Upload
duongcong
View
216
Download
2
Embed Size (px)
Citation preview
AN ISO 9001 &14001COMPANY
TENDER DOCUMENT
TENDER No: DLI/CON/686A/625
FOR
Construction of G+7 RCC Framed Structure tenements blocks with Bus bar
rooms including internal water supply, sanitary, electrifications works in
Chennai near Perumbakkam Phase- II -Reach-II-Balance work.
VOLUME – II
Additional Conditions of Contract
& Special Specifications
&
Drawings
Signature ofwithseal 1 EPI
ADDITIONAL CONDITIONS OF CONTRACT (ACC)
The following Additional Conditions of Contract shall be read in conjunction with
General Conditions of Contract. If there are any provisions in these Additional
Conditions of Contract, which are at variance with the provisions of General
Conditions of Contract, the provisions in these Additional Conditions of Contract
shall take precedence.
1.0 Introduction:
Construction of G+7 RCC Framed Structure tenements blocks with Bus bar rooms including internal water supply, sanitary, electrifications works in Chennai near Perumbakkam Phase- II -Reach-II-Balance work. M/s TNSCB is the client and have appointed a PMC to supervise the works.
2.0 Order of Precedence: Clause 42.1 of GCC stands amended as under:
In case of difference, contradiction, discrepancy, dispute with regard to Conditions of Contract, Specifications, Drawings, Bill of Quantities and Rates quoted by the Contractor and other documents forming part of the contract, the following shall prevail in order of precedence
2.1 Contract Agreement which includes NIT, Special Instructions to Tenderer /Bidder,
Memorandum.
2.2 Letter of Intent, detailed letter of Work Order along with statement of agreed variations and its enclosures.
2.3 Description in Bill of Quantity / Schedule of Quantities
2.4 Additional Conditions of Contract.
2.5 Special Specification as given in the Tender Documents.
2.6 General Conditions of Contract.
2.7 Drawings
2.8 TN PWD/ Highways Department specifications, TNDSS and MDSS
The item description mentioned in BOQ attached to this tender are generally based on items which are a part of Agreement No: L S Agreement C.R No.10/SE(J)/2011-12 dtd 28.03.2012,L S Agreement C.R No.43/SE(JNURM)/2013-14 dtd 31.10.2013 and L S Agreement C.R No.69/SE(CC-II)/2015-16 dtd 03.03.2016 between Engineering Projects (India) Ltd and Client M/s Tamil Nadu Slum Clearance Board based on Tamil Nadu Schedule Of Rates. If incase of any discrepancy between BOQ and afore mentioned agreement description, Description given in aforesaid agreement with TNSCB shall prevail.
3.0 Scope of work:
The project site for the work is available. The works have been started and are in various stages/Level of progress and the details of works completed and stage of progress are as follows:
Signature ofwithseal 2 EPI
3.1 Structural Works:
Construction of multi-storied buildings G+7 R.C.C framed structure including civil,
plumbing etc.
Sl No.
Description Level of work completed/ stage
1. Block No.11 2nd
Floor Roof Slab
2. Block No.12 3rd
Floor Roof Slab
3. Block No.13 7th
Floor Roof Slab
4. Block No.14 3rd
Floor Roof Slab
5. Block No.15 3rd
Floor Roof Slab
6. Block No.16 7th
Floor Roof Slab
7. Block No.19 5th
Floor Roof Slab
8. Block No.20 7th
Floor Roof Slab
3.2 Finishing Works: The total scope of finishing works includes the Brick work, Plastering, Flooring, Door and Window fixtures, Plumbing, Painting, Firefighting etc for 14 blocks ( including 8 blocks mentioned above) where RCC structural works are completed / advanced stages of completion.
3.3 Electrical Works:
The scope of Electrical Work does not include Supply, Installation, Testing and Commissioning of Main Incomer Panels for the above 14 blocks, however minor electrical works for development works and Miscellaneous work mentioned below as per BOQ are included.
3.4 Development and MiscellaneousWorks: Apart from above Buildings/Blocks, scope of work also consists:
3.4.1 Filling of Low Lying areas
3.4.2 Formation of Road
3.4.3 Pavement around the Blocks 3.4.4 Construction of Nursery School (1Nos)
3.4.5 SFRC around the Park area 3.4.6 Providing Fire Fighting arrangement for Blocks
4.0 Tender Rates
The work is to be quoted on percentage rate above, below or at par basis on the estimated bill of quantities and tender conditions.
5.0 Completion Time The entire work shall be completed within 06 (Six) months from the date of issue of
LOI. The time of completion is firm and final and supersedes any other time
mentioned elsewhere in any clause(s) of tender document.
6.0 Quantity Variation: Deviation limit shall apply to individual items (as per GCC Clause No: 69.1 – V a))
+/- 25 % is modified to +/- 100%. 7.0 Defect Liability Period:
Defect Liability Period as per GCC Clause No: 74.0 stands modified as Twenty Four Months (24 Months) instead of twelve months (12 months).In addition, the contractor should furnish an Indemnity Bond for his scope of work for a further period of three years after completion of Defect liability period. Format of Indemnity bond enclosed as Annexure-1 in Special specifications.
Signature ofwithseal 3 EP
8.0 Disqualification:
The tenderers may note that they are liable to be disqualified and not considered for the opening of Price Bid if;
8.1 Representation in the forms, statements and attachments submitted in the pre-
qualification document are proved to be incorrect, false and misleading. 8.2 They have record of poor performance during the past 10(ten)years such as
abandoning the work, rescinding of contract for which the reasons are attributable to the non-performance of the, inordinate delay in completion, consistent history of litigation / arbitration awarded against the or any of its constituents or financial failures due to bankruptcy etc. in their ongoing / past projects.
8.3 They have submitted incompletely filled in formats without attaching certified supporting documents and credentials to establish their eligibility to participate in the Tender.
8.4 If the tenderers attempt to influence any member of the selection committee.
8.5 EPI reserves its right to take appropriate action including disqualification of tenderer(s) as may be deemed fit and proper by EPI at any time without giving any notice to the in this regard. The decision of EPI in the matter of disqualification shall be final and binding on the Tenderers.
9.0 Specifications:
All works in general are to be carried out in accordance with the relevant Tamil Nadu PWD Specifications, high ways department, Tamil Nadu Detailed Standard Specification (TNDSS), Madras Detailed Standard Specification (MDSS), Indian standard Specifications and as per the special specifications separately attached with this tender.
10.0 Taxes&Duties:Clauseno13ofGCCshallbeamended/deleted as per below:
10.1 The bidder/Contractor must be registered with GST and should have valid GSTIN number.
10.2 The bidder/contractor must submit as an compliances of GST Act, the invoices in GST compliant format failing which the GST amount shall be recovered/ adjusted by EPI without any prior notice from the next invoices or available dues with EPI.
10.3 The bidders/Contractors are requested to update/upload the GST/Taxes data periodically so as to avail ITC credit by EPI failing which it shall be recovered/ adjusted by EPI without any prior notice from the next invoices or available dues with EPI.
10.4 Rates quoted in this tender are inclusive of all taxes, levies, cess, duties etc.
including GST.
10.5 Bidder while quoting the rates in the tender must also consider the ITC credit applicable for the works, if any.
11.0 Price Escalation/Adjustment:
Clause 16.0 of GCC stands good. Prices shall remain firm and fixed for the entire duration of the contract. No escalation on prices whatsoever shall be admissible.
Signature ofwithseal 4 EPI
12.0 Mobilization Advance: Clause no .8.0 of General Conditions of Contract (GCC) stands deleted.
13.0 Security Deposit cum Performance Guarantee: Clause 9.0 of GCC shall be
amended as below: “Security Deposit cum Performance Bank Guarantee in the form appended, from any Nationalised bank / Scheduled Bank equivalent to 1.5 % (One point five percent only) of the Contract Value for the due and proper execution of the contract This bank guarantee shall remain valid up to 90 (ninety) days after the end of defects liability period”.
14.0 RETENTION MONEY - Clause no. 10.0 of GCC shall be modified asunder:
“The Retention Money shall be deducted from each running bill of the Contractor at 5% (five percent only) of the gross value of the Running Account bill. The Retention Money shall be refunded to the Contractor after expiry of defects liability period (referred to in Clause No.7 of ACC) or on payment of the amount of the final bill whichever is later.”
15.0 Secured Advance: No Secured advance shall be paid to the contractor hence Clause no. 35.0 of General Conditions of Contract (GCC) stands deleted.
16.0 Water & Electricity: In addition to clause No: 44.0 of GCC, the required water and electricity to be arranged by the tenderer only. If in case avails the existing electric supply at site, arranged by EPI recovery of the same shall be made as per actuals including maintenance.
17.0 Compulsory Site Visit: Bidders are advised to mandatorily visit the site, make their
assessment on all works already executed and satisfy himself prior to submission of bid. Bidders are instructed to obtain certificate of Site visit from the Engineer-in-Charge (EPI) / EPI Site Engineer as a proof of site visit and submit the same along with the Technical Bid compulsorily.
18.0 Handing Over Of Site To Contractor After Joint Measurement: As the works are
in various stages of completion, joint measurements are to taken along with EPI representative before start of Work; CONTRACTOR shall depute authorized engineer and all necessary manpower to take the joint measurement of incomplete works like reinforcement steel works/ Steel dowels, RCC Works including columns levels, slab executed, brick work executed, and electrical conducting works etc. as per site conditions. The joint measurement activity is part of the scope of work. Since time is of the essence CONTRACTOR has to deploy sufficient number of labour and engineers to complete the joint measurements for his scope of work within 10 days commencement of work.
19.0 Structural Safety and Stability: It shall be the responsibility of the successful bidder to undertake their own studies on soil testing and structural design before actual commencement of works. These studies should be duly certified by reputed institutions like IIT / Anna University/NIT. Any lapse in future, due to failure on account of structural design shall be total responsibility of the contractor in terms of Monetary value or otherwise. The contractor is to take full responsibility of the structural safety and stability of the entire structure including the works executed earlier including the structural designs and any damages to physical properties due to structural failure or
Signature ofwithseal 5 EP
soil failure before handing over to the Superintending Engineer (JNURM) shall be solely attributable to the contractor.
In line with above, upon commencement of work contractor shall satisfy himself of the structural safety and stability of the for the structural works completed prior to taking over by contractor and shall submit certificate of structural stability from aforementioned reputed institutions at his own cost, which is to be furnished by contractor at the earliest along with their acknowledgement and acceptance of Stability of the structure. Further after completion of works, structural stability certificate for the completed structure shall be submitted as required by client before handing over to client M/s TNSCB.
20.0 Requirement of Technical Staff for the work:
In addition to Clause 27.0 of GCC, the following minimum Technical staff to be deployed/ engaged for the contract:
Requirement of Technical Staff / Qualification
Minimum Nos Required
Minimum Experience ( Years)
Rate of Recovery in Case of Non- Compliance
Project Manager with degree 01 10 years Rs. 60000/- p.m
Planning/Quality Control Engineer
Degree BE Civil
01 05 years Rs. 40,000/- p.m
Site Engineers with Degree (B.E Civil) 03 03 years Rs. 25,000/- p.m
Junior Engineer /Site supervisor ( Diploma- civil)
05 02 years Rs 20,000/- p.m
Junior Engineer /Site supervisor ( Diploma/ITI- Electrical)
01 02 years Rs 20,000/- p.m
Safety officer 01 03 years Rs. 25,000/- p.m
21.0 FACILITIES TO BE PROVIDED BY CONTRACTORTOEPI
Immediately on placement of LOI/Work order (whichever is earlier) by EPI on the
CONTRACTOR, the CONTRACTOR at his own cost shall provide furnished office,
facilities etc. exclusively for the use of personnel of EPI as per details given below.
The CONTRACT OR shall make his rates/prices in his offer sufficiently
comprehensive to cover the cost of the facilities as per details shown below and the
CONTRACTOR shall not be entitled for any extra payment for the same:
DESCRIPTION QUANTITY
A) OFFICE ACCOMMODATION
Fully furnished site office having a sample room, AC meeting room/
staff room along with toilet, pantry with file storage facility with basic
amenities like drinking water arrangement, lights fans etc. for
exclusive use of EPI‟s/clients ‟ Engineers & Staff and maintenance
of the same till Defect Liability Period. The Specifications and
Design of accommodation shall be as approved by EPI.
1500Sq.ft
B) FURNITURE OF TOTAL VALUE Rs. 1.00 lacs
C) OFFICE EQUIPMENT a) Fax Machine 1 Nos.
Signature ofwithseal 6 EPI
DESCRIPTION QUANTITY
b) Computer (Windows 10 and above) with minimum 1TB HDD, i5
processor (minimum) along with UPS and Latest version of
Software like MS Project, Windows, MS Office etc. and 2 lap
tops with similar configuration
3 Nos.
c)1 laser/inkjet color printer A4 size 2 Nos.
d) Internet Facilities(broad band) 1Nos.
e) Refrigerator (165 Itr.) or any other gadget of equivalent cost as
decided by EPI
1Nos.
f) Air Conditioner with cooling (1.5 Ton Capacity) 1 Nos.
g) Aqua Guard (Drinking Water) or any other gadget of equivalent cost
as decided by EPI
1 Nos.
h)Multi-Function Printer (A3) Size 1 Nos.
D) CONSUMABLES
a) All consumables like Stationary, ink etc. shall be provided by
contractor till end of defect liability period.(Stationary items are
inclusive of visiting cards, rubber-stamps, letter pads, photocopies,
photocopy papers & other items of daily office use).Amount shall
be restricted to:
Rs.4000/ per month
b) Running & maintenance of the equipment mentioned above are
to be done by the PARTY at his cost.
As per Actual
E) TELEPHONE WITH STD FACILITY ANDINSTRUMENT
a) Office Telephone (Fixed Line):
b)Mobile Phone :
Monthly operational expenditure on account of all telephones shall
be restricted to.(The cost of each Mobile Phone Instrument shall
be restricted toRs.6,000/-)
1 Nos. 1 Nos.
Rs. 3000 per month
F) OFFICE BOY CUM COOK on Full time basis for EPI 1 No
G) VEHICLE (Brand New) New Four wheel drive Scorpio DX
vehicle or equivalent with Driver and accessories valuing
Rs.45,000/- Monthly running shall be restricted to 4000KMS
1 Nos
The CONTRACTOR shall provide „Sign Board(s) ‟ as per design approved by EPI and/ or Client, as per format mentioned in Annexure-1
In case the above facilities are not provided by the CONTRACTOR within
10(ten)days of award of work or replacement is not provided within the specified
period, EPI shall arrange the same at the risk and cost of the CONTRACTOR and
make the recoveries from the bills of the CONTRACTOR for the same. The decision
of EPI shall be final binding on the CONTRACTOR in this regard.
22.0 Insurance: WCP and CAR Policy for his scope of work is the responsibility of the
CONTRACTOR. EPI has already taken the policies and the expenditure so incurred by EPI shall be recovered on prorate basis.
Signature ofwithseal 7 EPI
23.0 Arbitration: Modification of arbitration’s clause no 76.0 of GCC
General Conditions of Contract (GCC) Sub Clause no.76.1 and 76.3 of Arbitration
Clause no.76.0 are amended as given below. Sub Clause no.76.2 will remain the
same.
76.0 ARBITRATION
76.1 Before resorting to arbitration as per the clause given below, the parties if they so
agree may explore the possibility of conciliation as per the provisions of Part III of the
Arbitration and Conciliation Act, 1996 as amended by Arbitration and Conciliation
(Amendment) Act, 2015. When such conciliation has failed, the parties shall adopt the
following procedure for arbitration:
i) Except where otherwise provided for in the contract, any disputes and differences
relating to the meaning of the Specifications, Design, Drawing and Instructions herein
before mentioned and as to the quality of workmanship or materials used in the work
or as to any other questions, claim, right, matter or things whatsoever in any way
arising out of or relating to the Contract, Designs, Drawings, Specifications, Estimates,
Instructions, or these conditions or otherwise concerning the works of the execution or
failure to execute the same whether arising during the progress of the work or after the
completion or abandonment thereof shall be referred to the Sole Arbitrator appointed
by the Chairman & Managing Director (CMD) of Engineering Projects (India) Limited
(EPI) or any other person discharging the functions of CMD of EPI. The person
approached for appointment as Arbitrator shall disclose in writing circumstances, in
terms of Sub-Section (1) of Section (12) of the Arbitration and Conciliation Act, 1996
as amended by Arbitration and Conciliation (Amendment) Act, 2015 as follows:
a) such as the existence either direct or indirect, of any past or present relationship with or
interest in any of the parties or in relation to the subject-matter in dispute, whether
financial, business, professional or other kind, which is likely to give rise to justifiable
doubts as to his independence or impartiality ;and
b) which are likely to affect his ability to devote sufficient time to the arbitration and in
particular his ability to complete the entire arbitration within a period of twelvemonths.
The Arbitrator shall be appointed within 30 days of the receipt of letter of invocation of arbitration duly satisfying the requirements of this clause.
ii) If the arbitrator so appointed resigns or is unable or unwilling to act due to any reason
whatsoever, or dies, the Chairman & Managing Director aforesaid or in his absence the
person discharging the duties of the CMD of EPI may appoint a new arbitrator in
accordance with these terms and conditions of the contract, to act in his place and the
new arbitrator so appointed may proceed from the stage at which it was left by his
predecessor.
iii) It is a term of the contract that the party invoking the arbitration shall specify the
dispute/ differences or questions to be referred to the Arbitrator under this clause
together with the amounts claimed in respect of each dispute.
Signature ofwithseal 8 EPI
iv) The Arbitrator may proceed with the arbitration ex-parte, if either party, in spite of a
notice from the arbitrator, fails to take part in the proceedings.
v) The work under the contract shall continue as directed by the Engineer-In-Charge,
during the arbitration proceedings.
vi) Unless otherwise agreed, the venue of arbitration proceedings shall be at the venue
given in the “Memorandum” to the “Form of Tender”.
vii) The award of the Arbitrator shall be final, conclusive and binding on both the parties.
viii) Subject to the aforesaid, the provisions of the Arbitration and Conciliation Act, 1996 as
amended by Arbitration and Conciliation (Amendment) Act, 2015 or any statutory
modifications or re-enactment thereof and the Rules made there under and for the time
being in force shall apply to the arbitration proceedings and Arbitrator shall publish his
Award accordingly.
76.3 JURISDICTION:
The courts in Chennai alone will have jurisdiction to deal with matters arising from the
contract.
.
Signature ofwithseal 9 EPI
Special Specifications & Drawings
Index
SL No. Description Printed Page Nos
A Special Specifications 1‐23
B Annexures
B.1 Annexure number 1 (Indemnity Bond‐TNSCB) 1‐2
B.2 Annexure number 2 (INTEGRITYPACT) 3‐9
C Drawings
C.1 General Layout 1
C.2 Typical Slab Layout 2
C.3 Staircase drawings 3‐4
C.4 Brickwork Layout (Typical) 5
Annexure Number - 1
PROFORMA FOR INDEMNITY BOND
This deed of indemnity bond executed at Chennai (Place) on this..............day of
(month) 2018 (year) by and between
Thiru.____________________________________________________________________________
___________________________________________________________________ (full address)
(hereinafter called “Contractor” which expression unless excluded by or repugnant to the context
include his/her heirs, executors, administrators and legal representatives) to and in favour of the
TNSCB (hereinafter called “the Tamil Nadu Slum Clearance Board” which expression shall unless
excluded by or repayment to the context include his successor and assigns) represented by the
Executive Engineer of Chennai special Division-II Chemancherry (place) shows as follows:.
Contd.......
B. Annexures
1 of 9 Part of Vol- 2
2) Whereas the contractor has submitted the tender for Repairs to the 1116 slum
tenements at perumbakam Phase-II scheme in Kanchepuram District,Chennai under NNURM
Reach-V 2013-14 Vide CR No.11/SE (JNNURM)/2011-12 (place of work supply, and such
tender has been accepted subject to the General Conditions to Contract appended to TNDSS and other
conditions issued along with tender documents.
3) And where as in pursuance of the terms of contract as per the Agt.No. L S Agreement
C.R No.11/SE(J)/2011-12 Date:28.03.2012.that a sum equal to 5% of the total value of work done, has
been retained with the Board for a period of 2 years reckoned from the date of completion of the
work in order to enable the departmental officers to watch the effect of all seasons on the work and
the structural stability of the work executed by the contractor.
4) And whereas it was decided to refund the said sum equal to 5% of the total value of
the work done retained with the Board on the expiry of two years period reckoned from the date of
completion of work provided that the contractor executes an indemnity bond for a period of further
three years indemnifying the TNSCB against any loss or expenditure incurred to rectify any defect
noticed due to the faulty workmanship by the contractor or substandard materials used by the
contractor during the period of 5 years from the date of completion of the work.
5) Now, this deed of indemnity witnessth-that in consideration of the contract entrusted
to the contractor by the Board, the contractor has agreed to the following terms and conditions and
executed this indemnity bond in conformation of all and undertakes to comply with the terms referred
to infra.
6) The contractor doth hereby indemnity the TNSCB against any loss or damage that may
be caused to the TNSCB in respect of rectification and defect noticed due to the faulty workmanship,
by the contractor, or substandard materials used by the contractor in the execution of work entrusted
to the contractor during the period of three years i.e. from 28.03.2017 up to 27.03.2020 (dates to be
specified).
7) It is hereby confirmed that in all other respects, the agreement conditions will be
binding between the parties.
In witness where of Thiru._______________________ has signed this deed on this day
............. of month __________ years 201_
Witness Signature of Contractor
1.______________
2._______________
B. Annexures
2 of 9 Part of Vol- 2
(OL
D M
AH
AB
AL
IPU
RA
M R
OA
D)
Raj
iv G
andh
i (6
1.0
m W
ide)
Roa
d
8.0 m ROAD WIDENING
10.0 m EXISTING ROAD
TO
CH
EN
NA
IT
O M
AH
AB
AL
IPU
RA
M
PROPOSED 18.0M ROAD
9.0 m ROAD
7.5 cm height dwarfwall @ entrance
7.2 M ROAD
7.2 M ROAD
7.2
M R
OA
D
N.S- 3686 sq.m
R.S-4144sq.m
PARK-9
951 sq.m
7.2
M R
OA
D
M.B-353 sq.m
C.S
-46
8 s
q.m
TENTATIVE LAYOUT FOR PROPOSED CONSTRUCTION OF TENEMENTS AT PERUMBAKKAM
49.4
201
.2
201.2
60.4
7.2 m ROAD
7.2 m ROAD
7.2 m ROAD
7.2 m ROAD
COMMERCIAL-3
6951 sq.m
PARK-1925 sq.m
CO
MM
ER
CIA
L-4
693 s
q.m
C.P.S-2 246 sq.m
7.2 m ROAD
7.2
m R
OA
D
7.2 m ROAD
7.2 m ROAD
7.2
m R
OA
D
7.2 m ROAD
7.2 m ROAD
7.2
m R
OA
D
7.2 m ROAD
7.2 m ROAD
7.2
m R
OA
D
7.2 m ROAD
7.2 m ROAD
7.2
m R
OA
D
7.2 m ROAD
7.2 m ROAD
7.2
m R
OA
D
7.2 m ROAD
18.0
m R
OA
D
18.0 m ROAD
7.2 m ROAD
7.2 m ROAD
COMMERCIAL-27028 sq.m
CP
S-5
193 s
q.m
CP
S-6
115 s
q.m
PARK -3745 sq.m
9
20
21
RAIN WATERHARVESTING TRENCHOF SIZE 1m x 1.5mALONG THE BOUNDARY
545
9.1
5 m
RO
AD
9.1
5 m
RO
AD
9.1
5 m
RO
AD
9.1
5 m
RO
AD
9.15 m ROAD
9.15 m ROAD
RAIN WATERHARVESTING TRENCHOF SIZE 1m x 1.5mALONG THE BOUNDARY
PR
OP
OS
ED
PW
D D
RA
IN 1
.94 H
EC
T
PR
OP
OS
ED
18.0
M R
OA
D
12.0
m R
OA
D12.0
m R
OA
D
(OL
D M
AH
AB
AL
IPU
RA
M R
OA
D)
Raj
iv G
andh
i (6
1.0
m W
ide)
Roa
d
8.0 m ROAD WIDENING
10.0 m EXISTING ROAD
TO
CH
EN
NA
IT
O M
AH
AB
AL
IPU
RA
M
PROPOSED 18.0M ROAD
C.P.S-1246 sq.m
7.2
m R
OA
D7.2
m R
OA
D
7.2
m R
OA
D
D
D
D
F
7.2 m ROAD 7.2 m ROAD
7.2
m R
OA
D
D
S
S
F
F
DSF
D
S
S
F
F
DSF
F
FS
9.15 m ROAD
7.2 m ROAD
7.2 m ROAD
7.2 m ROAD
7.2 m ROAD
7.2
m R
OA
D
7.2
m R
OA
D
EXG. TNSCB SCHEMEAT SEMMANCHERI
S.No. 441
Forest Land
S.No. 442
S.No. 442
Arasangalani village
PR
OP
OS
ED
PW
D D
RA
IN 4
0M
WID
E
REFERENCE:
ADOPTED T.D. NO. 7 / 2008.NO. OF FLOORS - (G + 7) FLOORS.PLINTH AREA / UNIT - 36.22 sq.m.TOTAL NO. OF BLOCKS - 11 Nos.[186 IN 1 / BLOCK]NO. OF UNITS - 2046 Nos.
ADOPTED T.D. NO. 9 / 2008.NO. OF FLOORS - (G + 7) FLOORS.PLINTH AREA / UNIT - 28.74 sq.m.TOTAL NO. OF BLOCKS - 21Nos.[186 IN 1 / BLOCK]NO. OF UNITS - 3906 Nos.
ADOPTED T.D. NO. 7A / 2008.NO. OF FLOORS - (G + 7) FLOORS.PLINTH AREA / UNIT - 36.22 sq.m.TOTAL NO. OF BLOCKS - 158 Nos.[94 IN 1 / BLOCK]NO. OF UNITS - 14852 Nos.
ADOPTED T.D. NO. 4 / 2012.NO. OF FLOORS - (G + 3) FLOORS.PLINTH AREA / UNIT - 36.53 sq.m.TOTAL NO. OF BLOCKS - 2 Nos.[32 IN 1 / BLOCK]NO. OF UNITS - 64 Nos.
TOTAL NO. OF UNITS : 20868 Nos.
SPACE FOR
SUMP 861 sq.m
PARK -21084 sq.m
C.S-1125 sq.m R.S-2
1 44 sq.m
N.S-1686 sq.m
PARK - 51430 sq.m
PARK -41710 sq.m
N.S-2768 sq.m
PARK- 6736 sq.m
MB
-13
9 s
q.m C.S-2
187 sq.m
PARK -82150 sq.m
R.S-3
1 44 sq.m
PARK -7999 sq.m
MB-239 sq.mC.S-3
161 sq.m
CP
S-4
19
4 s
q.m
SF D
D
SS
D
F F
GYM -18 4 sq.m
D
S
S
S F
D S F
CP
S-7
75 s
q.m
F
D S F
D S F
DSF
DSF
SS
D
F
S
D
F
S
D S F
D S F
DS F
S FD
DSF
DSF
SS
D
F
F
DD
S
S
DF
S
G.B
-11
9 s
q.m
1
2
3
4
5
6
7
8
1011
12
13
14
15
16
17
18
19
R.S
-11
44
sq.m
S
CPS-3
176 s
q.m
1
2
3
4
5
6
8
7
9
10
11
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R
R RR R
R R
R R
COLLEGE
20747.4 Sq.m
BUS TERMINUS20234.8 Sq.m
HOSPITAL
21251.5 Sq.m
SPORTS
DEVELOPMENT6554.7 Sq.m
SW
M -
LA
ND
FIL
L
7665.6
Sq.m
T.N.E.B
4000.0 Sq.m
CO
MM
ER
CIA
L-1
2073
.6 S
q.m
TNSCBBUILDING CENTRE
9425.1Sq.m
PARK-1115409.1 Sq.m
EXCHANGE LAND FOR
CALL EXPRESS INDIA23225.0 Sq.m
R.S
-51
44
sq.m
M.B
-48
8sq
.m
A.W-1465.3Sq.m
C.SHOP-5298.2 Sq.m
GR
EEN
BEL
T-3
1067
.1 S
q.m
HIGHERSECONDARY
SCHOOL4029.9 Sq.m
PRIMARYSCHOOL-1
3058.1Sq.m
A.W
593.2
Sq
.m
V.T
.C5
30.6
Sq
.m
HIGHERSECONDARY
SCHOOL4386.0 Sq.m
PRIMARYSCHOOL-2
2181.2 Sq.m
R.S
-16
14
4sq
.m
M.B
-15
88
sq.m
GAS AGENCY455.4 Sq.m
L.P.G 2151.7 Sq.m
V.T.C383.9 Sq.m
RELIGIOUSPURPOSE
687.1 Sq.m
MARKET1323.6 Sq.m
POLICESTATION
687.1 Sq.m
GY
M1
84
.2sq
.m
A.W
51
7.8
sq.m
BURIALGROUND
5496.5 Sq.m
PARK 1751.7Sq.m
PARK2051.9 Sq.m
R.S
-20
14
4sq
.m
M.B
-19
88
sq.m
A.W455.4 sq.m
PARK 950.2 Sq.m
R.S
-18
14
4sq
.m
M.B
-17
88
sq.mA.W
197.8sq.m
C.SHOP197.8sq.m
R.S
-21
14
4sq
.m
M.B
-20
88
sq.m C.SHOP
271.4sq.m
PARK 1875.1 Sq.m
PARK 3101.4Sq.m
A.W429.5 Sq.m
A.W503.1sq.m
A.W511.9sq.m
A.W
21
8.6
sq.
m
PR
OP
OS
ED
PW
D D
RA
IN 4
0.m
WID
E
PR
OP
OS
ED
PW
D D
RA
IN 4
0.0
m W
IDE
30
.0 M
WID
E R
OA
D
30.0
M W
IDE
RO
AD
30.0
M W
IDE
RO
AD
13
6.9
5
119.01
146.82
183.41
79. 1
2
51.27
54.54
72
.79
29.17
69
.4
29.36
R.S-22
1 44sq.m
M .B-21
8 8sq.m
R.S
-15
14
4sq
.m
M.B
-14
88
sq.m
GR
EEN
BELT
-2 1
294.1
Sq
.m
PARK 5675.7 Sq.m
KEROSINEBUNK
226.6sq.m
PARK11174.0 Sq.m
PETROL BUNK815.3 Sq.m
POSTOFFICE-1
803.7 Sq.m
PRIVATE LAND
LEGEND:
ANGANWADI / NURSERY SCHOOL
BUS TERMINUS
CPS, PARK & GREEN BELT
CONVENIENT SHOP & COMMERCIAL
COMMUNITY HALL
SCHOOLS, COLLEGE,
HOSTEL & LIBRARY
CHANNEL, SUMP, STP & CMWSSB
FUEL
GYM & SPORTS DEVELOPMENT
HOSPITAL
MILK BOOTH
MARKET
POLICE STATION
POST OFFICE
RELIGIOUS
RATION SHOP
V.T.C
TNEB
TNSCB - BUILDING CENTRE
R.S
-18
14
4sq
.m
M.B
-17
88
sq.m
C.SHOP174.3sq.m
R.S
-16
14
4sq
.m
M.B
-15
88
sq.m
C.SHOP298.5sq.m
R.S
-20
14
2sq
.m
M.B
-19
90
sq.m
A.W452.2 sq.m
12.0 m ROAD
7.2 m ROAD
6.0 m ROAD
6.0
m R
OA
D
6.0
m R
OA
D
7.2 m ROAD
6.0 m ROAD
12
.0 m
RO
AD
9.0
m R
OA
D
9.0
m R
OA
D
7.2 m ROAD
6.0 m ROAD
6.0
m R
OA
D
6.0
m R
OA
D
7.2 m ROAD
9.0
m R
OA
D
18.0
m R
OA
D
9.0
m R
OA
D
9.0
m R
OA
D6. 0
m R
OA
D
6.0 m ROAD
7.2 m ROAD
6.0 m ROAD
9.0
m R
OA
D
9.0 m ROAD
7.2
m R
OA
D
6.0
m R
OA
D
6.0
m R
OA
D
7.2
m R
OA
D
12.0 m ROAD
7.2 m ROAD
9.0
m R
OA
D
9.0
m R
OA
D
12
.0 m
RO
AD
12
.0 m
RO
AD
9. 0
m R
OA
D
12
.0 m
RO
AD
GR
EEN
BEL
T
98.8
Sq.m
C.P
.S-9
163.2
Sq
.m
PARK-121011.0 Sq.m
18.0
m R
OA
D
6.0 m ROAD
7.2
m R
OA
D
9.0
m R
OA
D
7.2
m R
OA
D
7.2 m ROAD
9.0
m R
OA
D
12
.0 m
RO
AD
18.0 m ROAD
12.0 m ROAD 12.0 m ROAD
7.2
M R
OA
D
9.0 m ROAD
9.0 m ROAD
9.0
m R
OA
D
C.P
.S1
92
.7 s
q.m
135.3
9
175.34
10
3.7
5
25.74
236.49
COMMUNITY HALL
4080.7 Sq.m
HR. SEC.SCHOOL-1
3730.4 Sq.m
COMMERCIAL-5
5464.8Sq.m
M.L.G
72291.9 Sq.m
HOSTEL1270.0 Sq.m
GAS AGENCY215.0 Sq.m
PRIMARYSCHOOL-5
1875.3 Sq.m
COMMUNITYHALL
3146.8 Sq.m
M.B
-8
88
sq.m
R.S
-9
14
4sq
.m A.W210.9sq.m
COMMERCIAL 4415.1Sq.m
RELIGIOUSPURPOSE
623.1 Sq.m
RESERVED
FOR SCHOOL
(COURT
CA SE)
550 Sq.m
20.0
27.5
R.S
-20
14
4sq
.m
M.B
-19
88
sq.m
A.W447.0 Sq.m
GY
M3
58
.4sq
.m
KEROSINE
BUNK
224.3 Sq.m C.S
HO
P
14
6.6
sq.m
A.W446.7 Sq.m
7.2 m ROAD
7.2 m ROAD
12
.0 m
RO
AD
9. 0
m R
OA
D
6.0 m ROAD
9.0
m R
OA
D
GREE N BELT
62.8 Sq.m
C .P .S
75.8 Sq.m
6.0 m ROAD
9.0
m R
OA
D 7.2
m R
OA
D7.2 m ROAD
6.0
m R
OA
D 9.0
m R
OA
D
6.0
m R
OA
D
6.0
m R
OA
D
GREE N BELT
62.8 Sq.m
C. S
HO
P3
55
.9sq
.m
POLICE STATION-1862.2 Sq.m
PARK-10 862.2 Sq.m
7.2 m ROAD
6.0 m ROAD
6.0 m ROAD
7.2 m ROAD
6.0 m ROAD
7.2 m ROAD
7.2 m ROAD
9.0
m R
OA
D9
.0 m
RO
AD
C.P.S-857.1 Sq.m
PRIMARYSCHOOL-4
2133.8 Sq.m
R.S
-10
14
4sq
.m C.SHOP147.2sq.m
M.B
-9
88
sq.m
6.0 m ROAD
7.2 m ROAD
PARK663.94 Sq.m
PA
RK
-13
12
48
.6 S
q.m
R.S
-7
14
4sq
.m
M.B
-6
92
sq.m
SH
OPS
744.5
4 S
q.m
HIGH SCHOOL2610.7 Sq.m
POST OFFICE715.8 Sq.m
R.S
-14
14
4sq
.m
M.B
-13
88
sq.m C.SHOP
197.8sq.m
PARK 2181.2 Sq.m
PARK 715.8 Sq.m
R.S-12
1 44sq.m
M .B-118 8sq.m
A.W482.6 Sq.m
A.W530.2 sq.m
7.2 m ROAD
9.0
m R
OA
D
9.0
m R
OA
D
PARK 714.32 Sq.m
CO
MM
ER
CIA
L7
44.5
4 S
q.m
R.S
-15
14
4sq
.m
M.B
-14
88
sq.m
6.0
m R
OA
D
7.2 m ROAD
6.0 m ROAD
7.2
m R
OA
D
GREEN BELT
100.9 Sq.m
COMMERCIAL5056.6 Sq.m
9.0 m ROAD
PARK 9900.9.1Sq.m
A.W562.7 sq.m
PARK744.5 sq.m
6.0 m ROAD
9.0
m R
OA
D
9.0
m R
OA
D
198.35
180.05
144.1
106
.32
C.S
HO
P7
09.3
5 S
q.m
STP
6001.6 Sq.m
12.0 m ROAD
12
.0 m
RO
AD
CMWSSB SUMP
2739.9 Sq.m
RELIGIOUS
PURPOSE
984.1 Sq.m
LIBRARY
1102.9 Sq.m
R.S-5
1 44sq.m
M .B-4
8 8sq.m
A.W-1465.3Sq.m
82.57 m
59.4
2 m
59
.9 m
72.5 m14.97m
59
.5 m
36.95m
104.65m
43.3
5 m
6.4
m
72.5m
53.4
3 m
151.39
102.08 m
2.18 m
11
9.4
3 m
10
4.3
5
226.24
EPI SCOPE of WORK forREACH V
C.Drawings
1 of 5
..... .,·•
r,
:,
�
"· )
�..
------------------------- 29720 -------·---- 4190 4190 4190 4S80 4190 4190 4190----.
t :::---=-. - ---=---=-� -=---=---=---=-1.::--=---=---=---=---l
-----�---- .------· I 1:1 :1 1:1
,· 1:1 @ 1:1 @ 1:1 @ 1:1 � ® 1,1 1,1 l'I 1:1 1'1
1 1: ti
' I
�
I -----1�------ --------?t--------- --------?1 1'i @ ,I ,� i: ,, I
1 ' 1 I 1 : ff@l80c/c 1: 1 @ t==============t @ 1:1 @ : @ 1:1
. I- I -��� I, ',, /,, , 1 �::::a�� I -==-I � �
8@180<ic Id I ', . ./ I 1,1 °
�
___ A@JI0:1,, _ .
r ':;.::",, ,:i1:1 _)
--...... ,:1
,:, - _:· - ,:i ,:, t
It . . ' 11 . ... Ill I •• ' '.. 11 I • • II • 111 I
I --=-��==1::--=-�-�-1·:... :I,--==-.=,-.£_-'�--=---=si o -�
'_ � -=----=--Jf � -=---=--'.l�, - --=---=--:I.£_--=---=-..:
j
ij I #S@IBO<ic 1'1 I � I 111
1'1 "1 • U®l.;11
c/c o fil m 1'1 I
Ir [ .... : .... ® #�SOc/c l'I I 118@l00c/
I . ::1 1'1 1'1 : 1,1
' 11 @ I IIOdc I @ • ,.. • "°I ,.. • SJ I @ I @ Iii @ 1'1
I .... ... • l'I D,
lf t' I
� � "' 0, N �
� i--=---=-'-� --=---=-- - '
;:-_:- - :;�::=:--=--.=:-i:--=--:--=-� i -=--t' -=---;=-- - I --=---=-:...:; I - --=---=--t! .=.--=---=--i
m I #S@IBO�� I .• ,, IIJ SLAB1llJCKN
&SSjm r--=--, I I ,, , I I m • J'I '"'° I
/' .. 11
11 Utmm 1
1
1 ' /
1'1 LI . ,.,
J'
1'1 l'I .. I I I ,," ', I I I '· , I I I • ', I I I
� •- 1:1
�--1--4 1 :1 ili, ",, ili 1:, �4-=- 1:1 -'-I g 1:1 @ 1:1 @ 1:1 @ 1:1 �-=--:;I ,:, : @ 1:1 @ • ,:, @ 1:1
· ,I lli 1!1 ill j +
!1 ,
, ·: 1 11
�t t= =========I======== =-I=========�=========== - -=== == == == == == = == + === == == - - j111
1:1 ,:, : / I
•,:,• I ::1,: 1 ® 1,1 ® 1 -� 1 1 1 · 111 ® 1 ® 111 ® 'Il'l I l'I I I l'I I I' g I ltl I 111 l1l I 111 'I ;;; I Iii I 11 ,1 I It . I 111 I l'I I I 1'1 I
I' II----------==I==---------==I:------- --==� �-=--- - - - - ---==I==- --------!-==- - - -- - --==-I --- 4190 4190 4190 4S80 4190 4190 4190 --� �------------------------- 29720 -----------------,----------
/,ll.u� 471
!L,r;f...l,�lr./ll.
ExecutiVe Engineer Tsunami PC & M Cell
Tamimsdu Slum .Cl�rance J;loardaiennai, 600 005. Sd/- Dr. A.R. Sanlhalcumar
01: 11.10.2012.
---
I. AU dimension� an: m mm. 2. M2S Concrete and Fe 415 grade
steel shall be adopted. 3. Slab Thickness is 130 ll1.lIL 4. Clear cover to slab is 25 !l.lJl.l. 5. Crank point distances are as shown.6. ·--· deootes extra rods to be
provided at top.
.
STRUCTURAL DETAILS
PROJECT: CONSTRUCTION OF TENEMENTS @PERUMBAKKAM TITLE: FLOOR/ ROOF SLAB DETAll.S
TYPE DESIGN NO.: 7 A/ 2008 (Amended)
DWG. NO.: !NSCB / PERUM AMENDED/ 17
REVISION NO.: 0
�,o:,,-
AJJIJttnl En:fnttr Aut. £x� Engl,ottr
u. .. ._. .. ,u,u £ittutlv1 E,nciattr Chld !ngJnetr
• STRUCTURAi. & QU.U.ITY COl'mtOI. Wll<C TAMIL !<ADU SLUM C'l.EIIIW<CJ: BOAJ\D NO.$, lCAMARA.IAR SAi.Al • CHEl<l<AI • '°' MS.
lC.Drawings
2 of 5
195
25
65
11
50
12
20
10
25
25
65
33
30
60
0
60
0
91
0
13
90
46
0
39
03
00
16
75 10
60
910
50
0
14
10
25
15
14
60
13
40
12
20
84
5
10
4010
60
65
0
53
0
730
54
0
9201
52
5
26
20
26
20
46
25
2515
1075
12
20
910
460
1075
4155
1410
910
91
0
9901
185
10
25
1185
10
60
20
601
900
2565
1150
12
201
025
600
1390
91010
4026
201
075
2565
3330
600
2480
10754
60
4155
1375
2780
910
2620
195
990
11
8510
2511
85
106
0
2060
1900
11
50
12
20
10
25
25
65
33
30
60
0
1075 4
60
1075
4155
9901
185
10
25
1185
20
601
9001
1501
220
1025
2565
600
910 10
401
075
600
1075
4155
990
11
8510
2511
85
106
0
2060
1900
300
1072
1070
1070
10
60
9105
30530
106
0
530
14
40
1440
1060
106
01
06010
601
06
01
060
10603
00
1070
1070
940
2180
2130
I,II,III,IV,V
,VI,V
II FL
OO
R B
RIC
K W
OR
K L
AY
OU
T
C.Drawings
5 of 5