Upload
karenomalley
View
1.407
Download
1
Embed Size (px)
DESCRIPTION
GBREB / Commercial Brokers Association, Continuing Education Unit –Commercial Leasing
Citation preview
© Goulston & Storrs 2010. All rights reserved.
GBREB / Commercial Brokers Association
Continuing Education Unit – Commercial Leasing
Lease Provisions Demystified
and LOI Language Lawyers Long For
Construction and Option Provisions in Leases
A Truly Understandable Explanation of the Gross-Up
Clause
LOI Pitfalls to Avoid
May 20, 2010
© Goulston & Storrs 2010. All rights reserved.
Raymond Kwasnick, Esq.
Goulston & Storrs, P.C.
617-574-4197
and
Karen O’Malley, Esq.
Goulston & Storrs, P.C.
617-574-3503
Materials Prepared by:
Barbara Schmitt, Esq.
Goulston & Storrs, P.C.
617-574-4071
Presented by:
© Goulston & Storrs 2010. All rights reserved.
I. CONSTRUCTION PROVISIONS
Construction provisions in a lease ultimately boil down to a few key questions:
Who prepares the plans?
Who performs the work?
Who pays for the work?
When does rent start?
Key Practice Point: The answers to these questions have a major impact on the way the entire lease is
structured. This is why lawyers cannot draft leases with two alternate construction provisions (for example,
Landlord does work and Tenant does work) with the choice to be made later. Having a clearly drafted LOI
on these points facilitates getting a lease done quickly.
1
© Goulston & Storrs 2010. All rights reserved.
Simple Scope of Work: If the work to be done is so simple, sometimes no real plans are drawn. The lease may just
have a list of items of work to be done (such as repainting, carpeting and the like), or a simple space plan sketch
attached.
Architectural Plans: If the work is more involved, in most cases, an architect draws the plans.
→ It is critical to determine who is hiring the architect, Landlord or Tenant. This is important because whoever
signs the contract with the architect is taking on certain risks.
Delay Risks: For example, what if the architect doesn’t deliver plans when she is supposed to? If the Tenant
hires the architect, this delay is charged to the Tenant, not the Landlord; if the Landlord hires the architect,
the opposite is true.
Error Risks: What if the plans are drawn wrong, and the building inspector won’t give a certificate of
occupancy? If Tenant hires the architect, Tenant has a fight with the architect, but the Landlord is left out of
it. If the Landlord hires the architect, then the Tenant has a fight with the Landlord, and the Landlord's only
recourse is to turn around and have a fight with the architect.
→ Since hiring the architect involves taking risk, Landlord wants to push this off onto Tenant as much as possible.
Tenant may decide to use the same architect that Landlord has used in the past, but Landlord still wants the deal
structured so that Tenant, not Landlord, is hiring the architect and responsible for preparing the plans. This is a
reasonable outcome because it is the architect, not the Landlord, who is an expert in what the building code
requires, and it is the Tenant, not the Landlord, who will be making almost all of the choices about what the plans
will show. Thus, Landlord says, the responsibility for the plans should be between the Tenant and the architect.
Given that Tenant wants as much control as possible with respect to its build out, most often Tenant is willing to
take on this responsibility.
1. Who prepares the plans?
2
© Goulston & Storrs 2010. All rights reserved.
This is probably the question that has the most potential to lead to confusion in LOI and lease drafting. In answering this
question, the parties are essentially addressing the same set of issues as with who is hiring the architect -- who bears the risk
of delay or mistake, and if there is a problem, whom does the Tenant go after?
2. Who does the work?
A. Landlord does the work.
In this scenario, Landlord hires the GC, who builds the space out in accordance with the plans.
→ Typically, rent does not start until the construction is substantially complete. This means that if the carpenters go on
strike, it is the Landlord's problem -- the work isn’t getting done, and rent doesn’t start until the work is done (unless
the Tenant has done something to cause a delay).
→ Similarly, if the GC makes a mistake or walks off the job, it is the Landlord's problem and not the Tenant's; rent still
doesn’t start until the work is done.
→ If there are problems with the work, Tenant is going to have a fight with Landlord, not with the GC. In fact, Landlord
often gives the Tenant a warranty on the work for a period of up to a year, so if there is a problem, Landlord has to fix
it. Of course, this usually is the same coverage as Landlord's warranty from the GC, so if Tenant comes to Landlord
with a problem, Landlord turns around and presents the problem to the GC to fix -- assuming, of course, that the GC is
still around, and is returning phone calls.
3
© Goulston & Storrs 2010. All rights reserved.
B. Tenant does the work.
In this scenario, Tenant hires the GC, who builds the space out in accordance with the plans.
→ Typically, rent starts a certain number of days after the space is delivered to Tenant for the start of
construction, whether or not the work is done. This means that if the carpenters go out on strike, it is the
Tenant's problem -- the work isn’t getting done, but rent starts anyway whether or not the work is done (unless
the Landlord has done something to cause a delay).
→ Similarly, if the GC makes a mistake or walks off the job, it is the Tenant's problem and not the Landlord's;
rent still starts whether or not the work is done.
→ If there are problems with the work, Tenant has to fight with the GC, and Landlord is left out of it. The only
warranty on the work comes from the GC -- assuming, of course, that the GC is still around and is returning
phone calls.
Why would a Tenant agree to do its own work, if there is so much risk? Three (3) basic reasons:
(1) This may be what is market for the location, so Tenant may not have much choice.
(2) Tenant may try to negotiate for a benefit if it completes the build-out early (rent doesn’t start until 90 days
after delivery, regardless of whether the work is finished and Tenant occupies the space before that, or a
reduced oversight/construction management fee payable to Landlord).
(3) Tenant wants to control its own construction process.
2. Who does the work?
4
© Goulston & Storrs 2010. All rights reserved.
3. Who pays for the work?
There are three basic answers to this question:
→ Landlord Pays: If Landlord pays for all the work, it is also called a “turnkey” deal (which comes from the idea
that Landlord has done everything, so all Tenant has to do is turn the key in the door and move in).
→ Both Landlord and Tenant Pay: If the parties share the costs, typically Landlord will agree to pay a certain
amount (the TI Allowance or Landlord's Contribution are common names for this) and Tenant pays the rest.
→ Tenant Pays: The situation where Tenant pays for everything is relatively rare.
Key Practice Point: If Landlord is providing an allowance, the LOI should specify (i) whether a portion can be used
for soft costs (if this is given, it is often limited to about 20% of the allowance), (ii) the timing and criteria for paying out the
TI (for example, will some portion be paid at start of construction? At 50% substantial completion? At full completion? Will
lien waivers be required), (iii) what happens to the unused portion if Tenant doesn’t spend it all on TI (Tenant gets a rent
credit for some or all of the unused amount, or Tenant has no rights to any unused portion), and (iv) if the work costs more
than the allowance, whose money (Landlord or Tenant) gets spent first.
Key Practice Point: In today’s economic climate where Tenants may have questions about Landlord viability,
Tenants should be determining if Landlord is capable of funding the TI Allowance. Consider utilizing the following
options to get comfort for Tenants: Letter of Credit, Parent Guaranty, Escrow (make sure this is a “true” escrow), and/or
if the Tenant is capable of covering costs itself, offset rights.
5
© Goulston & Storrs 2010. All rights reserved.
4. When does rent start?
This depends on who is doing the work.
A. Landlord does the work.
→ Typically, the space becomes vacant, and Landlord begins construction.
→ The term (and rent, unless there is free rent involved) begins on the Commencement Date, which is typically
defined as the earlier of (i) substantial completion of construction, or (ii) the date that construction would have
been substantially complete, except for Tenant delays. (For example, if Tenant is responsible for the plans, and
the architect is late with the plans, this would be a Tenant delay.)
→ Where Landlord is doing the work, construction delays, unless caused by Tenant, do act to delay the
Commencement Date, even if they are not Landlord's fault.
→ Typically, the term (say, five years) runs from the Commencement Date, and the rent bumps occur on the
anniversary of the Commencement Date.
Key Practice Point: What remedies does Tenant have if Landlord is late? Consider:
Liquidated damages (e.g., day for day rent credit)
Termination rights (with reimbursement of costs)
Self-help and offset rights
6
© Goulston & Storrs 2010. All rights reserved.
B. Tenant does the work.
→ Typically, the space becomes vacant, and Landlord delivers it to Tenant for the beginning of construction (the
“Delivery Date”). Tenant starts construction.
→ The stated term (say, 5 years) (and rent, unless there is free rent involved) begins on the Commencement Date,
which is typically defined as XX (typically, 90 or 120) days after the Delivery Date, but XX is often extended for
each day of Landlord delay to Tenant's construction. (For example, if Landlord is supposed to approve change
orders in 5 days but takes 7 days to approve one, that would be two days of Landlord delay.)
→ Where Tenant is doing the work, construction delays, unless caused by Landlord, do not act to delay the
Commencement Date, even if they are not Tenant's fault.
→ Technically, the term starts on the Delivery Date (because the term needs to be in effect before Tenant gets the keys
so that the insurance and indemnity provisions are effective), but the term stated in the LOI (say, five years) runs
from the Commencement Date (not the Delivery Date), and the rent bumps occur on the anniversary of the
Commencement Date (not the Delivery Date).
→ In order to avoid confusion, the period between the Delivery Date and the Commencement Date is often referred to
as the “build-out period” to distinguish it from a “true” free rent period – one where Tenant is occupying the space
but has the rent abated for X months.
Key Practice Point: Landlord needs hard Commencement Date, subject only to Landlord delay.
4. When does rent start?
7
© Goulston & Storrs 2010. All rights reserved.
C. No work is being done.
→ In this situation, sometimes called a “true as-is” deal, Tenant is going to move into the space without any work
being done.
→ The space becomes vacant, Landlord gives Tenant the keys, and the term (and rent, unless there is free rent
involved) starts immediately.
→ Typically, the term (say, five years) runs from the Commencement Date, and the rent bumps occur on the
anniversary of the Commencement Date.
4. When does rent start?
8
© Goulston & Storrs 2010. All rights reserved.
II. RFR, ROFO, RFN AND EXPANSION OPTIONS
A Tenant's ability to take on more space in a lease generally falls into one of four
categories:
1. Right of first refusal (RFR)
2. Right of first offer (ROFO)
3. Right of first negotiation (RFN)
4. Expansion option.
These all give the Tenant certain unilateral rights to expand, but they differ in
what triggers that right and when it can be exercised.
9
© Goulston & Storrs 2010. All rights reserved.
1. Right of First Refusal (RFR)
In a true RFR, nothing happens until Landlord has gone out and completely negotiated a deal with a
third party to lease the space that is subject to the RFR.
Once that deal has been finalized, Landlord then must give Tenant the right to take the space on all of
the terms and conditions that Landlord has negotiated with the third party.
Naturally, this is a great impediment to Landlord in leasing the space, since it doesn’t know if the space
is truly available until after the negotiations are complete, and few prospective tenants want to play that
game.
Accordingly, true RFR’s are rare, and most times that this term is used, it is actually referring to a
ROFO.
10
© Goulston & Storrs 2010. All rights reserved.
2. Right of First Offer (ROFO)
In a typical ROFO, Landlord decides that it wants to lease the space that is subject to the ROFO, and (often) how that
space will be configured. Whether or when to lease the space is up to Landlord; there is no obligation to offer it to
Tenant at any particular time, and often no obligation to lease it in any particular size or shape (for example, if the
ROFO applies to contiguous space on the third floor, Landlord can choose to offer that space in 2,500 sf chunks or
10,000 sf chunks).
When Landlord does decide to lease it, Landlord goes to Tenant first and asks if Tenant wants the space. Tenant has a
short period of time in which to say yes or no; if it does not say yes within the specified time frame, it loses the right to
the space, and Landlord is free to lease it to others.
Typically, Tenant must take the ROFO space in the size and configuration specified by Landlord.
ROFO space is usually leased at market rates (or 95% of market rates). Often, Tenant can go to an arbitration or broker
determination of market rent if it disagrees with Landlord's quote; however, Landlords want to be sure that Tenant is
bound to take the space before the arbitration happens.
If there is no arbitration right, then Tenant will often ask for some protection in the lease to be sure that Landlord is not
quoting an inflated rental to discourage Tenant from taking the space. The most common way to provide this protection
is that if Tenant does not exercise the right, Landlord must re-offer the space to Tenant if it wants to lease it to someone
else on materially better terms.
11
© Goulston & Storrs 2010. All rights reserved.
Key Practice Points: A great LOI will address the following issues relating to a ROFO:
Identify the ROFO space with as much specificity as possible. For example, with plans.
→ Avoid contiguous creep. Avoid identifying ROFO space as “contiguous” because space that is not presently
contiguous might become contiguous.
Spell out what the rent for the ROFO space will be (e.g., market rate).
→ If Landlord is willing to give arbitration, this can be stated as well.
What will the term be for the ROFO space?
→ Will Tenant take the space for the same remaining term as the rest of its premises, or must Tenant agree to
whatever term (e.g., 5 years) Landlord is offering to the world at large.
→ In the coterminous instance, the ROFO right will often expire a period of time (e.g., 2 or 3 years) prior to the
expiration of the lease term, to avoid Landlord having to lease the ROFO space for a short period of time.
Is the ROFO a one-time right or a rolling right?
→ A one-time right means that once Tenant is offered a particular space and does not take it, it loses all rights in
that space for all time. (A variation on this is that once Tenant does not take a particular space, it loses all rights in
all of the ROFO space for all time.)
→ A rolling right means that once Tenant is offered a particular space and does not take it, it continues to have
ROFO rights in that space the next time it becomes available for lease. One-time rights are much cleaner, and
therefore are preferable to Landlords.
2. Right of First Offer (ROFO) (cont’d)
12
© Goulston & Storrs 2010. All rights reserved.
3. Right of First Negotiation
A right of first negotiation is essentially a ROFO without the price protection for the Tenant.
Landlord agrees that it will offer the space first to the Tenant, and that it will negotiate in good faith with the Tenant for
XX days.
However, if Landlord and Tenant are unable to reach agreement on the rent in that period, Tenant has no further rights
in the space and Landlord can lease it to anyone else at any rent, whether or not lower than what it offered Tenant.
Obviously, Tenants do not like this because it gives them little protection against Landlord quoting an unreasonably
high rent in order to discourage Tenant from taking the space.
As a result, a true RFN is rare, especially in today’s market.
Landlords should be willing, as an alternative, to enter into a ROFO with an arbitrated market rent, provided that Tenant
is committed to take the space before it can go to arbitration. Like a ROFO, an RFN can be one-time or rolling, and the
LOI should give the same information as for a ROFO (except the rent).
13
© Goulston & Storrs 2010. All rights reserved.
4. Expansion Option
While RFR/ROFO/RFNs may apply to a loosely-defined class of space (any contiguous space on the third floor, for
instance), expansion rights are typically more tightly defined (the 5,284 sf on 3 currently occupied by XYZ
Corporation, for instance, or a space designated by Landlord containing between 5,000 and 7,500 sf on the sixth floor).
What really separates an expansion option from a RFR/ROFO/RFN is timing.
In an expansion option, Landlord must offer the space to Tenant within a certain window of time, and Tenant must
notify Landlord that it wants the space by a certain number of months ahead of that time period.
Tenant knows that it absolutely has the right to add that space within that time frame, and Landlord knows that it
absolutely must offer that space to Tenant within that time frame. Both Landlord and Tenant know that if Tenant does
not exercise by a certain date, then the expansion option is void.
The window of time for delivery of the space can be tied to the dates in the lease (e.g., space must be offered in the fifth
lease year) or may be specific calendar dates (e.g., space must be offered to Tenant between 1/1/11 and 3/31/12).
Typically, the rent is market, but in some cases it may be the rental rates then in effect (on a psf basis) under the lease.
Key Practice Point: A great LOI will identify the following with respect to the expansion space: (1) when it will be
available, (3) how much notice Tenant must give, and (3) what the rent will be. It may also be useful to state any
conditions to exercise: no (continuing) default, minimum occupancy, etc.
14