E-Mail
िवभाग/Department OTS(OUTSOURCING DEPT.)�य अिधकारी/Purchase Exec. MOHAMED ASRAFF Bदूरभाष सं./Telephone No 23763084फै� स सं./Fax No 23743198ई-मेल/E-Mail [email protected]
िनिवदा सं./Tender No 6000001275
आरएफ� यू सं./RFQ No 2110001498
िनिवदा ितिथ/ Tender Date 17.02.2020िनिवदा बंद की ितिथ/Tender Closing Date 17.03.2020िनिवदा बंद होने का समय/Tender Closing Time 15:00:00
िनिवदा शु% क/Tender Fee &/Rs 0.00बयाना रािश/EMD Amount &/Rs 60,000.00पुव( िबड बैठक ितिथ और समय/Pre Bid Meeting Date & Time ,00:00:00िनिवदा खोलने की ितिथ और समय/Tender Opening Date & Time 18.03.2020,15:30:00-. ताव वैधता ित िथ है/Offer should be valid up to 17.07.2020सुर/ा जमा/Security Deposit 5.00 %आदेश मू1 का/PO valueवरीय ब2क जमानत /Perf. Bank Guarantee 10.00 %आदेश मू1 का/PO value
( आगे के िववरण हेतु कृपया स� बं� िनयम शत� को पढ़े । सुिनि त कर! िक कोटेशन और संबंिधत प%ाचार के िलए िवभाग का नाम, *य अिधकारी का नाम ,िनिवदा सं- या,बंद होने का समय एवं ितिथ एवं आरएफ0 यू सं. अपने कोटेशनम! िलख! ।Kindly read and refer relevant terms & conditions for further details. Do ensure to Quote Department Name, Purchase Executive ‘s Name , Tender
Number, closing date & time and RFQ Number in your Quotation & related correspondence )
ि-य महोदय/महोदयाDear Sir / Madam ,
िवषय /SUB:- E-TENDER FOR NON-COMPREHENSIVE MAINTENANCE OF 6 NOS. EOT CRANES AND 3 NOS. SEMIGOLIATH CRANES OF EAST YARD & SSA SHOP FOR THE PERIOD OF TWO YEARS
माझगाँव डॉक िशपिब% डस( िलिमटेड -िति7त/संभािवत आपूित(कता(ओं से िन9 न हेतु, -ितयोिगता:क दो बोली -णाली म� ( भाग -।तकिनकी - वािण= बोली एवं भाग ।। मू1 बोली ) बोली आमंि>त करती है।Mazagon Dock Shipbuilders Limited (MDL) invites Competitive – Bid from reputed Supplier for the following in TWO BIDsystem ( Part - । Techno - Commercial Bid & Part - ।। Price Bid ).
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
00100 Maintenance OF EOT CRANES MAINTENANCE 1 Activity unit 24.06.2022
Service Description :NON-COMPREHENSIVE MAINTENANCE CONTRACT FOR 6 Nos. EOTCRANES AND 3 Nos. SEMIGOLIATH CRANES
Page: 1 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
Non-Comprehensive maintenance contract of 6 Nos. EOT cranes & 3 Nos.Semiogoliath cranesinstalled in various workshops in SSA workshop & EY The Cranes are having SCHNEIDER makeVVVF Drives & Encoder: Hubner make, The Main aim of Maintenance Contract is to ensure smoothfunctioning of the Cranes all the time and availability of the spare parts immediately to attend thebreakdown, enhancing the performance of the Cranes and reduction of production loss due to machinedowntime.
CAPACITY OF CRANES UNDER MAINTENANCE CONTRACT:
Sr.No. Crane Type Crane capacity Qty1 EOT 30 /10 Ton 4 nos.2 EOT 40/5 Ton 1 No.3 EOT 10/2Ton 1No.4 Semi goliath 150/30 Ton 2 Nos.5 Semi goliath 60/20 Ton 1 No.
The Line item 00100 covers the following services
0000000010
सेवा सं./Service Number :- 32 Per Quarter
संि/? वण(न/Short Description :- Mtc of 30/10TonEOT crane,(04 Nos.)
0000000020
सेवा सं./Service Number :- 8 Per Quarter
संि/? वण(न/Short Description :- Mtc of 40/5TonEOT crane,(01 Nos.)
0000000030
सेवा सं./Service Number :- 8 Per Quarter
संि/? वण(न/Short Description :- Mtc of 10/2TonEOT crane,(01 Nos.)
00200 Maintenance of Semi Goliath Crane 1 Activity unit 23.12.2020
The Line item 00200 covers the following services
0000000010
सेवा सं./Service Number :- 16 Per Quarter
संि/? वण(न/Short Description :- Mtc of 150/30 TSemi Goliath Crane,(2Nos
0000000020
सेवा सं./Service Number :- 8 Per Quarter
संि/? वण(न/Short Description :- Mtc of 60/20T Semi
Page: 2 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
Goliath Crane,(1 Nos.
00300 Supply Of Spares 1 Activity unit 23.12.2020
The Line item 00300 covers the following services
0000000010
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- VFD,Make-Schneider (Altivar 71, 15 Kw ,
सेवा िववरण/Service Details :- VFDMake- SchneiderModel No. - Altivar 71, 15 Kw , Model -8EB71HD15N4
0000000020
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- Contactor, Make-Siemens, 3TH30/22E, Coi
सेवा िववरण/Service Details :- Contactormake- SiemensModel No. - 3TH30/22E, Coil 110 Volts
0000000030
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- Contactor,Make-Siemens, 3RT1023-xA-1, C
सेवा िववरण/Service Details :- ContactorMake- SiemensModel No. 3RT1023-xA-1, Coil 110 Volts
0000000040
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- Overhead Relay,Make-Siemens,UVX 1420, 1
सेवा िववरण/Service Details :- Overload RelayMake-SiemensModel No.- UVX 1420, 12.5 A to 20 Amp.
0000000050
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- VFD,Make-Schneider, Altivar 71, 75 Kw,
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No.- Altivar 71, 75 Kw, Model - ATV71 HD75N4
0000000060
सेवा सं./Service Number :- 2 Number
Page: 3 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
संि/? वण(न/Short Description :- MCCB,Make-Siemens, VL250, 200 Amp
सेवा िववरण/Service Details :- MCCBMake-SiemensModel No. -VL250, 200 Amp
0000000070
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- Contactor,Make-Siemens, 3TR1034.1A
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No. - 3TR1034.1A
0000000080
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- Cotactor.Make-Siemens, 3TR1023.1A
सेवा िववरण/Service Details :- ContactorMake-SiemensModel no. -3TR1023.1A
0000000090
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- VFD,make-Schneider, Altivar 71, 45 Kw,
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No.- Altivar 71, 45 Kw, Model - ATV71HU40N4
0000000100
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- MCCB,Make-Siemens, 125 Amp, VL 160 X
सेवा िववरण/Service Details :- MCCBMake-SiemensModel No. - 125 Amp, VL 160 X
0000000110
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- VFD,Make-Schneider, Altivar 71 , 4Kw /5
सेवा िववरण/Service Details :- VFDMake-Schneider
Page: 4 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
Model No. - Altivar 71 , 4Kw /5 HP, Model No. - ATVT1HU40N4
0000000120
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- Contactor,Make-Siemens, 3TR 1023, coil
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No. -3TR 1023, coil 110 Volts
0000000130
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- Regenerative Unit,Make-Schnieder,VW3A72
सेवा िववरण/Service Details :- Regenerative UnitMake-SchneiderModel No. - VW3A7201
0000000140
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- Contactor,Make-Siemens, 3TR1056.6…..6 ,
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No. -3TR1056.6…..6 , 115 Amp, Coil 110 Volts
0000000150
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Contactor,Make-Siemens, 3TF32 , Coil 110
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No.- 3TF32 , Coil 110 Volts
0000000160
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- Single PhasePreventor, Make-Minillec, V
सेवा िववरण/Service Details :- Single Phase PreventorMake- MinillecModel No.- VSP-3
0000000170
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-
Page: 5 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
Contactor,Make-Siemens, 3RT1035.6….6, 33
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No.- 3RT1035.6….6, 330 Amp, Coil 110 Volts
0000000180
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Contactor,Make-Siemens,3TF30, Coil 110 V
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No.- 3TF30, Coil 110 Volts
0000000190
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,Altivar 71, 7.5 Kw /
सेवा िववरण/Service Details :- VFDMAke-SchneiderModel No- Altivar 71, 7.5 Kw / 10 HP, Model - ATV71HD45N4
0000000200
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,Altivar 71, 45 KW, Mo
सेवा िववरण/Service Details :- VFDMAke-SchneiderModel No.- Altivar 71, 45 KW, Model -ATV71HD45N4
0000000210
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- Regenerative Unit,Make-Schneider,VW3A72
सेवा िववरण/Service Details :- Regenerative UnitMake-SchneiderModel No. - VW3A7208
0000000220
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Cotactor,Make-Siemens,3TF34, Coil 110 V
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No.- 3TF34, Coil 110 Volts
000000023 सेवा सं./Service Number :- 1 Number
Page: 6 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
0
संि/? वण(न/Short Description :-VFD,Make-Schneider,Altivar 71, 110Kw/150
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No.- Altivar 71, 110Kw/150 HP, Model - ATV71HC11N4
0000000240
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-MCCB,Make-Siemens,3VT2, 250 Amp
सेवा िववरण/Service Details :- MCCBMake-SiemensModel No.- 3VT2, 250 Amp
0000000250
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Contactor,Make-Siemens,3TF30/10 E, Coil
सेवा िववरण/Service Details :- ContactorMake- SiemensModel No.- 3TF30/10 E, Coil 110 Volts
0000000260
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,make-Schneider,ATV71HC11N4
सेवा िववरण/Service Details :- VFDmake-SchneiderModel No- ATV71HC11N4
0000000270
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,make-Schneider,Altivar 71, 22 Kw/30
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No.- Altivar 71, 22 Kw/30 HP, Model - ATV71HD22N4
0000000280
सेवा सं./Service Number :- 2 Number
संि/? वण(न/Short Description :- RegenerativeUnit,Make-Schneider,Altivar
Page: 7 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
सेवा िववरण/Service Details :- Regenerative UnitMake-SchneiderModel No.- Altivar VW3A7202
0000000290
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,Altivar 71, 15 Kw, Mo
सेवा िववरण/Service Details :- VFDMake-Schneider'Model No- Altivar 71, 15 Kw, Model - ATV71HD15N4
0000000300
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,make-Schneider,Altivar 71, 45 Kw, Mo
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No. - Altivar 71, 45 Kw, Model - ATV71HD45N4
0000000310
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-chneider,Altivar 71, 5.5Kw/7.5
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No- Altivar 71, 5.5Kw/7.5 HP, Model - ATV71HU5.5N4
0000000320
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Contactor,make-Siemens,3RT064.6….6, Coil
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No.- 3RT064.6….6, Coil 110 Volts
0000000330
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,make-Schneider,Altivar 71, 15 Kw, Mo
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No.- Altivar 71, 15 Kw, Model VX5A1HD15N4
000000034 सेवा सं./Service Number :- 1 Number
Page: 8 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
0
संि/? वण(न/Short Description :-Contactor,Make-Siemens,3TR1023.1 A
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No. -3TR1023.1 A
0000000350
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,Altivar 71, 4Kw, Mode
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No. - Altivar 71, 4Kw, Model VX5A1HU75N4
0000000360
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Contactor,Make-Siemens,3RT1056.6…..6, 21
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No. -3RT1056.6…..6, 215 Amp, Coil 110 Volts
0000000370
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :- Regenerative Unit,Make-Schnieder,VW3A72
सेवा िववरण/Service Details :- Regenerative UnitMake-SchneiderVW3A7207
0000000380
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,11 Kw, Model - ATV71
सेवा िववरण/Service Details :- VFDMake-Schneider'Model No.- 11 Kw, Model - ATV71HD11N4A
0000000390
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,7.5 Kw, Model - ATV71
सेवा िववरण/Service Details :- VFD
Page: 9 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
Make-SchneiderModel No. - 7.5 Kw, Model - ATV71HU55N4A
0000000400
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,1.5 Kw, Model - ATV31
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No. - 1.5 Kw, Model - ATV312HU15N4
0000000410
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,3 Kw, Model - ATV312H
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No. -3 Kw, Model - ATV312HU30N4
0000000420
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-MCCB.Make-Schneider, 250/36KA, Model - L
सेवा िववरण/Service Details :- MCCBMake-SchneiderModel No. -250/36KA, Model - LV525341N
0000000430
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-Contactor,make-Schneider,250 A, 3 pole ,
सेवा िववरण/Service Details :- ContactorMake-SiemensModel No. - 250 A, 3 pole , Model - LC1F265
0000000440
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,Make-Schneider,125 HP/90 Kw, Model -
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No. -125 HP/90 Kw, Model - ATV71 HD 90N4
0000000450
सेवा सं./Service Number :- 1 Number
Page: 10 of 11
िनिवदा सं./ Tender No:- 6000001275 िनिवदा ितिथ/ Tender Date:- 17.02.2020 आरएफ� यू सं./RFQ No:- 2110001498
* सं.SL.No.
साम2ी / सेवा िववरणMaterial / Service Details
मा%ा / इकाईQuantity / unit
आपूित5 ितिथDelivery Date
संि/? वण(न/Short Description :-VFD,Make-Schneider,50 Hp/37 Kw, Model -
सेवा िववरण/Service Details :- VFDMake-SchneiderModel No.- 50 Hp/37 Kw, Model - ATV71HD37N4
0000000460
सेवा सं./Service Number :- 1 Number
संि/? वण(न/Short Description :-VFD,make-Schneider,7.5 HP/5.5 Kw, Model
सेवा िववरण/Service Details :- VFDMake-Schneider'Model No. -7.5 HP/5.5 Kw, Model - ATV312HU55N4
िनयम और शत@ : भाग ए मे िलखी Aई और इतर संलCप>े इस िनिवदा एक अिभD अंग ह2 |हम� आशा ह2 की,हम� -ितयोिगE:क और उिचत-Hाव इस िनिवदा के िलए -ा? होगा |Terms & Conditions as indicated in Part A of this tender and other enclosures / annexures form an integral part of this tenderdocument. We look forward to receive your most competitive and reasonable offer against this Tender.
माझगाँव डॉक िशपिबIस( िलिमटेड के िलए /For Mazagon Dock Shipbuilders Ltd
Page: 11 of 11
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 1 of 29
PART- “A”
MAZAGON DOCK SHIPBUILDERS LIMITED invites on-line competitive bids from reputed
Bidders / Suppliers in TWO BID SYSTEM (Part-I Techno Commercial Bid and Part-II Price Bid) on our e-
procurement portal https://eprocuremdl.nic.in for the following Scope of Work / Supplies, terms and
conditions:
1. DESCRIPTION OF WORK / SUPPLIES / SERVICES: Biennial Rate Contract for Non-
Comprehensive Maintenance of 6 Nos. EOT Cranes and 3 Nos. Semi Goliath Cranes of East Yard & SSA
Shop for the period of Two years.
The detailed scope of work is as per Enclosure-1
2. PRE - QUALIFICATION CRITERIA: The bidder should submit scanned copies of necessary
documents as below to ascertain their qualifying status. MDL reserves the right to verify the authenticity of
the documents submitted / claims made by the bidder wherever felt necessary.
i) Bidders Company Profile and Shop & Establishment / Registration certificate.
ii) Bidders Audited Balance sheets and Profit & Loss A/c of the company for last 3 financial years
ending 31st March 2017, 2018 and 2019. The average minimum turn over for 3 years should be at
least Rs. 4.5 Lakhs
iii) Bidder’s own past experience of having successfully completed similar works during last 7 years
ending January 2020 should be either of the following:
a) Three similar completed works each costing not less than Rs. 12 Lakhs
OR
b) Two similar completed works each costing not less than Rs. 15 Lakhs
OR
c)
One similar completed work costing not less than Rs. 24 Lakhs
d) Similar completed works in a continuous span of 12 months of cumulative value not less than
Rs. 7.5 Lakhs
Note: Similar completed work mentioned above shall be Maintenance of similar type of Cranes.
(iv) The bidders should submit documentary proof of having past experience in the Drives and PLC in their own name.
(v) The bidders should submit documentary proof of having experience in maintenance / installation of minimum 50 Ton capacity Cranes in their own name.
NOTE: 1) Documentary evidence for Pre-qualification criteria shall be in the name of the firm who is bidding.
2) If any cash transaction included in turnover (statement of profit & loss) the same will not be considered
for turnover value.
3) It is clarified that the work executed by the contractors for their in-house or capital use will not be
considered for the purpose of bidders’ experience of completion of similar works.
4) Bidders need to Upload documentary evidence in support of the Pre-Qualification Criteria Viz. Work
Order, Work Completion Certificate issued by the party for whom the work is done. MDL has a right to
verify / cross verification of authenticity of the said documents whenever felt necessary.
3. EARNEST MONEY DEPOSIT (EMD):
3.1 Bidders shall furnish EMD of Rs. 60,000/- (Rupees Sixty Thousand only) against this tender.
3.2 The EMD can be remitted directly to MDL Bank Account as per details given in Annexure- “A” of
this tender. Further, the bidder should specifically mention the details of company name as well as
nature of remittance, tender number/order number etc. in the text/narration fields of Bank’s NEFT
remittance in order to identify the same.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 2 of 29
3.3. EMD can be submitted online. “For making online payment please follow the following steps:
• Go to www.mazdock.com
• Click on Online payment tab available on home page.
• 4 options viz. Career, Tender, Security, Scrap / Disposal will be available.
• Click on the respective tab and make the payment online using Debit cards, Credit Cards, Net banking,
BHIM/UPI etc. after filling the required details.
3.4 EMD can also be submitted in the form of Bank Guarantee in the prescribed format drawn in favour
of MAZAGON DOCK SHIPBUILDERS LIMITED payable at Mumbai. The format of Bank Guarantee for
EMD is available on MDL Website. The bid bond / Bank Guarantee should be valid for 4 more weeks
beyond the offer validity period indicated in the tender. Bank Guarantee should be drawn on reputed
Nationalized / Scheduled Banks excluding co-operative banks. In case of BG, Bidders to advise their
bank/banker to send original BG directly to OTS department in sealed envelope to dispense with additional
step of verification of authenticity of signatories.
3.5 Bidders are requested to upload the scanned image of EMD i.e. Annexure-A/Bank Guarantee online
along with the bid. If bidders are submitting the Bank Guarantee, they are requested to inform us the address,
Tel. No., Fax No. of the issuing Bank and forward the original of the scanned copy of EMD enclosed in an
envelope addressed to HOD (Outsourcing), 6th floor, Service Block, North Yard, Mazagon Dock
Shipbuilders Limited, Mumbai – 400 010, super scribing Tender No. & Tender date by Speed Post /
Registered Post / Courier Service/Hand Delivery to reach the office of HOD (Outsourcing) within seven days
from the Tender closing date.
3.6 Timely submission of the EMD is the responsibility of the bidders and no reasons / excuses in this
regard will be entertained by MDL.
3.7 EMD of unsuccessful bidders will be returned after finalization of the tender and shall be interest
free. If bidders are submitting the Bank Guarantee, they are requested to inform us the address, Tel. No., Fax
no. of the issuing Bank.
3.8 EXEMPTION FROM SUBMISSION OF EMD
Following bidders shall be exempted from submission of EMD:
a) State & Central Government of India departments, Public Sector Undertakings.
b) Firms Permanent registered with Mazagon Dock Shipbuilders Limited (MDL) under both Service
Groups 1402169 (Repairs/Modifications of Cranes-EOT) and 1402147 (Repairs of Cranes-Other
than EOT). (Exemption will apply only to items/services for which they are registered). To qualify
for EMD exemption, firms should necessarily submit VALID copy of the Registration Certificate
issued by MDL, for the items for which the offer being submitted, in Part-I offer/bid. Firms in the
process of obtaining MDL registration will not be considered for EMD exemption.
c) Firms registered with NSIC under its “Single Point Registration Scheme”. (Exemption will apply
only to items/services for which they are registered). To qualify for EMD exemption, firms should
necessarily submit VALID copy of the Registration Certificate along with the list of items/services
for which they are registered, as issued by NSIC, in Part-I offer / bid. Firms in the process of
obtaining NSIC registration will not be considered for EMD exemption.
d) All Micro & Small Enterprises subject to their submitting the Registration Certificate from the
Competent Authority regarding their Micro/Small Industry status. Firms registered with Micro &
Small Enterprises under its “Single Point Registration Scheme”.
e) Common/Deemed DPSU registered vendors qualify for EMD exemption. Such firms shall submit
valid copy of the Green Channel certificate issued by MoD for the items for which the offer is being
submitted in Part-I offer/bid. Firms in process of obtaining registration in other DPSUs will not be
considered for EMD Exemption.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 3 of 29
f) Green Channel Status vendors qualify for EMD exemption. Such firms shall submit valid copy of
the Green Channel Certificate issued by MoD for the items for which the offer is being submitted in
Part-I offer/Bid. Firms in the process of obtaining this certificate will not be considered for EMD
exemption.
4. VALIDITY PERIOD: Bids / Offers shall have the validity period of 120 Days from the tender
closing date.
5. ONLINE SUBMISSION OF OFFER IN TWO-BID SYSTEM: Offer must be submitted in two
parts, Part - I (Techno-Commercial Bid) & Part - II (Price Bid) on the MDL’s e-Procurement website
https://eprocuremdl.nic.in. Offer in any other form will not be considered.
Techno-Commercial Bid Part-I: This part should contain the following:
i) Online Acceptance on clauses of Tender Enquiry, (TEF) General Terms & Conditions (GT&C),
Standard Terms & Conditions (STACS) in the Prescribed Formats stating ‘Accepted OR
Deviation’ as applicable for each of the clause.
ii) Deviation sheet in case of any deviations from Terms, Conditions specified in the Standard Terms
and Conditions, Tender Enquiry & General Terms & Conditions shall be uploaded online.
iii) Any deviation with respect to Technical requirement shall be uploaded online by the bidder.
iv) The scanned image of Annexure-“A” / Bank Guarantee towards Earnest Money Deposit (EMD) /
BID BOND as stipulated in TEF clause no. 3 shall be uploaded.
v) Scanned image of Valid GST certificate.
vi) Price schedule BLANKING the PRICES but clearly indicating ‘QUOTED / UNQUOTED’, also
indicating the % of actual taxes/ duties applicable, in the prescribed format available on MDL’s e-
Procurement website https://eprocuremdl.nic.in
vii) Bidders / Vendors should upload scanned documents as per clause 2.
viii) Scanned Image of valid Registration or Approval certificates in case of Bidder’s/ firms registered
with MDL/ NSIC/ Micro or Small Enterprises/Industries.
ix) Scanned image of Vendor Declaration in bidder’s letterhead as per the format at Enclosure-6.
x) Scanned image of duly filled RTGS/NEFT as per Enclosure-7.
Note:
i) MDL has the right to verify / cross verification of authenticity of the scanned documents with respect to
originals submitted against this tender.
ii) The bidder is requested to ensure that all the documents asked for are submitted and are clear, legible
& duly signed (i.e. self-attested), as it would save considerable time without necessitating the need for
furnishing of the documents again by them. The bidder is also requested not to submit unnecessary
documents not asked for, like signed & stamped copy of this Tender document, etc.
iii) The bidder is required to compulsorily select “ACCEPTED” or “DEVIATION” from the drop-down field
choices available against the relevant Para no. / Clause no. of TEF/STACS/GT&C (as applicable). In case
“DEVIATION” is selected against a particular Para no. /Clause no., it would be mandatory to explain the
deviation proposed by the bidder in the adjoining text field. Any deviation(s) mentioned elsewhere in the
Offer/Bid, other than in the said forms, will not be considered.
iv) Blank Rate Sheet form is required to be filled-up by the bidder online by selecting “QUOTED” or “NOT
QUOTED” from the drop-down field choices available, depending upon whether the bidder has quoted for
the particular Service/Item tendered. Therein, the bidder is also required to specify the Taxes & duties (if
any) quoted & the rate of the Taxes/Duties.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 4 of 29
Part-II: In this part bidders are requested to fill the PRICES for each of the listed items/services strictly in
the prescribed format/ Rate sheet provided in e-Procurement Portal. Offer in any other form shall not be
considered.
6. BID REJECTION CRITERIA:
a. Following bids shall be categorically rejected:
i) The Bids received after tender closing date and time.
ii) Bids received without EMD (other than those who are exempted from payment of EMD), as
specified in the tender
iii) Bidders not quoting for all the items in the Rate Sheet in the prescribed format available on
MDL’s e-Procurement website https://eprocuremdl.nic.in
iv) If the dates of remittance of EMD amount/issue of EMD BG is later than the tender Closing date.
b. Following bid rejection criteria may render the bids Liable for Rejection.
i) Bidder’s failure to submit sufficient or complete details for evaluation of the bids within the
given period on intimation of deficiency in the bid.
ii) Incomplete / misleading / ambiguous bids in the considered opinion of TNC.
iii) Bids with technical requirements and or terms not acceptable to MDL.
iv) Bids received without scanned copies of pre-qualification documents wherever required as per
the tender.
v) Bids not meeting the pre-qualification parameters stipulated in the tender enquiry.
vi) Validity period indicated by bidders is shorter than that specified in the tender enquiry.
vii) Bidders not agreeing to furnish Security Deposit till completion of the supplies / services as per
contract.
viii) Bidders not submitting documents as per clause 5.
ix) The original of the uploaded copy of EMD BG if received after seven days of the tender closing
date.
7. Opening of Techno-Commercial Bid (Part-I): Techno-Commercial bid (Part-I) will be opened
online on the tender closing date or extended tender closing date or next working day if closing date happens
to be holiday declared by MDL. The participant bidder can also witness opening of the bids online from their
locations by logging on MDL E-Portal website with their Class IIIB Digital Signature Certificate (DSC) or
higher version. Bidders may be called for attending TNC meeting at MDL if MDL desire so.
8. Opening of Price Bid (Part–II): After completion of the Techno-Commercial scrutiny of the
received bids, intimation for opening of price bid (s) will be communicated only to the Techno-commercially
qualified bidders, with the date & time of opening declared in such intimation. Such intimation may be given
at a short notice by Fax, E-mail or even by telephone. The participant bidders can also witness the opening of
the bids online from their location by logging on to the portal with their Class-IIIB Digital Signature
Certificate (DSC).
9. Bid Evaluation Criteria: Lowest bidder (L1) will be determined on the basis of total quoted price
of service items (exclusive of GST) as per Rate Sheet A and 25% of total quoted price of spare part items
(exclusive of GST) as per Rate Sheet B. The lowest bidder (L1) will be considered for further processing for
placement of order.
On-line Ranking visible to the bidders after opening price bid is without loading parameters. However, the
Overall L1 bidder will be evaluated offline after applying all applicable loading parameters as mentioned in
the tender document and commercial terms.
Taxes are excluded for the purpose of ranking of price bids to determine L1 Bidder. There may arise a
situation where overall cost (inclusive of taxes) of services and 25% of spare parts by the adjudged L1 bidder
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 5 of 29
may be higher compared with any other bid(s) depending on the tax structure. Therefore, the adjudged L1
bidder has to reduce the price to make it competitive both before including taxes and after including taxes. If
the adjudged L1 bidder does not agree to reduce the price to make it competitive after including taxes, then
the next lowest ranked bidder will be given the opportunity in the order of ranking so that procurement is
competitive.
Note: In case of any discrepancies observed in any Rate Sheets, or against each item and / or in Grand total
in the price bid, evaluation would be carried out by arriving on the grand total by considering the unit rate
and quantity indicated in Rate sheets.
10. Contract Period: The Contract shall be valid for two years starting from PO date and may be
extended for a further period of three months on mutual consent basis on same rates and terms and
conditions. However, if the performance of contractor is not satisfactory then contract may be terminated
with one month notice period by applying relevant clauses of contract such as Risk Purchase, forfeiture of
Security Deposit etc.
11. Mobilisation: The successful bidder shall mobilise the required manpower / tools/ materials within
10 working days from the placement of LOI / Order whichever is earlier.
12. PRICING: 12.1 Bidder shall quote prices for all the items listed in the Price rate sheets which will be inclusive of all
costs such as labour charges, transportation, all incidental expenses etc. in compliance with statutory
requirements (minimum wages, PF, Insurance, etc.). MDL shall not be liable to pay any charges whatsoever
other than the contract rates. However, the applicable GST will be indicated separately in the rate sheets.
Quoted base rate will remain firm and fixed during the currency of order /contract execution.
MDL shall not be bound by any printed conditions or provisions in the bidder's bid forms or
acknowledgement of Order/Contract, invoices, packing list and other documents which purport to impose
any conditions at variance with or supplemental to Order/Contract.
13. Price Escalation: Price shall be firm and fixed during entire tenure of the contract. Price escalation
is not applicable.
14. TAXES & DUTIES:
I. GST as per GST Laws shall be payable extra as quoted and agreed. II. In case of purchases of goods/services from unregistered dealers under GST Laws, GST will be paid by
MDL under reverse charge mechanism.
III. Benefits from reduction in rate of tax/ITC are required to be passed on to consumer. Where “applicable
GST” has been quoted as extra, Goods and service providers (except un-registered dealers under GST Law)
have to submit declaration that they have complied with ‘Anti-profiteering clause’ under GST Law. Such
declaration is given in technical bid.
IV. If the vendor is registered under GST, vendor shall mention the HSN code for goods &/or services in
their tax invoice, etc. These codes must be in accordance with GST Laws and responsibility of specifying
correct HSN codes for goods &/or services is that of the vendor. MDL shall not be responsible for any error
in HSN code for goods &/or services specified by supplier / contractor. Supplier /Contractor shall pay
penalty and/ or interest imposed on MDL or any loss due to delay in availing ITC by MDL or any loss of
ITC to MDL due to errors by vendors at any stage. MDL reserves right to recover any such interest, penalty
or loss from any amount due to Supplier /Contractor or otherwise.
V. In case, MDL is unable to avail ITC, supplier/contractor at their own cost shall rectify the shortcoming
in the returns to be filed immediately thereafter. Further, if the ITC is delayed / denied to MDL / reversed
subsequently as per GST Laws due to non / delayed receipt of goods and / or services and / or tax invoice or
expiry of timelines prescribed in GST Laws for availing ITC, non-payment of taxes or non-filing of returns
or any other reason not attributable to MDL, Supplier /Contractor shall pay any loss of amount along with
interest and penalty on MDL under GST Laws for the number of days the ITC was delayed. If the
shortcoming is not rectified by supplier/contractor and MDL ends up in reversal of credits and / or payments,
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 6 of 29
supplier /contractor is fully liable for making good all the loss incurred by MDL. MDL reserves right to
recover any interest, penalty or loss from any amount due to Supplier /Contractor or otherwise.
VI. If the vendor is registered under GST, the GST registration number (15 digit GSTIN) issued by GOI
shall be mandatorily provided by the vendor. Vendor having multiple business verticals within state / at
multiple states with separate GST registration numbers shall forward GSTIN of only that vertical which is
involved in supply of goods and/or services. MDL GSTIN is 27AAACM8029J1ZA and vendor shall
mention the same while invoicing and avoid any data entry error on GST portal.
VII. If the vendor is registered under GST, Vendor shall ensure timely submission of invoice as per the
provisions / requirement / timeline promulgated by GOI in relation to GST Law with all required supporting
documents to enable MDL to avail input tax credit promptly. The vendors invoice inter alia should contain
GSTIN of vendor, GSTIN of MDL (i.e. 27AAACM8029J1ZA), GST tax rate separately, HSN code wise
goods or services, place of supply, signature of vendor, etc. Original invoice needs to be submitted to Bill
Receipt Centre at MDL gate, and a copy of the invoice should be given to the goods receiving section (GRS).
VIII. If the vendor is registered under GST, vendor shall file all applicable returns under GST Laws in the
stipulated time & any losses of tax credit to MDL arising due to delay in filing will be recovered from their
invoice wherever MDL is eligible to avail tax credit. Any default towards payment of tax and / or uploading
of monthly returns by supplier/contractor, MDL retains right to withhold payments towards tax portion until
the same is corrected & complied by the supplier/contractor with the requirement of GST along with
satisfactory evidence.
IX. The rate sheet enclosed with the tender will indicate the rates to be entered under each head wherever
applicable. Bidders must clearly mention the applicable Taxes & Duties. The item-wise rates quoted in the
Rate Sheet should exclude Taxes & Duties. Bidder should indicate GST rates as applicable separately under
each of the head in the same Rate sheet, which will be paid extra based on tax invoice to the extent
applicable. The GST will be applicable on total basic rate of each item.
15. TERMS OF PAYMENT:
i) 90% payment for the completed work/service on quarterly basis will be made through NEFT/RTGS
within 15 to 20 days on submission of Tax invoice in triplicate to Invoice Receipt Section along with
Work Completion Certificate (SAP Service Entry Sheet copy).
ii) WCC shall be certified by Chief Manager or above of Maintenance department of East Yard.
iii) Set of Original + 3 Copies of signed Tax Invoice to be submitted to Receipt Section along with Service Entry through SAP system from user department. Contractor will be required to submit bills
indicating details of earlier billing in every bill/invoice and also showing cumulative value of work
done, failing which, the invoice will not be accepted / cleared. The invoice should be preferably
submitted within four weeks of certification of Work Completion Certificate ‘WCC’. iv) Balance 10% will be paid on completion of Guarantee period of 12 months for the complete work
based on satisfactory completion report by WCC certifying authority of MDL i.e. Chief Manager or
above rank of Maintenance department of East Yard OR on submission of PBG. v) 10% retained payment of billed work against invoice can be released on submission of PBG of
equivalent value and validity covering the guarantee period of 12 months of certified work in
respective invoice. vi) No advance will be paid in any manner against the Contract.
vii) WCC should confirm that work is completed in time and in case of delay the duration shall be
certified to effect recovery from invoice. (Refer L.D./ Penalty clause 22) viii) WCC shall be issued within 10 days along with SAP entry by user department of MDL on
completion of work progressively. ix) In case of failure to rectify short fall in invoice within 2-3 days, the same shall be returned
x) "Alternate MSME vendor payment through TReDS: “In order to address the financial needs of
MSME firms, GoI has introduced a platform for facilitating the financing of trade receivables of
MSMEs from buyers, through multiple financiers which is termed as Trade Receivables Discounting
System (TReDS). At TReDS, auctioning of invoices at competitive & transparent environment is
done by financers based on Buyer’s credit profile.
MDL is registered on the "Invoicemart" TReDS platform and M1xchange of M/s. Mynd Solutions
Pvt Ltd.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 7 of 29
MSME bidders desirous to receive payments through TReDS platform may avail the facility if they
are already registered on
1."Invoicemart" TReDS platform or by registering on it.
Contact details at "Invoicemart" TReDS platform are as below:
022 6235 7373 and a new mail id [email protected].
2. "M1xchange" TReDS platform or by registering on it.
Contact details at "M1xchange" TReDS platform are as below:
+91 9920455374 MsAshwathi Jayandran email id [email protected]
+91 8839915724 Ms. Prinyaka Shah email id [email protected]
16. SITE VISIT FOR QUOTING: Prior to submission of your quotation, bidders are requested to
visit the site and if any clarification is required bidders may contact Mr. R.K. Gupta, DGM (Maintenance-
EY) on Telephone No 2376 3655 or Mr. Ananda B. Patil, CM (Maintenance- EY) on Telephone No 2376
3656 and submit duly filled Vendor declaration as per format at Enclosure 6 along with the offer.
17. Modifications to the Bids: Bidder will not be allowed to bid after the closing time is over. Bidder
can change the submitted bid any Time till the closing time through e-portal only and the last changed
bid will be considered for ranking of the bids.
18. SECURITY DEPOSIT (SD): The successful bidder (Contractor) shall submit the Security Deposit
@ 5 % of the value of order (excluding Taxes) within 25 days from the date of Order/Contract. Security
deposit on reducing balance can be accepted on completion of services. Reducing balance bank guarantee
towards security deposit is to be submitted by successful bidder where it will be valid for at least one year
with claim period of three months within which the same can be extended for further period by amendment.
18.1 Submission of SD is exempted for Indian PSUs. In lieu, Indemnity Bond in favour of MDL is
required to be submitted (Format of the same would be forwarded with the Order).
18.2 Please note that MDL does not extend any concession such as exemption in payment of Security
Deposit to any organization (Except PSU) irrespective of their status, like registered with MDL,
NSIC, SSI, MSE, etc.
18.3 No interest will be paid on Security Deposit. The security deposit will be returned only after
successful execution of the order and shall be interest free.
18.4 Mode of SD: Security Deposit to be submitted in the form of NEFT / DD/ Pay Order/ Bank Guarantee
drawn in favor of MAZAGON DOCKSHIPBUILDERS LIMITED from the list of banks approved by
SBI/ Canara bank published on MDL website within 25 days from the date of contract. Crossed DD /
Pay Order issued by Cooperative banks however will be accepted subject to realization. In case of
SD-BG, the same shall be valid for one year from the start date of contract plus three months claim
period. Bidders to advise their bank/banker to send SD-BG directly to Outsourcing Department to
dispense with additional step of verification of authenticity of signatories. No change/modification in
the text of the prescribed format of the BG is permissible.
18.5 SD through NEFT- remittance through Bank: In case of online remittance of SD amount, scanned
image of Annexure-VI, duly filled is to be submitted to Outsourcing Department. Further, the bidder
should specifically mention the details of company name as well as nature of remittance, tender
number/order number etc. in the text/narration fields of Bank’s NEFT remittance in order to identify
the same.
18.6 Any delay in submission of SD shall result into charging of interest by MDL on the Contractor @
PLR of SBI + 2 % on the SD amount for the delayed period. Additionally, in case of failure to submit
SD within twenty five (25) days from the date of order placement, the EMD submitted by the
Contractor will be encashed and the Order would be liable for cancellation/termination with the
invocation of Risk Purchase provisions of the Tender/Order. In case of failure to submit revised-
rolling SD within twenty five (25) days from the date of intimation by MDL, the previously submitted
SD by the contractor will be encashed by MDL. Additionally, SD amount could be withheld from the
payable Invoice (s) of the Contractor, if any.
18.7 In case the completion of work is likely to be delayed beyond the Order completion
period/Contractual completion period or this period is required to be extended, the Contractor shall
have to extend the validity of the Bank Guarantee for SD till such extended period. In case of failure
to comply with such extension of the Bank Guarantee for SD by the Contractor, the Bank Guarantee is
liable for encashment by MDL.
18.8 Non-performance of the Terms & conditions of Order and/or default/breach by the Contractor will
result in forfeiture of the SD with application of Risk Purchase provisions.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 8 of 29
19. Guarantee/Warranty: If any item or component was found defective during Preventive / Break
down maintenance, the same has to be replaced by the contractor at actual. If the item is available with
MDL, the same will be issued for fitment of it. Tentative list of spare parts required during contract period
along with Make, Model No. and quantity is attached at ANNEXURE II of Scope of work. Guarantee for
supplied spare parts will be for one year after fitment.
20. Performance Bank Guarantee (PBG): The bidder (Contractor) shall submit PBG of value
equivalent to value of the spare parts and validity covering the guarantee period of the spare parts against
invoice in lieu of 10% payment retention as mentioned at (iv & v) in the payment terms to avail 100%
payment or to release the 10% retained payment against respective invoice.
Performance Bank Guarantee shall be in the form Bank Guarantee (as per Format OTS -F-09) drawn in
favour of MAZAGON DOCK SHIPBUILDERS LIMITED for 10% value of spare parts certified in the
WCC /billed in respective invoice and valid for 12 months guarantee period plus one month claim period.
Bank Guarantee should be drawn on reputed Nationalized / Scheduled Banks excluding co-operative
banks and shall be Payable at Mumbai. On satisfactory completion of performance Guarantee obligation, the PBG will be returned without interest. In case of BG, Bidders to advise their bank/banker to send the BG
directly to OTS department in sealed envelope to dispense with additional step of verification of authenticity
of signatories.
21. Inspection: Inspection will be done by Maintenance Department, East Yard of MDL. Any objection
raised by MDL inspection team against quality of service shall be satisfactorily corrected by the contractor at
his expenses including replacement as may be required.
22. Liquidated Damage (LD) / Penalty: Time is an essence of the contract therefore the service to be provided within the required time as mentioned in the tender. In cases of delay not attributable to MDL
beyond the agreed schedule, following penalties shall be levied for the delay from invoice amount/dues
payable;
a. The contractor shall rectify all minor faults within one day. Delay in defect rectification should not
exceed one day unless & until MDL is fully convinced with proper reasons & justification. Major
breakdowns shall be rectified within three days. If the breakdown requires more than 3 days, then the
contractor & MDL will mutually decide exact time period required for rectification. If the delay exceeds this
mutually agreed period, then penalty will be levied for delayed work on pro-rata basis on the quarterly
maintenance charges subject to maximum of 15 days. For example, if delay is 5 days beyond mutually
agreed period then penalty should be 5/90 times the quarterly maintenance charges of crane. The penalty
amount will be levied from the quarterly bills raised by the contractor.
b. If delivery of spare parts delayed beyond mutually agreed schedule, LD shall be levied @ 0.5% per
week or part thereof for the delayed work subject to maximum of 5 %.
c. In case of delay in attending the preventive maintenance within 15 days, LD shall be levied @ Rs.
500/- per day for delay on pro-rata basis on the quarterly maintenance charges subject to maximum of 15
days.
23. LOADING CRITERIA: Deviations sought by the bidder in respect of Payment terms and delivery
period shall be loaded on the bidder/s quoted prices during price evaluation by MDL as per MDL Norms. It
is desirable that the bidder accepts the Payment Terms indicated by the company in the Tender document.
Varied payment terms quoted by bidders as compared to the terms stated in the Tender document shall be
normalized by loading the Prime Lending Rate of State Bank of India plus 2% on the quoted price.
Note: Online ranking visible to bidders after opening part II price bids is without loading parameters.
However, the L1 bidder will be evaluated offline by applying all applicable loading parameters as mentioned
in the tender document.
24. FREAK LOW QUOTES: In case after opening of price bid of technically cleared firms, it is noted
that L-1 firm has quoted very low rates and indicates to withdraw from the tender then EMD shall be
forfeited and firm may be given tender holiday including intimation to other PSUs. If the rates quoted are
less than MDL estimates by 40% or so and if the difference in rate between L1 and L2 is 30% (w.r.to L1) or
more then the firm will have to give additional BG of 20% of the PO value as additional security. Bank
charges for this additional BG shall be borne by MDL and reimbursed against proof of payment.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 9 of 29
25. HINDRANCE REGISTER: All hindrances with date of occurrences and removal shall be noted in
the Hindrance Register. The Hindrance Register shall be signed by the reps of both MDL as well as
Contractor.
26. Contractors shall not engage employees of other contractors, presently working in MDL and
recorded at Security Department. The contractor can engage such employees if other contractor gives no
objection certificate for such engagement and cancel the name of such desirous employee from his roll and
accordingly convey to the security. The contractor engaging such employee without permission is liable for
penalty including termination of contract. Such penalty can also be imposed if it is observed that supervisors
/ workers deployed by contractors are not on their role as per statement submitted by him at Security.
27. ARBITRATION a) Any unresolved claim, dispute or difference between the parties out of or relating to the construction,
meaning, scope, operation or effect of this contract or the validity or the breach thereof shall be settled by
arbitration in accordance with the provisions of Arbitration and Conciliation Act 1996 by a sole arbitrator
appointed with the mutual consent of both the parties.
b) The Cost of the arbitration, fee of the arbitrator, remuneration of the stenographer and clerk, stamp paper
etc., as shall be decided by the Sole Arbitrator, shall be shared equally by the parties.
c) The seat of the arbitration shall be at Mumbai and the arbitration proceedings shall be conducted in
English Language.
d) The governing laws for the arbitration agreement and the contract shall be the substantive laws of India.
28. The Contractor shall also abide all statutory requirements, Official Secrets Act 1923, Security &
Safety regulations, etc. as per references, which are part of this Tender & also adhere to the health, safety and
environment norms, equipping their personnel with suitable safety gears, Personal Protective Equipments
(PPEs), etc.
29. RISK PURCHASE: If the article / service or any portion thereof be not delivered / performed by
the scheduled delivery date / period, any stoppage or discontinuation of ordered supply / awarded contract
without written consent by Purchaser or not meeting the required quality standards the Purchaser shall be at
liberty, without prejudice to the right of the Purchaser to recover Liquidated Damages / penalty as provided
for in these conditions or to any other remedy for breach of contract, to terminate the contract either wholly
or to the extent of such default. Amounts advanced or part thereof corresponding to the undelivered supply
shall be recoverable from the Contractor / Bidder at the prevailing bank rate of interest.
MDL shall also be at liberty to purchase, manufacture or supply from stock or utilize the services as it deems
fit, other articles of the same or similar description to make good such default and/or in the event of the
contract being terminated, the balance of the articles of the remaining to be delivered there under. Any
excess over the purchase price cost of manufacture or value of any articles supplied from the stock, as the
case may be, over the contract price shall be recoverable from the Bidder / Contractor.
30. PUBLIC GRIEVANCE CELL: A Public Grievance Cell headed by Shri H.V. Karekar,
Executive Director (EY), 4th floor, D1 Building has been set up in the Company. Members of public having
complaints or grievances are advised to contact him on Wednesday between 10.00 hours and 12.30 hours in
his office or send their complaints / grievances to him in writing for redressal. His Telephone No. is 2376
3506 or 2373 8368.
31. WORKING ON MDL HOLIDAYS: Request for permission for working on Saturday / Sunday /
holidays if required, should be submitted 3 working days prior to the date of holiday, to Personnel
department and Security through concerned Department.
32. INSTRUCTIONS TO THE BIDDERS:
Note: Before quoting against this Tender, the prospective bidder is requested to go through the Tender
Enquiry document (& Annexes, if any) thoroughly & carefully. Deviations to the Terms & Conditions of the
Tender are highly discouraged. Therefore, any doubts arising in respect of any of the Terms & Conditions
stipulated, Qualification Criteria, Eligibility for exemption from submission of EMD, clarification if any
w.r.t. Documentation / Procedural requirements, etc. shall get clarified by the prospective bidder through the
Dealing Executive invariably before the submission of the Bid.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 10 of 29
32.1 Submission of bids against e-Tenders: The bidder is required to quote online on the e-Procurement
website (www.eprocuremdl.nic.in) by the deadline, by submitting the Techno-commercial Bid & Price Bid
in Electronic format only. The prices/quotes & a few declarations shall have to be entered/uploaded by the
bidder online in the Tender’s entry forms & other bid documents’ scanned /soft copies shall have to be
uploaded as part of the bid. All bids should be digitally signed using DSC (as explained below).
32.2 To be able to participate in e-Tender (s), every bidder must register themselves on the ASP’s website
(registration is free of cost) & must possess a legally valid Class-IIIB or above Digital Signature Certificate
(DSC) (also known as Class-III B or above DSC with encryption& signing authority) as per IT Act-2000,
using which they can sign their electronic bids. The DSC can be procured from any Certifying Authority
(CA) authorized by Controller of Certifying Authorities (CCA) of Govt. of India.
32.3 National Informatics Centre (NIC) has been appointed by MDL as the Application Service Provider
(ASP).
32.4 In order to familiarize prospective bidders to e-tendering / e-procurements other aspects, etc., regular
orientation training programs {of two (2) hours duration} are being organized at MDL. The interested
bidders are requested to get themselves acquainted with all the requisite aspects & be prepared by attending
the training conducting by the ASP/MDL official(s). The firms may nominate only one representative from
their organization to attend such training. Training shall be conducted every Friday between 2 & 4 PM in
MDL.
32.5 Besides the training being organized, Online User Manual is available on the website for the
guidance of users & for participating in the e-Procurement/ e-Tendering, the bidder must ensure having the
requisite (IT) infrastructure at their office premises.
32.6 In case of any difficulty during online submission of offer on e-procurement portal maintained by
NIC, bidders are requested to contact toll free customer help line no 0120-4200462, 120-4001002 of e-
procurement portal http://eprocuremdl.nic.in
32.7 Bidders in their own interest are requested to upload their bids well in advance of tender closing date
to avoid the last minute difficulties in uploading the bids. Request for extension, if at all to be made, shall be
forwarded at least 3 working days in advance to the tender closing date / time with proper reasoning. MDL
reserves all rights in this regard & decision of MDL shall be binding to the applicant. Problems in
hardware/software, internet connectivity, system configurations, Browser setting etc., for whatsoever reason
shall not be considered for extension of tender closing date and time.
33. MDL will not be responsible for any error in downloading of tender documents from web by the
bidders. The version appearing on MDL website will be considered final and authentic.
34. All bidders are requested to get their technical queries, if any, clarified in advance (3 days in advance
to tender closing date) before bidding to avoid last minute delay. For any technical clarification,
bidders are requested to contact Mr. B. Mohamed Asraff, CM (OTS), Tel. no. 2376 3084.
35. Entry Pass for Contractors and their workmen: Bidders shall comply with the “MDL Security
Procedures laid down in MDL for entry passes in respect of Contractors and their workmen” which
is available in the home page of OUTSOURCING DEPT. of MDL Website www.mazdock.com
Shipbuilding → Outsourcing→ Tenders.
36. Bids received against online participation shall only be accepted. Bids submitted in any other mode
will not be considered.
37. MDL bidder’s earlier quoted for MDL tender on website https://mdl.eprocure.in have to register
again (free of cost) on website https://eprocuremdl.nic.in
38. The contractor has to abide by all statutory requirements and submit the proof when called for. Any
penalty levied on MDL due to contractor’s failure to abide by statutory requirement shall be
recoverable from the contractor.
39. MDL reserves the right to consider placement of Order / Contract in part or in full against the
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 11 of 29
tendered quantity or reject any or all tenders without assigning any reason.
We look forward to receive your most competitive and reasonable offer against this tender.
Yours faithfully,
For MAZAGON DOCK SHIPBUILDERS LIMITED,
CM (OUTSOURCING)
(B. Mohamed Asraff)
022- 2376 3084
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 12 of 29
Enclosures to the Tender
Annexure – “A” Earnest Money Deposit (EMD)/Security Deposit format
Enclosure –1 Scope of Work
Enclosure –2 Illustration of Rate sheet Format
Enclosure –3 Tender Terms & Conditions Acceptance Form
Enclosure –4 General Terms & Conditions Acceptance Form
Enclosure –5 Standard Terms & Conditions Acceptance Form
Enclosure –6 Vendor Declaration
Enclosure –7 RTGS/NEFT Form
References: Terms & Conditions (Available on MDL Website - www.mazdock.com/ →Tenders
→Shipbuilding→ Outsourcing
1) Standard Terms & Conditions (STACS) 2) General Terms and Conditions while executing work 3) Official Secrets Act 1923 (Extract)
Formats: Available on MDL Website- www.mazdock.com/ →Tenders →Shipbuilding→ Outsourcing.
1) OTS -F-05 Format for Bank Guarantee for E.M.D.
2) OTS -F-07 Order acceptances Format
3) OTS -F-08 Format for Bank Guarantee for Security Deposit
4) OTS -F-09 Format for Performance Bank Guarantee
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 13 of 29
Annexure- “A”
MAZAGON DOCK SHIPBUILDERS LTD
DOCKYARD ROAD
MUMBAI 400010
---------------------------------------------------------------------------------------------------------------------------
1. For payment of various remittances online, the following links are available to the vendors/
contractors through MDL website:
a. www.mazagondock.in/onlinepayment.aspx
b. OR one can find online payment tab on MDL website home page as under: -
• Go to www.mazagondock.in
• Click on online payment tab available on home page.
• 4 options viz. Career, tender, security, scrap/disposal will be available.
• Click on the respective tab and make the payment online using debit cards,
credit cards, net banking, BHIM / UIP etc. after filling the required details.
2. DETAILES OF REMITTANCE TO MDL’S BANK ACCOUNT:
(To be filled in by the vendors/firms making remittance of funds in MDL’S Bank Account)
Date of
Remittance Name of Firm Vendor Code MDL
tender/PO. Ref
No.
Nature of
Remittance viz.
EMD/SD etc.
Amount
Remitted
(Rs.)
Signature of Vendor/Representative
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 14 of 29
Enclosure –1
SCOPE OF WORK
1. The Scope of work pertains to Non-Comprehensive Maintenance of 6 Nos. EOT cranes & 3
Nos. Semi goliath cranes installed in various workshops in SSA workshop & EY. The Cranes are
equipped with SCHNEIDER make VVVF Drives, PLC, Remote Control & Encoder: Hubner make.
The Main aim of Maintenance Contract is to ensure smooth functioning of the Cranes all the time
and availability of the spare parts immediately to attend the breakdown, enhancing the performance
of the Cranes and reduction of production loss due to machine downtime.
2. Scope of work mainly comprises of Preventive & Breakdown Maintenance of following
EOT Cranes.
Location and Capacity of EOT Cranes Under Non Comprehensive Maintenance contract.
Sr.
No.
ID No. of Crane Crane Type Capacity Location
1 SSA-1 EOT 30/10 SSA Workshop
2 SSA-2 EOT 30/10 SSA Workshop
3 SSA-3 EOT 30/10 SSA Workshop
4 SSA-4 EOT 30/10 SSA Workshop
5 SSA - 5 Semi Goliath 60/20 SSA Workshop
6 SSA-6 Semi Goliath 150/30 SSA Workshop
7 SSA – 7 Semi Goliath 150/30 SSA Workshop
8 SA-1 EOT 40/5 Workshop ‘A’- EY
9 Stores Complex Central Bay EOT 10/2 Stores Complex Central Bay-
Cradle Assembly Shop.
i) Preventive Maintenance: Firm has to carry out the Preventive Maintenance of each of the Cranes
quarterly as per schedule and Checklist attached at ANNEXURE – I.
The firm shall carry out the maintenance activities to prevent failures and also execute
improvement activities / repair activities to prolong the crane life, reduce maintenance hours and to
ensure maximum availability of the system.
ii) Breakdown Maintenance:
a. Firm has to attend all the breakdowns during the Maintenance Contract. Separate charges for
attending Breakdowns will not be paid. Quarterly payment for preventive and breakdown
maintenance will be paid.
b. Firm has to depute their Engineers/Electricians/Millwright Mechanics/ Fitters during
breakdowns.
c. Breakdown of the Crane will be intimated to the firm by Email / Fax or telephone. Firm has
to respond / attend the call within 8 Hrs during working hours and next day if breakdown
occurs in night / after office hours.
3. Penalty:
a. The contractor shall rectify all minor faults within one day. Delay in defect rectification should
not exceed one day unless & until MDL is fully convinced with proper reasons & justification.
Major breakdowns shall be rectified within three days. If the breakdown requires more than 3 days,
then the contractor & MDL will mutually decide exact time period required for rectification. If the
delay exceeds this mutually agreed period, then penalty will be levied for delayed work on pro-rata
basis on the quarterly maintenance charges subject to maximum of 15 days. For example, if delay is
5 days beyond mutually agreed period then penalty should be 5/90 times the quarterly maintenance
charges of crane. The penalty amount will be levied from the quarterly bills raised by the contractor.
b. If delivery of spare parts delayed beyond mutually agreed schedule, LD shall be levied @ 0.5%
per week or part thereof for the delayed work subject to maximum of 5 %.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 15 of 29
c. In case of delay in attending the preventive maintenance within 15 days, LD shall be levied @
Rs. 500/- per day for delay on pro-rata basis on the quarterly maintenance charges subject to
maximum of 15 days.
4. SPARE PARTS:
a List of spare parts required during Maintenance Contract is attached at ANNEXURE II
b. Firm has to quote separately for spare parts. The rates quoted for spare parts will be fixed for
two years. Guarantee for supplied spare parts will be for one year after fitment.
c. If any item or component was found defective during Preventive / Breakdown maintenance, the same has to be replaced by the contractor at actual. If the item is available with MDL, the
same will be issued for fitment of it.
d. Proper record of services and service reports should be maintained by the firm including
breakdown call, spare parts used / consumed.
e. Necessary permanent entry passes to enter EY, NY, ALY and SY must be made by the
contractor through MDL security dept. and to be renewed as and when necessary.
f. Water, electricity and compressed air will be provided by MDL on free of cost as and when
needed.
5. GENERAL:
a. Firm has to maintain all the records of preventive Maintenance and breakdown repairs, spare parts replaced.
b. Firm should submit all the records of preventive Maintenance, Breakdown Maintenance and replaced spare parts to EY – MTC Department quarterly for work completion certificate for
payment purpose.
c. Firm should depute their manpower (Engineers /Electricians/Fitters/Millwright Mechanics) as standby during load testing and heavy load shifting. Firm will be intimated one-day in advance
regarding this work.
6. Safety Requirements:
a. Contractor should engage only those workers who are qualified and experienced for the work to
be done and for which contract has been awarded.
b. Work should be supervised either by qualified engineer or by qualified authorized supervisor of
the contractor.
c. It is the responsibility of the contractor to ensure safe working of his workers while carrying out
the work and should follow all Statutory Safety provisions and rules. Contractor should provide
and ensure use of full harness Safety Belts, good quality leather Safety Shoes, Safety Helmets as
per IS – 2925, Face Shield, Nose & Mouse Masks, good quality safety Goggles, Ear plugs,
Welding Shields, Hand Gloves, etc. by workers for safe working. The contractor shall take all
safety precautions and follow safety rules prevailing at MDL.
d. Special precautions should be taken while working at height or handling of heavy jobs.
Contractor should ensure that none of his worker works at a height without using safety belts. The
contractor should supervise the work while working at height or handling of Heavy Plants &
Equipment and should intimate in writing to concerned MDL Supervisor / Engineer before
commencement of work.
e. Contractor should ensure that none of his employees work without safety shoes. No work should
be allowed to work inside the MDL premises wearing slippers / chappals.
f. Contractor workers should in no case operate MDL’s E.O.T / Mobile Cranes / Jumbo / Fork Lift
trucks/ and any of the Machine Tools & Equipment’s without permission from MDL executive.
g. The contractor shall be responsible for safety procedures strictly.
h. In case of any Accident causing injury of casualty to any of Contractor’s worker while carrying
out the work, the complete responsibility lies with the Contractor. Contractor should ensure to
provide immediate Medical help to his injured worker / workers and should provide
Compensation as per Workmen Compensation Act 1923 in case of injury or casualty causing out
of accident while on work to his workers.
i. All the employees of the contractor must follow the safety and security procedures of MDL.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 16 of 29
7. PRE-QUALIFICATION CRITERIA:
a. Firm should have past experience in the Drives and PLC. Firm should submit documentary evidence for the same.
b. Firm should have experience of Maintenance / installation of Cranes having minimum Capacity 50 Ton.
8. MOBILISATION:
The successful bidder shall mobilise the required manpower / tools/ materials within 10 working
days from the placement of LOI / Order whichever is earlier.
-----------------------------------------------------------------------------------------------------------------------------------
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 17 of 29
ANNEXURE – I
Checklist for Quarterly Preventive Maintenance
A. ELECTRICAL:
(i) Electrical Panel, Motors:
a. Switch off the Power supply of Control panel of Main Hoist, Auxiliary Hoist, Cross Travel and Long Travel.
b. Clean all the Control panels and junction boxes internally and externally with dry air. c. Tighten all the connections in the entire control panel if needed. d. Clean the filters in the Control panels. e. Check all ACB’S, MCCB’s, MCBs, Switches, Contactors, Relays, Indicating lamps, Push
buttons, joysticks etc. Replace the same if found defective.
f. Check the cooling fans of the control panels. Replace the same if found defective.
g. Clean all the contacts of Master controllers by cleaning agent. h. Check the oil level in the Electro Hydraulic thrusters of MH, AH, CT & LT and fill the oil in
the thrusters if needed. Check the Electromagnetic Brake systems.
i. Check the motor terminals and tighten the connections of the motors if needed. j. Check the winding resistance of the motors.
(ii) VFD Maintenance:
a. Dismantling the drive to repair / service of VFDs. b. Repair / Cleaning of Cards, rectifiers, inverter IGBT’s. c. All power & control connections shall be checked for its tightness. d. Control signals for all cards shall be checked. e. Inspect the DC bus Capacitors for any leakage. f. Reassemble the drive. Inspect all power & Control connections of Drives. Check the system
earthling.
g. Take the Voltage measurement while VFD is in operation. h. Storage of parameters of all VFDS. i. Cleaning of installed PLCs & Storage of Logic Backup. j. Check the healthiness after power ON. k. Inspection of the Emergency Stop circuits.
(iii) Safety Checks:
a. Check the limit switches of Long Travel and Cross-travel for proper functioning. b. Check the Rotary and gravity (Counter weight) limit switches of Main Hoist and Auxiliary
hoist and adjust (reset) the limit switches if needed.
c. Check the anti-collision switches.
(iv) Load Cell:
Calibration, testing and routine checking of load cell for error free performance is in
contractor's scope.
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 18 of 29
B. MECHANICAL:
SL.
NO. TO CHECK TO CHECK REMARKS
1 LONG TRAVEL DRIVE
a) Wheels, pins and bearing Noise, wear, lubrication.
b) L.T. shaft, couplings, bearing
Plummer blocks.
Trueness, wear, noise
alignment, breakage.
Lubrication
c) Drive wheels and Pinion
wheels.
Wear pitting burrs.
d) Gear box & couplings Backlash, teeth breakage
alignment , oil leakage, oil level
and refill the gearbox oil .
e) L.T. brake system Liner wear, clearance slackness
in joints, pins bolts, nuts.
f) L.T. thruster Oil level for proper operation.
g) Long travel limit Switch For operation.
2. CROSS TRAVEL DRIVE
a) Cross trolley wheels, pins
and bearings
Wear, noise, lubrication
b) Cross trolley shaft, coupling
bearing, keys
Trueness, wear, alignment and
Leakage, lubrication
c) Cross trolley drive gearbox
couplings
Backlash, breakage, alignment
And oil leakage
d) Cross travel brake system Liner wear, clearance slackness
on bolts, joints nuts
e) C.T. thruster Oil level for proper operation.
f) Cross travel limit switch For operation
3. MAIN HOIST DRIVE
a) Main hoist gear boxes ,
couplings, bearings, and keys
Backlash, alignment, wears
noise, lubricating oil
b) Main hoist rope drum and
bearings
Wear, alignment and noise
c) Main hoist hook pulleys
assembly
Freeness, wire grip, bearing
wear and noise and lubrication
d) Main hoist brake system Liner wears, clearance
slackness on joints, bolts, nuts
e) M.H. Thruster Oil level for proper operation
f) Main hoist wire rope Strand breakage anchoring and
lubrication
g) Main hoist limit switch For operation
4. AUXILIARY HOIST DRIVE
a) Auxiliary hoist gearbox
couplings, keys
Backlash, alignment wear,
noise, Lubrication oil
b) Auxiliary hoist drum Wear and alignment
c) Auxiliary hoist hook pulleys
assembly
Freeness, wire grips bearing
wear and lubrication
d) Auxiliary hoist wire rope Strand breakage anchoring and
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 19 of 29
SL.
NO. TO CHECK TO CHECK REMARKS
lubrication
e) Auxiliary hoist brake system Liner wears clearance
slackness on joint, bolts, nuts
f) A.H. thruster Oil level for proper operation
g) Auxiliary hoist limit switch For operation
5. STRUCTURE
a) Girder structure For twist, proper tightness of
bolts, welded joints for
soundness
b) Rail Clamping bolts for tightness,
alignment, wear
c) Main & Aux, Hoists Wire
ropes
Check and Lubricate wire
ropes whenever required
d) Lubrication System Check and refill the grease in
the centralised lubrication
systems whenever necessary,
leakage prevention
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 20 of 29
ANNEXURE – II
LIST OF SPARES
Sr.
No. Part Description Make Model No.
1 VFD Schneider Altivar 71, 15 Kw , Model -8EB71HD15N4
2 Contactor Siemens 3TH30/22E, Coil 110 Volts
3 Contactor Siemens 3RT1023-xA-1, Coil 110 Volts
4 Over Load Relay Siemens UVX 1420, 12.5 A to 20 Amp.
5 VFD Schneider Altivar 71, 75 Kw, Model - ATV71 HD75N4
6 MCCB Siemens VL250, 200 Amp
7 Contactor Siemens 3TR1034.1A
8 Contactor Siemens 3TR1023.1A
9 VFD Schneider Altivar 71, 45 Kw, Model - ATV71HU40N4
10 MCCB Siemens 125 Amp, VL 160 X
11 VFD Schneider
Altivar 71 , 4Kw /5 HP, Model No. -
ATVT1HU40N4
12 Contactor Siemens 3TR 1023, coil 110 Volts
13 Regenerative Unit Schneider VW3A7201
14 Contactor Siemens 3TR1056.6…..6 , 115 Amp, Coil 110 Volts
15 Contactor Siemens 3TF32 , Coil 110 Volts
16
Single Phase
Preventor Minillec VSP-3
17 Contactor Siemens 3RT1035.6….6, 330 Amp, Coil 110 Volts
18 Contactor Siemens 3TF30, Coil 110 Volts
19 VFD Schneider
Altivar 71, 7.5 Kw / 10 HP, Model -
ATV71HD45N4
20 VFD Schneider Altivar 71, 45 KW, Model -ATV71HD45N4
21 Regenerative Unit Schneider VW3A7208
22 Contactor Siemens 3TF34, Coil 110 Volts
23 VFD Schneider
Altivar 71, 110Kw/150 HP, Model -
ATV71HC11N4
24 MCCB Siemens 3VT2, 250 Amp
25 Contactor Siemens 3TF30/10 E, Coil 110 Volts
26 VFD Schneider ATV71HC11N4
27 VFD Schneider
Altivar 71, 22 Kw/30 HP, Model -
ATV71HD22N4
28 Regenerative Unit Schneider Altivar VW3A7202
29 VFD Schneider Altivar 71, 15 Kw, Model - ATV71HD15N4
30 VFD Schneider Altivar 71, 45 Kw, Model - ATV71HD45N4
31 VFD Schneider
Altivar 71, 5.5Kw/7.5 HP, Model -
ATV71HU5.5N4
32 Contactor Siemens 3RT064.6….6, Coil 110 Volts
33 VFD Schneider Altivar 71, 15 Kw, Model VX5A1HD15N4
34 Contactor Siemens 3TR1023.1 A
35 VFD Schneider Altivar 71, 4Kw, Model VX5A1HU75N4
36 Contactor Siemens 3RT1056.6…..6, 215 Amp, Coil 110 Volts
37 Regenerative Unit Schneider VW3A7207
38 VFD Schneider 11 Kw, Model - ATV71HD11N4A
39 VFD Schneider 7.5 Kw, Model - ATV71HU55N4A
MDL Tender 6000001275 dated 17.02.2020 for NC-Maintenance of EOT & Semi Goliath Cranes
Page 21 of 29
40 VFD Schneider 1.5 Kw, Model - ATV312HU15N4
41 VFD Schneider 3 Kw, Model - ATV312HU30N4
42 MCCB Schneider 250/36KA, Model - LV525341N
43 Contactor Schneider 250 A, 3 pole , Model - LC1F265
44 VFD Schneider 125 HP/90 Kw, Model - ATV71 HD 90N4
45 VFD Schneider 50 Hp/37 Kw, Model - ATV71HD37N4
46 VFD Schn