Upload
others
View
0
Download
0
Embed Size (px)
Citation preview
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
JOHN C. CRUDEN Assistant Attorney General Environment & Natural Resources Division United States Department of Justice MICHAEL C. ORMSBY United States Attorney Eastern District of Washington DAVID J. KAPLAN ELIZABETH B. DAWSON CHLOE H. KOLMAN AUSTIN D. SAYLOR Environmental Defense Section P.O. Box 7611 Washington, D.C. 20044 (202) 514-2219 VANESSA WALDREF Assistant United States Attorney 920 West Riverside Ave., Suite 300 Spokane, WA 99201 (509) 353-2767
UNITED STATES DISTRICT COURT
EASTERN DISTRICT OF WASHINGTON
STATE OF WASHINGTON, DEPARTMENT OF ECOLOGY,
Plaintiff,
v. ERNEST MONIZ, Secretary of the United States Department of Energy, and the UNITED STATES DEPARTMENT OF ENERGY, Defendants.
NO. 2:08-cv-5085-RMP UNITED STATES’ BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
i
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
TABLE OF CONTENTS
TABLE OF AUTHORITIES ................................................................................. iv
INTRODUCTION .................................................................................................. 1
BACKGROUND .................................................................................................... 1
I. PROCEDURAL HISTORY ......................................................................... 2
II. FACTUAL BACKGROUND ...................................................................... 3
ARGUMENT .......................................................................................................... 4
I. DOE’S PROPOSAL REGARDING THE WTP IS SUITABLY TAILORED BECAUSE IT PRESERVES THE ORIGINAL OBJECTIVES OF THE CONSENT DECREE WHILE ACCOUNTING FOR PRESENT UNCERTAINTIES. ............................... 5
A Suitably Tailored Proposal Must Account for the Significant Uncertainty Created by Persistent Technical Issues. ......................... 5
B. DOE’s Second Proposal Ensures the Enforceability of Milestones While Accounting for Present Uncertainties. .................. 8
1. DOE’s Proposal Pairs Enforceable Milestones with a Narrow Extension Mechanism Based on Three Areas of Uncertainty. ......................................................................... 8
2. DOE’s Proposal for WTP Milestones Is Suitably Tailored to the Changed Circumstances. ............................... 15
II. DOE’S REVISED PROPOSAL TO COMPLETE SINGLE-SHELL TANK RETRIEVALS IS SUITABLY TAILORED TO ADDRESS ONGOING VAPOR-RELATED DELAYS AND FUNDING CONSTRAINTS. ........................................................................................ 17
III. DOE’S PROPOSED ACCOUNTABILITY MEASURES ARE SUITABLY TAILORED TO ASSIST THE PARTIES IN RESPONDING TO PROJECT DISRUPTION. ......................................... 20
A. Suitable Accountability Proposals Must Reflect the Particular Factual Causes of Disruption Underlying the Changed Circumstances. ................................................................................. 21
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
ii
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
B. DOE’s Proposal is Suitably Tailored to Increase Transparency Without Constraining Effective and Safe Management of the WTP ................................................................. 29
IV. A CONTINGENT REQUIREMENT TO CONSTRUCT NEW DOUBLE-SHELL TANKS IS NOT SUPPORTED BY—OR SUITABLY TAILORED TO ADDRESS—ANY CHANGED CIRCUMSTANCE IN THIS CASE. ......................................................... 25
A. No Changed Circumstances Warrant New Double-Shell Tanks. ............................................................................................... 26
1. No Relevant Changed Circumstances Exist. ......................... 26
2. Construction of New Double-Shell Tanks Would Not Be Suitably Tailored to Address Any Changed Circumstances. ....................................................................... 29
B. New Double-Shell Tanks Are Beyond the Scope of the Decree, Not Realistically Achievable, and Contrary to the Public Interest. .................................................................................. 30
1. New Double-Shell Tanks Are Beyond the Scope of the Consent Decree Because They Are Exclusively Addressed By the Tri-Party Agreement and are Unnecessary to Complete Retrievals ..................................... 30
2. Building New Double-Shell Tanks Is Not Realistically Achievable or in the Public Interest. ...................................... 34
C. Mandating New Double-Shell Tanks on a Contingent Basis Is Inconsistent with the Atomic Energy Act. ................................... 36
D. In the Alternative, DOE Proposes that New Double-Shell Tanks Be Required Only If Failure to Achieve Yearly Targets for Aggregate Tank Waste Volume Reduction Cannot Be Mitigated. ....................................................................... 37
1. Any Contingent Obligation to Build New Double-Shell Tanks Should Be Based on Failure of the Evaporator To Achieve Predetermined Annual Tank Waste Volume Reductions. .................................................... 38
2. Placing Conditions on Double-Shell Tank Construction Is Necessary Because There are More Effective Means of Maintaining the Pace of Retrievals. ....... 39
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
iii
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
CONCLUSION ..................................................................................................... 40
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
iv
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
TABLE OF AUTHORITIES
CASES
Cromeens, Holloman, Sibert, Inc. v. AB Volvo, 349 F.3d 376 (7th Cir. 2003) ........................................................................... 27
Keith v. Volpe, 784 F.2d 1457 (9th Cir. 1986) ................................................... 8, 10, 15, 31, 40
Labor/Cmty. Strategy Ctr. v. L.A. Cnty. Metro. Transp. Auth., 564 F.3d 1115 (9th Cir. 2009) ......................................................................... 26
Rufo v. Inmates of Suffolk Cnty. Jail, 502 U.S. 367 (1992) .............................................. 11, 16, 24, 25, 27, 30, 34, 35
United States v. Armour & Co., 402 U.S. 673 (1971) ........................................................................................ 31
STATUTES
42 U.S.C. § 6972(a)(1)(B) .................................................................................. 18
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
1
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
INTRODUCTION
The Department of Energy’s (“DOE”) remediation project at the Hanford
Site represents an unprecedented effort to safely and responsibly dispose of
wastes generated by nuclear weapons development from World War II through
the Cold War. Central to this cleanup effort is the Hanford Waste Treatment and
Immobilization Plant (“WTP”), a multi-facility, multi-billion dollar project to
treat approximately fifty-six million gallons of mixed radioactive and hazardous
waste stored in single- and double-shell tanks on site. However, progress has
been delayed by persistent unresolved technical issues at two WTP facilities that
have necessitated lengthy resolution efforts and that will require extensive
reworking of current plans for, and contracts supporting, the project. In addition,
unpredictable annual funding constraints, unanticipated equipment failures, and
worker safety issues have affected the pace of single-shell tank waste retrievals.
Given these challenges, DOE’s second proposed modification, submitted as
required by the Court’s August 13, 2015 Order and subject to the reservation of
rights set forth below, presents a reasonable, responsible, and suitably tailored
approach to achieving WTP initial operations and retrieving the waste from the
single-shell tanks covered by the Consent Decree. DOE’s proposal is tailored to
the changed circumstances because they preserve and promote the original
objectives of the Consent Decree—initial operations at the WTP and retrieval of
waste from nineteen tanks—while ensuring that DOE is able to effectively and
safely address current and potential obstacles at the Site.
BACKGROUND
DOE’s original Motion to Modify the Consent Decree sets forth in detail
much of the relevant background in this matter. U.S. Mot. to Modify Consent
Decree (“U.S. Br.”) (ECF 76) at 5-16 (factual and legal background). The
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
2
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
following supplemental background provides a short overview of proceedings in
this case and the status of the WTP and single-shell tank retrievals.
I. Procedural History
On October 3, 2014, DOE submitted its first proposed modification of the
Consent Decree. DOE’s proposed modification included several key features to
align the Consent Decree with the ongoing work and the significant uncertainty at
the WTP, while maintaining the original objectives of the Consent Decree.
Primary among these features was a new, sequenced, and more realistic process
for setting WTP construction and commissioning milestones once adequate
certainty is achieved, i.e., technical issues are resolved, new or revised project
baselines are established, and contracts are executed. Absent this information,
DOE cannot accurately predict or responsibly commit to certain key construction
deadlines. Following briefing and two oral arguments, the Court issued two
significant Orders regarding the Parties’ proposals.
First, on May 11, 2015, the Court held that both the State and DOE
identified significant and unanticipated changed factual conditions that make
certain aspects of the Decree unworkable and detrimental to the public interest.
Order Regarding Mots. to Amend Consent Decree (“First Order”) (ECF 139) at
52-53. Second, on August 13, 2015, the Court: (1) concluded that the Decree must
include “predetermined, enforceable deadlines” for the WTP rather than
milestones set on a rolling basis, Second Order Regarding Mots. to Modify
Consent Decree (“Second Order”) (ECF 170) at 16-17; (2) declined to modify the
Decree to incorporate a direct feed capability for either low- or high-activity
waste, id. at 21; (3) determined that, if certain as-yet-to-be-determined events
regarding DOE’s 242-A Evaporator (“Evaporator”) occur, the Court will require
DOE to build one or more new double-shell tanks, id. at 27; and (4) stated its
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
3
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
intent to adopt additional reporting requirements and accountability measures, id.
at 32. Rather than deciding how the Decree should be modified, the Court ordered
that the parties “must submit revised Consent Decree modifications consistent
with [these] rulings.” Id. at 36; see also id. at 36-37. In particular, the Court
directed that the modifications should contain “specific milestone deadlines” for
WTP construction and initial operations as well as for the twelve remaining
single-shell tank retrievals, a conditional requirement to build new double-shell
tanks, and reporting requirements and “recovery plan[s]” should there occur a
serious risk of not meeting a milestone. Id. at 32. The Court also stated its intent to
appoint three “technical advisors” to “organize, advise on, and help the [C]ourt
understand relevant scientific evidence and the engineering and project
management issues relevant to this case.” Id. at 33-35 (internal quotations
omitted). The Court has “presumptively selected” three individuals to serve on
that panel. ECF 192 at 3.
II. Factual Background
Unresolved technical issues continue to delay progress at the High-Level
Waste (“HLW”) and Pretreatment (“PT”) Facilities and prevent compliance with
the 2010 Consent Decree milestones. Resolution efforts are ongoing, but
construction at the PT Facility remains suspended. Third Supp. Decl. of Benton J.
Harp (“Harp 3d Supp. Decl.”) ¶¶ 2, 5. At the HLW Facility, DOE has resumed
production engineering and civil construction, though construction work is still
suspended in areas affected by outstanding technical issues. Id. ¶¶ 3, 5. Work at
the Low-Activity Waste (“LAW”) Facility continues; DOE is presently
negotiating a modified performance baseline and contract to reflect adjustments
and new capacity necessary to support “direct feed” of waste to that Facility,
which will allow the treatment of low-activity waste to proceed before the PT and
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
4
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
HLW Facilities are completed. Id. ¶ 4. In addition, twelve single-shell tanks
remain to be retrieved under the Consent Decree: three C Farm tanks and nine A
and AX Farm tanks. Fifth Supp. Decl. of Thomas Fletcher (“Fletcher 5th Supp.
Decl.”) ¶ 3. Retrievals are ongoing, but have been slowed by the use of enhanced
personal protective equipment related to tank vapors. Id. ¶¶ 5-11. Progress on
retrievals has been further affected by current funding limits under a continuing
resolution that keeps funding at 2015 levels rather than the increased levels
requested for fiscal year 2016. Id. ¶¶ 25-27. Appropriations after the continuing
resolution expires on December 11, 2015, are still unknown.
ARGUMENT
As directed by the Court’s Second Order, DOE submits: enforceable WTP
milestones paired with a reasonable, collaborative extension mechanism; adjusted
dates for tank retrievals to reflect worker safety and funding concerns; and
accountability measures to bolster transparency in the face of compliance
obstacles. Although a requirement to build new double-shell tanks would be
inappropriate for the reasons discussed below, DOE also proposes a modification
to specify when and under what circumstances such tanks might be built.1
1 Particularly because the Court has not yet determined how the Consent Decree
will be amended, DOE submits all of these proposed modifications with the
express reservation of, and without prejudice to, DOE’s prior positions, including
DOE’s arguments that its first proposed modification should be entered by the
Court. DOE reserves and preserves all rights to appeal the Court’s prior rulings
regarding DOE’s and the State’s first proposed modifications.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
5
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
I. DOE’s Proposal Regarding the WTP Is Suitably Tailored Because It Preserves the Original Objectives of the Consent Decree While Accounting for Present Uncertainties. DOE continues to believe that given existing project uncertainties, its first
proposed Consent Decree modification is the appropriate approach to address the
changed circumstances and to establish a WTP construction and commissioning
schedule. The milestone-setting process in DOE’s original proposal would ensure
that the milestone dates are meaningful and enforceable, without requiring
constant further adjustments as information develops. DOE’s second proposed
Consent Decree modification, however, responds to the Court’s direction that new
modification proposals “address . . . specific milestone deadlines for constructing
and achieving initial operations of the WTP.” Second Order at 32. Along with a
table of enforceable milestones, DOE’s second proposal includes a narrow but
essential mechanism that would extend WTP milestones, if necessary, based upon
reliable new information. In light of significant information gaps in three areas—
resolution of technical issues, completion and verification of facility redesign, and
development and execution of new or modified performance baselines and
contracts—DOE’s proposed extension mechanism is a necessary and suitably
tailored modification of the Consent Decree.
A. A Suitably Tailored Proposal Must Account for the Significant Uncertainty Created by Persistent Technical Issues.
Any modification of the Consent Decree must account for the pervasive
uncertainties presently facing the WTP. As DOE explained in its previous filings,
the persistence of certain WTP technical issues has resulted in a period of
significant project uncertainty that prevents the parties and the Court from
projecting firm milestone dates. U.S. Br. at 57-58; U.S. Reply (ECF 113) at 3-9.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
6
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Until the five primary technical issues affecting the HLW and PT Facilities are
resolved, see Second Order at 6, DOE cannot complete and verify the updated
WTP design, or develop new or modified performance baselines and contracts to
define and direct the execution of that design. Id.; Supp. Decl. of Todd Shrader
(“Shrader Supp. Decl.”) (ECF 106-5) ¶¶ 11-13. The absence of this critical
information is not, as the State alleges, a mere inconvenience. See Wash. Resp. at
29. Each of these elements is necessary to determine the scope of the project and
the tasks necessary to reach initial operations. U.S. Resp. at 24-25; Supp. Decl. of
Delmar Noyes (“Noyes Supp. Decl.”) (ECF 113-1) ¶ 22; Shrader Supp. Decl. ¶¶
11-13. And each may cause significant additional delay if not addressed as part of
the Court’s modification order. U.S. Reply at 18-20. An order that fails to account
for these uncertainties increases the likelihood that the WTP will not operate as
intended, jeopardizing the cleanup mission and risking a malfunction that could
endanger workers, the public, and the environment. U.S. Resp. at 23-24; Decl. of
Todd Shrader (“Shrader Decl.”) (ECF 76-5) ¶ 10; Shrader Supp. Decl. ¶¶ 9-10.
First among the persistent project uncertainties is the time and work needed
to resolve the primary technical issues. These issues are highly complex and their
inadequate resolution would risk significant consequences, including possible
releases of radiation once the WTP is operational. Decl. of Robert A. Gilbert
(“Gilbert Decl.”) (ECF 76-6) ¶¶ 45-46, 48, 54, 57, 59; Shrader Decl. ¶ 10.
Resolving the technical issues is an iterative and evolving scientific inquiry. U.S.
Br. at 40-42; U.S. Resp. at 21-22; Supp. Decl. of Robert A. Gilbert (“Gilbert
Supp. Decl.”) (ECF 106-1) ¶ 5; Shrader Supp. Decl. ¶ 3. Constraining the time
available to complete this inquiry may put the project and the public at risk.
Second, the parties’ proposals must account for the uncertain amount of
time and work needed to redesign the HLW Facility and, more significantly, the
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
7
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
PT Facility. Redesigning these facilities in response to technical issue resolution
may require altering designs for equipment, components, or processes, with any
changes verified to ensure that they still meet DOE’s extensive quality assurance,
nuclear safety, and other specifications. Shrader Supp. Decl. ¶¶ 3-5; Gilbert Decl.
¶ 10. However, if design changes do not meet these specifications, new issue
resolution, redesign, and verification efforts may be necessary. Id. Like technical
issue resolution, the redesign process is an engineering endeavor where results are
not guaranteed and an iterative approach is often necessary. Shrader Supp. Decl.
¶¶ 4-5; see U.S. Response Brief (“U.S. Resp.”) (ECF 106) at 21-22.
Third, substantial uncertainty will persist so long as primary WTP facilities
lack new or modified performance baselines and contracts (i.e., the documents
that define and implement how the project will be constructed, at what expected
cost, and on what schedule). U.S. Resp. at 24-25; see Noyes Supp. Decl. ¶ 22.
DOE cannot prepare an approved performance baseline, and thereafter a contract,
until technical issue resolution and redesign have concluded. Even at that point,
the preparation schedule can be unpredictable, as the contractor completes its
analysis of necessary equipment, labor, suppliers, cost, space, and other factors,
and as DOE negotiates each document consistent with federal contracting laws.
Shrader Supp. Decl. ¶¶ 12-13; Harp 3d Supp. Decl. ¶ 10(c). Although this process
is not a scientific endeavor like technical issue resolution or facility redesign, it
requires complex engineering and project planning tasks that can be time-
consuming due to the nuclear safety issues, project management concerns, and
substantial taxpayer dollars at stake. Harp 3d Supp. Decl. ¶ 10(c).
The uncertainties now affecting the WTP schedule are considerable and
consequential. When the parties agreed to the original Consent Decree, they
premised their milestones on a fully defined project. The technical issues then
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
8
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
identified had an approved path for resolution, and performance baselines and
contracts were in place for every WTP facility—outlining detailed schedules for
procurement, installation, and construction. See U.S. Br. at 61. Today, that is not
true of a single WTP facility. Noyes Supp. Decl. ¶ 22. As the Court stated in its
Second Order, “a consent decree modification should ‘retain the essential features
and further the primary goals’ of the decree, and . . . in making modifications, the
court ‘should consider the original expectations of the parties.’” Second Order at
13 (quoting Keith v. Volpe, 784 F.2d 1457, 1460, 1462 (9th Cir. 1986)). Primary
among the parties’ expectations in 2010 was that the project was governed by a
workable, reasonable plan—embodied in approved baselines and contracts—and
that the agreed-upon milestones could be achieved based upon that plan and
without risks to the public and the environment. U.S. Br. at 31, 61; see Decl. of
Benton J. Harp (ECF 76-2) (“Harp Decl.”) ¶ 52; Noyes Supp. Decl. ¶ 22. That
expectation has been turned on its head. Consequently, a modification cannot be
suitably tailored to the changed circumstances unless it thoughtfully addresses the
period of project uncertainty created by the unresolved technical issues.
B. DOE’s Second Proposal Ensures the Enforceability of Milestones While Accounting for Present Uncertainties.
1. DOE’s Proposal Pairs Enforceable Milestones with a Narrow Extension Mechanism Based on Three Areas of Uncertainty.
DOE’s second proposed modification regarding construction and
commissioning of the WTP is designed to realistically address the many variables
that affect project uncertainty. It is built on two interrelated components. First, the
modification identifies new dates for the fourteen outstanding milestones in the
original Consent Decree. United States’ Second Proposed Order (“2d U.S.P.O.”)
App. D ¶ 1. Given the uncertainties facing the project, these dates rely on
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
9
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
numerous assumptions, noted below and described further in Mr. Harp’s Third
Supplemental Declaration. See ¶¶ 6, 25-44. Second, DOE’s proposal establishes
an extension mechanism within the Consent Decree itself to negotiate and adjust
milestones if more complete information demonstrates that need. 2d U.S.P.O.
App. D ¶ 2. This mechanism ensures that the WTP is not governed by inflexible
deadlines that ignore the changing realities of the project and that will lead to
inefficiency, waste, and further delay. See U.S. Resp. at 20-25; U.S. Reply at 4-9.
It allows instead for reasonable adjustment of WTP milestones where accurate
information regarding the scientific, technical, and management constraints
demonstrates that certain assumptions used to set the milestones no longer reflect
the circumstances of the project. Harp 3d Supp. Decl. ¶¶ 8, 10-11, 21. Together,
these two components—enforceable milestones paired with a narrow extension
mechanism—will allow DOE to safely and responsibly advance Hanford’s waste
treatment mission, while maintaining the underlying structure of the Consent
Decree.
Table of Enforceable Milestones: In compliance with the Court’s Second
Order, DOE’s second proposal maintains and updates the table of enforceable
milestones included in the original Decree. Under DOE’s new enforceable
milestones, construction will be substantially complete for the LAW Facility in
2030,2 the HLW Facility in 2032, and the PT Facility in 2033. Hot commissioning
of all three facilities will be completed in 2036, with WTP initial operations to
begin in 2039. See 2d U.S.P.O. App. D ¶ 1.
2 As described below, LAW Facility dates provide for simultaneous operations
of the WTP, notwithstanding DOE’s intent to pursue Direct Feed LAW.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
10
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
The significant uncertainties described above restrict DOE’s ability to
predict precise and accurate timelines for the WTP. Consequently, the milestones
provided in the table reflect the delay to-date as well as a number of general
assumptions regarding the path forward. First, DOE assumes that technical issue
resolution will be completed on June 30, 2019, based on the present progress of
efforts to resolve the primary technical issues. Harp 3d Supp. Decl. ¶¶ 14, 34-35;
see Gilbert Decl. ¶¶ 120-23. DOE also assumes that, in light of the commitment of
resources necessary to advance and operate the LAW Facility (described below),
redesign work for the HLW Facility will be completed on December 31, 2021,
and for the more complex PT Facility on December 31, 2024. Harp 3d Supp. Decl.
¶¶ 15, 30-31, 33, 36-38. The development and execution of baselines and
contracts for each facility is assumed to take three years once redesign is
completed and verified. Id. ¶¶ 16, 32, 39-40. Ensuing periods for construction are
based on information currently being developed for the LAW Facility—where
DOE is presently working on a modified baseline and contract—with adjustments
for the greater complexity of the HLW and PT Facilities. Id. ¶¶ 32, 41; see id. ¶
43. Commissioning periods for all three facilities are set to align with the PT
Facility, which will feed waste to the other two. Id. ¶¶ 26, 42. These, and
additional, assumptions underlying the milestone dates are described in further
detail in Mr. Harp’s Third Supplemental Declaration. Id. ¶¶ 25-43.
The milestone dates incorporate a number of additional considerations to
reflect what is “realistically achievable.” See Keith, 784 F.2d at 1460. First, the
milestone dates assume that funding at current (and historical) levels is
maintained. Harp 3d Supp. Decl. ¶¶ 27-28. Excepting fiscal years 2011 and 2012,
DOE’s annual funding for the WTP has remained at $690 million (or below) over
the past eight years, Decl. of James M. Owendoff (ECF 106-6) (“Owendoff
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
11
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Decl.”) ¶¶ 19-26, and is likely to remain at $690 million in the current fiscal year
and in the foreseeable future. Harp 3d Supp. Decl. ¶¶ 27-29. Aligning WTP
Consent Decree obligations with historical WTP funding is the prudent course and
is a proper consideration for the Court. Rufo v. Inmates of Suffolk Cnty. Jail, 502
U.S. 367, 392-93 (1992) (“Financial constraints . . . are a legitimate concern of
government defendants . . . and therefore are appropriately considered in tailoring
a consent decree modification.”).
Second, the milestones account for DOE’s commitment to accelerate waste
treatment by sequencing the LAW Facility to come online first, as supported by
Direct Feed LAW, as soon as practicable. Harp 3d Supp. Decl. ¶¶ 30, 33. In its
Secord Order, the Court declined to modify the Consent Decree to include the
Direct Feed LAW approach proposed by both parties, and instructed the parties to
provide milestone dates consistent with the original Consent Decree, which
contemplates simultaneous operations of the WTP facilities. Second Order at 17-
21. However, the Court did conclude that the parties should pursue Direct Feed
LAW “voluntarily” because it “likely furthers the goals of the [Tri-Party
Agreement] to treat all of Hanford’s tank waste as expeditiously as possible”; the
Court thus concluded it “will not prohibit DOE from moving forward with the
Direct Feed LAW approach at this time.” Second Order at 19, 21.
It is DOE’s continued judgment that Direct Feed LAW is essential to
advance tank waste treatment and to support additional tank waste retrievals, and
so DOE is proceeding with steps to voluntarily bring the LAW Facility online as
soon as practicable. Harp 3d Supp. Decl. ¶ 30; see Shrader Decl. ¶ 18. This early
focus on the LAW Facility will place near-term constraints on the availability of
funding and skilled labor for other projects, and so is reflected in the timing of
construction and commissioning of the HLW and PT Facilities. Harp 3d Supp.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
12
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Decl. ¶¶ 30-31, 33. Notwithstanding DOE’s commitment to Direct Feed LAW,
however, DOE has proposed milestones for the LAW Facility consistent with
simultaneous operation of the WTP and the Court’s Second Order. See 2d
U.S.P.O. App. D ¶ 1; Second Order at 17-21.
Milestone Conditions and Extensions: The milestone table set forth in
DOE’s proposal cannot stand alone given the pervasive uncertainties at the WTP
and the substantial variability in the time that may be needed for (1) technical
issue resolution, (2) completion and verification of redesign, and (3) re-baselining
and contracting. Harp 3d Supp. Decl. ¶¶ 6, 8-10, 21-25, 44. Consequently, DOE’s
proposal establishes a mechanism that adjusts the milestone table according to
three “conditions”—one for each of those three sources of WTP uncertainty. 2d
U.S.P.O. App. D ¶ 2; Harp 3d Supp. Decl. ¶ 10-12.
Each “condition” functions in the same manner, through a four-step
process. First, for each condition there is an established trigger date. See, e.g., 2d
U.S.P.O. App. D ¶ 2.A.iii. Trigger dates represent the date by which the specified
work (i.e., resolution of technical issues, completion of redesign, or preparation of
a construction contract) can be completed without impacting identified
milestones.3 If the specified work extends past its trigger date, it demonstrates that
the underlying assumptions in DOE’s milestone table were inadequate, thus
justifying an extension of the associated milestone dates. Harp 3d Supp. Decl. ¶
11; see id. ¶ 25. Second, each condition provides for negotiations between DOE 3 As further explained in Mr. Harp’s Third Supplemental Declaration, trigger
dates for technical issue resolution and redesign work are fixed dates, while the
trigger date for re-baselining and contracting adjusts to account for any
extensions already triggered. See Harp 3d Supp. Decl. ¶¶ 14-16.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
13
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
and the State as to the proper length of an extension once the condition is
triggered. See, e.g., 2d U.S.P.O. App. D ¶ 2.A.iv. This provides the State with an
opportunity to consider up-to-date information about the project status and discuss
appropriate schedule adjustments. DOE’s proposal provides 30 days for the
parties to commence such negotiations, followed by a 90-day negotiation period.
Harp 3d Supp. Decl. ¶ 12(a)-(b). If the parties do not agree on the duration of the
extension within the 90-day period, an automatic extension will apply to the
associated milestones unless and until the extension is replaced by the Court. See,
e.g., 2d U.S.P.O. App. D ¶ 2.A.v. That automatic extension, the third step in the
process, is one year in duration (for all associated milestones) unless DOE
determines, in writing, that a different extension period is necessary. Id.; Harp 3d
Supp. Decl. ¶ 12(c). Fourth, DOE’s proposal allows the State to challenge the
duration of the automatic extension (including where DOE has determined more
than one year is necessary) in Court, where DOE’s scientific, technical, or project
management judgment may be overturned if it is found to be arbitrary or
capricious. See, e.g., 2d U.S.P.O. App. D ¶ 2.A.vi; Harp 3d Supp. Decl. ¶ 12(d).
Under DOE’s proposal, the extensions are each triggered and apply
independently; if necessary, a single milestone could be separately extended for
each of the conditions above as distinct information in each category is developed
and distinct assumptions in each category are shown to be inadequate. 2d U.S.P.O.
App. D ¶ 2.D; Harp 3d Supp. Decl. ¶ 18. In addition, the four-step mechanism
could be repeated, and an additional extension provided, for any of the conditions
if DOE later notifies the State that the work remains unresolved and a further
extension is required. See, e.g., 2d U.S.P.O. App. D ¶ 2.A.vii. During the
pendency of any extension under this process, DOE must provide the State with
regular briefings on the status of the ongoing work. See, e.g., id. ¶ 2.B.xi.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
14
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
In addition to the above mechanism, DOE’s condition for performance
baselines and contracts provides for separate adjustment of the milestone dates in
the event that the construction and commissioning dates in the ultimate contract
conflict with the dates in the table. Id. ¶ 2.C.ix. When the re-baselining and
contracting process begins, DOE will have more complete information about the
scope of the project that may contradict present assumptions about the time
needed to reach WTP initial operations. See Noyes Supp. Decl. ¶ 22. Although
DOE will seek to align the final negotiated contract to the milestone table dates,
that may not be possible due to project constraints, including budgetary limitations
and the availability of skilled labor and equipment vendors. Harp 3d Supp. Decl.
¶ 17. Accordingly, the condition for performance baselines and contracts provides
that, in the event of a conflict, DOE will designate a new milestone that reflects
current information and that will substitute for the existing milestone, unless the
Court finds that the new milestone date is arbitrary and capricious.
Finally, the proposal provides for extensions of facility hot and cold
commissioning dates as necessary to maintain simultaneous operations of the
WTP. 2d U.S.P.O. App. D ¶ 3. Because hot commissioning uses tank wastes—
which must be separated in the PT Facility and then vitrified in the HLW and
LAW Facilities—and because cold and hot commissioning must be sequenced
together, commissioning milestones for all three WTP facilities4 must remain in
alignment. Harp 3d Supp. Decl. ¶¶ 19-20, 26. Consequently, if commissioning
4 As described above, DOE has aligned LAW Facility dates to provide for
simultaneous operations, consistent with Court Order, notwithstanding its intent
to pursue Direct Feed LAW.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
milestones for the PT or HLW Facilities are extended, commissioning milestones
for the remaining facilities will be realigned accordingly.
2. DOE’s Proposal for WTP Milestones Is Suitably Tailored to the Changed Circumstances.
The approach described above is suitably tailored to the changed
circumstance, and is a measured, reasonable response to present conditions at the
WTP—conditions that differ dramatically and materially from the conditions that
existed when the Consent Decree was entered in 2010. DOE’s modification
addresses the primary changed circumstance and cause of delay: technical issues
that may require significant but still unknown changes to the plan and design of
the WTP. Harp 3d Supp. Decl. ¶¶ 6, 8-10(a), 21. The combination of enforceable
milestones and an extension mechanism responds to the changed circumstances
and promotes what is “realistically achievable” by ensuring that WTP milestones
are responsive to the uncertain timeframes for completing technical issue
resolution, redesign, and performance baselines and contracts. See Keith, 784 F.2d
at 1460; Harp 3d Supp. Decl. ¶¶ 8-12, 21-24, 44. At the same time, DOE’s
proposal ensures the State will, at all times, have enforceable Consent Decree
milestones and an opportunity to negotiate or challenge the duration of any
automatic extension period affecting those milestones. Harp 3d Supp. Decl. ¶¶ 8,
12(d).
DOE cannot reasonably or responsibly project fixed dates for the HLW and
PT Facilities at this time, and so cannot commit to a proposal that sets milestones
for these Facilities without an extension process. U.S. Br. at 57-58; U.S. Reply at
3-5. The work necessary to resolve the unforeseen technical issues, and to
incorporate resolutions into the design and management of the project, is too
uncertain, and the potential harm to workers, the public, and the environment from
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
16
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
ill-chosen and inflexible milestones is too large. Shrader Supp. Decl. ¶¶ 9-10;
Harp 3d Supp. Decl. ¶ 6, 10, 21-24, 44. Together, however, DOE’s milestone
table and extension mechanism are suitably tailored to address both the
uncertainty created by the technical issues and the Court’s conclusion that the
Decree must contain enforceable milestones.
Because numerous Consent Decree modifications are likely to be needed as
information becomes more complete, a new modification mechanism is required.
Pursuing individual extensions as each need arises may have been suitable in 2010
when there was a fully defined project and the parties had far more confidence in
the milestones. But that process does not account for the current status of the
project or the need to realign milestones with constantly developing project
information. Lengthy, recurrent extension proceedings would undermine efficient
project management and advance planning, and result in irretrievable
commitments of resources in the pursuit of impossible or unsuitable tasks that
only serve to harm the project—all while imposing unnecessary burdens on the
Court and the parties. Harp 3d Supp. Decl. ¶¶ 22-24. Securing extensions under
the current Consent Decree for milestones the parties already anticipate will need
adjusting would thus create further delay and disruption at the WTP. Id.; id. ¶ 44.
Moreover, because DOE can already anticipate the types of extensions that
may become necessary due to the uncertainties described above, provisions
addressing these extensions should be express in the Consent Decree. Otherwise,
the identified uncertainties may not later serve as a basis for an extension under
this Court’s application of Rufo. See First Order at 21 (“[I]f the change was
actually anticipated when the decree was entered, then ordinarily, modification is
not warranted.”). The State has already taken that position in this case, Wash.
Resp. at 14-15 n.13, and may do so again. Accordingly, the identified
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
17
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
uncertainties that will affect WTP milestones must be addressed by the express
terms of the modified Consent Decree, as DOE has proposed through the
extension mechanism.
Finally, because the present obstacles involve technical questions of nuclear
safety and engineering, DOE’s determinations regarding additional time needed to
resolve technical issues or verify facility redesign will reflect its expertise in such
matters. See Harp 3d Supp. Decl. ¶ 10(a)-(b), 21; U.S. Br. at 7-10. Extension
requests pursued through the Decree’s existing dispute resolution process fail to
give appropriate deference to that expertise and authority, especially given the
new issues confronting the project. And because the existing process was never
designed to address the issues inherent in establishing a new or modified baseline
or negotiating federal contracts, it fails to give adequate weight to the issues and
restrictions DOE must consider when undertaking these activities, including the
substantial public funds at stake. See Harp 3d Supp. Decl. ¶¶ 10(c), 21. When the
Decree was negotiated in 2010, the work to be performed and the estimated time
to perform it had already been determined—at DOE’s sole discretion. U.S. Br. at
31; see Harp Decl. ¶ 52. Thus, in DOE’s proposal, its determinations as to
extensions are properly assessed under an arbitrary and capricious standard, rather
than the Decree’s de novo standard for extensions under Section VII.
II. DOE’s Revised Proposal to Complete Single-Shell Tank Retrievals Is Suitably Tailored to Address Ongoing Vapor-Related Delays and Funding Constraints.
DOE proposes to complete the remaining twelve tank retrievals covered
under the Consent Decree by a new milestone date of March 31, 2024. The
Consent Decree deadline of 2022 is no longer viable due to ongoing delays
associated with tank vapor-related protective measures and funding constraints.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
18
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
In addition, DOE is proposing new and revised milestone deadlines for
completing the retrievals of two tanks—C-105 and C-111—that have proven
especially challenging to retrieve. DOE also re-proposes adjustments to
milestones concerning the staging of tank retrievals to account for best practices
developed through retrievals to date.
DOE previously explained that an average fifty percent reduction in worker
productivity associated with use of additional protective equipment (including
self-contained breathing apparatus (“SCBA”))5 will extend retrievals until
September 30, 2023. Fletcher 3d Supp. Decl. ¶¶ 2-5; ECF 148-1 at 12. The State
is well aware of these delays and the underlying conditions, having filed a lawsuit
against DOE and its contractor on September 2, 2015, alleging that tank vapors
pose an “imminent and substantial endangerment” under the Resource
Conservation and Recovery Act, 42 U.S.C. § 6972(a)(1)(B). State of Wash. v. U.S.
Dep’t of Energy, et al., E.D. Wash. No. 4:15-cv-05087. DOE still anticipates, and
its proposal assumes, that vapor-related SCBA will continue in the A and AX
Farms (which contain nine of the remaining twelve tanks to be retrieved) through
the end of September 2016. Fletcher 5th Supp. Decl. ¶ 23. However, DOE’s
proposal contains a mechanism for further extending tank retrieval milestones if
use of SCBA in the A and AX Farms continues beyond September 30, 2016. See
id. ¶ 10; 2d U.S.P.O. App. B ¶ 3. In that case, certain retrieval milestones would
5 SCBA, already in use for specific retrieval-related tasks, was instituted on a
full-time basis in an abundance of caution to guard against potential high-dose,
short-term vapor exposures. See Third Supp. Decl. of Thomas Fletcher
(“Fletcher 3d Supp. Decl.”) (ECF 148) ¶¶ 2-5.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
19
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
be extended automatically by one day for every two days in SCBA, until DOE
notifies the Court that the extension is no longer necessary. See Fletcher 5th Supp.
Decl. ¶¶ 26-27; 2d U.S.P.O. App. B ¶ 3.
In addition, the funding climate in Congress has been increasingly
constrained in recent years, with funding levels subject to disruption through
Congress’s frequent resort to “continuing resolutions” in place of appropriations
bills. See U.S. Br. at 42-45. The September 30, 2015 continuing resolution to fund
the federal government through December 11, 2015, holds funding at the fiscal
year 2015 level, although DOE needed and requested additional funds for fiscal
year 2016 to enable continued progress toward completing tank waste retrievals.
Fletcher 5th Supp. Decl. ¶¶ 18-20. This has resulted in a delay of at least two
months, primarily by limiting DOE’s ability to hire and train tank farm workers.
Id. ¶ 19. DOE’s proposed retrieval completion date of March 31, 2024, reflects
this delay, and includes a reasonable period for operational flexibility in the wake
of further effects from funding-related disruption (e.g., inability to execute
contracts for the fabrication of certain equipment). Id. ¶¶ 19-20.
Significantly, completing Consent Decree retrievals by 2024 would not
increase risks to public health or the environment as compared to 2022 or 2023.
DOE has concluded based on ongoing monitoring that the single-shell tanks are
structurally sound and that interim stabilization has greatly reduced the risk of
leakage. See Supp. Decl. of Thomas Fletcher (“Fletcher Supp. Decl.”) (ECF 106-
4) ¶¶ 12-16. In the unlikely event that an interim-stabilized single-shell tank were
to leak during the additional time to complete the twelve remaining Consent
Decree retrievals, it would not pose a threat to groundwater or to the Columbia
River. See U.S. Resp. at 43-46; Fletcher Supp. Decl. ¶¶ 22-25; Second Supp. Decl.
of Thomas Fletcher (“Fletcher 2d Supp. Decl.”) (ECF 113-2) ¶ 36.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
20
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
DOE also proposes specific Consent Decree modifications for two tanks.
First, DOE continues to experience difficulties with retrieval of the waste in tank
C-111. See id. ¶ 21. Although DOE recently resolved two nuclear safety-related
issues that arose earlier this year, those issues have further delayed C-111
retrievals. Fletcher 5th Supp. Decl. ¶¶ 10-16. In light of these issues, DOE has
identified April 30, 2016, as the most appropriate date for completing the C-111
retrieval. Id. ¶ 16. Second, as DOE described in previous filings, retrieval of tank
C-105 has been delayed due to funding constraints, ECF 94 ¶ 44; ECF 76-4 ¶ 22,
and difficulties identifying tank waste properties, Fletcher 2d Supp. Decl. ¶¶ 18-
20. DOE has initiated negotiations regarding retrieval technology for tank C-105,
as anticipated by milestone B-1A in DOE’s original proposal, and now commits to
propose within sixty days after the State’s approval of a Tank Waste Retrieval
Work Plan a milestone for completion not to exceed September 30, 2022. Fletcher
5th Supp. Decl. ¶¶ 7-9. Finally, DOE re-proposes to stage retrieval milestones to
allow for the efficient installation of tank infrastructure before retrievals. See U.S.
Br. at 59; Shrader Decl. ¶ 44; 2d U.S.P.O. App. B ¶ 1.
III. DOE’s Proposed Accountability Measures are Suitably Tailored to Assist the Parties in Responding to Project Disruption. DOE re-proposes the three new accountability measures set forth in its first
proposal. First, DOE will file annual reports describing DOE’s compliance with
the Consent Decree. Second, DOE will provide more detailed reporting if there is
a “serious risk” that DOE will not meet a milestone. Third, DOE will provide a
comprehensive analysis and regular briefings regarding technical issue resolution.
These measures, which augment numerous reports already required by the Decree,
address the Court’s interest in greater transparency when unforeseen obstacles
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
21
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
disrupt DOE’s compliance with Consent Decree milestones. They are also tailored
to the specific underlying facts warranting modification of the Decree.
A. Accountability Proposals Must Reflect the Particular Factual Causes of Disruption Underlying the Changed Circumstances.
In its Orders, the Court found two changed circumstances relevant to
additional accountability in the Consent Decree: “(1) the extent of DOE’s failure
to comply with the Consent Decree terms; [and] (2) DOE’s unilateral decision to
cease construction of the WTP.” Second Order at 6. As the record demonstrates,
the bases for both of these changed circumstances identified by the Court—the
extent of the present disruption and DOE’s corresponding management decisions
to address that disruption—are direct consequences of the unresolved technical
issues themselves (another changed circumstance). Moreover, the unresolved
technical issues, and the resulting disruption, would not have been prevented by
additional reporting measures. These facts must be considered in evaluating the
suitability of the parties’ accountability proposals.
First, as the Court has recognized, DOE’s inability to meet the remaining
milestones in the Consent Decree is a result of the persistence of unresolved
technical issues at the WTP. However, the fact that DOE has been confronted with
unforeseen obstacles that will impact its compliance going forward does not mean
it has failed to comply with the terms of the Consent Decree. In fact, the Decree
anticipates that unforeseen obstacles might affect milestones and so specifically
provides that “if DOE has requested an extension of a deadline, DOE shall not be
deemed to be in violation of that deadline while DOE’s request is being
evaluated” and until “the date on which the Court acts on the request.” CD ¶ IX–C
(emphasis added). DOE has fully complied with that process, and thus with the
Consent Decree, providing notices of risk before any milestones were missed and
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
22
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
before construction was suspended at the WTP;6 engaging the State on the issues;
and developing a proposal—after necessary consideration of the problem and
potential solutions—to modify the Decree to account for the changed
circumstances.7 See U.S. Br. at 26-28; U.S. Resp. at 12-16. Consequently,
although the Court notes the “extent of DOE’s failure to comply with the Consent
Decree terms,” the “extent” of milestones at risk does not reflect non-compliance
but rather reflects the pervasive nature of the unresolved technical issues. 8
Second, DOE directed its contractor to suspend construction at the HLW
and PT Facilities in August 2012 as a direct consequence of the technical issues.
U.S. Br. at 49. In doing so, DOE acted consistent with its exclusive expertise in
matters of nuclear safety under the Atomic Energy Act (“AEA”), and its necessary
management discretion to prevent wasteful expenditure of taxpayer funds and 6 The Court in fact rejected Intervenor State of Oregon’s allegation that DOE
provided insufficient information when reporting risks to milestones—a report
the Court noted was “the same notification . . . that it submits to Washington,”
First Order at 15—or that this constituted a changed circumstance. Id. at 64. 7 Had this process been insufficient, the State could have filed a motion to
enforce the Consent Decree or sought sanctions (which, as the Court noted, the
State did not do, see First Order at 17 n.7). 8 These facts are also relevant to the parties’ positions concerning double-shell
tanks, as the Court’s Second Order found that “DOE’s history of noncompliance
with Consent Decree milestones and repeated delay retrieving Hanford’s
[single-shell tanks]” justified a contingent requirement to build new double-shell
tanks. Second Order at 25, 27. As discussed infra, Section IV, such a contingent
requirement is not appropriate on those or any other grounds.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
23
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
minimize the work to be redone after issue resolution. Id. The mere fact that the
Decree “contains no mention of a unilateral cessation of construction,” First Order
at 58, cannot be a prohibition, or DOE could take virtually no actions at the Site at
all. On the contrary, because the suspension of construction was not a new cause
of milestone delay—the delay being attributable to the underlying technical
issues—it falls within DOE’s management discretion. Nor should the cessation of
work have come as a surprise to the State. By the time the decision was made,
DOE had already notified the State that technical issues imperiled construction
and commissioning milestones at the HLW and PT Facilities, and the potential
disruption posed by the technical issues was already apparent. U.S. Resp. at 14-
16; Harp Decl. ¶ 57; Supp. Decl. of Benton J. Harp (ECF 106-3) ¶¶ 10-11.
Third, even if additional accountability provisions—including the State’s
unduly burdensome proposals, see U.S. Resp. at 36-38—had been part of the
Consent Decree from the start, they would not have forestalled the persistence of
the technical issues, the consequent “risk” notices, or the sound conclusion that
these issues required suspension of construction at portions of the WTP. The
unresolved technical issues were complex and unforeseen, as the Court has held,
First Order at 45-47, and were the subject of extensive expert oversight. Gilbert
Decl. ¶¶ 12-13, 65; Gilbert Supp. Decl. ¶ 23. And as noted above, DOE’s actions
in the face of the technical issues were consistent with good project management.
U.S. Reply at 16-17. Because the changed circumstances flow from the underlying
technical issues, they should not be interpreted as an invitation to propose
sweeping modifications to constrain DOE’s project management (or to justify new
project elements, such as new double shell tanks). Rather, accountability
provisions must be tailored to increase the flow of information when responding
to project disruption—like that caused by the unresolved technical issues. See
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
24
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Rufo, 502 U.S. at 391 (“A court should do no more” than what is suitably
tailored). As explained below, DOE’s proposal properly accounts for the
circumstances that have necessitated changes to the Decree, while preserving the
flexibility needed to safely and efficiently respond to new challenges.
B. DOE’s Proposal Is Suitably Tailored to Increase Transparency Without Constraining Effective and Safe Management of the WTP.
DOE’s proposal supplements DOE’s existing reporting obligations with
three additional accountability measures. These measures are suitably tailored
because they support judicial enforceability of the Decree, bolster the information
available to the State when issues arise that may impede the project, and apprise
the State of developments and operational decisions regarding the current issues
impeding the project. First, the requirement for DOE to file annual reports with
the Court assessing DOE’s compliance with the Decree will assure that the Court
is aware of DOE’s current compliance efforts and informed about developments
that may necessitate modifications in the future. 2d U.S.P.O. App. D ¶ 5.A. This
requirement conforms to the Court’s direction that the parties’ proposals address
additional reporting “regarding DOE’s progress toward completing [the Consent
Decree] milestones.” See Second Order at 32.
Second, DOE will be required to provide detailed reporting in the event
obstacles—including new technical issues—arise that threaten DOE’s ability to
comply with the Consent Decree milestones. 2d U.S.P.O. App. D ¶ 5.B. This
measure is consistent with the Court’s conclusion that the Decree should include
provisions that “explain[] why DOE cannot meet a certain milestone and how it is
remedying the delay.” Second Order at 32. Specifically, DOE would be obligated
to augment its current notifications under the Decree that “a serious risk has arisen
that DOE may be unable to meet” a milestone, see CD ¶ IV-C-3, by providing the
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
25
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
State with an explanation of the reasons for the notification and DOE’s planned
actions to address the identified risk. 2d U.S.P.O. App. D ¶ 5.B.
Third, DOE will enhance reporting related to the technical issues that have
caused the present need for modification. DOE will provide the State with a
detailed update on the progress of and forthcoming work to advance technical
resolution one year after the Court’s modification is entered. In addition, DOE
will provide progress briefings to the State every 90 days to keep it informed as to
the course of technical issue resolution.9 Id. ¶¶ 2.A.viii-ix; U.S. Br. at 54.
Together, these proposals strengthen DOE’s obligations under the Consent
Decree to provide the State and the Court with timely, and sound, information
regarding unresolved technical issues. Broader modifications aimed at
constraining DOE’s sphere of operational discretion (or delaying such discretion
until after a court proceeding) would improperly curtail DOE’s ability to protect
public health and safety. Contrary to the Supreme Court’s warning that consent
decree modifications should address changed circumstances but “do no more,”
Rufo, 502 U.S. at 391, such modifications would also impede DOE’s ability to
manage the project efficiently, cost-effectively, and consistent with its extensive
obligations under federal project guidelines and the AEA.
IV. A Contingent Requirement to Construct New Double-Shell Tanks Is Not Supported By—or Suitably Tailored to Address—Any Changed Circumstance in this Case. The Consent Decree should not be modified to require construction of new
double-shell tanks. As discussed below, the Court has rejected the State’s proposal
9 Additional reporting requirements would apply if an extension is triggered
under the WTP milestone appendix. See supra at 13.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
26
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
that DOE be required to construct additional double-shell tank capacity either as
“mitigation” for WTP delays, or because retrieval delays under the Consent
Decree may (the State alleges) delay the tank retrievals governed by the Tri-Party
Agreement. See Second Order at 22. Yet, the Court has indicated that it will
nonetheless modify the Consent Decree to require construction of new double-
shell tanks as mitigation if DOE fails to “reduce a predetermined amount of waste
through Evaporator campaigns [to support the retrievals required by the Decree]
by a given date,” and directed the parties to submit proposed conditions for
building double-shell tanks. Id. at 27. Such a contingent obligation to construct
new double-shell tanks is neither authorized nor suitably tailored to address any
relevant changed circumstances in this matter.
Should the Court nonetheless proceed to modify the Consent Decree to
include a contingent requirement for DOE to construct new double-shell tanks,
DOE submits a proposal, as directed by the Court, describing the terms and
conditions to govern such potential construction (infra Section IV.D).
A. No Changed Circumstances Warrant New Double-Shell Tanks. 1. No Relevant Changed Circumstances Exist.
Modifying the Consent Decree to require double-shell tank construction
would be improper because it would not address any existing changed
circumstances the Court has identified. Modification of a consent decree may
occur only where there has been an unanticipated and “significant change either in
factual conditions or in the law” that makes “compliance with the consent decree
more onerous, unworkable, or detrimental to the public interest.” Labor/Cmty.
Strategy Ctr. v. L.A. Cnty. Metro. Transp. Auth., 564 F.3d 1115, 1120 (9th Cir.
2009). Further, a proposed modification must be closely tied to a particular
changed circumstance; specifically, the modification must be “suitably
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
27
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
tailored . . . to resolve the problems created by the change in circumstances” and
“do no more[.]” Rufo, 502 U.S. at 391. Contingent double-shell tank construction
does not meet this tailoring principle because there are no relevant “changed
circumstances” that new tanks are suitably tailored to address.
Requiring new double-shell tanks based on potential future changed
circumstances—in particular, the failure of the evaporator DOE routinely uses to
reduce the volume of retrieved wastes—would be improper for at least two
reasons. See Second Order at 27. First, the State never argued in its prior briefs,
and the Court has never found, that any aspect of DOE’s present retrieval
protocol, including the Evaporator, constitutes a changed circumstance. The
State’s mere speculation, raised for the first time during the July 23, 2015 oral
argument, that DOE’s existing protocols may not prove adequate in the future to
reduce enough waste for DOE to timely retrieve the remaining twelve Consent
Decree tanks does not establish a changed circumstance. To the contrary, by not
previously raising the assertion in its briefs, the State waived this argument. See
Second Order at 32 (describing the scope of the current stage of the proceedings
as limited to submission of modified proposals and briefs in support, and directing
that the proposal “may not incorporate any additional tasks not previously
submitted to the Court”); see Cromeens, Holloman, Sibert, Inc. v. AB Volvo, 349
F.3d 376 (7th Cir. 2003) (argument raised for the first time in a district court
summary judgment reply brief is waived).
Second, implicit in the case law is the concept that a court’s authority to
modify a consent decree is limited to situations where circumstances have already
changed (past tense). See, e.g., Rufo, 502 U.S. at 385 (unanticipated upsurge in
inmate population); First Order at 53 (finding these existing changed
circumstances cited by DOE: technical issues affecting WTP design, funding and
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
28
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
manpower issues, and technical difficulties and equipment failures affecting tank
retrievals); id. at 61 (finding these existing changed circumstances cited by the
State: “the quantity of at-risk milestones, the missed deadlines, DOE’s unilateral
cessation of the WTP construction, and the leaking [double-shell tank]”).
Indeed, the Court’s predicate inquiries as to whether the parties had
anticipated the changed circumstances—and whether those changed
circumstances would make compliance with the Decree more onerous,
unworkable, or detrimental to the public interest—logically depended on whether
the changes at issue had already occurred. See First Order at 43-51, 55-60.
Modifying the Consent Decree now to address potential Evaporator performance
shortfalls in the future would exceed the Court’s authority in these proceedings
because there are no relevant existing changed circumstances to justify any such
modification.
Nor is DOE’s alleged “history of non-compliance with the Consent Decree
milestones and repeated delay retrieving Hanford’s [single-shell tanks]” a valid
basis for imposing a contingent obligation to construct new double-shell tanks.
See Second Order at 25; id. at 27. DOE’s alleged past non-compliance with
certain Consent Decree terms could not possibly support a new (and unrelated)
contingent requirement—pegged solely to future potential changed
circumstances—to build new double-shell tanks. As discussed above, courts lack
authority to predicate consent decree modifications on events that have not yet
(and may never) occur. Moreover, past retrieval delays have been tied to specific
causes (e.g., specific equipment failures and funding challenges) that are unrelated
to failures with use of the Evaporator. An exceedingly costly and resource-
intensive requirement to build double-shell tanks would not be commensurate
with or tailored to address those past delays. Nor would such a requirement be
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
29
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
appropriate to address the limited delay that might result from any future issues
with the Evaporator.
2. Construction of New Double-Shell Tanks Would Not Be Suitably Tailored to Address Any Changed Circumstances.
Nor are the existing changed circumstances identified by the Court a basis
for requiring double-shell tanks. Among those changed circumstances, the only
one arguably related to DOE’s ongoing retrieval protocols is the internal leak in
double-shell tank AY-102. See First Order at 59-60. The Court found that having
that tank offline will “likely . . . slow the tank retrieval process.” Id. at 61. But this
circumstance does not justify the Court’s proposed contingency for new double-
shell tanks, and nothing in the record establishes otherwise. Evaporator
performance is not influenced by the need to retrieve the waste from AY-102, and
DOE has already explained that the loss of AY-102 storage space “was never
necessary to” and “will not affect DOE’s schedule for completing the remaining
single-shell tank retrievals required by the Consent Decree,” Fletcher 3d Supp.
Decl. ¶¶ 7-9. The State has provided no evidence to rebut that conclusion.
Nor did the State in its briefs argue that the potential loss of AY-102
necessitated construction of double-shell tanks to facilitate the Consent Decree
tank retrievals. To the contrary, the State argued only that the AY-102 leak was a
changed circumstance requiring DOE to construct new double-shell tanks to
facilitate Tri-Party Agreement tank retrievals. Wash Br. at 51-54. Indeed, the State
estimated that there would be approximately 4.8 million gallons of excess usable
double-shell tank space even after the remaining twelve tanks under the Consent
Decree are retrieved and tank AY-102 is taken out of service. Wash. Resp. at 38
n.23; Decl. of Jeffery Lyon (“Lyon Decl.”) (ECF 84) ¶¶ 24, 29. Moreover, the
Court rejected the State’s argument, concluding that the Tri-Party Agreement and
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
30
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
the single-shell tank retrieval milestones contained therein are beyond the Court’s
modification authority in these proceedings. Second Order at 22. Accordingly, the
Court’s earlier finding regarding tank AY-102 provides no basis for requiring
double-shell tanks to support Consent Decree tank retrievals. In sum, a
modification requiring new double-shell tanks on a contingent basis if the
Evaporator fails to perform as expected is not tailored to address any relevant,
existing changed circumstance. Accordingly, such a modification is neither lawful
nor suitably tailored.
B. New Double-Shell Tanks Are Beyond the Scope of the Decree, Not Realistically Achievable, and Contrary to the Public Interest.
A consent decree modification must not expand the scope of the decree,
impose new requirements that are unduly burdensome, costly, or otherwise
unjustified, or be inconsistent with existing law. See Rufo, 502 U.S. at 391
(modification must be tailored to address problems created by changed
circumstances and “do no more”). Even if one or more of the alleged changed
circumstances discussed above were relevant, a contingent obligation to build new
double-shell tanks would not satisfy these modification criteria.
1. New Double-Shell Tanks Are Beyond the Scope of the Consent Decree Because They Are Exclusively Addressed By the Tri-Party Agreement and Are Unnecessary to Complete Retrievals.
The Court has acknowledged that the Consent Decree covers a defined,
limited scope: construction and operation of the WTP, the retrieval of waste from
nineteen single-shell tanks, and related reporting. CD ¶ X-A (defining “matters
covered” by the Decree); see Second Order at 4-5; id. at 25-26 (acknowledging
the well-established limits on courts’ authority to impose new obligations).
Modification of a consent decree is not an invitation to reconsider or renegotiate
the parties’ essential agreement, see Rufo, 502 U.S. at 391-92, and courts may not,
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
31
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
absent exceptional circumstances, impose burdens on the defendant beyond those
required by the decree’s original terms. United States v. Armour & Co., 402 U.S.
673, 681-82 (1971); Keith, 784 F.2d at 1460.
As an initial matter, and as the State has pointed out, the Tri-Party
Agreement governs potential adoption of new double-shell tank construction
requirements “as a response to potential . . . insufficient [double-shell tank]
capacity[.]” Wash. Br. at 20. The parties explicitly agreed in the Consent Decree
that such requirements are within the exclusive province of the Tri-Party
Agreement. See CD ¶ XI-A (“the Decree shall not give the court jurisdiction over
the [Tri-Party Agreement] or otherwise govern the [Tri-Party Agreement] or its
enforcement”). The Court should decline to modify the Consent Decree to impose
an obligation to build new double-shell tanks because that issue is addressed
within the exclusive bounds of the Tri-Party Agreement. See U.S. Br. at 65-67;
see also ECF 106-7 (TPA, Appendix D, Milestone M-062-45, Item 2 (providing
for negotiations between the Washington State Department of Ecology and DOE
regarding potential construction of new double-shell tanks)). Construction of new
double-shell tanks is fundamentally different in kind and scope than the limited
tank retrieval and WTP construction and initial operations requirements in the
Consent Decree, and should therefore be rejected.
Moreover, the Court’s stated plan to require DOE to build additional
double-shell tanks in the event of Evaporator failure, see Second Order at 27,
would not further—and in fact would hinder—DOE’s completion of the
remaining Consent Decree tank retrievals. Such a requirement is unnecessary in
light of the improbability of a future shortfall in double-shell tank space, see
Fletcher 5th Supp. Decl. ¶¶ 28-45, and also unjustified in light of more tailored
options to mitigate any potential shortfall should the Evaporator fail.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
32
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Evaporator performance is highly unlikely to impede single-shell tank
retrievals under the Consent Decree. DOE currently has 3.31 million gallons of
double-shell tank storage capacity available for retrievals, and will need an
additional 5.9 million gallons to accomplish the twelve remaining retrievals.
Fletcher 5th Supp. Decl. ¶ 81; see 2d U.S.P.O. App. E ¶ 1.A. A series of planned
Evaporator campaigns will allow DOE to create the additional space needed, and
likely more. As noted above, even the State’s own estimates confirm that a lack of
double-shell tank space is not expected to impede those retrievals. Wash. Resp. at
38 n.23; Lyon Decl. ¶¶ 24, 29. Indeed, the State only suggested that Evaporator
performance might affect needed double-shell tank space after the retrieval of
these twelve tanks, see Wash. Br. at 53, but the Court has already ruled that such
future additional retrievals are beyond the scope of the Consent Decree, Second
Order at 22.
DOE’s most recent assessment of the capability, reliability, and projected
performance of the Evaporator confirms that the facility will reduce waste volume
in double-shell tanks by at least 5.9 million gallons between 2016 and 2021. See
Fletcher 5th Supp. Decl. ¶¶ 32-45; id., Ex. C at 14, Table 3-3. The Evaporator is
“mechanically sound and capable of sustained operation,” and has a demonstrated
ability “to process large volumes of feed in a short period of time.” Fletcher 5th
Supp. Decl., Ex C. at 19. Even using a conservative assumption that the
Evaporator will operate approximately fourteen percent of its permitted operation
time, and taking into account contingencies such as the possibility of an 18-month
outage, DOE estimates that the Evaporator will reduce an average of
approximately one million gallons of waste per year. Fletcher 5th Supp. Decl. ¶¶
42-43; id., Ex. C. at 14, Table 3-3. Analysis demonstrates that the Evaporator will
perform reliably and ensure adequate double-shell tank space to complete the
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
33
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
remaining retrievals required under the Consent Decree. Fletcher 5th Supp. Decl.
¶¶ 33-39. Additional measures such as new double-shell tanks are not needed to
meet the retrieval obligations of the Decree, and are therefore beyond its scope
and unnecessary.
As DOE has noted previously and above, the State’s recent skepticism
regarding the Evaporator’s performance conflicts with its own proposal and
declarations in this case, and is not substantiated by the facts. See Fourth Supp.
Decl. of Thomas Fletcher (“Fletcher 4th Supp. Decl.”) (ECF 153) ¶¶ 7-14;
Fletcher 5th Supp. Decl. ¶ 30; Wash. Resp. at 38 n.23; Lyon Decl. ¶¶ 24, 29. This
precludes the State from now reversing course to challenge the adequacy of the
Evaporator or the estimated tank space available. In any event, the State’s latest
contrary argument regarding the Evaporator, raised for the first time during the
July 23, 2015 oral argument, is unsupported. For example, the State’s declarations
rely heavily on statements in River Protection Project System Plans 6 and 7
regarding uncertainty in double-shell tank space management. Fourth Supp. Decl.
of Jeffrey Lyon (ECF 150) ¶¶ 8-19. But System Plans are long-term planning
documents that do not reflect the current status of facts on the ground. The State’s
reliance on System Plan 7 is particularly unhelpful, as it was based solely upon
certain project assumptions selected by the State that DOE believes are unrealistic.
Fletcher 5th Supp. Decl. ¶¶ 78-79. DOE’s current assessment confirms that the
Evaporator is mechanically sound and will perform at a level of efficiency
sufficient to ensure ample double-shell tank space and accomplish the retrievals.
Fletcher 5th Supp. Decl. ¶¶ 33-39; see also Fletcher 4th Supp. Decl. ¶¶ 8-14. New
double-shell tanks would shatter the bargain agreed to by the parties.
Nor would new double-shell tanks be appropriate even as a backstop. From
a technical perspective, as set forth in detail in Mr. Fletcher’s Fifth Supplemental
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
34
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Declaration, DOE has several much more efficient and effective options if
unanticipated Evaporator performance issues were to result in a shortfall in
double-shell tank space. Fletcher 5th Supp. Decl. ¶¶ 52, 63-69. Among DOE’s
potential mitigation options would be: (1) additional or longer evaporation
campaigns, (2) modifications to the Evaporator to improve efficiency, (3)
implementation of alternative technologies or waste management practices, or (4)
construction of a new evaporator. Id. ¶¶ 65-67. Compared to double-shell tank
construction, each of these options would be a less expensive, more efficient, and
faster means of addressing any Evaporator waste-reduction shortfalls. Id. ¶ 53.
Finally, as DOE has observed before, new double-shell tanks would not be
built in time to affect the pace of the twelve remaining retrievals. Fletcher 4th
Supp. Decl. ¶ 16; Fletcher 5th Supp. Decl. ¶¶ 52, 62. Given that a double-shell
tank would take approximately eight to ten years to construct, Fletcher 4th Supp.
Decl. ¶ 16; Fletcher Supp. Decl. ¶ 37, it is almost certain that the tank would not
be available until long after the twelve remaining retrievals required under the
Consent Decree are complete. Fletcher 5th Supp. Decl. ¶¶ 52, 62. A contingent
requirement to construct new double-shell tanks thus would not further the
primary objectives or comport with the limited scope of the Consent Decree. The
Court therefore should not impose such a modification.
2. Building New Double-Shell Tanks Is Not Realistically Achievable or In the Public Interest.
A significant, inherent impediment to building new double-shell tanks is the
financial cost of such an endeavor. See Rufo, 502 U.S. at 392-93 (“Financial
constraints . . . are appropriately considered in tailoring a consent decree
modification.”). DOE projects that new double-shell tanks would cost between
$85 million to $150 million per tank for one-million-gallon tanks, depending on
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
35
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
their number, configuration, and location. Fletcher Supp. Decl. ¶ 35; Fletcher 5th
Supp. Decl. ¶ 55. DOE has previously explained the financial constraints on the
tank waste treatment mission at Hanford, and why the excessive cost of
constructing new double-shell tanks would likely jeopardize other important
nuclear cleanup activities at Hanford and around the Nation. U.S. Resp. at 41-43;
Owendoff Decl. ¶¶ 16-35; Fletcher Supp. Decl. ¶¶ 22-38. Accordingly,
construction of new double-shell tanks would not be “realistically achievable.”
In any event, there are no countervailing benefits in the public interest. See
Rufo, 502 U.S. at 392 (“a court should surely keep the public interest in mind in
ruling on a request to modify”). To the contrary, construction of new double-shell
tanks would not appreciably reduce the risk of groundwater contamination at
Hanford. As DOE has described in detail, the evidence indicates that the risk of
single-shell tank leakage will not be significantly greater due to the delay in WTP
operations. U.S. Resp. at 43-46; U.S. Reply at 26. Moreover, future leaks from
Hanford’s single-shell tanks would not pose an immediate or near-term threat to
public health, and long-term modeling demonstrates that even a large-volume leak
would not significantly increase risks to groundwater or the Columbia River. Id.;
Fletcher Supp. Decl. ¶¶ 22-25; Fletcher 2d Supp. Decl. ¶ 36; Fletcher 5th Supp.
Decl. ¶ 69. Construction of new double-shell tanks is therefore not justified from a
risk-reduction perspective.
Nor is the public interest served by rigid adherence to a given retrieval
completion date (whether 2022, 2023, or 2024) as a basis to compel new double-
shell tank construction. In the event of an Evaporator performance issue, it may
well be in the public interest (and appropriate based on resource considerations) to
move that completion date rather than construct new double-shell tanks. Fletcher
5th Supp. Decl. ¶ 69. The Court should not at this juncture foreclose such a
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
36
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
potentially suitably-tailored modification, especially given that the Consent
Decree itself recognizes that moving dates may be an appropriate solution to a
changed circumstance. Consent Decree ¶¶ VII.B (allowing amendment to
milestone deadlines), VII.D. While the Court has accepted the State’s assertion,
offered for the first time at oral argument, that certain dates in the Consent Decree
are “material,” such a distinction makes little sense. See Second Order at 19
(ruling that “2022” is a “material term” in the context of WTP initial operations).
Any term of the Consent Decree could conceivably be material, depending on the
context in which it is invoked. The Court should reject the State’s attempt to
elevate certain dates in the Consent Decree in such a way that they are sacrosanct:
if a consent decree deadline becomes unworkable or contrary to the public interest
due to changed circumstances, then a court should assess a full range of potential
solutions, including an extension of that deadline.
C. Mandating New Double-Shell Tanks on a Contingent Basis Is Inconsistent with the Atomic Energy Act.
A contingent requirement to build new double-shell tanks would be
inconsistent with DOE’s determination pursuant to the AEA that new double-shell
tanks are not required for the retrieval of waste from single-shell tanks. DOE has
concluded in the Final Tank Closure & Waste Management EIS that new double-
shell tanks would not benefit the tank waste treatment mission. U.S. Resp. at 52.
The present delays have not altered that conclusion. Fletcher Supp. Decl. ¶ 30.
Indeed, building new double-shell tanks would likely further delay WTP initial
operations due to funding and logistical constraints. Id. ¶ 31. As DOE has
explained, new double-shell tanks would be a massive capital construction project
that would require years to complete and could cost hundreds of millions of
dollars (or more, depending on the mandated amount of new tank space), see U.S.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
37
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Resp. at 51–55, without reducing risks to groundwater, id. at 43-46. These
determinations, made pursuant to DOE’s AEA authority, deserve substantial
weight and militate against a contingent requirement to build new double-shell
tanks.
D. In the Alternative, DOE Proposes That New Double-Shell Tanks Be Required Only If Failure to Achieve Yearly Targets for Aggregate Tank Waste Volume Reduction Cannot Be Mitigated.
For the reasons discussed above, it would be improper to modify the
Consent Decree to include a contingent obligation to construct new double-shell
tanks. Most critically, the lack of double-shell tank space is not projected to limit
retrieval of the remaining twelve single-shell tanks and would inevitably impede
rather than expedite retrievals given funding and other resource constraints.
However, in accordance with the Court’s Second Order, and subject to
DOE’s reservation of rights, DOE proposes a modification that ensures that
double-shell tanks will only be built if more efficient, cost-effective measures are
not available. DOE’s proposal sets annual benchmarks for Evaporator
performance; if these targets are not met, DOE’s proposal ensures that DOE has a
first opportunity to implement alternative measures adequate to mitigate any
unexpected shortfalls in Evaporator performance. Only after consideration of
these alternatives will double-shell tanks be considered. This process, paired with
additional conditions that address public interest factors, is designed to capture
salient variables that responsible engineers, project managers, and policy makers
must consider to ensure that faster and more cost-effective alternatives are
exhausted before launching upon a costly new construction project. For this
reason, DOE’s proposal is necessarily complex and deliberate. The alternative of a
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
38
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
rigid and simplistic requirement to construct double-shell tanks may be
superficially appealing, but would be imprudent and unworkable in practice.
1. Any Contingent Obligation to Build New Double-Shell Tanks Should Be Based on Failure of the Evaporator To Achieve Predetermined Annual Tank Waste Volume Reductions.
Under DOE’s longstanding tank retrieval protocol, DOE plans to reduce
tank waste volume by at least 5.9 million gallons through a series of planned
Evaporator campaigns between 2016 and 2021 (with the potential for additional
campaigns in 2022 and 2023). 2d U.S.P.O. App. E ¶ 1.A. This reduction will be
sufficient to complete the nine A and AX Farm tank retrievals without the need
for new double-shell tanks. Fletcher 5th Supp. Decl. ¶ 44.10 Accordingly, DOE’s
proposal premises contingent tank construction on DOE’s ability to meet this
Evaporator target, or to otherwise demonstrate that adequate space exists to
complete the nine retrievals. DOE would file annual reports with the Court
identifying the target amount of tank waste volume to be reduced that year (which
will vary year-to-year based on the specific contents of the tanks being retrieved),
to reach the overall target of 5.9 million gallons. 2d U.S.P.O. App. E ¶ 2.B.
In addition to the annual Evaporator target, each annual report will also
contain a statement and supporting data as to whether the Evaporator achieved the
waste volume reduction target from the prior year. Id. ¶ 2.A. If at the end of the
year the anticipated waste volume reduction has not been achieved, DOE will
explain in the report whether and how it will be able to recover the shortfall. Id. ¶¶
2.D-E. If DOE identifies a means of recovering the shortfall that will meet DOE’s
10 There is currently adequate double-shell tank space to accomplish retrievals of
the C Farm tanks without use of the Evaporator. Fletcher 5th Supp. Decl. ¶ 33.
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
39
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
total Evaporator target for the nine retrievals, including by reducing additional
waste volume in future Evaporator campaigns, then the obligation to build new
tanks will not be triggered. See id. But, if the Evaporator cannot meet its annual
target due to inadequate waste feed, the obligation to build new tanks will not be
triggered; instead, the time to achieve the required waste volume reduction would
be extended in proportion to the amount of time that sufficient waste feed was
unavailable, unless DOE determines a different extension is necessary. Fletcher
5th Supp. Decl. ¶ 50; see 2d U.S.P.O. ¶ 1.B. Accordingly, a new double-shell tank
will only be constructed if DOE cannot first identify an alternative means to meet
its waste volume reduction target. Id. ¶ 2.F. If this obligation is triggered,
consistent with further conditions noted below, a tank (or tanks) must be placed
into service within ten years to hold a volume of waste equivalent to the shortfall
(i.e., the difference in volume between the target and actual waste volume reduced
when the tank building obligation was triggered). Id. ¶¶ 4.A-B.
Linking the conditional requirement to build new double-shell tanks to
actual Evaporator performance, as demonstrated by reductions in double-shell
tank waste volume, is consistent with the Court’s emphasis on keying construction
to whether the Evaporator “reduce[s] a predetermined amount of waste . . . by a
given date,” Second Order at 27.
2. Placing Conditions on Double-Shell Tank Construction Is Necessary Because There Are More Effective Means of Maintaining the Pace of Retrievals.
In addition to the process described above, DOE’s proposal identifies
additional necessary conditions on the obligation to construct new double-shell
tanks. The obligation to build new double-shell tanks, if triggered, will be
suspended if DOE determines at any time that either (1) “[t]he cost of constructing
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
40
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
and placing in service additional double-shell tanks would result in diversion of
funds that would jeopardize DOE’s ability to undertake cleanup activities
important to protect public health and the environment,” or (2) “[t]he detriments
of constructing and placing in service additional [double-shell tanks] are greater
than the detriments to the Hanford tank waste project or the risk to public health
and the environment from any delay in completing” the remaining Consent
Decree retrievals. 2d U.S.P.O. App. E ¶¶ 3.A-B. The tank construction obligation
would also be suspended if mitigation measures implemented thereafter can
recapture the shortfall or if the remaining retrievals can be completed as soon as or
sooner than would be achieved were new DSTs to be constructed. Id. ¶¶ 3.C-D.
These conditions are vital not only to ensure that any such modification to
the Consent Decree is “realistically achievable,” Keith, 784 F.2d at 1460, but to
ensure that tanks are not mandated despite the ready availability of equally (or
more) effective alternative means of addressing or compensating for Evaporator
performance issues, or where compliance with such a mandate would endanger
public health or the environment. DOE’s proposal also accommodates practical
engineering and project management considerations as a check against what might
otherwise constitute an illogical or environmentally-unsound undertaking.
CONCLUSION
For these reasons, the United States respectfully requests that the Court
grant DOE’s original proposed Consent Decree modification (except as to
Appendix B, which should be modified as set forth in new Appendix B in the
attached Proposed Order). Alternatively, the United States submits that the
attached Proposed Order contains revised Consent Decree modifications
consistent with the Court’s rulings in its August 13, 2015 Order.
Respectfully Submitted,
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
41
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
JOHN C. CRUDEN Assistant Attorney General Environment & Natural Resources Division United States Department of Justice MICHAEL C. ORMSBY United States Attorney Eastern District of Washington /s/ David. J. Kaplan DAVID J. KAPLAN ELIZABETH B. DAWSON CHLOE H. KOLMAN AUSTIN D. SAYLOR Environmental Defense Section P.O. Box 7611 Washington, D.C. 20044 (202) 514-0997 (Kaplan) (202) 514-8293 (Dawson) (202) 514-9277 (Kolman) (202) 514-1880 (Saylor) VANESSA WALDREF Assistant United States Attorney 920 West Riverside Ave., Suite 300 Spokane, WA 99201 (509) 353-2767
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
U.S. BRIEF IN SUPPORT OF ITS SECOND PROPOSED CONSENT DECREE MODIFICATION
42
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
CERTIFICATE OF SERVICE
I hereby certify that on November 13, 2015, I electronically filed the foregoing (along with attachments) with the Clerk of the Court using the CM/ECF system which will send notification of such filing to counsel of record in this action. I hereby certify that I have mailed by United States Postal Service the document to the following non-CM/ECF participants: NA s/Austin D. Saylor Austin D. Saylor Trial Attorney U.S. Department of Justice
Case 2:08-cv-05085-RMP Document 196 Filed 11/13/15
1
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
UNITED STATES DISTRICT COURT EASTERN DISTRICT OF WASHINGTON
STATE OF WASHINGTON, DEPARTMENT OF ECOLOGY,
Plaintiff,
v. ERNEST MONIZ, Secretary of the United States Department of Energy, and the UNITED STATES DEPARTMENT OF ENERGY, Defendants.
NO. 2:08-cv-5085-RMP [PROPOSED] ORDER
Pursuant to Federal Rule of Civil Procedure 60(5), and for the reasons set
forth in the corresponding Memorandum and Opinion issued this day, the Court
hereby ORDERS that the Consent Decree in this matter be modified as follows:
The milestones in Paragraph IV-A and Appendix A that have not passed
as of the filing of United States’ Motion to Modify Consent Decree (filed
October 3, 2014), are hereby VACATED and are SUPERSEDED by the new
milestones in the new Appendix D set forth in pages 2–3 of this Order.
The milestones in Paragraphs IV-B-1 and IV-B-2 of the Consent Decree,
and Paragraph 1 of Appendix B of the Consent Decree, are hereby VACATED
and REPLACED with a new Paragraph 1 of Appendix B as set forth in page 18
of this Order. Appendix B of the Consent Decree shall also be modified by
adding new Paragraphs 3 and 4 as set forth in pages 18–20 of this Order.
New Appendix E is added to the Consent Decree as set forth in pages 20-
29 of this Order.
Paragraph XV-B of the Consent Decree (Effective and Termination
Dates) is hereby VACATED and is REPLACED with the following:
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
2
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
“This Consent Decree shall terminate when the milestones in Appendix B
and Appendix D have been met, and initial plant operations for the Waste
Treatment Plant, as defined in Paragraph IV-A-3 of the Consent Decree,
have been achieved. As appropriate, a Party, or the Parties jointly, will
notify the Court of this event by a motion to terminate the Consent
Decree.”
The following shall be ADDED to the Consent Decree:
APPENDIX D: WTP CONSENT DECREE MILESTONES, SCHEDULE,
AND ASSUMPTIONS
1. WTP Construction and Startup
The milestones referred to in Section IV of the Consent Decree are as follows,
subject to the conditions outlined in Paragraphs 2 and 3 of this Appendix D:
Project Description Date A-1 Achieve Initial Plant Operations for the
Waste Treatment Plant12/31/2039
A-2
Interim HLW Facility Construction Substantially Complete
12/31/2032
A-3 Interim
Start HLW Facility Cold Commissioning 6/30/2035
A-4 Interim
HLW Facility Hot Commissioning Complete
12/31/2036
A-5 Interim
LAB Construction Substantially Complete
12/31/2012 (COMPLETED)
A-6 Interim
Complete Methods Validations 12/31/2034
A-7 Interim
LAW Facility Construction Substantially Complete
12/31/2030
A-8 Interim
Start LAW Facility Cold Commissioning 6/30/2035
A-9 Interim
LAW Facility Hot Commissioning Complete
12/31/2036
A-12 Interim
Steam Plant Construction Complete
12/31/2012 (COMPLETED)
A-13 Interim
Complete Installation of Pretreatment Feed Separation Vessels FEP-SEP-00001A/1B
12/31/2033
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
3
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
A-14 Interim
PT Facility Construction Substantially Complete
12/31/2033
A-15 Interim
Start PT Facility Cold Commissioning 6/30/2035
A-16 Interim
PT Facility Hot Commissioning Complete 12/31/2036
A-17
Hot Start of Waste Treatment Plant 12/31/2036
A-18 Interim
Complete Structural Steel Erection Below Elevation 56' in PT Facility
12/31/2009 (COMPLETED)
A-19 Interim
Complete Elevation 98' Concrete Floor Slab Placements in PT Facility
12/31/2033
A-20 Interim
Complete Construction of Structural Steel to Elevation 14' in HLW Facility
12/31/2010 (COMPLETED)
A-21 Interim
Complete Construction of Structural Steel to Elevation 37' in HLW Facility
12/31/2012 (COMPLETED)
2. Conditions Affecting HLW and PT Milestones
The milestones identified in Paragraph 1 of this Appendix D have been
established in the absence of necessary information regarding the HLW and PT
Facilities, including critical information concerning the resolution of outstanding
primary technical issues, potential redesign activities necessitated by the
resolution of those issues, and the creation and negotiation of new or modified
Performance Baselines and contracts that reflect those activities. Given the
substantial uncertainty that presently exists at the HLW and PT Facilities, the
milestones in Paragraph 1 are expressly subject to the conditions and extensions
specified in this Paragraph 2. Extensions of milestones at the HLW and PT
Facilities may be triggered, as provided below, as greater certainty develops
with respect to the time needed for technical issue resolution, facility redesign to
implement the results of technical issue resolution, and the establishment and
execution of new or modified Performance Baselines and contracts. Paragraphs
2.A.iv-vi, 2.B.iii-v and vii-ix, and 2.C.iii-v establish procedures for the United
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
4
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
States Department of Energy (“DOE”) and the Washington Department of
Ecology (the “Parties”) to reach agreement on the appropriate duration of the
extension period for any extension triggered, subject to an automatic extension
and opportunities for judicial review if agreement cannot be reached.
A. Technical Issue Resolution
i. Milestones for the HLW and PT Facilities cannot be accurately and
responsibly established before the unresolved primary technical issues at the
WTP are resolved. This Paragraph shall apply to the following unresolved
primary technical issues associated with the WTP:
a. hydrogen gas events in pulse jet mixed vessels and in piping and
ancillary vessels;
b. criticality in vessels in the PT Facility;
c. pulse jet mixer control;
d. erosion and localized corrosion in WTP vessels and piping; and
e. ventilation balancing.
ii. The unresolved primary technical issues listed above are
interrelated such that resolution of one technical issue may create additional
problems with another unresolved technical issue, as well as with a
previously resolved technical issue.
iii. In the event that all primary technical issues identified in
Subparagraph 2.A.i. above, are not resolved by June 30, 2019, then the
continuing need for work to resolve the primary technical issues shall extend
the date for completing each of the following milestones (as provided
below): - Milestone A-1
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
5
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
- Interim Milestone A-2
- Interim Milestone A-3
- Interim Milestone A-4
- Interim Milestone A-6
- Interim Milestone A-13
- Interim Milestone A-14
- Interim Milestone A-15
- Interim Milestone A-16
- Milestone A-17
- Interim Milestone A-19
iv. Extension Period. DOE shall notify the Washington Department of
Ecology if DOE determines that all primary technical issues will not be
resolved by June 30, 2019. Within 30 days of such notification, the Parties
shall start discussions as to the appropriate period of extension for
completion of the above milestones that incorporates the additional time
expected for full resolution of all primary technical issues. If agreement
cannot be reached in the time period specified in Subparagraph 2.A.v, the
automatic extension set forth in Subparagraph 2.A.v shall be applied and the
Parties shall have the opportunity to dispute the duration of the automatic
extension period pursuant to Subparagraph 2.A.vi.
v. In the event the Parties cannot reach agreement as to the duration of
an appropriate extension within 90 days of the start of the discussions
provided for in Subparagraph 2.A.iv, the milestones identified in
Subparagraph 2.A.iii shall be automatically extended by a period of one year
or such other period that DOE determines in writing to be necessary.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
6
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
vi. If the Washington Department of Ecology disputes the duration of
the extension period established pursuant to Subparagraph 2.A.v, it may seek
the Court’s review of the duration of the extension. The Court shall not alter
the extension period established pursuant to Subparagraph 2.A.v unless it
determines that the extension period provided is arbitrary and capricious.
vii. If, at any time after the provision of an extension pursuant to
Subparagraphs 2.A.iv-vi, the primary technical issues remain unresolved and
DOE determines that a further extension is necessary, DOE shall notify the
Washington Department of Ecology. Within 30 days of such notification, the
Parties shall start discussions pursuant to Subparagraph 2.A.iv regarding a
further extension of the above milestones. If the parties cannot reach
agreement as to the duration of an appropriate extension within 90 days of
the start of those discussions, as provided in Subparagraph 2.A.v, an
additional automatic extension shall apply to the milestones according to the
terms of that Subparagraph 2.A.v, and the Washington Department of
Ecology may seek review of that additional automatic extension pursuant to
Subparagraph 2.A.vi.
viii. Not later than 12 months after entry of the Court’s order
modifying the Consent Decree, DOE shall submit to the Washington
Department of Ecology a report detailing the progress made on the
unresolved technical issues identified in Subparagraph 2.A.i and the steps
DOE plans over the subsequent 24 months toward resolution of those issues.
ix. Until such time as DOE resolves each of the technical issues
identified in Subparagraph 2.A.i above and notifies the Washington
Department of Ecology of such resolution in writing as provided in
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
7
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Subparagraph 2.A.x below, DOE shall brief the Washington Department of
Ecology, either in person or by teleconference or other electronic means,
every 90 days to advise the Washington Department of Ecology on DOE’s
progress towards resolving those technical issues.
x. DOE shall notify the Washington Department of Ecology and the
Court upon resolution of all primary technical issues identified in
Subparagraph 2.A.i.
B. Facility Redesign
i. Milestones for each WTP facility cannot be accurately and
responsibly established before DOE and its contractors have completed and
verified any redesign work necessary to implement the outcomes of technical
issue resolution. Accordingly, this Paragraph provides for certain extensions
of the milestones in Paragraph 1 in the event redesign work cannot be
completed safely and responsibly on the timeframes assumed in Paragraph 1.
ii. High-Level Waste Facility. In the event that redesign work at the
HLW Facility is not completed and verified by December 31, 2021, then the
continuing need for work to complete and verify any redesign work shall
extend the date for completing each of the following milestones (as provided
below): - Milestone A-1
- Interim Milestone A-2
- Interim Milestone A-3
- Interim Milestone A-4
- Interim Milestone A-6
- Interim Milestone A-13
- Interim Milestone A-14
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
8
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
- Interim Milestone A-15
- Interim Milestone A-16
- Milestone A-17
- Interim Milestone A-19
iii. Extension Period. DOE shall notify the Washington Department of
Ecology if DOE determines that redesign at the HLW Facility will not be
completed and verified by December 31, 2021. Within 30 days of such
notification, the Parties shall start discussions as to the appropriate period of
extension for completion of the above milestones that incorporates the
additional time expected for the completion and verification of all redesign
work necessary to implement the outcomes of technical issue resolution at
the HLW Facility. If agreement cannot be reached in the time period
specified in Subparagraph 2.B.iv, the automatic extension set forth in
Subparagraph 2.B.iv shall be applied and the Parties shall have the
opportunity to dispute the duration of the automatic extension period
pursuant to Subparagraph 2.B.v.
iv. In the event the Parties cannot reach agreement as to the duration of
an appropriate extension within 90 days of the start of the discussions
provided for in Subparagraph 2.B.iii, the milestones identified in
Subparagraph 2.B.ii shall be automatically extended by a period of one year,
or such other period that DOE determines to be necessary.
v. If the Washington Department of Ecology disputes the duration of
the extension period established pursuant to Subparagraph 2.B.iv, it may seek
the Court’s review of the duration of the extension. The Court shall not alter
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
9
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
the extension period established pursuant to Subparagraph 2.B.iv unless it
determines that the extension period provided is arbitrary and capricious.
vi. Pretreatment Facility. In the event that redesign work at the PT
Facility is not completed and verified by December 31, 2024, then the
continuing need for work to complete and verify any redesign work shall
extend the date for completing each of the following milestones (as provided
below): - Milestone A-1
- Interim Milestone A-6
- Interim Milestone A-13
- Interim Milestone A-14
- Interim Milestone A-15
- Interim Milestone A-16
- Milestone A-17
- Interim Milestone A-19
vii. Extension Period. DOE shall notify the Washington Department of
Ecology if DOE determines that redesign at the PT Facility will not be
completed and verified by December 31, 2024. Within 30 days of such
notification, the Parties shall start discussions as to the appropriate period of
extension for completion of the above milestones that incorporates the
additional time expected for the completion and verification of all redesign
work necessary to implement the outcomes of technical issue resolution at
the PT Facility. If agreement cannot be reached in the time period specified
in Subparagraph 2.B.viii, the automatic extension set forth in Subparagraph
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
10
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
2.B.viii shall be applied and the Parties shall have the opportunity to dispute
the automatic extension period pursuant to Subparagraph 2.B.ix.
viii. In the event the Parties cannot reach agreement as to the duration of
an appropriate extension within 90 days of the start of the discussions
provided for in Subparagraph 2.B.vii, the milestones identified in
Subparagraph 2.B.vi shall be automatically extended by a period of one year
or such other period that DOE determines to be necessary.
ix. If the Washington Department of Ecology disputes the duration of
the extension period established pursuant to Subparagraph 2.B.viii, it may
seek the Court’s review of the duration of the extension. The Court shall not
alter the extension period established pursuant to Subparagraph 2.B.viii
unless it determines that the extension period provided is arbitrary and
capricious.
x. If, at any time after the provision of an extension pursuant to
Subparagraphs 2.B.iii-v or Subparagraphs 2.B.vii-ix, redesign work at either
the HLW or PT Facility has not yet been completed or verified, and DOE
determines that a further extension is necessary, DOE shall notify the
Washington Department of Ecology. Within 30 days of such notification, the
Parties shall start discussions pursuant to Subparagraph 2.B.iii or 2.B.vii
regarding a further extension of the above milestones for the affected facility.
If the Parties cannot reach agreement as to the duration of an appropriate
extension within 90 days of the start of those discussions, as provided in
Subparagraph 2.B.iv or 2.B.viii, an additional automatic extension shall
apply to the milestones for that facility according to the terms of either
Subparagraph 2.B.iv or 2.B.viii, as applicable, and the Washington
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
11
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Department of Ecology may seek review of that additional automatic
extension pursuant to Subparagraph 2.B.v or 2.B.ix.
xi. During the pendency of any extension under Subparagraph 2.B,
DOE shall brief the Washington Department of Ecology, either in person or
by teleconference or other electronic means, every 90 days to advise the
Washington Department of Ecology on DOE’s progress towards completing
redesign work at the WTP.
xii. DOE shall inform the Washington Department of Ecology and the
Court upon completion of redesign work at each of the HLW and PT
Facilities.
C. Performance Baseline & Contract
i. Milestones for each WTP facility cannot be accurately and
responsibly established until each facility has a current Performance Baseline
(as defined in Paragraph 4) and a new or modified contract in place, because
these documents provide necessary information regarding cost, schedule, and
contractor capacity with regard to each facility and the WTP as a whole.
Accordingly, this Paragraph provides for certain extensions of the milestones
in Paragraph 1 in the event preparation and negotiation of new or modified
Performance Baselines and contracts cannot be completed consistent with
Paragraph 1, and in the event that the timeframes embodied in the
Performance Baselines and contracts conflict with and require amendments
to the timeframes in Paragraph 1.
ii. In the event that a Performance Baseline is not established and a
new or modified contract has not been executed by the date provided for each
facility identified in this Subparagraph, then the continuing need for work to
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
12
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
establish a Performance Baseline and execute a new or modified contract
shall extend the milestones applicable to that facility, as identified in this
Subparagraph 2.C.ii (as provided below):
FACILITY DATE AFFECTED MILESTONES
HLW December 31, 2024, plus any extension period(s)
under 2.A-B
Milestone A-1 Interim Milestone A-2 Interim Milestone A-3 Interim Milestone A-4 Interim Milestone A-6 Interim Milestone A-13 Milestone A-17
PT December 31, 2027 plus any extension period(s)
under 2.A-B
Milestone A-1 Interim Milestone A-6 Interim Milestone A-13 Interim Milestone A-14 Interim Milestone A-15 Interim Milestone A-16 Milestone A-17 Interim Milestone A-19
iii. Extension Period. DOE shall notify the Washington Department of
Ecology if DOE determines that a Performance Baseline will not be
established and a new or modified contract will not be executed for any
facility by the date provided in Subparagraph 2.C.ii for that facility. Within
30 days of such notification, the Parties shall start discussions as to the
appropriate period of extension for completion of the above milestones that
incorporates the additional time expected for the establishment of a
Performance Baseline and the execution of a new or modified contract. If
agreement cannot be reached in the time period specified in Subparagraph
2.C.iv, the automatic extension set forth in Subparagraph 2.C.iv shall be
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
13
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
applied and the Parties shall have the opportunity to dispute the duration of
the automatic extension period pursuant to Subparagraph 2.C.v.
iv. In the event the Parties cannot reach agreement as to the duration of
an appropriate extension within 90 days of the start of the discussions
provided for in Subparagraph 2.C.iii, the milestones identified in
Subparagraph 2.C.ii shall be automatically extended by a period of one year,
or such other period that DOE determines in writing to be necessary.
v. If the Washington Department of Ecology disputes the duration of
the extension period established pursuant to Subparagraph 2.C.iv, it may seek
the Court’s review of the duration of the extension. The Court shall not alter
the extension period established pursuant to Subparagraph 2.C.iv unless it
determines that the extension period provided is arbitrary and capricious.
vi. If, at any time after the provision of an extension pursuant to
Subparagraphs 2.C.iii-v, a new or modified contract has not been executed
for that facility and DOE determines that a further extension is necessary,
DOE shall notify the Washington Department of Ecology. Within 30 days of
such notification, the Parties shall start discussions pursuant to Subparagraph
2.C.iii regarding a further extension of the milestones identified in
Subparagraph 2.C.ii for that facility. If the Parties cannot reach agreement as
to the duration of an appropriate extension within 90 days of the start of those
discussions, as provided in Subparagraph 2.C.iv, an additional automatic
extension shall apply to the milestones according to the terms of that
Subparagraph 2.C.iv, and the Washington Department of Ecology may seek
review of that additional automatic extension pursuant to Subparagraph
2.C.v.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
14
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
vii. During the pendency of any extension under Subparagraph 2.C,
DOE shall brief the Washington Department of Ecology, either in person or
by teleconference or other electronic means, every 180 days to advise the
Washington Department of Ecology on DOE’s progress towards establishing
a Performance Baseline and executing a new or modified contract for the
subject facility.
viii. DOE shall inform the Washington Department of Ecology and the
Court upon execution of a new or modified contract for each facility
identified in Subparagraph 2.C.ii.
ix. If, for any facility identified in Subparagraph 2.C.ii, the
Performance Baseline and new or modified contract, once established, are
inconsistent with a milestone date or milestone dates identified in Paragraph
1 (as modified by any extensions under this Paragraph 2), DOE shall
designate a substitute milestone date or dates informed by the dates
established in the contract and the substitute date or dates shall replace the
date or dates identified in Paragraph 1, unless the Court determines that one
or more dates is arbitrary and capricious.
D. Unless the parties agree otherwise, the extensions provided for in
Subparagraphs 2.A through 2.C are not mutually exclusive; in the event more
than one condition identified above is met, each extension shall be
independently (i.e., cumulatively) added to the appropriate milestones. In the
event one or more conditions in Subparagraphs 2.A through 2.C is met and
automatic or negotiated extensions are established, the applicable milestone
dates identified in Paragraph 1 shall be automatically replaced for all purposes
by the new date as extended by the appropriate Subparagraph(s).
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
///
///
3. Maintaining Simultaneous Operations
DOE shall meet the milestone dates identified in Paragraph 1 for the
LAW, HLW, and PT Facilities (including any extensions pursuant to the
conditions in Paragraph 2), provided, however, that milestone dates for the
commissioning of these Facilities shall remain in alignment to ensure
simultaneous operations of the WTP. Accordingly, in the event of an extension
of the HLW or PT milestones under Paragraph 2, the commissioning milestone
dates for the LAW, HLW, and PT Facilities in Paragraph 1 shall be substituted,
as follows:
Project Description Date A-3
Interim Start HLW Facility Cold Commissioning
6/30/2035, plus an extension period equivalent to that established for the HLW or PT Facility under Paragraph 2.A-2.C, whichever is greater
A-4 Interim
HLW Facility Hot Commissioning Complete
12/31/2036, plus an extension period equivalent to that established for the HLW or PT Facility under Paragraph 2.A-2.C, whichever is greater
A-8 Interim
Start LAW Facility Cold Commissioning
6/30/2035, plus an extension period equivalent to that established for the HLW or PT Facility under Paragraph 2.A-2.C, whichever is greater
A-9 Interim
LAW Facility Hot Commissioning Complete
12/31/2036, plus an extension period equivalent to that established for the HLW or PT Facility under Paragraph 2.A-2.C, whichever is greater
A-15 Interim
Start PT Facility Cold Commissioning
6/30/2035, plus an extension period equivalent to that established for the HLW or PT Facility under Paragraph 2.A-2.C, whichever is greater
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
16
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
A-16 Interim
PT Facility Hot Commissioning Complete
12/31/2036, plus an extension period equivalent to that established for the HLW or PT Facility under Paragraph 2.A-2.C, whichever is greater
4. Additional Definitions
“Performance Baseline” is a group of data sets such as work packages,
schedules, and costs that is developed between DOE-ORP and its prime
contractor to define the entire project budget (total cost of the project including
contingency), the project completion date (including a detailed schedule), and
the scope of the project. The Performance Baseline is based on and subject to a
DOE-approved funding profile.
5. Additional Reporting Requirements
A. DOE shall file status reports with the Court on an annual basis,
beginning one year after entry of the Court’s order modifying the Consent
Decree, to apprise the Court of DOE’s progress in complying with the
requirements of this Consent Decree.
B. Within 90 days of the date that DOE provides the Washington
Department of Ecology notice pursuant to Section IV-C-3 of this Consent
Decree that DOE has determined that a serious risk has arisen that DOE may be
unable to meet a schedule as required in Section IV and/or Appendix D, DOE
shall provide the Washington Department of Ecology with an explanation of the
reasons for that notice and the steps DOE is taking to address the issue (or
issues) requiring such notice.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
17
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
6. Conforming Provisions
A. Except as set forth in Paragraphs 2 and 3 of this Appendix D,
amendment of milestones established pursuant to this Appendix D shall be
governed by the standards and procedures in Section VII of the Consent Decree.
B. The milestones and schedule set forth in Appendix D above are subject
to the WTP Construction and Startup Concerns and Assumptions set forth in
Paragraph 2 of Appendix A of this Consent Decree. However, the conditions
and automatic extensions set forth in Paragraphs 2 and 3 of this Appendix D
shall operate independent of Paragraph 2 of Appendix A of this Consent Decree,
and are not subject to the conditions established in therein.
C. DOE shall provide the notice required by Section IV-C-3 of the
Consent Decree, as applicable, with respect to milestones established pursuant to
this Appendix D. Such notice shall be consistent, where applicable, with any
automatic extension of such milestones under Paragraphs 2 or 3 of this
Appendix D.
D. Section IX-C of the Consent Decree shall be applicable to any DOE
requests for extensions of milestones established pursuant to this Appendix D,
except for those extensions provided under Paragraphs 2 or 3 of this Appendix
E. Except as provided in Subparagraphs 6.A, 6.B, and 6.C of this
Paragraph, milestones extended under Paragraphs 2 or 3 shall be governed, as
extended, by the provisions of this Consent Decree and of this Appendix D. The
provision of an extension or extensions under Paragraphs 2 or 3 shall not
prevent DOE from seeking further modification of the milestones in this
Appendix D pursuant to Sections VI or VII of this Consent Decree.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
18
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
7. Savings Provision: Nothing in this Consent Decree shall be interpreted
to require DOE to undertake any obligation that is inconsistent with applicable
law.
* * * * * * * * * * *
APPENDIX B:
1. Tank Waste Retrievals
Project Description DateB-1 Complete retrieval of tank wastes from Waste
Management Area C single-shell tank C-102. 12/31/2015
B-1A Propose milestone, not to exceed 9/30/2022,
for completion of retrieval of C-105. 60 days after
approval of a Tank Waste Retrieval
Work Plan modification in accordance with
Section IV-B-4 and Appendix C
B-1B Complete retrieval of tank wastes from single-shell tank C-111
4/30/2016
B-2 Complete retrieval of tank waste, with retrievals initiated by the deadlines specified in B-3, B-4, and B-5 below, from the following single-shell tanks in Tank Farms A and AX: A-101, A-102, A-104, A-105, A-106, AX-101, AX-102, AX-103, and AX-104. Subject to the requirements of Section IV-B-3, DOE may substitute any of the identified nine single-shell tanks and advise the Washington State Department of Ecology accordingly.
3/31/2024
B-3 Initiate startup of retrieval in two of the single-shell tanks referred to in B-2.
12/31/2018
B-4 Initiate startup of retrieval in two additional single-shell tanks referred to in B-2.
12/31/2020
B-5 Initiate startup of retrieval in five additional single-shell tanks referred to in B-2.
3/31/2023
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
19
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
“Initiate startup of retrieval” means that actual pump operations in the
single-shell tank have commenced and that transfers from the single-shell tank
have totaled an estimated 5% of the waste in the tank.
3. SCBA-Based Extension:
A. The dates set forth in milestones B-1, B-2, B-3, B-4, and B-5 above are
based upon the assumption that Self-Contained Breathing Apparatus (“SCBA”)
will continue to be used during all retrieval work at the A and AX Tank Farms
through Federal fiscal year 2016 (September 30, 2016). Unless, on or before
September 30, 2016, DOE determines that SCBA is no longer necessary to be
used for all retrieval work, milestones B-2, B-3, B-4, and B-5 shall be extended
automatically by one day for every two days SCBA continues to be used after
September 30, 2016. DOE shall notify the Court within 30 days of making a
determination that SCBA is no longer necessary for all retrieval work. Absent
such notification to the Court, the automatic extension shall be presumed to have
begun.
B. If, regardless of whether DOE has made a determination pursuant to
Subparagraph 3.A above, a significant number of tank farm workers voluntarily
choose to continue using SCBA for all retrieval work at A and AX Tank Farms
beyond September 30, 2016, milestones B-2, B-3, B-4, and B-5 shall be
extended automatically by one day for every two days SCBA continues to be
used after September 30, 2016. DOE shall notify the Court within 30 days of the
initiation of the automatic extension. Pending such notification to the Court, the
automatic extension shall be presumed to have begun.
C. If the B-2, B-3, B-4, and B-5 milestones are extended pursuant to
either Subparagraph 3-A or 3-B above, DOE shall notify the Court when the
extension is no longer necessary.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
20
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
D. If the Washington Department of Ecology disagrees with DOE’s
interpretation of the term “significant” in a notification to the Court pursuant to
Subparagraph 3.B above, then Washington Department of Ecology may invoke
the Dispute Resolution mechanism of Section IX of this Consent Decree. In the
event either party petitions the Court for review of such a dispute, the Court
shall review DOE’s determination under the arbitrary and capricious standard of
review.
E. Other than as provided in Subparagraph 3.C above, nothing in this
Paragraph 3 shall be subject to judicial review.
4. Savings Provision: Nothing in this Appendix B shall be interpreted to
require DOE to undertake any obligation that is inconsistent with applicable law.
* * * * * * * * * * * *
APPENDIX E: EVAPORATOR CAMPAIGNS AND DST
TRIGGERS
1. Background Regarding DOE’s Planned 242-A Evaporator Campaigns
A. DOE estimates that, between Federal fiscal year (“FY”) 2016 and
FY2021, the 242-A Evaporator will achieve, through multiple campaigns spread
over those years, a total waste volume reduction (“WVR”) of at least 5.9 million
gallons (“Mgal”) of liquid from the waste in A and AX Farm tanks (“Total
WVR Target”). To achieve the Total WVR Target, DOE estimates that, on a
year-by-year basis, the aggregate WVR (“Yearly Aggregate WVR Target”) will
be as follows:
Federal Fiscal Year Yearly Aggregate WVR Target
FY2016 At least 0.6Mgal
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
21
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
FY2017 At least 0.9Mgal
FY2018 At least 0.7Mgal
FY2019 At least 1.2Mgal
FY2020 At least 0.9Mgal
FY2021 At least 1.6Mgal
TOTAL: At least 5.9Mgal
B. DOE’s ability to achieve each Yearly Aggregate WVR Target and the
Total WVR Target is subject to sufficient waste feed being available and ready
to process through the 242-A Evaporator. The Total WVR Target need not be
achieved until the March 31, 2023, or the end of the calendar year prior to the B-
2 Milestone date in Appendix B of this Consent Decree, should it be extended
(the “Target WVR Date”). Therefore, to account for disruptions in waste feed
availability and any other events that may delay the ability of the 242-A
Evaporator to meet a Yearly Aggregate WVR Target, DOE shall adjust the
Yearly Aggregate WVR Targets as necessary in accordance with Paragraph 2 of
this Appendix E to meet the Total WVR Target by the Target WVR Date,
including adding campaigns in FY2022 and FY2023 as necessary. If a reduction
in the expected waste feed for processing necessitates an adjustment to the
Target WVR Date, or if the B-2 Milestone in Appendix B to this Consent
Decree is extended, DOE shall adjust the Target WVR Date and the remaining
Yearly Aggregate WVR Targets as necessary in accordance with Paragraph 2 of
this Appendix. If DOE determines that the Total WVR Target should be revised,
DOE shall adjust the Total WVR Target and remaining Yearly Aggregate WVR
Targets as necessary to achieve the Target WVR Date in accordance with
Paragraph 2 of this Appendix E.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
22
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
C. The performance of the 242-A Evaporator, both in terms of efficiency
and gallons of liquid evaporated, will vary on a campaign-by-campaign basis,
depending upon factors such as the composition and characteristics of the tank
waste.
i. To increase the accuracy of DOE’s assessment of how individual
campaigns will perform, before each 242-A Evaporator campaign DOE will
perform a small-scale test of the waste to be evaporated during the campaign
to determine with greater certainty what WVR the campaign may be
anticipated to create. DOE shall make the results of these tests publicly
available in advance of each 242-A Evaporator campaign.
ii. Although any individual 242-A Evaporator campaign may not
achieve the WVR estimated in the test described above in Subparagraph
1.C.i, DOE may be able to recover any shortfall by, among other mitigation
efforts, undertaking additional 242-A Evaporator campaigns, extending the
duration of time that 242-A Evaporator campaigns were otherwise expected
to run, achieving greater performance efficiency than anticipated in other
campaigns, or taking other measures that achieve the equivalent of the
projected WVR.
D. If, without regard to DOE’s achievement of any prior Yearly
Aggregate WVR Target, DOE determines that the Total WVR Target should be
revised, whether because that amount of WVR is not necessary to achieve the B-
2 Milestone in Appendix B or because a reduction in the expected waste feed for
processing necessitates an adjustment, it shall so state in the next Annual Report
following such determination as required by Paragraph 2 below, and shall adjust
all subsequent Yearly Aggregate WVR Targets as necessary.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
23
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
2. Annual Report of 242-A Evaporator Performance
No later than December 31 of each year until DOE has achieved the Total
WVR Target, or is otherwise relieved of that obligation due to intervening
events, DOE shall file an Annual Report with the Court on the operational
performance of the 242-A Evaporator. In this report, DOE shall:
A. State whether the 242-A Evaporator achieved the Yearly Aggregate
WVR Target for the FY for which the report is due (hereinafter, the “Reporting
Period”), either as identified in Paragraph 1.A, or as modified pursuant to
Paragraphs 1.B or 1.D above, or Paragraph 2.B.ii below, in a prior Annual
Report, and shall provide the data supporting DOE’s conclusions. If the 242-A
Evaporator did not achieve the Yearly Aggregate WVR Target, DOE shall
provide additional explanation pursuant to Subparagraphs 2.D and 2.E below, as
necessary, consistent with the assumptions as stated in Subparagraph 1.C above,
that evaporator campaigns are variable in nature and that, on an annual basis,
variation in one campaign may be offset by another.
B. State whether DOE anticipates it will achieve the Yearly Aggregate
WVR Target for the following FY, either as identified in Subparagraph 1.A, or
as modified pursuant to Subparagraphs 1.B or 1.D above, or Subparagraph 2.B.ii
below, in a prior Annual Report. If DOE states that it does not anticipate
achieving the Yearly Aggregate WVR Target for the following FY, either as
identified in Subparagraph 1.A above, or as modified pursuant to Subparagraph
1.A, or as modified pursuant to Subparagraphs 1.B or 1.D above, or
Subparagraph 2.B.ii below, in a prior Annual Report, DOE shall address the
following:
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
24
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
i. Whether and how DOE’s updated WVR projection for the
following FY is still on track to meet the Total WVR Target, either as
identified in Subparagraph 1.A above, or as modified pursuant to
Subparagraph 1.A, or as modified pursuant to Subparagraphs 1.B or 1.D
above, or Subparagraph 2.B.ii. below, in a prior Annual Report, by the Target
WVR Date identified in Subparagraph 1.B, consistent with the assumptions
as stated in Subparagraph 1.C above, that evaporator campaigns are variable
in nature and that, on an annual and multi-annual basis, variation in one
campaign may be offset by another.
ii. Whether, consistent with the explanation described in
Subparagraph 2.A.i above, DOE can identify updated Yearly Aggregate
WVR Targets to replace those previously identified to achieve the Total
WVR Target by the Target WVR Date. If DOE can identify such updated
Yearly Aggregate WVR Targets, they shall then replace those previously
identified for all future Annual Reports. If DOE cannot identify such updated
Yearly Aggregate WVR Targets, DOE shall state in the Annual Report at the
end of the following FY whether, pursuant to Subparagraph 2.A above, DOE
is in fact no longer on track to meet the Total WVR Target by the Target
WVR Date.
C. Achievement of the Yearly Aggregate WVR Target constitutes
compliance with this Appendix for the Reporting Period.
D. In the event that DOE states, pursuant to Subparagraph 2.A above, that
the 242-A Evaporator did not achieve the Yearly Aggregate WVR Target for the
Reporting Period, DOE shall explain the reason for the failure to meet the target.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
25
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
i. DOE shall also describe whether, and in what manner, the 242-A
Evaporator may be operated in future campaigns to still achieve the Total
WVR Target by the Target WVR Date. This may include an explanation of
additional or longer evaporation campaigns, or improvements to the total
operating efficiency of the 242-A Evaporator in the event of malfunction. If,
consistent with this explanation, DOE identifies updated Yearly Aggregate
WVR Targets to replace the targets either as identified in Subparagraph 1.A
above, or as modified pursuant to Subparagraphs 1.B or 1.D above, or
Subparagraph 2.B.ii above in a prior Annual Report, that will still achieve the
Total WVR Target by the Target WVR Date, those updated Yearly
Aggregate WVR Targets shall replace those previously identified for all
future Annual Reports.
ii. If the reason the 242-A Evaporator did not achieve the Yearly
Aggregate WVR Target was that inadequate waste feed was available and
ready to process, then the Target End Date as identified in Subparagraph 1.B
above is extended by a duration of time equivalent to the duration that
adequate feed was not available and ready for processing in the 242-A
Evaporator, and DOE shall adjust the Yearly Aggregate WVR Targets
accordingly, unless DOE determines that some other extension is necessary
and adjusts the Target End Date and Yearly Aggregate WVR Targets
accordingly.
E. In the event that DOE cannot demonstrate pursuant to Subparagraph
2.D above that the 242-A Evaporator can meet the Total WVR Target by the
Target WVR Date (either as identified in Subparagraph 1.B above, or as
amended pursuant to Subparagraph 2.D.ii above), then DOE shall explain any
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
26
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
alternative technologies or waste management practices that are available to
meet the Total WVR Target or its equivalent.
F. If DOE is unable to demonstrate, after providing explanations pursuant
to Subparagraphs 2.D and 2.E above, that it will achieve the Total WVR Target
by the Target WVR Date (either as identified in Subparagraph 1.B above or as
amended pursuant to Subparagraph 2.D.ii above) due to the performance of the
242-A Evaporator during the Reporting Period, then DOE shall, subject to the
provisions in Paragraph 3 of this Appendix E, be conditionally required to
construct and place in service additional double-shell tanks (“DSTs”).
G. If, pursuant to this Paragraph 2, DOE becomes conditionally required
to construct and place in service additional DSTs subject to the provisions in
Paragraph 3 of this Appendix, DOE’s obligation to file an Annual Report shall
be suspended for such time as DOE is conditionally required to construct and
place in service such DSTs.
3. Conditions on the Construction of Additional DSTs
If DOE becomes conditionally obligated to construct and place into
service additional DSTs pursuant to Paragraph 3 of this Appendix, such
obligation shall be suspended if, and at such time that, DOE determines that any
of the following conditions apply and has either made such determination in an
Annual Report or in a separate notification to the Court (“Paragraph 3
Notification”):
A. Notwithstanding any statement in a previous Annual Report, the cost
of constructing and placing in service additional DSTs would result in the
diversion of funds that would jeopardize DOE’s ability to undertake cleanup
activities important to protect public health and the environment.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
27
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
B. Notwithstanding any statement in a previous Annual Report, the
detriments of constructing and placing in service additional DSTs are greater
than the detriments to the Hanford tank waste project or the risk to public health
and the environment from any delay in achieving the B-2 Milestone in Appendix
B of this Consent Decree, including any amendments thereto.
C. Notwithstanding any statement in a previous Annual Report, the
conditions of Subparagraphs 2.D or 2.E above have been satisfied such that any
shortfall in previous performance can be appropriately mitigated and the Total
WVR Target will be achieved.
D. Notwithstanding any statement in a previous Annual Report, DOE can
still achieve the B-2 Milestone in Appendix B of this Consent Decree, including
any amendments thereto, or the retrievals subject to the B-2 Milestone can be
completed by a date after that date that is the same as or sooner than they would
be completed before additional DST space from the construction of new DSTs
would be available and useful to expedite the retrieval of the remaining single-
shell tank retrievals.
If DOE’s conditional obligation to construct and place in service
additional DSTs remains suspended through such time as DOE achieves the B-2
Milestone in Appendix B of this Consent Decree, then DOE shall be relieved of
any obligation under the Consent Decree to construct and place in service
additional DSTs. If at any time a condition described in Subparagraphs 3.A, 3.B,
3.C, or 3.D above ceases to apply, DOE will notify the Court in a Paragraph 3
Notification.
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
28
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
4. Terms and Schedule for Construction of Additional DSTs
If DOE becomes conditionally obligated to construct and place into
service additional DSTs pursuant to Paragraph 2 of this Appendix E, and DOE’s
conditional obligation is not suspended pursuant to Paragraph 3 of this
Appendix E, then DOE shall construct and place into service additional DSTs in
accordance with the following:
A. DOE shall construct additional DST capacity sufficient to replace the
WVR not accomplished by the failure of the 242-A Evaporator to meet DOE’s
Total WVR Target identified in Subparagraph 1.A.
B. The additional DST capacity required pursuant to Subparagraph 4.A
shall be constructed and placed into service no later than 10 calendar years from
the date that requirement was triggered under Paragraph 2 (hereinafter “the
Trigger Date”).
C. However, the deadline calculated in Subparagraph 4.B above shall be
suspended if, after the Trigger Date, any condition in Paragraph 3 above applies.
If any condition in Paragraph 3 ceases to apply thereafter, the deadline
calculated in Subparagraph 4.B above shall be extended by the amount of time
the condition in Paragraph 3 above applied. If more than one condition in
Paragraph 3 applies, and subsequently ceases to apply, the deadline shall be
calculated from the last date a condition in Paragraph 3 applied.
5. Judicial Review
A. If Washington Department of Ecology takes issue with an alteration to
a Yearly Aggregate WVR Target, the Total WVR Target, or the Target WVR
Date pursuant to Paragraph 2 above, or with a Paragraph 3 Notification, then
Washington Department of Ecology may invoke the Dispute Resolution
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
29
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
mechanism of Section IX of this Consent Decree. In the event either party
petitions the Court for review of such a dispute, the Court shall review DOE’s
determination under the arbitrary and capricious standard of review.
B. Other than as provided in Subparagraph 5.A above, nothing in this
Appendix E shall be subject to judicial review.
6. Conforming Provision: In addition to the conditions and assumptions set
forth in Paragraph 1 to this Appendix E, the milestones and schedule set forth in
this Appendix E are subject to the Tank Retrieval Milestones and Schedule
Concerns and Assumptions set forth in Paragraph 2 of Appendix B.
7. Savings Provision: Nothing in this Appendix E shall be interpreted to
require DOE to undertake any obligation that is inconsistent with applicable law.
* * * * * * * * * * *
The foregoing is so ORDERED this ___ day of 20__.
______________________ United States District Judge
Case 2:08-cv-05085-RMP Document 196-1 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
1
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
JOHN C. CRUDEN Assistant Attorney General Environment & Natural Resources Division United States Department of Justice MICHAEL C. ORMSBY United States Attorney Eastern District of Washington DAVID J. KAPLAN ELIZABETH B. DAWSON CHLOE H. KOLMAN AUSTIN D. SAYLOR Environmental Defense Section P.O. Box 7611 Washington, D.C. 20044 (202) 514-2219 VANESSA WALDREF Assistant United States Attorney 920 West Riverside Ave., Suite 300 Spokane, WA 99201 (509) 353-2767 UNITED STATES DISTRICT COURT
EASTERN DISTRICT OF WASHINGTON
STATE OF WASHINGTON, DEPARTMENT OF ECOLOGY,
Plaintiff,
v. ERNEST MONIZ, Secretary of the United States Department of Energy, and the UNITED STATES DEPARTMENT OF ENERGY, Defendants.
NO. 08-5085-RMP THIRD SUPPLEMENTAL DECLARATION OF BENTON J. HARP
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
2
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
I, Benton J. Harp, pursuant to 28 U.S.C. § 1746, declare, under penalty of
perjury, that the following statements are true and correct based upon my
personal knowledge or upon information provided to me by colleagues.
1. This declaration supplements my three previous declarations, filed
in the Court’s docket as ECF Nos. 76-2, 106-3 and 184-1. As further described
in my first declaration, ECF No. 76-2 ¶ 1, I am the Assistant Manager for the
Waste Treatment Plant (“WTP”) Startup Commissioning and Integration at the
U.S. Department of Energy (“DOE”) Office of River Protection in Richland,
WA. I have held this position since 2010. In this role, I am accountable for start-
up and commissioning issues, project and contractor performance, and technical
issue identification and resolution for issues that affect the interfaces between
the Tank Farm and Waste Treatment Plant (“WTP”) contractors.
Current Status of the WTP
2. At present, all design and construction work at the Pretreatment
Facility remains suspended, in light of the significant project uncertainties and
ongoing technical issue resolution work described below and in previous
declarations. Construction work at the Pretreatment Facility will not restart until
after resolution of the technical issues, described in Paragraph 5 below, and the
completion and verification of necessary redesigns. Additional information is
provided in my first declaration. ECF No. 76-2 ¶¶ 44, 56, 63.
3. As described in my previous declarations, at the High-Level Waste
Facility, construction work related to areas affected by the unresolved technical
issues—in particular areas that might be affected by erosion-corrosion concerns
and ventilation issues—remains suspended. This work will not restart until after
resolution of the technical issues and the completion and verification of
necessary redesigns. However, design and structural work (like the construction
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
3
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
of walls and slabs) has restarted in areas of the High-Level Waste Facility that
are not impacted by the technical issues. Additional information is provided in
my first declaration, ECF No. 76-2 ¶¶ 44, 56, 64, and in the Declaration of Todd
Shrader (ECF No. 76-5).
4. The Low-Activity Waste Facility was not affected by the primary
unresolved technical issues affecting the Pretreatment and High-Level Waste
Facilities. Accordingly, work at the Low-Activity Waste Facility continues. In
particular, because DOE remains dedicated to a “direct feed” approach to begin
waste treatment at the Low-Activity Waste Facility as soon as practicable
(known as “Direct Feed LAW”), DOE has committed significant resources to
advancing the construction and design of the components of that approach.
These activities have included modifications of support facilities known as
Balance of Facilities, design of the Effluent Management Facility, and design of
the interface between the Low-Activity Waste Facility and the Low-Activity
Waste Pretreatment System (“LAWPS”). LAWPS, which will treat the low-
activity waste being directly fed into the Low-Activity Waste Facility, received
“Critical Decision-1” approval on May 19, 2015, which recognizes that LAWPS
represents the best of several alternatives to meet the mission need. This
approval authorizes DOE to begin executing the project. As a next step, DOE
will work with the contractor to establish a performance baseline (defined
below) for LAWPS. DOE and its contractor have also begun the process of
developing a modified performance baseline and negotiating a modified contract
for the Low-Activity Waste Facility. The status of the Low-Activity Waste
Facility is discussed in my first declaration, ECF No. 76-2 ¶¶ 44, 65. LAWPS
and Direct Feed LAW, and their importance to the success of DOE’s cleanup
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
4
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
mission, are discussed in my second declaration, ECF No. 106-3 ¶¶ 2-27, and
the Declaration of Todd Shrader (ECF No. 76-5).
5. Technical issue resolution for the Pretreatment and High-Level
Waste Facilities is ongoing. The five primary unresolved technical issues are:
(1) hydrogen gas events in pulse jet mixed vessels and in piping and ancillary
vessels; (2) criticality in vessels in the Pretreatment Facility; (3) pulse jet mixer
control; (4) erosion and localized corrosion in WTP vessels and piping; and (5)
ventilation balancing. At present, DOE is, among other things, completing
“Phase 2” of its full-scale vessel testing plan, preparing simulants and designing
prototypes for erosion and corrosion experiments, reviewing contractor studies
on criticality risk, and performing other safety and engineering calculations and
analyses.
6. Because technical issues have not yet been resolved, DOE cannot
finalize designs of necessary components, equipment, or processes at the High-
Level Waste and Pretreatment Facilities, which may be redesigned as part of
issue resolution or in response to it. Likewise, because redesign work has not yet
been completed or verified, both Facilities continue to lack up-to-date
performance baselines and contracts, which will have to be negotiated once all
resolution and redesign work is completed. As a result, there is very little
reliable information available from an engineering, scientific, and project-
management standpoint about the scope of work necessary for the WTP to
progress to completion or the time it will take to do so. During this period of
uncertainty, DOE cannot accurately predict when certain project steps will be
taken, and cannot responsibly commit to schedules for achieving milestones.
This uncertainty reflects the scarcity of necessary information, but not the
absence of adequate expertise; there is simply no way to set a firm schedule until
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
5
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
these fundamental tasks have been completed and the scope and timing of the
remaining work is determined.
7. Because of this uncertainty, DOE continues to believe that
milestones for the WTP must be established only after critical information is
developed concerning the resolution of outstanding primary technical issues,
potential redesign activities necessitated by the resolution of those issues, and
the creation and negotiation of new or modified performance baselines and
contracts that reflect those activities. This is the approach that DOE laid out in
its first proposed modification to the Consent Decree. ECF No. 76-1 at App. D.
DOE continues to believe that its first proposed modification, and specifically its
milestone-setting process, is the proper and responsible path forward given the
uncertainties associated with primary technical issue resolution, redesign, and
baselining and contracting. However, in response to the Court’s August 13, 2015
Order (“Second Order”), ECF No. 170, DOE has prepared a second proposed
modification to the Consent Decree (also referred to as DOE’s “proposal” and
attached as Exhibit A to the United States’ brief) that is consistent with the
direction of the Court. This second proposed modification is described below.
DOE’s Second Proposed Modification to the Consent Decree
8. The Court’s Second Order required that the parties submit new
proposals that include “specific milestone deadlines for constructing and
achieving initial operations of the WTP.” Second Order at 32. In consideration
of this instruction, DOE’s second proposal includes specific milestone deadlines
for the fourteen outstanding milestones in the original table of milestones in
Appendix A of the Consent Decree. The new milestone dates are proposed in
accordance with the assumptions described below. However, because the results
of and timeframes for completing technical issue resolution, redesign, and re-
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
6
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
baselining and contracting cannot be predicted with certainty at this time, these
assumptions and resulting milestones cannot account for the significant
variability in the time that may be necessary to reach WTP initial operations.
Accordingly, DOE’s proposal pairs enforceable milestones with a mechanism,
in the Consent Decree itself, to extend the milestones if highly uncertain
underlying assumptions about technical issue resolution, redesign, and re-
baselining and contracting are shown to be inaccurate. This mechanism,
described below, provides for reasonable extensions, subject to initial
negotiations between the parties and reviewable by the Court if the parties are
unable to agree. It is intended to ensure that enforceable milestones remain
aligned with the project as necessary scientific, engineering, and project
management processes progress. Because of the pervasive project uncertainties,
DOE cannot reasonably commit to milestones without this extension process.
9. Pairing enforceable milestones with the proposed extension
mechanism also reflects the changed status of the project since the Consent
Decree was entered in 2010. DOE’s ability to negotiate and agree to fixed
milestones in 2010 reflected the fact that it had at that time firm project
information for all WTP facilities, including performance baselines and
contracts to define the scope and schedule of the project. This is also discussed
in my first declaration. ECF No. 76-2 ¶ 52. Providing an extension mechanism
as part of this new proposal is necessary so that enforceable milestones can be
adjusted if the key project information, once available, like the project
information that DOE had during the original Consent Decree negotiations,
indicates the need. This will ensure that, as the parties believed in 2010, the
milestones guiding the project will ultimately reflect an accurate scope and
schedule for the WTP project.
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
7
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
10. DOE’s proposed extension mechanism provides for necessary
extensions based on three specific categories where the present uncertainty is
substantial and precludes establishing fixed milestones:
a. Technical Issue Resolution. As described in previous
declarations, significant unresolved technical issues affect the High-Level
Waste and Pretreatment Facilities. These unresolved primary technical
issues, noted in Paragraph 5 above, are the main reason the parties seek
modification of the Consent Decree and were a key factor in the decision
to suspend construction in August 2012 at the two affected facilities. The
unresolved technical issues must be resolved before proceeding with
redesign and construction. However, it is impossible to predict the
outcome of and time needed for issue resolution; as previous declarations
have discussed, technical issue resolution is an iterative, scientific process
that must take as long as necessary to ensure that the WTP can operate
safely and complete the mission. The technical issues and their resolution
are discussed at length in the Declaration of Robert A. Gilbert (ECF No.
76-6) and the Supplemental Declaration of Robert A. Gilbert (ECF No.
106-1).
b. Redesign. After technical issues are resolved, additional
work will be required to redesign the WTP to incorporate those
resolutions. This redesign work might include changes to components,
equipment, or processes. There is no way to determine the scope and
nature of the work that will be necessary before the technical issue
resolutions are known. Once completed, a new design must be verified to
ensure it meets the nuclear safety and other required specifications. If
redesigned components, equipment, or processes cannot be verified as
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
8
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
meeting applicable standards, DOE may need to undertake additional
rounds of issue resolution and redesign. As discussed in previous
declarations, like issue resolution, the design and verification processes
are iterative, scientific processes that must continue until a safe and
effective solution is found. Facility redesign, verification, and nuclear
safety specifications are further discussed in the Declaration of Robert A.
Gilbert (ECF No. 76-6) and in the Supplemental Declaration of Todd
Shrader (ECF No. 106-5).
c. Performance Baseline and Contract. In contrast to the
circumstances in 2010, the High-Level Waste and Pretreatment Facilities
do not presently have up-to-date performance baselines and contracts,
which are the documents that define the work to be done, establish the
detailed project schedule, and set the overall project cost. New or
modified baselines and contracts cannot be developed until after redesign
is complete and the changes that need to be made are known. At that
point, the re-baselining and contract process will require DOE and its
contractor to analyze and negotiate the scope, schedule, and cost of the
work. Although this process is not a scientific inquiry, developing and
negotiating these critical framework documents involves extensive
engineering work and project planning regarding necessary equipment,
labor, suppliers, cost, space, and other factors. It is an iterative process
that cannot be completed on a set timeframe. The performance baseline is
subject to a third-party review, described below, and to management
approval, both of which could take longer than anticipated or result in
changes necessitating new negotiations between DOE and its contractor
regarding the performance baseline. In addition, forcing negotiations of
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
9
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
the contract modifications necessary to implement the modified
performance baseline to end on a predetermined date could compromise
DOE’s negotiating position, ultimately resulting in a higher cost to the
taxpayer and extending the length of the mission. Performance baselines
and contracts are further discussed in the Supplemental Declaration of
Todd Shrader (ECF No. 106-5).
11. Under DOE’s second proposal, the extension mechanism is
triggered only if DOE’s assumptions as to the three categories noted above—(1)
technical issue resolution, (2) redesign, and (3) performance baselines and
contracts—are proven to be incorrect. To accomplish this, the extension
mechanism takes the completion dates that DOE assumed when estimating the
milestones and uses these dates as triggers. If the work in one of the three
identified categories cannot be completed on the timeframe DOE assumed when
developing its proposed milestones, then an extension is triggered and applies to
all of the milestones listed in the proposal that are affected by that category of
work.
12. The extension mechanism is a four-part process:
a. First, if DOE determines that the necessary work in any
category will not be completed by the trigger date, then DOE notifies the
State that an extension will be necessary for all affected milestones.
Separate trigger dates are set for (1) all technical issues, as defined above,
affecting both the High-Level Waste and Pretreatment Facilities, (2)
redesign for the High-Level Waste Facility, (3) redesign for the
Pretreatment Facility, (4) re-baselining and contracting for the High-Level
Waste Facility, and (5) re-baselining and contracting for the Pretreatment
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
10
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Facility. From the date of notification, the parties have 30 days to begin
negotiations on the proper duration of the extension.
b. Second, once negotiations begin, the parties have 90 days to
come to an agreement as to the appropriate duration of the extension. A
90-day period should provide the parties with sufficient time for thorough
negotiations, which will likely include discussions between technical staff
regarding the status of these technical matters, while ensuring that
negotiations do not extend so long that they slow progress at the WTP or
impact responsible project management.
c. Third, if the parties agree to an extension within 90 days,
then the listed milestones for that category will be automatically adjusted
by the period agreed to by the parties. If the parties cannot reach
agreement as to the duration of an appropriate extension within the 90-day
negotiation period, then an extension is triggered. The extension will be
one year in duration unless DOE determines in writing that a different
extension period is warranted. Once triggered, the extension becomes
effective and will immediately apply to each of the affected milestones.
d. Fourth, if the parties do not reach agreement and the State
disagrees with the duration of the extension triggered—whether the
automatic one-year extension or a different extension period determined
by DOE—the State may seek the Court’s review of the extension’s
duration. Because the extensions deal with highly technical matters, such
as the additional time needed to redesign WTP components and processes,
the proposal provides that the Court may only supplant the extension if “it
determines that the extension period provided is arbitrary and capricious.”
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
11
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
13. In addition to the set triggers and extensions, DOE’s proposal
allows the parties to repeat this four-step process in the event the first extension
is not adequate to account for the completion of issue resolution, redesign, or re-
baselining and contracting. In that case, DOE can notify the State in writing that
the relevant work is still not complete, which will once again trigger the
negotiation process, and the steps outlined above. This ensures that the
milestones will account for additional work that the parties did not anticipate
when the first extension was triggered but that will nonetheless further delay
DOE’s ability to construct and commission the WTP facilities.
14. The extension for technical issue resolution has a trigger date of
June 30, 2019. The extension is triggered if all five primary unresolved technical
issues identified in DOE’s proposal and above are not resolved by that date. The
proposal requires that all five primary issues identified be resolved because
these technical issues are highly interrelated and need to be considered as a
whole: the proposed resolution of one issue may impact, and perhaps disrupt, the
proposed resolution of another issue. Likewise, because the technical issues
affect both the High-Level Waste and Pretreatment Facilities, if the extension is
triggered it applies to milestones at both Facilities. Finally, if an extension is
triggered, DOE will be obligated to brief the State every 90 days until the
technical issues are resolved and will be required to notify the State and the
Court upon resolution.
15. The extension for facility redesign has a trigger date of December
31, 2021, for the High-Level Waste Facility and a trigger date of December 31,
2024, for the Pretreatment Facility. Each extension will be independently
triggered by the progress of redesign work at the subject facility and will apply
only to the milestones for that facility (plus milestones for the WTP as a whole);
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
12
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
this ensures that work can continue to progress—and re-baselining and
contracting can begin—at one facility, even if the other is delayed. The trigger
dates are fixed dates, i.e., they do not shift even if issue resolution is taking
longer than expected, because issue resolution and redesign work are
interrelated and may be going on concurrently or on an iterative basis.
Accordingly, DOE will know by the specified trigger dates whether its
assumptions regarding the time needed for the redesign process at each facility
are accurate. As with extensions on the basis of technical issue resolution, if an
extension is triggered by the need for additional redesign work, DOE will be
obligated to brief the State every 90 days until redesign is complete.
16. The extension for re-baselining and contracting has a trigger date
of December 31, 2024, for the High-Level Waste Facility and a trigger date of
December 31, 2027, for the Pretreatment Facility. Each extension will be
independently triggered by delay in developing new or modified performance
baseline and contract at the subject facility and will apply only to the milestones
for that facility (plus milestones for the WTP as a whole); this ensures that work
can continue to progress at one Facility, even if the other is delayed. In contrast
to the other two categories, however, the trigger dates for re-baselining and
contracting shift to account for any delay in completing issue resolution or
redesign. Until those two preceding processes are completed, DOE will not have
the information necessary to begin re-baselining and contracting and so will not
be able to determine whether re-baselining and contracting will take longer than
anticipated. Accordingly, the trigger date for each Facility will be the date
identified above plus the extension period applicable to that Facility because of a
delay in resolving technical issues or completing redesign. If an extension is
triggered by the need for additional time to complete performance baselines and
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
13
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
contracts, DOE will be obligated to brief the State every 180 days until re-
baselining and contracting is complete. Briefings on a more extended schedule
are appropriate for baseline and contract issues because information develops
less quickly than for issue resolution and redesign.
17. The extension for re-baselining and contracting also includes a
provision to address potential discrepancies between the eventual baseline and
contract and the pre-existing milestone schedule. It provides that in the event the
baseline and contract result in a date (or dates) for an activity that is inconsistent
with the existing milestone, then DOE will designate a new milestone date (or
dates) that reflects the new information and that will serve as a substitute, unless
the Court “determines that one or more dates is arbitrary and capricious.” While
DOE hopes that these conflicts will not arise, adjusting the milestone dates after
the baseline and contract are developed ensures that the milestones are informed
by important engineering, project management, and contracting realities—such
as the scope of work to be performed, the sequence of particular construction or
installation steps, vendor and personnel availability, and funding—that could not
have been known earlier.
18. Under DOE’s proposal, the extensions triggered in each of these
categories would be independent and cumulative; that is to say, a milestone
extended one year because of a delay in technical issue resolution may be
delayed another year if it takes more time than anticipated to finalize a contract.
Extensions are cumulative because the process of building a facility—including
resolving all primary technical issues, redesigning based on the technical issue
resolution, and re-baselining and contracting—is sequential. As discussed
above, redesign of a facility cannot occur until there is a resolution of technical
issues. Likewise, DOE will establish a baseline and contract only after redesign
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
14
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
is complete. A delay in any of these phases would likewise delay subsequent
phases, so extensions must be cumulative to accurately reflect the time needed
to complete the project.
19. Finally, to make sure that the Consent Decree continues to provide
for simultaneous operations, DOE’s proposal provides that the commissioning
milestones for the Low-Activity Waste, High-Level Waste, and Pretreatment
Facilities will all be extended to align with whichever facility—once all
extensions are accounted for—is expected to come on line last. As discussed in
previous declarations, maintaining the alignment of the commissioning
milestones for the High-Level Waste and Pretreatment Facilities is necessary
because hot commissioning will use tank waste from the Tank Farms: once that
waste moves through the Pretreatment Facility it must have somewhere to go.
Likewise, for the High-Level Waste Facility to begin making glass, it must have
waste feed that has been treated in the Pretreatment Facility. Additional
information is provided in my first declaration. ECF No. 76-2 ¶¶ 20-21. DOE
expects that hot commissioning will follow closely after cold commissioning
because certain equipment like melters must continue to run; therefore, cold
commissioning dates are also aligned.
20. Like the High-Level Waste Facility, the Low-Activity Waste
Facility would also need to commission at the same time as the Pretreatment
Facility to ensure simultaneous operations. However, Direct Feed LAW will
allow the Low-Activity Waste Facility to begin making glass before the
Pretreatment Facility is finished by moving the waste through LAWPS.
Nonetheless, DOE’s proposal provides that the commissioning milestones for
the Low-Activity Waste Facility will remain in alignment with the other two
facilities, consistent with the Court’s order and the original Consent Decree that
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
provides for simultaneous operations even if DOE is, voluntarily and outside of
the Decree, pursuing Direct Feed LAW.
21. The extension mechanism is necessary because, notwithstanding
DOE’s best efforts to develop and comply with milestones, DOE cannot in good
faith attest that the milestones in its second proposal—were they adopted
without a mechanism for extension—would reflect an informed or reasonable
path to completing the WTP or that DOE would be able to meet those
milestones. Until the present uncertainties are resolved, it is not possible to make
that representation. Prematurely cutting off the time to resolve technical issues
or to redesign the facility could have disastrous consequences for human health
and the environment, including a possible release of radiation. These are
complex scientific and engineering processes that must be allowed to run their
course to ensure that the WTP will operate as designed, fulfill its mission, and
protect public health and the environment. Similarly, the re-baselining and
contracting process involves extensive engineering work and project planning,
and is critical to developing necessary project information and providing
direction to the contractor. To require performance baselines and contracts to be
set on a particular schedule would improperly limit these efforts and undermine
DOE’s ability to adequately negotiate scope, schedule, and cost by giving
contractors leverage to force DOE to accept a deal simply because the deadline
was up. This would have consequences for efficient project management, would
drive up costs to the taxpayer, and would almost certainly extend the overall
schedule of the project by requiring DOE to spend more of its limited
appropriations to get less done.
22. Providing a specific process for extensions in these three categories
is also vital because the project impacts of an incompatibility between the
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
16
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Consent Decree obligations and the new information to be developed in these
areas would be particularly acute. The need to confirm a safe and successful
design of these facilities and to establish that those designs can be constructed is
fundamental to the success of the treatment mission; without an extension
process, any discrepancy between the milestones and actual project conditions
would create undue pressure to manage the project in a manner reflective of
outdated information and inaccurate expectations, despite the fact that another
course or schedule would be safer or more efficient. This would impair DOE’s
long-term project planning and destabilize the project.
23. Having an extension mechanism and automatic default extensions
for these categories built into the Consent Decree, rather than seeking piecemeal
extensions through contested litigation, prevents this potential friction by
establishing clear and definite expectations as to how the parties and the Consent
Decree will accommodate significant developments in these areas. DOE’s
proposed extension mechanism makes extensions for these narrow, technical
causes more certain; provides DOE with a default extension of one year around
which it can plan ongoing activities; and provides for judicial review that gives
appropriate weight to the technical nature of these issues and to DOE’s expertise
in considering them.
24. In addition, the automatic extension mechanism helps to preserve
the parties’ resources, which could otherwise be drained by serial litigation over
extending Consent Decree milestones. Negotiations that include technical staff
discussions of these engineering and management-focused issues are more
efficient and more likely to result in mutual agreement. The presence of an
automatic extension period, set at a default of one year, will help guide these
discussions and give the parties a starting place from which to advance their
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
17
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
negotiations. By contrast, going to Court for every possible extension requires
significant staff resources and for a much longer time period, which can mean
that valuable resources are continually diverted away from the project itself. By
creating a simple, collaborative process limited to the narrow technical question
of how much more time is needed to complete particular tasks, DOE’s extension
mechanism gives the parties the best opportunity to come to agreement about the
duration of the extension needed.
Assumptions Used to Propose Milestones in DOE’s Second Proposal
General Assumptions and Parameters
25. Because the WTP does not presently have up-to-date performance
baselines and contracts, DOE has had to rely on a number of assumptions to
propose enforceable milestones (and associated extension triggers, noted above).
Primary among these, and as described further below, are that DOE will
continue to receive appropriations that align with current and historical patterns;
that DOE will accelerate work at the Low-Activity Waste Facility to begin waste
treatment as soon as practicable; and that the primary technical issues will be
resolved by June 30, 2019. In addition, DOE proposes milestones that are
sequenced to ensure simultaneous operations, consistent with the Court’s
Second Order. DOE has also made a number of specific assumptions about the
durations of redesign, re-baselining and contracting, construction, and
commissioning that are further described below.
26. Consistent with the Court’s Second Order and with the original
Decree, DOE’s proposal maintains a milestone sequence that supports
simultaneous operations. The purpose of the Pretreatment Facility within the
WTP system is to separate high-level waste from low-activity waste and send
the two separate streams of waste to the High-Level Waste and the Low-Activity
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
18
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Waste Facilities, respectively, for vitrification. If the Pretreatment Facility is to
be operational and processing waste, the other two facilities would have to be
operational at the same time to receive that waste. To enable this approach,
construction and commissioning milestones are set so that construction will
conclude at the three facilities in close succession—at the Low-Activity Waste
Facility on December 31, 2030, at the High-Level Waste Facility on December
31, 2032, and at the Pretreatment Facility on December 31, 2033—and so that
both cold and hot commissioning at all facilities will occur simultaneously (cold
commissioning by June 20, 2035, and hot commissioning by December 31,
2036). As noted above, DOE actually intends to construct and commission the
Low-Activity Waste Facility earlier than the dates included in the milestone
table—consistent with Direct Feed LAW—but aligning milestones for all three
facilities is consistent with the Court’s order and the original Consent Decree,
which provides for simultaneous operations.
27. A fundamental, key assumption underlying the projected milestone
dates in DOE’s proposal is that WTP funding will continue at its present, and
historical, levels. If Congress were to reduce funding for the WTP, DOE’s
projected proposal milestone dates would no longer be accurate.
28. As described in previous declarations, DOE has received $690
million (or below) in appropriations for WTP work nearly every fiscal year from
2008 to 2014 (except in Fiscal Year 2011, when appropriations did not specify
amounts for particular facilities; and Fiscal Year 2012, when WTP received
$740 million in funding). This material is discussed in the Declaration of James
M. Owendoff (ECF No. 106-6). In Fiscal Year 2015, the WTP received an
appropriation of $667 million. (The remainder of the $690 million requested for
the WTP was appropriated to LAWPS.) For the first part of Fiscal Year 2016,
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
19
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
which began on October 1, 2015, DOE has been funded under a “continuing
resolution”—maintaining funding levels and distribution from the previous year.
DOE does not yet know how much money Congress will appropriate for the
WTP after the continuing resolution expires on December 11, 2015. Consistent
with this history, DOE assumed when setting milestone dates that it will
continue to receive $690 million in annual funding for the WTP.
29. Funding is an important factor in setting milestones, because it
affects the scope of work that can be undertaken in a particular year. Using
present and historical funding levels—from which there has been little
deviation—is a necessary and responsible assumption.
30. DOE’s milestone dates were also projected consistent with its intent
to sequence the three main WTP facilities and to implement Direct Feed LAW
as soon as practicable. Advancing completion and operation of the Low-Activity
Waste Facility, as supported by Direct Feed LAW, has two chief project
benefits: beginning vitrification of waste as soon as 2022 and freeing up
additional space in the double-shell tanks. Getting the Low-Activity Waste
Facility up and running will also give project managers and personnel important
operational experience that will assist DOE in managing construction,
commissioning, and operations of the more complex and higher “hazard
category” High-Level Waste and Pretreatment Facilities. These points are also
discussed in my second declaration, ECF No. 106-3 ¶¶ 2-27, and the Declaration
of Todd Shrader, ECF No. 76-5. Advancing operations at the Low-Activity
Waste Facility and necessary support facilities, however, will mean that a larger
portion of DOE’s annual funding will be directed in the near term to the Low-
Activity Waste Facility. Accordingly, less funding will be available to advance
design and construction of the High-Level Waste and Pretreatment Facilities in
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
20
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
the early years, with that proportion reversed later in the project. DOE’s
assumptions as to the timing of the High-Level Waste and Pretreatment
Facilities reflect this sequencing.
31. While funding is a limitation on DOE’s assumptions for the High-
Level Waste and Pretreatment Facilities, it is not the only limitation. Even with
additional funds, there are physical and operational limits on how many people
and pieces of equipment can be in a single workspace at one time. These
limitations are more pronounced at the WTP because many spaces are small and
closed off (to prevent any spread of radiation when in operation), but house
intricate and complex systems and equipment. Likewise, the sequence of work
to be performed limits the pace of construction within a facility. For example, to
build a facility, first the concrete must be placed and then the pipes installed, and
then electrical systems built, and so on.
32. Finally, DOE’s milestone assumptions have been informed by its
experience in developing a modified performance baseline and negotiating a
modified contract at the Low-Activity Waste Facility. Unlike the other major
WTP facilities, this process is underway at the Low-Activity Waste Facility
because that facility has not been affected by the primary unresolved technical
issues. DOE’s experience in re-baselining and contracting this Facility has been
instructive: although the work is not complete, the process to date has suggested
that re-baselining and contracting might take longer for the WTP than for other
projects, given the complexity of the work and the types of issues that have
arisen. The work to develop a modified performance baseline and negotiate a
modified contract has also suggested that the WTP facilities may be more
costly—and so, with fixed appropriations, may take longer to build—than
anticipated under the original Decree.
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
21
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
33. Given these assumptions, DOE’s milestones assume that design and
construction work will proceed first at the Low-Activity Waste Facility, then at
the High-Level Waste Facility, and finally at the Pretreatment Facility (though
work to resolve the primary technical issues is already underway). This
assumption aligns with DOE’s expectations about the relative burden at each
facility to resolve technical issues and effectuate redesign work, with the
Pretreatment Facility subject to greater uncertainties than the other two facilities.
It also allows DOE to effectively manage its workforce: as the Low-Activity
Waste Facility progresses through redesign, the on-site engineering resources
previously devoted to that facility can be applied to the High-Level Waste
Facility, and then—in sequence—to the Pretreatment Facility. In this way, DOE
will transition engineering resources over to each facility when those resources
are available, and avoid the need to lay off and re-hire experienced engineers.
Specific Assumptions
34. Technical Issues. To establish WTP milestones, DOE assumed that
the five primary technical issues affecting the High-Level Waste and
Pretreatment Facilities will be resolved by June 30, 2019. This date assumes that
technical issues will be favorably and completely resolved through the current
testing or modeling approaches, along with a small amount of contingency built
in to account for the possibility of minor re-testing or other limited follow-on
work. Any additional work, which would become necessary if scientific
outcomes were instead unfavorable, would necessitate an extension under
DOE’s proposed extension mechanism. DOE’s assumed date for resolution of
the technical issues also includes the time necessary for testing results, data, and
findings to be reviewed by experts in the field, often including external experts,
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
22
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
and for the appropriate project manager to authorize issue closure and the
commencement of redesign.
35. DOE continues to work to resolve the primary technical issues, and,
as described above, is making progress. However, technical issue resolution has
been somewhat delayed by funding complications: in Fiscal Year 2015,
Congress reduced the funds available for the Pretreatment Facility. As a result,
DOE was forced to slow down the technical issue resolution process. Resolution
work is not yet back to full capacity because the present continuing resolution
has caused the budget shortfall to continue at least until December 11, 2015.
This delay has pushed back the timeframe for issue resolution.
36. Redesign Work. In estimating milestones, DOE also assumed that
redesign work will be completed at the High-Level Waste Facility by December
31, 2021, and at the Pretreatment Facility by December 31, 2024. These
timeframes are very difficult to predict, as discussed above, because the full
scope of the work to be done will not be known until after issue resolution is
complete. Redesigning a facility includes completing architectural drawings,
safety design, and all the calculations that support changes to address the
technical issues. Redesign is not limited to the narrow modification that resolves
the technical issue: for example, if technical issue resolution determines that a
new type of vessel must be used, then the redesign process will include that new
vessel, but must also consider how piping associated with the vessel is
redesigned. Similarly, a new vessel or the way that material is mixed in the
vessel could potentially change the power requirements for the facility. Thus,
redesign is not just about changing specific equipment, it is about identifying the
significant ripple effects in the structural layout, piping, power, ventilation, and
other systems that could themselves require detailed redesign. Moreover, even
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
23
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
after components, equipment, and processes are designed, DOE must still verify
the new work to ensure that it meets nuclear safety and other specifications.
37. Accordingly, DOE based its assumptions on its professional
judgment that facility redesign would take a minimum of two years after the
resolution of technical issues, plus some additional time to account for the
likelihood of a more-complicated-than-average redesign at the High-Level
Waste Facility, and a significantly more-complicated-than-average redesign at
the Pretreatment Facility. Given funding constraints and sequencing
expectations, described above, these dates also reflect the fact that redesign will
begin at the High-Level Waste Facility first, with work at the Pretreatment
Facility starting more slowly and ramping up as redesign at the High-Level
Waste Facility reaches completion. Redesign is complete and verified when
each layer of design has been approved. One layer of redesign, for example, is
updating and approving the piping and instrument drawings. Another example
of a layer of design is completing and approving the vessel specifications.
Layers of design are approved by the appropriate contractor engineers and site
managers. Because the design changes to the High-Level Waste and
Pretreatment Facilities will have to be reflected in changes to the performance
baseline, DOE will also have to approve the changes.
38. Notably, the two-year assumption for redesign does not account for
the time that may be necessary to perform further issue resolution and additional
rounds of redesign activities if designs cannot be verified as meeting nuclear
safety or other specifications. For example, technical issue resolution may result
in a new vessel design. But verification of the vessel’s design could show that
the new design does not meet seismic requirements for structural stability. If
meeting these requirements would require additional seismic supports within the
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
24
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
vessel itself, that could affect how the vessel operates and require a new round
of technical issue resolution and, likely, redesign. This additional work could
(very likely) not be completed in the two-year redesign period assumed as part
of the milestone dates and so would require an extension under the mechanism
described above.
39. Baseline and Contract. To establish WTP milestones, DOE also
assumed that development of performance baselines and execution of new or
modified contracts will be completed at the High-Level Waste Facility by
December 31, 2024, and at the Pretreatment Facility by December 31, 2027.
Typically, DOE estimates that it will take at least one year for the contractor to
develop a proposed performance baseline, followed by one to three years of
review and approvals regarding the final baseline and its embodiment in a
negotiated contract. In this instance, DOE has assumed that the baseline
proposal will take one year and that the review and approval process will take
two years, the median amount of time. The two-year period includes time for the
baseline and contract to be approved within DOE. It must also account for the
time necessary for a third-party review of the performance baseline under DOE
Order 413.3B, which is conducted by DOE’s Office of Acquisition and Project
Management in consultation with outside subject matter experts. This results in
a total of three years to complete re-baselining and contracting after the
conclusion of redesign at each facility.
40. Re-baselining and contracting for the WTP, however, will involve
negotiating difficult issues, including how new work relates to work already
provided for in the existing baselines and contracts. If negotiations become
especially complicated, and take more than two years to complete, then an
extension will be necessary under DOE’s extension mechanism. DOE’s
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
25
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
assumptions for re-baselining and contracting also do not account for any
possible delay that could result if management or third-party reviews of the
performance baseline were to suggest changes requiring DOE and the contractor
to restart negotiations.
41. Construction. To propose WTP milestones, DOE also had to make
assumptions about the duration of construction expected for each facility. In
contrast to 2010, when baselines and contracts were in place, DOE does not
presently have an up-to-date schedule for redesign and construction. Without
baselines and contracts to determine the schedule, estimating construction
timeframes is a highly speculative inquiry. DOE developed the assumptions
used to support its “construction substantially complete” milestones by basing
construction estimates on the only up-to-date information available: the work
being performed to propose a modified baseline for the Low-Activity Waste
Facility. That work suggests a lengthier construction schedule for the Low-
Activity Waste Facility than the original, approved baseline that informed the
milestones in the 2010 Consent Decree. DOE’s assumptions for construction
times for the High-Level Waste and Pretreatment Facilities build upon the
information learned through the development of the Low-Activity Waste
Facility schedule and presume a similar extension of the schedule will be
necessary for these two more complex facilities. On top of these factors, DOE
added time to approximate the new work needed to resolve the technical issues
and complete and verify redesign, and considered the fundamental workforce,
space, and equipment constraints on how much work, as a practical matter, can
be completed in the facilities at one time. The result is a highly uncertain
projection of the time needed to construct these two facilities, which will remain
uncertain until a baseline and contract are established.
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
THIRD SUPPLEMENTAL DECL. OF BENTON J. HARP
26
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
42. Commissioning. Finally, DOE has assumed that cold and hot
commissioning of the Pretreatment Facility will each take 1.5 years rather than
one year. This slightly extended schedule reflects the information presently in
development at the Low-Activity Waste Facility, which indicates that
commissioning times may be longer than expected. As noted above,
commissioning dates for the High-Level Waste and Low-Activity Waste
Facilities are set to align with those for the Pretreatment Facility so that the
waste fed into and separated by the Pretreatment Facility during hot
commissioning can be fed to the two vitrification facilities to support their own
hot commissioning.
43. In applying these assumptions to the original table of milestones,
DOE has generally maintained the same relative timing of the milestones.
However, independent from the assumptions above, DOE has altered the
proposed sequence of two of the more specific construction milestones—A-13
(vessel installation in the Pretreatment Facility) and A-19 (completing a concrete
floor in the Pretreatment Facility). Because the actual sequencing of these steps
will not be known until a baseline and contract are developed, the dates included
in DOE’s proposed milestone table align milestones A-13 and A-19 with the
“construction substantially complete” milestone for the Pretreatment Facility.
Once the new or modified baseline for the Pretreatment Facility provides detail
on how specific construction tasks will be sequenced, these milestones may be
updated to reflect actual construction plans.
44. DOE’s proposal reflects the informed projections presently
available regarding the timeframe for completing the WTP. However, even these
assumptions, developed by experts in the field, cannot adequately and
reasonably define a firm schedule. There is simply too much uncertainty
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
Case 2:08-cv-05085-RMP Document 196-2 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
1
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
JOHN C. CRUDEN Assistant Attorney General Environment & Natural Resources Division United States Department of Justice MICHAEL C. ORMSBY United States Attorney Eastern District of Washington DAVID J. KAPLAN ELIZABETH B. DAWSON CHLOE H. KOLMAN AUSTIN D. SAYLOR Environmental Defense Section P.O. Box 7611 Washington, D.C. 20044 (202) 514-2219 VANESSA WALDREF Assistant United States Attorney 920 West Riverside Ave., Suite 300 Spokane, WA 99201 (509) 353-2767 UNITED STATES DISTRICT COURT
EASTERN DISTRICT OF WASHINGTON
STATE OF WASHINGTON, DEPARTMENT OF ECOLOGY,
Plaintiff,
v. ERNEST MONIZ, Secretary of the United States Department of Energy, and the UNITED STATES DEPARTMENT OF ENERGY, Defendants.
NO. 08-5085-RMP FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
I, Thomas Fletcher, pursuant to 28 U.S.C. § 1746, declare, under penalty
of perjury, that the following statements are true and correct based upon my
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
2
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
personal knowledge or upon information provided to me by persons under my
supervision, or federal and contractor personnel with whom I routinely interact.
1. This declaration supplements my five previous declarations, filed
with this Court on October 21, 2014 (Corrected Declaration of Thomas Fletcher)
(ECF No. 94); December 5, 2014 (Supplemental Declaration of Thomas
Fletcher) (ECF No. 106-4); January 16, 2015 (Second Supplemental Declaration
of Thomas Fletcher) (ECF No. 113-2); June 5, 2015 (Third Supplemental
Declaration of Thomas Fletcher) (ECF No. 148); and June 19, 2015 (Fourth
Supplemental Declaration of Thomas Fletcher) (ECF No. 153). In this
declaration, I explain the Hanford Tank Farms-related elements of the U.S.
Department of Energy’s (“DOE”) Second Proposed Consent Decree
Modification in accordance with this Court’s Order of August 13, 2015 (ECF
No. 170), including an explanation of the facts relevant to revised proposed
deadlines for the remaining 12 tanks to be retrieved subject to the Consent
Decree and the basis for DOE’s proposal regarding use of the 242-A Evaporator
and contingent construction of new double-shell tanks (“DSTs”).
2. As explained more fully in my first declaration, ECF No. 94 ¶¶ 1–
6, I am currently the Assistant Manager for the Tank Farms in the Hanford
Office of River Protection (“ORP”). As Assistant Manager, I manage the day-to-
day operations of the Tank Farms, overseeing both federal employees and
contractors. I have bachelor’s and master’s degrees in civil engineering, and I
am a Registered Professional Engineer in the State of Washington, as well as a
Certified Project Management Professional and a DOE Certified Senior
Technical Safety Manager.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
3
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
APPENDIX B TANK RETRIEVAL COMPLETION MILESTONES
3. Appendix B of the Consent Decree currently requires that DOE
complete the retrieval of waste from a total of 19 single-shell tanks: ten by
September 30, 2014, and the remaining nine by September 30, 2022. ECF No.
59 at 33. DOE has already completed the retrieval of waste from seven of these
tanks, leaving 12 single-shell tanks subject to the Consent Decree remaining to
be retrieved. Nine of these remaining 12 tanks are located in the A and AX
Tank Farms. The other remaining three tanks, tanks C-102, C-105 and C-111,
are located in the C Tank Farm.
4. Since the filing of my prior declarations and the submission of
DOE’s revised proposal, DOE has determined that a revised milestone date of
March 31, 2024 (including a provision allowing for additional extensions
should workers continue to use self-contained breathing apparatus (“SCBA”)
equipment beyond September 30, 2016), is the earliest date DOE can
reasonably propose for completing the retrieval of the nine A and AX tanks
subject to the Consent Decree. Regarding the three C Farm tanks to be
retrieved, DOE proposes to retrieve tank C-102 by December 31, 2015, which
is the same date in DOE’s prior proposal and 15 months beyond the September
30, 2014, date currently in the Consent Decree. DOE is also proposing revised
milestones for tanks C-105 and C-111, based on current progress toward
retrieving those tanks. Specifically, tank C-105 would be retrieved by a date not
to exceed September 30, 2022, with a retrieval milestone to be set 60 days after
the tank-retrieval technology to be utilized is approved by the State, as detailed
further below. DOE also proposes that the retrieval date for tank C-111 be
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
4
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
extended from the current Consent Decree date of September 30, 2014, to April
30, 2016.
5. As described more fully below, DOE has three primary reasons for
proposing these revisions: (1) DOE is taking a cautious approach to the
continued use of additional protective equipment for workers related to tank
vapors; (2) the recent continuing resolution enacted by Congress on September
30, 2015, has caused delays that have resulted in a need to extend the final
retrieval deadline for the nine A and AX tanks; and (3) current progress towards
completing retrievals at C-Farm and the difficult retrieval circumstances
encountered require an extension of these milestones.
Tank C-102
6. Tank C-102 is one of the remaining 12 tanks to be retrieved under
the Consent Decree. Pursuant to DOE’s revised Milestone B-1, and consistent
with our first proposed modification, DOE proposes to retrieve tank C-102 by
December 31, 2015. ECF No. 94 ¶ 44.
Tank C-105
7. Tank C-105 is another one of the remaining 12 tanks to be retrieved
under the Consent Decree. As I noted previously, the identification of tank waste
properties at tank C-105 required additional time and resources beyond what
was expected. ECF No. 113-2 ¶ 18. DOE has already initiated negotiations of
retrieval technology for C-105 (as anticipated in DOE’s first proposed
modification). Accordingly, DOE is proposing a new B-1A milestone that would
require that, 60 days after the State approves a Tank Waste Retrieval Work Plan
revision in accordance with Section IV-B-4 and Appendix C of the existing
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
5
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
Consent Decree, DOE must propose a milestone, not to exceed September 30,
2022, to complete the retrieval of waste from tank C-105.
8. DOE and the State have ongoing discussions about the retrieval
technology for C-105; once the discussions are complete DOE will transmit a
formal revision to the Tank Waste Retrieval Work Plan for the State’s approval.
After the revision is approved by the State, DOE can proceed to proposing a
new milestone for completing retrieval of C-105. The requirement to complete a
Tank Waste Retrieval Work Plan for tank C-105 that includes a discussion of
the retrieval technologies to be used is not new; indeed, such a discussion is
required to comply with the Consent Decree. ECF No. 59 at 37–41. DOE had
prepared a Tank Waste Retrieval Work Plan for C-105, which the State
approved, before the retrieval issues arose. ECF No. 113-2 ¶ 18.
9. DOE’s proposed new B-1A milestone therefore accurately captures
the current state of planning for C-105 and provides a clear and achievable goal
for setting a date to complete retrieval of C-105, in light of the difficulties with
retrieving waste from the tank as described in my prior declarations. ECF No. 94
¶ 44; ECF No. 113-2 ¶¶ 18–20.
Tank C-111
10. Tank C-111 is also one of the remaining 12 tanks to be retrieved
under the Consent Decree. The current Consent Decree requires tank C-111 to
have been retrieved by September 30, 2014. As discussed in my prior
declarations, DOE has encountered particularly difficult conditions at tank C-
111 that have delayed retrieval of waste from that tank. ECF No. 94 ¶ 44; ECF
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
6
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
No. 113-2 ¶ 21. For those reasons, DOE had proposed that the date for retrieval
of C-111 be moved to December 31, 2015. ECF No. 76-1 at 12.
11. Since proposing a revised date, DOE has identified and made
progress towards resolving two nuclear safety-related issues that have delayed
the retrieval of the waste from the C-111 tank.
12. First, on June 15, 2015, DOE identified a problem that raises
significant safety issues concerning heat that can be transferred to waste transfer
process hoses during retrievals. Hoses used to transfer waste during retrieval
operations are bundled (co-located) with the high pressure hydraulic hoses that
operate the retrieval system pumps and sluicers. The fluid temperature in the
hydraulic hoses is a heat source and could result in the adjacent waste transfer
hoses exceeding their design temperature and potentially degrading and failing.
By the end of September 2015, DOE had completed the final calculations
needed to allow C-111 retrievals to commence, lowering temperature set points
on the high pressure units that operate retrieval pumps and sluicers based on the
new thermal analyses.
13. Second, on April 18, 2015, a component failed in the waste transfer
system located in the C-102 extended-reach sluicer hose reel assembly resulting
in a waste leak into the containment pit. Our nuclear safety procedures require
that DOE determine whether the leak was caused by a new failure mode that
may impact similar equipment including the sluicers that were to be installed in
C-111. If DOE were to determine that a new failure mode had been identified,
the C-111 sluicers would need to be redesigned, new controls would need to be
added to the nuclear safety basis, or similar potentially significant actions would
need to be taken to protect people and the environment from a waste leak. DOE
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
7
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
performed an analysis that identified the most probable components that could
have been involved with the waste leak. These components were checked during
an additional Factory Acceptance Test of the new C-111 sluicer unit prior to
tank installation. No anomalies were found and this issue was completed on
August 20, 2015. Attached as Exhibit A to this declaration is an Occurrence
Report that documents the identification, investigation, and resolution of these
issues.
14. Although these two nuclear safety issues have now been resolved,
they have delayed retrieving the waste from the tank, which makes the
previously-proposed deadline of December 31, 2015, unworkable.
15. As with other retrievals, the use of SCBA equipment due to vapors-
related concerns, described below, has also impacted retrievals at C-111.
16. Taking into consideration all of these issues, DOE has identified
April 30, 2016, as the most reasonable milestone deadline for completing the
retrieval of C-111.
A/AX Tanks: Revision to the Proposed B-2 Milestone Date
17. As described in my declaration supporting DOE’s revision to its
first proposed modification, and as discussed further below, retrieval of the nine
remaining A and AX Farm tanks had been delayed by a year, from September
2022 to September 2023, due to impacts from the vapors issue. ECF No. 148 ¶
3–5. This retrieval date assumed that the use of SCBA will conclude by the end
of Fiscal Year (“FY”) 2016.
18. In addition, on September 30, 2015, Congress passed and the
President signed H.R. 719, the Continuing Appropriations Act, 2016, which
continued to fund the federal government only through December 11, 2015.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
8
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
That continuing resolution held funding at the level appropriated for FY2015,
which is less than what was requested for FY2016 to allow DOE to continue to
make progress towards completing tank waste retrievals. DOE does not yet
know what its appropriations will be after December 11, 2015.
19. Due to the gap in funding, the September 30, 2023 retrieval
completion date previously proposed by DOE has been delayed by at least two
months, and likely as much as six months. This delay is attributed to, among
other consequences, limitations on DOE’s ability to hire and train Tank Farm
workers. Additionally, the gap in funding has resulted in the inability to execute
contracts for “long lead” equipment, i.e., equipment that takes a significant
amount of time to build. After adequate funding resumes, DOE can execute the
contracts, but then it will be in the back of the line for fabrication of the long
lead equipment, resulting in additional delay.
20. In light of that delay, DOE is proposing a milestone deadline of
March 31, 2024, for completion of retrievals. This date accounts for the
operational flexibility necessary to recover from the disruption caused by the
funding shortage. It also accounts for the use of SCBA until FY2016, although,
as explained below, DOE proposes automatic extensions in the event of
continued use of SCBA beyond FY2016.
Vapors
21. As I previously explained, waste tanks emit excess vapor to the
atmosphere to prevent the unsafe buildup of flammable gasses as part of normal
operation. ECF No. 113-2 ¶ 49. DOE and its Tank Farms contractor,
Washington River Protection Solutions (“WRPS”) received reports from
workers indicating that they may have experienced health-related impacts from
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
9
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
exposure to these vapors. ECF No. 113-2 ¶ 51. As discussed in previous
declarations, the Tank Vapor Assessment Team (“TVAT”) report prepared in
response to this issue hypothesized that potential short, intermittent, higher
concentration vapor emissions could result in brief but intense exposures for
some workers. ECF No. 113-2 ¶ 53. DOE is carefully studying the issue and is
taking a protective approach to worker safety; this includes directing Tank
Farm workers to wear additional protective equipment such as SCBA. ECF No.
113-2 ¶¶ 52–54; ECF No. 148 ¶¶ 2–5. The use of SCBA reduces the efficiency
of the tank waste retrievals for several reasons, among them physiological
constraints on workers from increased heat, weight, and reduced mobility; the
need for new compressed air tanks after only 20–40 minutes of work, ECF No.
148 ¶ 3; and regulatory requirements that prevent the use of SCBA when the air
temperature rises above a certain degree. SCBA has always been and will
continue to be used during Tank Farm work for specific tasks, but this across-
the-board use of SCBA for the retrieval of waste from tanks is a new
development.
22. Due to the uncertainty of how long the use of SCBA for all retrieval
work will be directed, DOE has reassessed whether the B-2 Milestone for
retrievals at the remaining nine A and AX Farm tanks is realistically
achievable. ECF No. 113-2 ¶¶ 56–57. In DOE’s June 5, 2015 revision to its first
proposed modification, DOE proposed that the September 30, 2022 date be
extended to September 30, 2023, to account for the inefficiencies caused by the
use of SCBA and DOE’s assessment, based on what was known at the time, of
how long SCBA might be used. ECF No. 148 ¶¶ 3–5.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
10
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
23. As previously indicated, DOE, in coordination with WRPS, still
anticipates that it may be able to verify the technical basis for the conclusion
that ending the vapor-related use of SCBA at the end of FY2016 is warranted,
as stated in my prior declaration. ECF No. 148 ¶ 4. Accordingly, as noted
above, DOE has set retrieval dates for the A and AX tanks on the assumption
that SCBA use will conclude by the end of FY2016.
24. However, it is possible that SCBA use may extend past FY2016—
which would necessitate further extension of the A and AX retrieval date. First,
because DOE is taking a cautious approach to worker safety, DOE may
determine based on available information that it is in the best interests of the
Tank Farm retrieval employees to continue using SCBA beyond FY2016.
Second, DOE cannot be certain that it will have the scientific evidence by the
end of FY2016 to be able to determine whether SCBA equipment is no longer
appropriate. DOE does not yet have all of the data it requires to make that
determination. Actions taken pursuant to Phase I of the TVAT Report
Implementation Plan and other research work may provide the needed
information to return to a level of respiratory protection that is commensurate
with the risks of retrieval work, as opposed to the blanket SCBA use currently
in place for the A and AX Tank Farm work scope—or they may not. Inability
to successfully return to a level of respiratory protection that is commensurate
with the risks of retrieval work by the end of FY2016 will further impede
DOE’s ability to meet the milestones and schedule DOE proposes for Appendix
B, because the continued use of SCBA may be directed.
25. Moreover, Tank Farm workers maintain the option to continue
using SCBA equipment, even if DOE, in conjunction with WRPS, determines
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
11
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
that it is not technically necessary. DOE expects that some workers will opt to
do so based on past and current experience. Because DOE cannot accurately
estimate how many workers will personally elect to use SCBA equipment or for
how long, it cannot accurately estimate the precise delay that could result from
optional use of SCBA beyond FY2016. However, I do expect that if a
significant number of employees choose to use SCBA, additional delays will
occur.
26. Due to this uncertainty regarding when across-the-board SCBA will
no longer be continued, DOE’s proposal includes an automatic extension of the
proposed B-2, B-3, B-4, and B-5 Milestones in the event that SCBA continues
to be used beyond September 30, 2016 (whether per a DOE and WRPS
direction or at the option of a significant number of employees). The extension
would begin to apply on October 1, 2016, if SCBA is still being used, and
would add an additional day to each milestone mentioned above for every two
days beyond September 30, 2016, that SCBA is used. For example, if SCBA is
used for an additional 60 days after September 30, 2016, then the proposed B-2
Milestone would be extended by 30 days, to April 30, 2024. This automatic
extension is a reasonable way to address a contingency—the possible need to
use SCBA for an indeterminate amount of time beyond FY2016—that may
occur, and that we know will impact retrievals if it does occur. The 2:1 ratio of
the extension is also reasonable, because experience has shown that SCBA
reduces the efficiency of retrieval work inside the Tank Farm by approximately
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
12
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
50%, and therefore only one additional day is needed for every two days of
continued SCBA use.
27. This automatic extension process reflects DOE’s present inability
to determine when SCBA will no longer be technically necessary for all
retrieval work, or when its use due to employees’ individual choice will end,
and therefore its inability to ascertain at this time the full impact that across-the-
board use of SCBA will have on the retrieval timeframe. Without the automatic
extension, DOE would not be able to responsibly set March 31, 2024 as the
milestone for completing Consent Decree retrievals. Instead, DOE would have
to propose a date well beyond 2024 to reasonably accommodate this
contingency and the very real risk it currently poses to completing the retrievals
in a timely fashion. Rather than providing a speculative date, DOE’s proposed
automatic extension is directly tied—and proportional—to the length of any
continued delay beyond FY2016 due to the use of SCBA equipment.
THE 242-A EVAPORATOR
28. The 242-A Evaporator reduces the waste volume stored in the
DSTs by concentrating the liquid waste, thereby creating additional storage
space for waste retrieved from single-shell tanks.
29. As I have previously explained, DOE planned to use the 242-A
Evaporator to create space to facilitate single-shell tank retrievals at the time
that the Consent Decree was entered in 2010. ECF No. 153 ¶ 5. I have
referenced DOE’s planned use of the 242-A Evaporator throughout the briefing
of proposals to modify the Consent Decree. ECF No. 113-2 ¶ 31; ECF No. 106-
4 ¶¶ 27–28.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
13
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
30. The State has also acknowledged DOE’s plan to run 242-A
Evaporator campaigns to create additional DST space during the Consent
Decree retrievals and expressed no reservations about the 242-A Evaporator’s
fitness for the task. ECF No. 102 at 38 n.23 (State Response Brief in Support of
Petition to Amend Consent Decree); ECF No. 84 ¶ 26 (Declaration of Jeffrey
Lyon in Support of Washington’s Petition to Amend Consent Decree). The
State raised concerns only regarding the ability of the Evaporator to create
adequate DST space to handle retrievals occurring after the Consent Decree
timeframe, as part of the Hanford Federal Facility and Compliance Order
(“HFFACO”). ECF No. 84 ¶¶ 34–38; ECF No. 102 at 37–39. ECF No. 150 ¶¶
8–19 (Fourth Declaration of Jeffrey Lyon in Support of Washington’s Petition
to Amend Consent Decree). The State has only recently questioned whether the
242-A Evaporator will reliably function as planned.
31. At the outset, it is important to keep in mind how the 242-A
Evaporator will be used for the A and AX Tank Farm retrievals. For those
retrievals, the 242-A Evaporator serves two distinct functions in two phases:
a. First, it evaporates liquid from the existing waste in the
DSTs, thereby creating additional capacity.
b. Second, the 242-A Evaporator operates to remove liquid that
was added to the single-shell tanks during the retrieval process.
During this second phase, the 242-A Evaporator will reduce the
overall volume of the waste in the DSTs after retrieval, including
the liquid that was added to the single-shell tanks. However,
because a portion of the added liquid cannot be completely
evaporated from the retrieved waste in the DSTs, roughly two times
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
14
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
as much waste will remain in the DSTs after the 242-A Evaporator
campaigns as compared to the original volume of waste in the
single-shell tanks. Additional background regarding the retrieval
process can be found in my first declaration. ECF No. 94 ¶ 48.
32. Attached as Exhibit C to this declaration is a report entitled
“Capability of the 242-A Evaporator to Support A and AX Farm Retrieval”
(“Evaporator Report”), which was prepared by WRPS at my direction. The
Evaporator Report describes in detail the history, use, and status of the 242-A
Evaporator, and explains why DOE is confident that the 242-A Evaporator is up
to the task of achieving sufficient waste volume reduction to support retrievals.
33. The Evaporator Report primarily focuses on the nine A and AX
Farm tanks remaining to be retrieved under the Consent Decree, and not on
those remaining to be retrieved in C-Farm. This is because the current available
space in the 200 East Area of the DST system—where C-Farm is located—is
greater than the space necessary to complete retrievals. More specifically, as of
the beginning of FY2016 the East Area has 3.31 million gallons (“Mgal”) of
available space. Evaporator Report at A-2, Table A-1b. The estimated volume
of as-retrieved waste (original waste plus liquid necessary for retrievals) for
tanks C-105 and C-111 is only 0.42 Mgal. Evaporator Report at A-2, Table A-
1c. Therefore, use of the 242-A Evaporator is not necessary to accomplish
retrievals at C-Farm.
34. The 242-A Evaporator was first put into service in 1977. Through
2015, it has processed over 130 Mgal of waste, for a total waste volume
reduction of over 80 Mgal. Evaporator Report at 2.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
35. Most of the 242-A Evaporator campaigns were conducted during
the 1970s and the 1980s, after which its use declined due to lack of mission
necessity (rather than inability to perform). Indeed, between 2010 and 2014, the
242-A Evaporator was not used at all because it was not needed to reduce waste
volume at that time. Instead, DOE used that time to perform equipment and
safety upgrades to the 242-A Evaporator, which extended its useful life.
Evaporator Report at 8. Because, as noted above, DOE has always been
planning to use the 242-A Evaporator to facilitate retrievals, DOE undertook
the upgrades between 2010 and 2014 to ensure that it could operate as needed.
Evaporator Report at i, 2–5.
36. The 242-A Evaporator was put back into service in September
2014, and between September 2014 and September 2015 achieved a waste
volume reduction of 1.9 Mgal from a waste feed of 4.6 Mgal over four
campaigns. Evaporator Report at 2.
37. A 2011 reliability assessment performed by a DOE contractor
concluded that, due to the equipment upgrades and other maintenance that was
performed prior to that assessment, and assuming continued ability to upgrade
and perform maintenance as necessary, the 242-A Evaporator would be capable
of operating for another 30 years. Evaporator Report at i, 18.
38. Past upgrades include expansion of the facilities; upgrading pumps,
slurry systems, and ancillary systems; replacing condensers and air
compressors; and upgrading ventilation systems. Evaporator Report at 25.
39. In addition to past upgrades, DOE has a suite of testing,
surveillance, and maintenance programs for the 242-A Evaporator to keep it in
good working order. Evaporator Report at 5–6.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
16
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
40. To assess the anticipated waste volume reductions the 242-A
Evaporator could achieve by evaporating liquid from A and AX Farm tanks,
DOE conducted both a steady-state evaluation and dynamic modeling using
DOE software (the Hanford Tank Waste Operations Simulator, or “HTWOS”).
The HTWOS model estimates the amount of waste volume reduction that will
be achieved on a tank-by-tank basis, using input parameters such as the specific
characteristics of the waste in each tank and estimates of the volumes of liquid
necessary to retrieve the waste in each tank. Evaporator Report at 7–8, 17,
Table 3-5. The HTWOS model assumes that the Low Activity Waste
Pretreatment System and the Direct Feed Low Activity Waste facility do not
become operational until FY2022. Therefore, the model does not assume that
the operation of those facilities would create any tank space for the time period
between FY2016 and FY2021, inclusive, which is when DOE plans to run the
242-A Evaporator to reduce waste volume to facilitate retrievals of the nine A
and AX Farm tanks. Evaporator Report at 8.
41. The steady-state evaluation demonstrated that the 242-A
Evaporator is not a limiting factor in having the tank space necessary to
complete the remaining A and AX Farm tank retrievals. Evaporator Report at
10.
42. Using the modeling software to evaluate a dynamic scenario
accounting for the current variables in A and AX Farms, DOE has also
concluded that the 242-A Evaporator will achieve a waste volume reduction
more than sufficient to provide space for the next nine A and AX Farm
retrievals. Evaporator Report at 11–14. The dynamic modeling shows that DOE
will only need to use the 242-A Evaporator for approximately 6% of the total
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
17
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
number of days from the beginning of FY2016 to the end of FY2021, and at
approximately 14% percent of its State-permitted capacity, to achieve a waste
volume reduction sufficient for these retrievals. Evaporator Report at 13. In
other words, although the 242-A Evaporator is permitted to operate up to 152
days per year, or 912 days from FY2016 through FY2021, DOE projects that it
will only need to operate it for 130 days total over that period to achieve its
goal for waste volume reduction.
43. DOE did not limit itself to modeling based on current variables.
DOE also modeled scenarios where the 242-A Evaporator would be out of
operation for 18 months, either at the start of retrieval of the last two A-Farm
tanks, or after retrieval of the first two AX-Farm tanks. Even then, the models
show that the 242-A Evaporator has sufficient capacity to achieve the necessary
waste volume reduction to retrieve the nine remaining A and AX Farm tanks in
compliance with the B-2 Milestone in Appendix B, either as now proposed by
DOE (i.e., March 31, 2024) or as subsequently modified pursuant to DOE’s
proposal. Evaporator Report at 15–16.
44. Based on these modeling scenarios, DOE has developed an
estimated schedule of 242-A Evaporator campaigns to be conducted over the
next six years that will reduce sufficient waste volume to facilitate tank waste
retrievals. Evaporator Report at 14, Table 3-3. The schedule as it appears in the
Evaporator Report describes the amount of waste volume reduction DOE’s
model suggests it will achieve, which is more than what DOE actually needs to
facilitate retrievals. Although in my Fourth Supplemental Declaration I
described DOE’s estimated 242-A Evaporator campaigns as running through
FY2022, ECF No. 153 ¶ 8, the Evaporator Report attached to this declaration
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
18
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
reflects DOE’s most updated estimates, i.e., campaigns running from FY2016
through FY2021, with the possible addition of campaigns in FY2022 and
FY2023 if necessary.
45. The Evaporator Report also demonstrates that the current schedule
for the 242-A Evaporator campaigns may be adjusted in a number of ways and
still achieve the required waste volume reduction in time to complete the
retrieval of the nine A and AX Farm tanks by DOE’s proposed B-2 Milestone
of March 31, 2024. In addition to extra time, because organic emissions from
the 242-A Evaporator campaigns have not reached a level where they would
approach regulatory limits, multiple campaigns could be conducted each year
without anticipated regulatory exceedances.
DOE’S PROPOSAL FOR DST CONSTRUCTION, CONTINGENT UPON
242-A EVAPORATOR PERFORMANCE
46. The following section of my declaration first describes the core
concepts underlying DOE’s proposal, in response to the Court’s Order, to make
the construction of new DSTs contingent upon the performance of the 242-A
Evaporator. I then describe the mechanics of the proposal, and how the
underlying concepts inform the proposal in practice.
Core Concepts Underlying DOE’s Proposal for DST Construction
Targets for Waste Volume Reduction
47. As described above, DOE has identified estimated annual waste
volume reductions from 242-A Evaporator campaigns from FY2016 through
FY2021 that will provide more than enough space to facilitate the retrieval of
the nine A and AX Farm tanks by March 31, 2024. For the purpose of DOE’s
proposal, DOE is identifying the estimated annual waste volume reductions that
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
19
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
are actually necessary to facilitate those retrievals. These estimated annual
waste volume reductions serve as the targets (subject to future modification) for
timely completion of those retrievals. This approach to identifying targets is the
most practicable way to ensure that sufficient waste volume reduction is
achieved without requiring extraordinary measures to achieve an estimated, but
unnecessary, waste volume reduction.
48. Although DOE plans to achieve all necessary waste volume
reduction by the end of FY2021, it does not actually need to be completed until
March 31, 2023 (i.e., one calendar year prior to the B-2 Milestone in Appendix
B, which DOE proposes to be March 31, 2024). Having approximately 1.5
years of “float” at the end of the proposed schedule provides additional
operational flexibility to adjust and recover from a lack of waste volume
reduction in a given campaign or from missing an annual waste volume
reduction goal.
49. The Evaporator Report explains that DOE’s estimates for waste
volume reduction are also based on DOE’s current knowledge regarding each
tank’s waste characteristics. To provide more specific knowledge in advance of
a campaign on an individual tank, DOE conducts a “boil-down” test run with
actual waste from the tank. It is possible that, after a boil-down test, the
estimated waste volume reduction could decrease or increase. In the event an
estimate is adjusted downward, DOE may be unable to achieve a waste volume
reduction target for that year. However, as noted above, DOE’s current plan
represents a very small amount of annual 242-A Evaporator usage compared
with what is allowed under DOE’s permit. This means that even if DOE could
not run enough campaigns in one year to make up a shortfall (whether due to a
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
20
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
changed estimate or otherwise), it could do so in the following year. DOE has
also built into its targets an extra one and a half years—FY2022 and the first
half of FY2023—to run additional campaigns as necessary. This provides DOE
with additional reasons why it is confident it can achieve sufficient waste
volume reduction to facilitate retrievals in compliance with DOE’s new
proposed deadline of March 31, 2024.
50. One variable that could cause a delay that could not be mitigated
within the approximate 1.5 year float time is a lack of sufficient waste feed to
process through the 242-A Evaporator. Obviously, without sufficient feed, the
242-A Evaporator cannot do its job. Therefore, if sufficient waste feed is
unavailable, DOE may be unable to achieve a waste volume reduction target for
one year or several. In contrast to the flexibility DOE proposes with respect to
other variables that would make use of the approximate 1.5 year float time in
the current plan, DOE’s proposal includes an extension of time that would be
triggered if sufficient waste feed is unavailable. Under DOE’s proposal, the
time to achieve the required waste volume reduction would be extended in
proportion to the amount of time that sufficient waste feed was unavailable,
unless DOE determines a different extension is necessary.
51. In sum, because the targets in DOE’s proposal are based upon
estimates—highly specialized though those estimates are—it is necessary to
have the flexibility to adjust both the time- and waste volume reduction-related
targets to adapt to subsequent events and analysis. With respect to timing,
because the 242-A Evaporator is planned to be used for so little of its actual
capacity, additional or longer campaigns can be readily scheduled and run to
account for unanticipated events either with respect to the 242-A Evaporator
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
21
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
itself or other areas of A and AX Tank Farm operations that delay planned
campaigns. With respect to waste volume, again, the ability to run additional
campaigns mitigates less-than-anticipated reductions. Moreover, over the
course of the next several years, DOE may determine that the original total
waste volume reduction target was either more or less than actually required to
facilitate retrievals.
Conditions on the Construction of a New DST
52. The construction of new DSTs is not only unnecessary, but would
also be a barrier to the timely retrieval of the 12 remaining tanks subject to the
Consent Decree. I have already discussed many of these reasons, chief among
them being (1) the staggering amount of resources, both financial and
otherwise, needed to construct a DST that can undermine DOE’s ability to meet
other important cleanup requirements at Hanford or at other DOE sites, ECF
No. 106-4 ¶¶ 35–38; (2) the detriments to the overall mission at Hanford due to
a shift in focus from waste treatment to tank construction and waste storage,
ECF No. 106-4 ¶ 31; and (3) apart from the drain on resources DSTs would
cause, any new DSTs would not be ready in time to provide extra space to
conduct retrievals required under the Consent Decree. ECF No. 106-4 ¶ 33;
ECF No. 153 ¶ 8. With respect to the relationship between DST construction
and the 242-A Evaporator in particular, two additional reasons support DOE’s
conclusion that DST construction is unnecessary. First, DOE would likely have
the ability to mitigate waste volume reduction shortfalls through other less
expensive, more efficient means than DST construction. Second, regardless of
any 242-A Evaporator shortfall in waste volume reduction, DOE likely can still
achieve the proposed B-2 Milestone for retrieving the remaining nine A and
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
22
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
AX Tank Farm tanks (i.e., March 31, 2024), and, even if that milestone date
cannot be met, DOE can still complete the retrievals subject to the B-2
Milestone more quickly without DST construction than with it.
53. DOE’s proposal therefore places important conditions on the
construction of DSTs in the event of 242-A Evaporator performance problems.
These conditions are necessary to ensure that DOE will not, by diverting time
and resources to DST construction, adversely affect cleanup activities that
protect public health and the environment. Without these conditions, DOE
would not be able to responsibly propose triggers to construct DSTs that are
linked to the performance of the 242-A Evaporator. In the ordinary course,
DOE would consider the benefits and detriments to DST construction before
determining that such a drastic measure—one that in these circumstances is
fundamentally at odds with DOE’s current approach for accomplishing its tank
waste cleanup mission at Hanford, ECF No. 94 ¶¶ 28–30; ECF No. 106-4 ¶
30—would be necessary to offset unexpectedly poor 242-A Evaporator
performance. Indeed, as I describe below, many other, less expensive and
easier-to-implement measures are available to compensate for 242-A
Evaporator shortfalls. Without the conditions in DOE’s proposal, a trigger for
constructing new DSTs would not help DOE achieve what the Court has
indicated is the purpose for construction, i.e., timely retrieval of waste from the
tanks subject to the Consent Decree, because such construction could actually
delay retrievals and be counterproductive to protecting public health and the
environment.
54. Resources: In my prior declarations I have highlighted the
irrationality of spending a large portion of already constrained resources on the
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
23
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
construction of new waste storage when DOE already has the means, through
waste volume reduction campaigns of the 242-A Evaporator, to establish more
than adequate space needed for retrievals, and DOE’s finite resources are better
spent towards bringing the Waste Treatment Plant online. Because building
new DSTs would divert resources and shift focus from waste treatment to waste
storage, it would be counterproductive to DOE’s mission at Hanford of
reducing nuclear safety risks. ECF No. 106-4 ¶ 30.
55. As I have previously stated, DOE is unlikely to be appropriated the
funds needed to design, review, and construct one, much less multiple, new
DSTs that could cost between $85 and $150 million apiece. ECF No. 106-4 ¶¶
33–36. Therefore, to bring a new DST into service, DOE would likely have to
divert resources from other projects at Hanford and potentially elsewhere,
risking other important operational goals and jeopardizing compliance with
other agreements or court orders.
56. Diversion of funds is not the only concern. DOE has not built a
DST in almost 30 years at the Hanford site, and a significant amount of time
and personnel resources would need to be devoted to the effort to design,
review, and construct the DST. ECF No. 106-4 ¶ 37. The supply of personnel
specially qualified to work at Hanford is limited; DOE cannot afford to remove
people from work that is essential to Hanford’s nuclear waste treatment mission
to build a DST that would not be usable until after all relevant Consent Decree
retrieval deadlines have passed.
57. Detriments to DOE’s Mission at Hanford: The detriments to the
Hanford tank waste project from DST construction would likely outweigh the
detriments to the project or the risk to public health and the environment from
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
24
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
any delay in completing retrievals. As I have previously explained, DOE has
published an environmental impact statement documenting DOE’s conclusion
that the Waste Treatment Plant is the appropriate mechanism through which to
address nuclear-safety risks from tank waste. ECF No. 106-4 ¶ 30.
58. As I have also explained at length in prior declarations, the
additional risk to groundwater or the Columbia River posed by allowing the
waste to remain in single-shell tanks beyond 2040 is not significant. ECF No.
106-4 ¶¶ 22–24; ECF No. 113-2 ¶¶ 38–44. Taking into account the existing
contamination and the relatively small amount of additional contamination that
could potentially occur, even under a conservative analysis, potential risk to
groundwater is not a credible justification for DST construction.
59. Nor would the construction of additional DSTs increase the rate at
which retrievals could occur or make it more likely that DOE could meet a
retrieval milestone. In fact, just the opposite. In the event the 242-A Evaporator
misses a target and triggers the requirement to build a DST, the diversion of
resources alone that would be required to begin the DST design and
construction process virtually guarantees waste retrieval delay. And even if a
provisional trigger to begin the process to construct new DSTs were to occur as
early as January 1, 2017, for example, and DOE did not determine that any
condition applied to suspend the DST requirement, the earliest the DSTs could
be constructed and put into service is 2025.
60. Additionally, due to the addition of liquid to facilitate single-shell
tank retrievals, the generation of liquid waste would outpace the construction of
the DSTs, which would take 8–10 years to come into operation. ECF No. 106-4
¶¶ 33, 37. But as I have explained, the construction of new DSTs is not
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
25
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
necessary, even considering the potential loss of the storage capacity provided
by AY-102. ECF No. 153 ¶¶ 2–6.
61. Therefore, even if there were uncertainty about the ability of the
242-A Evaporator to facilitate tank waste retrievals, DST construction would be
an illogical response. ECF No. 153 ¶ 16.
62. At the July 23, 2015 hearing on the Parties’ motions to modify the
Consent Decree, counsel for the State suggested that DST construction could
“guard against significant slips past 2022” even if the tanks would not be done
in time to “guarantee 2022.” Transcript of the July 23, 2015 Motion Hearing
Before Hon. Rosanna Malouf Peterson, Chief U.S. District Court Judge (“Mot.
Hr’g Tr.”) 101. That statement defies logic, implying that somehow DOE could
start using a half-constructed DST to have more retrieval space and “guard
against” missing a deadline. The DSTs cannot be used until they are finished,
and they would not be finished, even if construction started today, until late
2023, at the earliest.
63. Ability to Mitigate 242-A Evaporator Shortfalls: DOE has many
options at its disposal short of DST construction to mitigate a shortfall in waste
volume reduction caused by the failure of the 242-A Evaporator to perform as
expected.
64. DOE’s history of using the 242-A Evaporator demonstrates that,
even when unforeseen mechanical issues arise, DOE can fix them and still
achieve significant waste volume reduction. The 13-month period from
September 2014 through September 2015 demonstrates this, because DOE
revised its feed staging strategy to adjust for a failed transfer pump, installed a
new ammonia monitor, repaired a feed line valve, replaced a pump, and still
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
26
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
achieved a 1.9 Mgal volume reduction over the course of four campaigns.
Evaporator Report at 19. Note that some of these issues—like the failed transfer
pump—did not originate at the 242-A Evaporator facility.
65. In the event of less-than-anticipated waste volume reduction due to
mechanical issues that would delay operation of the 242-A Evaporator, DOE
has sufficient extra time already built into the 242-A Evaporator campaign
schedule to compensate for any such reduction. The same is true for an event
unrelated to the waste feed or 242-A Evaporator itself, such as a worker strike
or other work stoppage. Because the 242-A Evaporator only runs during a
portion of each calendar year, DOE could add campaigns to that year’s
schedule or add campaigns in future years, extend the duration of time that 242-
A Evaporator campaigns were otherwise expected to run, or expand the number
of tanks subject to 242-A Evaporator campaigns. Evaporator Report at 19.
Indeed, as stated above, DOE has modeled scenarios where the 242-A
Evaporator would be out for 18 months, or 25% of the total calendar time span
the 242-A Evaporator is currently expected to run campaigns for the purpose of
DOE’s proposal, and still reduce the amount of volume necessary to facilitate
retrievals of the next nine A and AX Farm tanks in compliance with DOE’s
proposed Appendix B milestones for retrievals. Evaporator Report at 15–16.
This is because the current plan for the 242-A Evaporator’s use already builds
in sufficient contingency to mitigate unexpected events.
66. In the event of a total breakdown, and in the event the 242-A
Evaporator cannot be repaired or replaced within 18 months, the time it would
take to construct an entirely new evaporator would only be 5–7 years. Since a
DST would take 8–10 years to construct, that means there would be 3 years
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
27
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
when a new evaporator could be processing waste feed and reducing waste
volume that would instead be delayed due to waiting for the construction of a
DST to be finished.
67. Moreover, although the 242-A Evaporator is the technology that
DOE plans to use to create enough tank space to facilitate the timely retrieval of
the nine A and AX Farm tanks, DOE has other options and contingency
measures it could deploy if the 242-A Evaporator fails to perform as expected.
These include constructing and using mini-evaporators, increasing the specific
gravity level of the waste (which means increasing the amount of water
evaporated from the waste in the tanks during the 242-A Evaporator runs), and
increasing the maximum allowable waste level in some double-shell tanks by
verifying that additional waste in those tanks will not increase environmental
risks. Evaporator Report at 16.
68. Achieving the B-2 Milestone: The entire purpose of the 242-A
Evaporator, and indeed, this entire aspect of DOE’s proposal, is to facilitate
retrieval of the A and AX Farm tanks. As such, if DOE can achieve the
proposed B-2 Milestone of March 31, 2024 without construction of a DST,
notwithstanding any waste volume reduction shortfall by the 242-A Evaporator,
DOE should not be required to construct a DST. Similarly, if the tanks subject
to the B-2 Milestone can be retrieved, even beyond a milestone date, but more
quickly without construction of a DST than with it, DOE should not be required
to construct a DST, especially where DST construction would have significant
and detrimental impacts on the Hanford cleanup mission. As I mention above,
DOE has identified several alternatives that, in the absence of sufficient
performance by the 242-A Evaporator, can recover waste volume reduction
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
28
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
shortfalls more quickly than the 8–10 years it would require to construct a DST.
These alternatives include everything from repairing the 242-A Evaporator or
building a new evaporator, to implementing other space-saving and space-
creating technologies.
69. Depending on the circumstances, it may also make more sense to
simply extend the proposed B-2 Milestone date of March 31, 2024, even
assuming DSTs could somehow mitigate some retrieval delays. As I have
explained, when weighing the great cost and detriment to the project of building
DSTs against both the lack of any significant risk to groundwater or the
Columbia River if retrievals were delayed and the absence of any specific
public health risk that makes 2024 a particularly-significant milestone, the
balance weighs in favor of milestone extension.
Mechanics of DOE’s Proposal
70. DOE’s proposal is structured in a way that most closely aligns with
the realities of engineering project management. For example, although DOE
has an estimate of the waste volume reduction the 242-A Evaporator campaigns
could achieve based upon detailed modeling scenarios, it is impossible to know
precisely how an individual tank’s waste characteristics will behave when being
processed through the 242-A Evaporator until a boil-down test occurs.
Accordingly, the proposal allows DOE to make adjustments to account for
actual results, but still achieve the total waste volume reduction goal in time to
facilitate tank waste retrievals.
71. Targets: Although DOE continues to believe that DSTs are an
inappropriate solution to the perceived problem of 242-A Evaporator
performance, to comply with the Court’s Order, DOE is proposing a schedule
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
29
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
for the use of the 242-A Evaporator that, if not met (either as initially set forth
in the proposal or as subsequently amended), will trigger a requirement to begin
constructing a DST to compensate for waste volume reduction not achieved by
the 242-A Evaporator, subject to the conditions described above.
72. DOE proposes to use its existing plan for the 242-A Evaporator to
identify waste volume reduction goals to measure performance and, if
necessary, trigger the construction of DST capacity sufficient to compensate for
a shortfall in 242-A Evaporator performance. The targets and reporting
mechanism DOE is proposing represent a workable path forward, consistent
with how project managers conceive of using the 242-A Evaporator and the
countervailing considerations that would negate any potential benefit of a new
DST.
73. Annual Report: The heart of DOE’s proposal is the Annual Report,
wherein DOE will (1) report on the performance of the 242-A Evaporator
during the prior fiscal year, i.e., whether it met the waste volume reduction goal
and, if not, whether and how that shortfall may be mitigated later to achieve
DOE’s overall waste volume reduction goal; and (2) provide an update as to
whether DOE believes its goals for the following fiscal year are achievable, and
if not, whether DOE is able to estimate whether and how the ultimate goal for
waste volume reduction can be met. If DOE has been unsuccessful in achieving
its waste volume reduction goals, but the reason is because of inadequate waste
feed to process through the 242-A Evaporator, DOE’s proposal provides an
automatic extension of time to achieve the required waste volume reduction in
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
30
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
proportion to the amount of time during which sufficient waste feed was
unavailable, unless DOE determines a different extension is necessary.
74. DST Trigger: If any shortfall in waste volume reduction is due to
other causes besides inadequate waste feed, DOE must demonstrate how it can
still meet its overall goal in time to facilitate retrievals, either through schedule
adjustments or other mitigation measures. If DOE cannot make such a
demonstration, it would then be required to construct DST space adequate to
mitigate the shortfall, subject to several important conditions.
75. Conditions: Above, I described the conditions that, if applicable at
the time the requirement to build a DST were triggered, would weigh against
DST construction under DOE’s proposal: (1) if the cost of one or more new
DSTs would result in diversion of funds or a lack of resources that could
jeopardize other DOE cleanup activities, (2) if the detriments of DST
construction would outweigh the detriments of delayed tank retrievals to the
Hanford tank waste project or to the risk to public health and the environment,
(3) if DOE is able to otherwise mitigate a shortfall in 242-A Evaporator
performance, and (4) if DOE is able to achieve the proposed B-2 Milestone date
of March 31, 2024 notwithstanding a waste volume reduction shortfall, or if
retrievals of tank waste, even if delayed beyond the B-2 Milestone, would be
accomplished sooner than it could were new DSTs constructed. DOE will
submit a notification to the Court if it determines that any of these conditions
apply. The requirement to construct a DST would thereafter be suspended
unless a condition ceases to apply, at which time DOE would again notify the
Court, and the requirement to construct a DST would resume, with the deadline
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
31
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
reflecting an extension for the length of time the construction requirement was
suspended.
76. Opportunity for State Challenges: Some elements of DOE’s
proposal include areas in which judgments must be made that affect the
schedule, as opposed to defined events that trigger extensions already defined
in the proposal. For example, DOE may determine that a change to a time- or
waste volume reduction-related target is necessary to achieve the overall waste
reduction goal, or that, subsequent to an event triggering the requirement to
build a DST, a condition applies that suspends that requirement. DOE’s
proposal accommodates disputes DOE and the State may have by identifying
those judgments that may be disputed, and establishes a process for their
resolution. Thus, the dispute resolution procedures of the Consent Decree will
apply if the State takes issue with an alteration DOE makes to its waste volume
reduction goals or timeline, or with a determination that one of the conditions
applies that would suspend DOE’s requirement to construct a DST.
Responding to State Inaccuracies
Corrections to Statements in the Fifth Declaration of Jeffrey Lyon
77. The following paragraphs respond to statements made in the Fifth
Declaration of Jeffrey Lyon, ECF No. 154, and explain how those statements
neither reflect DOE’s current plan for 242-A Evaporator usage nor undermine
current evaluations regarding the ability of the 242-A Evaporator to reduce
sufficient waste volume to provide space in the DSTs for the retrieval of the
remaining nine A and AX Farm tanks subject to the Consent Decree.
78. Mr. Lyon based the majority of his assertions in his Fifth
Declaration on outdated, incorrect, or unrealistic inputs and assumptions, which
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
32
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
appear to be taken primarily from System Plan 6 and System Plan 7. ECF Nos.
154-1, 154-2 (selected excerpts of the System Plans attached to the Fifth
Declaration of Jeffrey Lyon in Support of Washington’s Petition to Amend
Consent Decree). System Plan 7, for example, did not include any scenarios or
input data endorsed by DOE. System Plan 7 included only the State’s input,
assumptions, and parameters. DOE did not believe that the State’s approach to
preparing System Plan 7 would be a useful exercise because it was based upon
certain unrealistic and incorrect inputs and assumptions, and that is still the
case. DOE’s position is clear in the document itself, as set out in the disclaimer
to the document:
These five scenarios [analyzed in System Plan 7] were selected and
defined solely by Ecology without modification by DOE. ORP elected not
to select or define scenarios for evaluation in System Plan, Rev. 7. In
comparison to System Plans previously submitted by DOE both prior to
and after implementation of HFFACO milestone M-062-40, this System
Plan, Rev. 7 is unique in that a current baseline was not evaluated. The
five presented cases . . . do not reflect the current status of ORP’s mission,
and do not reflect a complete and adequate understanding of assumptions
of facility interim and startup dates associated with resolution of technical
issues with the [WTP] and the need to established new or revised
baselines for key project components.
System Plan 7 at ii; see also System Plan 7 at ES-1. An excerpt of System Plan 7
is attached as Exhibit D to this declaration.
79. Moreover, system plans are lifecycle projections, i.e., projections
for the entire scope of the Hanford cleanup, which are required by the
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
33
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
HFFACO and are not tailored to the specific subset of the cleanup that includes
retrieval of the remaining 12 tanks subject to the Consent Decree. System Plan
7 at ES-2. Therefore, references in that document to the 242-A Evaporator and
its ability to achieve necessary waste volume reduction, e.g. ECF No. 154-1 at
4-13, pertained to the context of the entire life of the tank waste cleanup, not the
limited timeframe of planned retrievals between now and FY2021 (i.e., the
relevant time period for the 242-A Evaporator’s ability to perform as needed
during the retrieval of the remaining tanks subject to the Consent Decree).
80. In addition to inappropriate references to System Plan 7, the
majority of Mr. Lyon’s declaration appears to be based on the assumption that
the 242-A Evaporator would only be used for three to four years in the
foreseeable future. ECF No. 154 ¶ 4. That assumption misconstrues a statement
I made in a prior declaration, where I said that “future Evaporator campaigns in
the next three to four years . . . will create approximately three to four million
gallons of additional DST storage capacity.” ECF No. 148 ¶ 9. That statement
is still correct. But DOE is not limiting itself to campaigns over just the next
three to four years. As discussed above, DOE plans to use the 242-A
Evaporator over at least the next six years to support the retrievals subject to the
Consent Decree, and DOE will continue to use the 242-A Evaporator after
those retrievals to support future retrieval work.
81. Additionally, DOE has 3.31 Mgal of DST space available in the
East Area as of October 1, 2015, Evaporator Report at A-2, Table A-1b, not the
1.8 or 1.2 Mgal mentioned in Mr. Lyon’s declarations, ECF No. 154 ¶ 5. That
3.31 Mgal figure does not include the additional space that already exists and is
set aside for an emergency pursuant to DOE Order 435.1, or the additional
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
34
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
existing space reserved for tank headspace requirements. Evaporator Report at
A-2, Table A-1b. The tank headspace is the space that is operationally unusable
due to nuclear safety and waste incompatibilities within the DST system.
Corrections to Statements Made at Motion Hearing
82. The misunderstandings apparent in Mr. Lyon’s declarations were
also reflected at the hearing on July 23, 2015. In my prior declaration, ECF No.
153 ¶ 13, I explained that, contrary to the implication in Mr. Lyon’s fourth
declaration that DOE is assuming a 60% efficiency rate for 242-A Evaporator
campaigns, ECF No. 150 ¶¶ 11–12, and thereby using an overly-optimistic
estimate of performance to inform its conclusions, DOE does not assume that
each campaign will achieve 60% efficiency. Rather, I explained that DOE
“instead bases its estimates on the available data for each campaign. For the
Evaporator campaigns planned between now and fiscal year 2018, DOE
projects that waste volume reductions will range from 18% to 59%, depending
on the particular campaign.” ECF No. 153 ¶ 13 (emphasis added). Described
as the range of “Waste Volume Reduction Factors” in the Evaporator Report,
Evaporator Report at 2 n.3, 14, Table 3-3 n.a, this percentage range reflects the
low and high values of expected results over all the different campaigns, taken
together. This percentage range does not in any way indicate that any one tank
or campaign is expected to exhibit anywhere from an 18% to a 59% reduction
in waste volume. Rather, the Waste Volume Reduction Factor range (e.g., 18%
to 59%) provides a picture of the overall performance range that can be
expected across all evaporator campaigns on multiple tanks. For example, for
all the campaigns DOE plans to run from FY2016–FY2021 specifically, DOE’s
modeling suggests that the Waste Volume Reduction Factors are expected to be
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
35
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
from 21–57%. Evaporator Report at 14, Table 3-3. That means that one tank
may have an estimated individual Waste Volume Reduction Factor of 21%, and
another tank may have an estimated individual Waste Volume Reduction Factor
of 57%—not that DOE’s estimate for one tank’s Waste Volume Reduction
Factor could be anywhere from 21% to 57%. That is why I stated in my prior
declaration that the particular expected reduction efficiency for any one
campaign depends upon the particular campaign and that tank’s waste
constituents. ECF No. 153 ¶ 13.
83. This is also why in my prior declaration, where I identified the
expected variability in total waste volume reduction under the prevailing
assumptions, it was quite small. As I explained: “The amount of additional
storage capacity created by the Evaporator could be slightly higher (8.84
million gallons) if the specific gravity achieved by evaporation of the waste is
higher than anticipated, or slightly lower (8.55 million gallons) if the specific
gravity achieved by evaporation of the waste is lower than anticipated. In either
case, however, DOE would have more than two million gallons of available
DST capacity after completing the retrievals required by the Consent Decree.”
ECF No. 153 ¶ 5.
84. At the July 23, 2015 motion hearing, counsel for the State distorted
my correction of the errors in Mr. Lyon’s fourth declaration, when he
interpreted my declaration as saying that the Waste Volume Reduction Factor
“can’t be known until you actually start feeding the evaporator, and it could
vary between 18 percent and 59 percent.” Mot. Hr’g Tr. 98. As explained
above, this statement distorts the import of my prior declaration, and thus
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
FIFTH SUPPLEMENTAL DECLARATION OF THOMAS FLETCHER
37
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
26
CERTIFICATE OF SERVICE
I hereby certify that on November 13, 2015, I electronically filed the
foregoing with the Clerk of the Court using the CM/ECF system which will send
notification of such filing to counsel of record in this action.
I hereby certify that I have mailed by United States Postal Service the
document to the following non-CM/ECF participants: N/A
/s/ Elizabeth B. Dawson
ELIZABETH B. DAWSON Trial Attorney U.S. Department of Justice
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EXHIBIT A
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
EM-RP--WRPS-TANKFARM-2015-0006 FINAL
Occurrence ReportAfter 2003 Redesign
Tank Farms
(Name of Facility)
Nuclear Waste Operations/Disposal
(Facility Function)
Hanford Site Washington River Protection Solutions, LLC
(Site) (Contractor)
Name: Tavelli, Mark FTitle: Manager, Engineering Telephone No.: (509) 373-5330
(Facility Manager/Designee)
Name: WATERS, SHAUN FTitle: OPERATIONS SPECIALIST Telephone No.: (509) 373-3457
(Originator/Transmitter)
Name: Date:
(Authorized Classifier (AC))
1. Occurrence Report Number: EM-RP--WRPS-TANKFARM-2015-0006
Supernate/Slurry Pump Process Hoses May Exceed Design Temperatures (PISA)
2. Report Type and Date: FINAL
Date TimeNotification: 06/25/2015 15:29 (ETZ)Initial Update: 07/01/2015 20:17 (ETZ)Latest Update: 10/05/2015 17:39 (ETZ)Final: 10/05/2015 17:39 (ETZ)
3. Significance Category: 4
4. Division or Project: Washington River Protection Solutions LLC (WRPS)
5. Secretarial Office: EM - Environmental Management
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
6. System, Bldg., or Equipment: Waste/241-C and 241-AN Farms/Supernate and Slurry Pumps
7. UCNI?: No
8. Plant Area: 200 East
9. Date and Time Discovered: 06/23/2015 10:45 (PTZ)
10. Date and Time Categorized: 06/23/2015 10:45 (PTZ)
11. DOE HQ OC Notification:
Date Time Person Notified OrganizationNA NA NA NA
12. Other Notifications:
Date Time Person Notified Organization06/23/2015 12:00 (PTZ) Sondag, J. M. DOE-ORP10/02/2015 11:14 (PTZ) Baker, S. G. MSA-EOC06/23/2015 12:01 (PTZ) Ringo, S. D. WRPS06/23/2015 11:55 (PTZ) Woodford, T. L. DOE-ORP10/02/2015 11:05 (PTZ) Frink, R. L. DOE-ORP10/02/2015 11:20 (PTZ) Smith, D. K. WRPS
13. Subject or Title of Occurrence:
Supernate/Slurry Pump Process Hoses May Exceed Design Temperatures (PISA)
14. Reporting Criteria:
3B(3) - Determination of a negative Unreviewed Safety Question (USQ).
15. Description of Occurrence:
A condition was identified which could result in temperatures in excess of design temperatures for the process hosesused in 241-AN-101, 241-AN-106, and 241-C-111 slurry and supernate pumps.
During engineering review of the design calculations described in RPP-RPT-42297 for the AX Retrieval System, acondition was identified for the slurry pump which could result in temperatures in excess of design temperatures forthe process hose in the hose cage located at the top of the pump assembly. Because the pump design proposed for theAX Retrieval System is very similar to those being utilized for C-Farm Retrievals, a review of the supporting analysisfor the pumps in use was performed. Subsequent review of the thermal analysis performed on the adjustable slurry andsupernate pumps used in 241-AN-101, 241-AN-106, and 241-C-111 identified that they do not consider a conditionthat may result in temperatures in excess of the 180 degrees Fahrenheit (F) design temperature of the process hose.
The process hose is an EPDM (ethylene propylene diene monomer) hose jumper (same material used for Hose-in-HoseTransfer Lines) and is safety significant as waste transfer primary piping systems (Section 4.4.1 of the Tank FarmDocumented Safety Analysis). The condition that is not analyzed is the temperature that can be reached within the hosecage assembly that results from the net heat generation within the hose cage from the hydraulic and process hoses and
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
the heat trace. The thermal analysis performed to date has only considered the bulk air temperature that can beachieved in the pit which surrounds the hose cage and not of components within the hose cage. The hose cage is anenclosure that contains the process and hydraulic hoses so they may "coil" as the pump height is adjusted. In off-normal conditions, the hydraulic hose fluid temperature can reach 195 F before the general service interlock at thehydraulic power unit (HPU) reservoir shuts down the HPU, which stops both hydraulic fluid and process fluid flows.This hydraulic fluid temperature as a heat source has not been considered in the calculation of the process hosetemperature within the hose cage.
The pump assemblies for 241-AN-106 and 241-C-111 (drawing H-14-109603) have hose cages that are heat tracedand insulated. The pump assembly for 241-AN-101 (drawing H-14-109608) has a hose cage that is not insulated orheat traced. Neither of these arrangements have a thermal analysis which demonstrates that the process hosetemperature remains below 180 F for all operating conditions. The slurry pump assembly for 241-C-105 is not anadjustable height pump and does not have the hose cage. Note that the 241-C-111 slurry pump has not yet been putinto service, therefore the temperature rating of the safety significant components has not been exceeded.
UPDATE 07/01/2015
On July 1, 2015, the Plant Review Committee (PRC) reviewed and approved Unreviewed Safety QuestionDetermination (USQD) TF-15-1079-D, Rev. 0. The USQD on the evaluation of supernate pump process hose for tank241-AN-106 utilizing HPU POR353 (retrieval function) was negative. The conclusion in this USQD was based on thesupporting analysis documented in RPP-CALC-60458 (Rev. 0), "Maximum Steady-State Temperature Analysis for241-AN-06A Pump Pit," which indicates that the 180 F design temperature for the processes hose in the hose cage inthe 241-AN-06A pump pit will not be exceeded and thus, there is no increase in the probability of failure of thisequipment important to safety.
The evaluation of the safety of the situation for removal of the operational restriction on the 241-AN-106 supernatepump utilizing HPU POR353 (retrieval function) only was provided the U.S. Department of Energy, Office of RiverProtection (DOE-ORP) via letter WRPS-1502852.
The USQD for tanks 241-AN-101 and 241-C-111 are pending.
UPDATE 07/14/2015
On July 13, 2015, Washington River Protection Solutions LLC (WRPS) notified DOE-ORP via letter WRPS-1503025,dated July 13, 2015, additional thermal analysis is required to complete the USQD for the other configurationsencompassed within the potential inadequacy of the safety analysis (PISA) (e.g., 241-AN-101 supernate pump, 241-AN-106 supernate pump utilizing HPU POR352 [decant function], and 241-C-111 slurry pump). These thermalanalyses are complex and will require significant effort to complete. Therefore, the USQD is expected to be completedprior to September 30, 2015.
The July 1, 2015, revised Red Arrow, "Do not remove Admin. Lock condition for adjustable slurry and supernatepumps for [tanks] C-111, AN-106 utilizing HPU POR352 (decant function), and AN-101 until engineeringtemperature evaluation is performed for associated hose cage assemblies," will remain in place until necessary actionsassociated with the PISA are complete.
UPDATE 07/30/2015
On July 29, 2015, the PRC reviewed and approved USQD TF-15-1239-D, Rev. 0. The USQD on the evaluation ofsupernate pump process hose for tank 241-AN-106 utilizing HPU POR352 (decant function) was negative. Theconclusion in this USQD was based on the supporting analysis documented in RPP-CALC-60458 (Rev. 1),"Maximum Steady-State Temperature Analysis for 241-AN-06A Pump Pit," which indicates that the 180 F design
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
temperature for the processes hose in the hose cage in the 241-AN-06A pump pit will not be exceeded and thus, thereis no increase in the probability of failure of this equipment important to safety.
The evaluation of the safety of the situation for removal of the operational restriction on the 241-AN-106 only wasprovided the DOE-ORP via letter WRPS-1503261.
The USQD for tanks 241-AN-101 and 241-C-111 are pending.
UPDATE 10/05/2015
Recategorization
On October 2, 2015, at 11:05 hours, Ronald L Frink of the DOE-ORP was notified this occurrence was recategorizedto a 3B(3) SC-4 occurrence.
Justification
The USQD TF-15-1604-D (Rev. 0), which evaluated the maximum temperature of the associated safety-significant 2-inch EPDM process hoses for the interior of the hose cage for the 241-C-111 slurry pump, the 241-C-111 extendedreach sluicing system (ERSS), and the 241-AN-101 supernate pump, was negative.
The PRC had reviewed and on September 29, 2015, approved USQD TF-15-1604-D, "Final Evaluation of ProcessHose May Exceed Design Temperature PISA Identified in Occurrence Report EM-RP--WRPS-TANKFARM-2015-0006 and WRPS-PER-2015-1158 (Includes Evaluation of RPP-CALC-60494, Rev. 0, RPP-CALC-48072, Rev. 2,RPP-CALC-46225, Rev 3, and RPP-RPT-42297, Rev. 14)."
PISA Evaluation
Waste transfer leak accidents are evaluated in the "Tank Farms Documented Safety Analysis" (RPP-13033) and in the"Hazard Evaluation Database Report" (RPP-15188). Both RPP-13033 and RPP-15188 indicate that fine spray leaks arenot postulated due to failures of the EPDM portion of non-metallic flexible hose jumpers or Hose-in-Hose TransferLine primary hose assemblies because the EPDM hose cannot maintain the fine crack geometry required for a finespray leak release (i.e., the EPDM hose leak location would expand [fish mouth] rather than form the narrow crackrequired for a fine spray leak that could exceed onsite guidelines). Thus, the hazard of concern with respect to aprocess hose failure due to high temperatures is a significant facility worker hazard due to a flammable gasdeflagration in a waste transfer-associated structure, which in the cases being evaluated are leaks into the 241-C-111saltwell pump pit, the 241 C-111 ERSS shield box, and the 241-AN-01A pump pit. Note that the 241 C-111 ERSSwas not identified in the original PISA but was added as part of the extent of condition.
The conclusions in USQD TF-15-1604-D (Rev. 0), which evaluated the maximum temperature of the associatedsafety-significant 2-inch EPDM process hoses, are supported by the thermal analysis for the interior of the hose cagewhen the 241-C-111 slurry pump (RPP-CALC-60494, Rev. 0), the 241 C-111 ERSS (RPP-CALC-48072, Rev. 2), andthe 241-AN-101 supernate pump (RPP-CALC-46225, Rev 3) are being operated are summarized below.
Note that RPP-CALC-46225 (Rev. 3) evaluates both HPU POR350 (retrieval function) and HPU POR348 (decantfunction) for the 241-AN-101 supernate pump.
Conclusions
The assumed conditions in RPP-CALC-60494 (Rev 0), RPP-CALC-48072 (Rev. 2), and RPP-CALC-46225 (Rev. 3)include high ambient temperature, solar heat gain, and a postulated failure of the waste transfer pump (or ERSS) HPUtemperature control, resulting in heat generation inside the pit (or ERSS shield box) from hot hydraulic hoses. Includedin the analysis is a Sol-Air temperature evaluation, a calculation of the maximum heat generation in the pit due to the
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
HPU hydraulic hoses (with worst-case failure of the HPU temperature control), a calculation of heat generation due toheat trace on jumpers, hydraulic hoses, and the pump hose cage, and a detailed heat transfer evaluation of the safety-significant 2-in, EPDM primary process hose that is contained inside the hose cage.
RPP-CALC-60494 (Rev. 0), "Maximum Steady-State Temperature Analysis for 241-C-111 Saltwell Pump Pit,"concluded that the maximum internal air and component temperature within the 241-C-111 saltwell pump pit duringthe hottest month of the year is 146 F, the maximum hose cage internal air and component temperature under steady-state operating conditions is 165 F, and the steady state temperature of the process hose after the HPU is shut downand process flow is lost is 167 F (which conservatively accounts for all the energy of the hot hydraulic hoses beingtransferred to the process hose and to the energy chain in which all the hoses are contained).
RPP-CALC-48072 (Rev. 2), "Extended Reach Sluicer Box Assembly Heat Trace Sizing and Maximum TemperatureAnalysis," concluded that the maximum internal air and component temperature within the 241-C-111 ERSS shieldbox during the hottest month of the year is 151 F and the maximum hose cage internal air and component temperatureduring the hottest month of the year is 170 F.
RPP-CALC-46225 (Rev. 3), "Maximum Steady-State Temperature Analysis for the 241-AN-01A Pump Pit and PumpHose Cage," concluded the maximum internal air and component temperature within the 241-AN-101A pump pitduring the hottest month of the year is 123 F, the maximum hose cage internal air and component temperature understeady-state operating conditions is 171 F, and the steady state temperature of the process hose after the HPU is shutdown and process flow is lost is 178 F, (which conservatively accounts for all the energy of the hot hydraulic hosesbeing transferred to the process hose and to the energy chain in which all the hoses are contained).
These conclusions indicate that the 180 F design temperature for the safety-significant process hoses in the hose cagein the 241-C-111 saltwell pump pit, the 241 C-111 ERSS shield box, and the 241-AN-01A pump pit will not beexceeded and thus, there is no increase in the probability of failure of this equipment important to safety.
Change to RPP-RPT-42297
In Rev. 13, RPP-RPT-42297, "Safety-Significant Waste Transfer Primary Piping Systems - Functions andRequirements Evaluation Document," was updated (per USQD TF-15-1079-D) to indicate that the primary pipingsystems and components may be affected by high temperatures when the systems are configured with an adjustableslurry or supernatant pump that feature a 2-inch, EPDM process hose together with hydraulic hoses routed inside aninsulated hose cage and RPP-CALC-60458, "Maximum Steady-State Temperature Analysis for 241-AN-06A PumpPit," was referenced. In Rev. 14, RPP-CALC-60494, Rev 0, RPP-CALC-48072, Rev. 2, and RPP-CALC-46225, Rev.3, are added to the description of calculations that evaluate various pits and above-grade enclosures for maximumsteady-state temperatures.
The evaluation of the safety of the situation for removal of the operational restriction on tanks 241-AN-101 and 241-C-11was provided the DOE-ORP via letter WRPS-1504314, dated September 30, 2015. The operational restriction for241-AN-106 was previously removed as described in the 07/01/2015 and 07/30/2015 updates above.
With the responses to USQD questions 1 through 7 being negative, an Unreview Safety Question does not exist withrespect to the PISA condition evaluated (all the hose cages within the extent of condition have now been evaluated).Therefore, this event is being recategorized as a Group 3B(3) SC-4 occurrence.
16. Is Subcontractor Involved? No
17. Operating Conditions of Facility at Time of Occurrence:
Does not apply.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
18. Activity Category:
03 - Normal Operations (other than Activities specifically listed in this Category)
19. Immediate Actions Taken and Results:
Requested Engineering perform a temperature evaluation of the associated hose cage assemblies.A Red Arrow entry in the Central Shift Office logbook states, "Do not remove Admin. Lock condition for adjustableslurry and supernate pumps for [tanks] C-111, AN-106, and AN-101 until engineering temperature evaluation isperformed for associated hose cage assemblies.
UPDATE 07/01/2015
As a result of the negative Unreviewed Safety Question Determination (USQD) completed for AN-106, the Red Arrowentry has been revised to allow operation of the AN-106 supernate pump utilizing the hydraulic power unit (HPU)POR353 (retrieval function) only.
The original Red Arrow restriction was revised to, "Do not remove Admin. Lock condition for adjustable slurry andsupernate pumps for [tanks] C-111, AN-106 utilizing HPU POR352 (decant function), and AN-101 until engineeringtemperature evaluation is performed for associated hose cage assemblies."
UPDATE 07/14/2015
No new immediate actions required as the Red Arrow revised 07/01/2015 will remain in place ensuring continued safeoperations until the necessary actions associated with the PISA are complete.
UPDATE 07/30/2015
As a result of the negative USQD completed for AN-106, the Red Arrow entry has been revised to, "Do not removeAdmin. Lock condition for adjustable slurry and supernate pumps for [tanks] C-111 and AN-101 until engineeringtemperature evaluation is performed for associated hose cage assemblies."
UPDATE 10/05/2015
As a result of the negative USQD completed for tanks 241-AN-101 and 241-C-111 on September 29, 2015, and theJuly 1 and July 30, 2015, negative determination for 241-AN-106 (retrieval and decant functions), the Red Arrow entryrestricting utilization of these three tanks was removed on October 2, 2015. No further action is required.
20. ISM:
2) Analyze the Hazards 3) Develop and Implement Hazard Controls
21. Cause Code(s):
22. Description of Cause:
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EM-RP--WRPS-TANKFARM-2015-0006
file:///M|/...Local/Microsoft/Windows/Temporary Internet Files/Content.Outlook/3D04YL0V/EM-RP--WRPS-TANKFARM-2015-0006.htm[11/11/2015 9:06:01 PM]
23. Evaluation (by Facility Manager/Designee):
24. Is Further Evaluation Required?: No
25. Corrective ActionsLocal Tracking System Name: Problem Evaluation Request
26. Lessons Learned:
27. Similar Occurrence Report Numbers:
28. User-defined Field #1:
29. User-defined Field #2:
Problem Evaluation Request WRPS-PER-2015-1158
30. HQ Keyword(s):
01H--Inadequate Conduct of Operations - Inadequate Safety Analysis/USQs12A--EH Categories - Authorization Basis14D--Quality Assurance - Documents and Records Deficiency
31. HQ Summary:
On June 23, 2015, a condition was identified which could result in temperatures in excess of design temperatures forthe process hoses used in AN-106, AN-101, and C-111 slurry and supernate pumps. Subsequent review of the thermalanalysis performed on the adjustable slurry and supernate pumps identified that they do not consider a condition thatmay result in temperatures in excess of the 180 degrees Fahrenheit (F) design temperature of the process hose. Thecondition that was not previously analyzed is the temperature that can be reached within the hose cage assembly thatresults from the net heat generation within the hose cage from the hydraulic and process hoses and the heat trace. Thethermal analysis performed to date has only considered the bulk air temperature that can be achieved in the pit whichsurrounds the hose cage and not of components within the hose cage. A temperature evaluation of the associated hosecage assemblies will be performed.
32. DOE Facility Representative Input:
33. DOE Program Manager Input:
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EXHIBIT B
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
1
UNITED STATES DISTRICT COURTEASTERN DISTRICT OF WASHINGTON
STATE OF WASHINGTON, DEPARTMENTOF ECOLOGY,
Plaintiff,and
STATE OF OREGON,
Plaintiff-Intervenor,
v.
ERNEST MONIZ, Secretary of theUnited States Department ofEnergy, and the UNITED STATESDEPARTMENT OF ENERGY,
Defendants.
))))))))))))))))))
Case No. 2:08-CV-5085-RMP
July 23, 2015
Richland, Washington
Motion Hearing
Pages 1 to 143
BEFORE THE HONORABLE ROSANNA MALOUF PETERSONCHIEF UNITED STATES DISTRICT COURT JUDGE
APPEARANCES:
For the Plaintiff: Andrew A. [email protected] [email protected] T. WoodAttorney General of Washington -Ecology Division2425 Bristol Court SWP.O. Box 40117Olympia, WA 98504360-586-6752
For the IntervenorPlaintiff:
Nina R. [email protected] Department of Justice1515 SW Fifth AvenueSuite 400Portland, OR 97201971-673-5000
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
2
For the Defendants: Kenneth C. [email protected] [email protected] B. [email protected]. Department of Justice - DC950 Pennsylvania Avenue NWWashington, DC 20530202-514-2000
Official Court Reporter: Kimberly J. Allen, CCR #2758United States District CourthouseP.O. Box 685Richland, Washington 99352(509) 943-8175
Proceedings reported by mechanical stenography; transcriptproduced by computer-aided transcription.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, CRR, RPR, CSR
OFFICIAL COURT REPORTER
3
INDEX
Proceedings: Page
OPENING REMARKS BY THE COURT 6ARGUMENT BY MR. AMADITZ 14ARGUMENT BY MR. KAPLAN 42ARGUMENT BY MR. FITZ 62ARGUMENT BY MS. ENGLANDER 108REBUTTAL BY MR. AMADITZ 114REBUTTAL BY MR. KAPLAN 124REBUTTAL BY MR. FITZ 131COMMENTS BY THE COURT 140
WITNESS INDEX
Plaintiff Witness: Page
None
*****
Defense Witnesses: Page
None
EXHIBITS ADMITTED
PlaintiffNumber Description Page
None
DefenseNumber Description Page
None
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, CRR, RPR, CSR
OFFICIAL COURT REPORTER
4
GENERAL INDEX
Page
Reporter's Certificate..............................143
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
03:13:06
03:13:26
03:13:49
03:14:11
03:14:29
State of Washington/State of Oregon v. Moniz, DOE/2:08-CV-5085-RMPMotion Hearing/July 23, 2015
Argument by Mr. Fitz
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
97
we have a three-year period where all of the facilities come
online simultaneously and all have to work together, and here
we're staggering them, so we shortened the time frame for each
individual facility. But again, you know, we're -- we're doing
as little as possible as necessitated by the circumstances to
change the existing decree.
And, again, you know, the -- the -- well, for Direct
Feed LAW, I should -- I should add about that, you know, we're
both within months of each other as far as the hot start date.
The difference is whether we have any interim milestones. And,
again, our position is that those interims are necessary so that
we can track progress and know whether we're getting off track
before it's too late.
So, moving to the DST issue, the Court's already
recognized a change in circumstance with the loss of DST AY-102,
together with Energy's larger inability to meet deadlines under
the decree. And our point isn't that AY-102 was necessary to
store waste, because it was already full. The point is the
capacity of AY-102, nearly a million gallons, now has to be
spread out among the other DSTs, and it reduces the overall
available space for the 19 retrievals -- or for, more
accurately, the 12 that are left to go.
We know right now that Energy doesn't have enough
available DST space to -- to retrieve the remaining Consent
Decree tanks plus transfer that waste over from AY-102. It's
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
03:14:47
03:15:10
03:15:28
03:15:51
03:16:12
State of Washington/State of Oregon v. Moniz, DOE/2:08-CV-5085-RMPMotion Hearing/July 23, 2015
Argument by Mr. Fitz
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
98
going to have to rely on the 242-A Evaporator to create space
through multiple evaporator runs.
And I'm not going to dicker about numbers. I'm just
going to use Mr. Fletcher's numbers for the sake of assuming
that all of Energy's numbers are correct, for the sake of
argument. He states that -- that there are 3.2 million gallons
in available DST space. That's currently. And we know that the
waste to be transferred over to the DSTs -- that includes the 12
retrievals plus AY-102 -- is 9.55 million gallons. So simple
math tells you we have a deficit of 6.3 million gallons.
So the solution from Energy's side -- and I should -- I
should cast it in terms of the theory from Energy's side is that
the evaporator is going to work well enough and efficiently
enough to create that space.
But, Your Honor, we can anticipate right now that
there's a good chance this plan will not work. Energy has to
bank on unprecedented performance by the 242-A Evaporator. And
there are a couple of issues here. First, it's an efficiency
issue. By its own estimates, Energy's plan -- Energy indicates
that the content of waste feed affects how efficiently the
evaporator can reduce waste volume. So Mr. Fletcher says that
that range can't be known until you actually start feeding the
evaporator, and it could vary between 18 percent and 59 percent.
So the idea here is that at a 50 percent efficiency, for
every gallon you feed in, you're going to come out with a half
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
03:16:30
03:16:50
03:17:11
03:17:36
03:17:53
State of Washington/State of Oregon v. Moniz, DOE/2:08-CV-5085-RMPMotion Hearing/July 23, 2015
Argument by Mr. Fitz
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
99
gallon, so you're going to create a half gallon of space at
50 percent efficiency.
So looking forward, Energy is planning 23 evaporator
campaigns over the next seven years to create what it wants in
terms of space of 8.77 million gallons. And I think it's
prudent to look for more than the 6.3 deficit because we
actually don't know whether 6.3 is going to be the right number.
Part of it depends on how much liquid is necessary to retrieve
those remaining SSTs, which are salt cake and sludge tanks and
might require a lot of liquid to retrieve them. So having a
little buffer is good.
So if we do just simple, simple math, simple algebra, we
can figure out a few things. At 40 percent efficiency, Energy
is going to have to process 21.9 million gallons of waste to end
up with that 8.77 million gallons of space created. And that's
a lot of waste to process. It's about the same volume of all
the liquid waste currently in the DST system. And if there are
any significant slips in that efficiency rate, that 40 percent,
it will make Energy's evaporator goals difficult or impossible
to meet.
The lower the efficiency, the less space you create, so
the more processing of waste you need to do. For example, at
30 percent, again, if we just use simple algebra, processing the
same 21.9 million gallons of waste is only going to create
6.5 million gallons of space. And if we look at the low end of
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
03:18:11
03:18:30
03:18:52
03:19:11
03:19:31
State of Washington/State of Oregon v. Moniz, DOE/2:08-CV-5085-RMPMotion Hearing/July 23, 2015
Argument by Mr. Fitz
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
100
Energy's efficiency, the 18 percent, processing that
21.9 million gallons is going to create 3.9 million gallons of
space, and right now we're below the space deficit.
So the only way to make up for that shortfall is to run
the evaporator more. But if we -- if we run at that low end of
the efficiency rate, the math tells you that if you run about a
million gallons per campaign, you're going to be running about
50 evaporator campaigns over the next seven years.
And that leads to the second issue, which is all of this
assumes that the evaporator works. But the evaporator has never
been relied on, at least recently, and there's no information
for Energy's projected 23 campaigns, let alone more than 23.
As we documented, the evaporator has been plagued with
operational issues and shutdowns and worker safety issues and
delays. In the last five years, it's performed three campaigns,
only one of which was able to start on time. Mr. Fletcher notes
that between 2003 and 2010 -- that's a similar seven-year period
to getting to 2022 -- it was used a total of ten times, and it
had a 30 percent efficiency rate.
So I'd like you to listen to the words in Mr. Fletcher's
fourth declaration. Quote, By increasing the number of
campaigns, evaporator operations should become more routine,
should avoid the gearing up and gearing down that's occurred
with past campaigns, and should minimize operational delays
caused by short-term startups and shutdowns. Continuing the
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
03:19:50
03:20:08
03:20:24
03:20:47
03:21:07
State of Washington/State of Oregon v. Moniz, DOE/2:08-CV-5085-RMPMotion Hearing/July 23, 2015
Argument by Mr. Fitz
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
101
quote, DOE anticipates that these more routine operations will
allow for better maintenance of the facility, more efficient
operations, and improved plannings of campaigns.
So, in other words, even though we don't have any actual
experience to base it on, and even though it hasn't worked this
way in the past, we anticipate that starting now the evaporator
should work in a way it's never worked before. So we don't have
a space problem.
To borrow Mr. Kaplan's words, this is a theory for how
Energy is going to create the space it needs. It's a theory.
We don't know it's going to work.
And, again, going back to the Court's May 13th order, if
we can anticipate a problem now, we should account for it now in
the decree before we get too late.
So the way we account for it is to say, Energy, we put
in our proposal, plan for and build a minimum of four DSTs. We
still think four is the right number, given that projected
$6.3 million gap -- gallon gap, I should say. We recognize that
the tanks won't be done in time to guarantee 2022, but the point
is trying to guard against significant slips past 2022 and keep
the performance as close to that date as possible.
And just as with direct feed high-level waste, if we get
to a point -- we've got three years in our proposed schedule for
Energy to be designing the DSTs. If we get three years down the
line and the evaporator is working well, Energy can come back
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
1
2
3
4
5
6
7
8
9
10
11
12
13
14
15
16
17
18
19
20
21
22
23
24
25
03:21:25
03:21:43
03:22:02
03:22:23
03:22:41
State of Washington/State of Oregon v. Moniz, DOE/2:08-CV-5085-RMPMotion Hearing/July 23, 2015
Argument by Mr. Fitz
OFFICIAL COURT REPORTERKIMBERLY J. ALLEN, RMR, CRR, RPR, CCR
OFFICIAL COURT REPORTER
102
and say, "You know what? We don't need those DSTs." But the
prudent thing to do now is to guarantee that those 19 tanks can
be retrieved under the decree as timely as possible.
I want to end by talking about our proposal, our request
for additional accountability measures. I said earlier that
regulating Energy has been a challenge. In the Asarco case, the
Ninth Circuit spoke to the, quote, greater enforceability, end
quote, a Consent Decree provides. And we thought we'd be
getting that greater accountability with this decree, but the
past four years have felt like wrestling an elephant. As I said
at the start, we're back to where we were before we filed our
suit. Energy's unable to meet its deadlines, its actions and
its planning no longer bear relation to the legal schedule, and
the decree doesn't have real meaning as a compliance instrument.
You look at the decree, and it's not reality.
When we talk about the enforceability of a decree, a lot
of people think that means sanctions. But we're in the
position -- if we're in the position of having to enforce the
decree, it's really already too late for us, because what we
need is to get the operating WTP and the tanks retrieved. We
don't need to club Energy over the head. We need it to do the
job right first.
The events of the past four years show that the current
terms of the decree aren't sufficient to ensure that kind of
accountability. Energy's early reporting under the decree gave
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EXHIBIT C
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046Revision 0
Capability of the 242-A Evaporator to Support Aand AX Retrieval
Prepared for the U.S. Department of EnergyAssistant Secretary for Environmental Management
Contractor for the U.S. Department of EnergyOffice of River Protection under Contract DE-AC27-08RV14800
P.O. Box 850 Richland, Washington 99352
Approved for Public Release; Further Dissemination Unlimited
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046Revision 0
Capability of the 242-A Evaporator to Support A and AXRetrieval
P. J. CertaWashington River Protection Solutions
Date PublishedNovember 2015
Washington River Protection Solutions
Prepared for the U.S. Department of EnergyAssistant Secretary for Environmental Management
Contractor for the U.S. Department of EnergyOffice of River Protection under Contract DE-AC27-08RV14800
P.O. Box 850 Richland, Washington 99352
Copyright License By acceptance of this article, the publisher and/or recipient acknowledges the U.S. Government's right to retain a non exclusive, royalty-free licensein an to any copyright covering this paper.
Release Approval Date
Approved for Public Release; Further Dissemination Unlimited
By Janis D. Aardal at 4:55 pm, Nov 12, 2015
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046Revision 0
LEGAL DISCLAIMER This report was prepared as an account of work sponsored by an agency ofthe United States Government. Neither the United States Government norany agency thereof, nor any of their employees, makes any warranty,express or implied, or assumes any legal liability or responsibility for theaccuracy, completeness, or any third party's use or the results of such useof any information, apparatus, product, or process disclosed, or representsthat its use would not infringe privately owned rights. Reference herein toany specific commercial product, process, or service by trade name,trademark, manufacturer, or otherwise, does not necessarily constitute orimply its endorsement, recommendation, or favoring by the United StatesGovernment or any agency thereof or its contractors or subcontractors. Theviews and opinions of authors expressed herein do not necessarily state orreflect those of the United States Government or any agency thereof.
This report has been reproduced from the best available copy.
Printed in the United States of America
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
Capability of the 242-A Evaporator to Support A and AX 1
Farm Retrieval 2
3
4
5
6
P. J. Certa 7
J. D. Belsher 8
J. M. Conner 9
L. J. Eslin 10
J. E. Meacham 11 Washington River Protection Solutions, LLC 12
13
14
15
16
17
Date Published 18
November 2015 19
20
21
Prepared for the U.S. Department of Energy 22
Assistant Secretary for Environmental Management 23
24
25
Contractor for the U.S. Department of Energy 26 Office of River Protection under Contract DE-AC27-08RV14800 27
28
Post Office Box 850 29 Richland, Washington 30
31
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
i
1
Capability of the 242-A Evaporator to Support 2
A and AX Farm Retrieval 3
4
Executive Summary 5
6
The Hanford Site 242-A Evaporator entered service in 1977 and is used to reduce waste volume 7
stored in the double-shell tanks by concentrating radioactive waste solutions. Through 2015, 8
over 130 Mgal has been processed through the facility, and a waste volume reduction of over 9
80 Mgal has been achieved. The 242-A Evaporator has undergone numerous upgrades since 10
construction to improve safety, increase efficiency, and extend its operating life. The facility 11
was operated more frequently in the 1970s and 1980s than it is currently; however, the Tank 12
Farms and site missions have also changed, resulting in reduced demand on the 242-A 13
Evaporator. 14
The U.S. Department of Energy has evaluated a modeled operating scenario (sequence and 15
timing of retrievals, level rises, waste transfers, and evaporator campaigns) and hypothetical 18-16
month evaporator outages; the operating scenario shows that there is sufficient double-shell tank 17
space and 242-A Evaporator capacity to complete the Consent Decree single-shell tank waste 18
retrievals by the milestone date. The model indicates only approximately 14% of the 152 days 19
per calendar year (the most limiting operational regulatory restriction: the Treated Effluent 20
Disposal Facility annual flow limit in the State Water Discharge Permit) is required to complete 21
the next nine A and AX SST retrievals. Approximately 2.9 Mgal of space remains in the East 22
Area double-shell tanks after the retrievals of the “next nine” tanks in the 241-A and 241-AX 23
Tank Farms have been completed (about 1.3 Mgal of emergency space plus 1.6 Mgal of space 24
available for operational flexibility). 25
This operating scenario requires the 242-A Evaporator to reduce the volume of waste in the 26
double-shell tanks by 6.4 Mgal over the next six years. The number of evaporator campaigns 27
and waste volume reduction needed to meet the proposed Consent Decree milestone dates are 28
well within the 242-A Evaporator capability as demonstrated over a recent 13-month period. 29
From September 2014 through September 2015, four campaigns were performed, with a waste 30
volume reduction of 1.9 Mgal. 31
Hypothetical outage scenarios also show that retrieval dates can still be met in the event of 32
reasonable contingencies such as an 18-month 242-A Evaporator outage. Additionally, a simple 33
steady-state evaluation demonstrates that the 242-A Evaporator capacity is not a limiting 34
constraint in meeting the proposed milestones. 35
The 242-A Evaporator receives routine integrity assessments on a frequency recommended by an 36
Independent Qualified Registered Professional Engineer. The last integrity assessment was 37
performed in 2007 and the report concluded that the minimum remaining life of each major 38
vessel tested is greater than 20 years. A 2011 reliability assessment concluded that continued 39
integrity assessments and equipment upgrades, along with a proactive maintenance strategy, 40
should keep the evaporator operating for another 30 years. The Tank Operations Contractor 41
maintains an integrated team of Operations, Engineering, Nuclear Safety, Environmental, and 42
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
ii
Design staff to monitor facility operation, identify issues and improvements, and provide an 1
ongoing upgrade and maintenance capability that can support maintaining facility availability. 2
Recent and historical performance of the 242-A Evaporator demonstrates that the facility will be 3
able to support the planned 241-A and 241-AX Tank Farms’ retrieval activities. 4
Even though the operating scenario and the outage scenarios show that the 242-A Evaporator's 5
capacity is adequate to ensure that DOE’s proposed retrieval milestones can be readily met, the 6
U.S. Department of Energy is also evaluating other contingencies and enhancements. Examples 7
include increasing the maximum allowable waste level in some double-shell tanks and 8
maintaining an inventory of critical spare parts. Level rises in six tanks in the 241-AN and 9
241-AW Tank Farms could result in approximately 600 kgal of usable tank space, but a major 10
structural engineering study would be required prior to approving these increases. The Tank 11
Operations Contractor already maintains a supply of spare waste transfer pumps to support 12
double-shell tank transfers that stage waste for delivery to the 242-A Evaporator and is actively 13
identifying critical spare parts for the 242-A Evaporator. 14
The 242-A Evaporator facility has demonstrated the ability to process large volumes of feed in a 15
short period of time, and to meet the operational needs of the Tank Farms. The 242-A 16
Evaporator is mechanically sound and capable of the sustained operation required to support the 17
retrieval of A and AX Tank Farms. 18
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
iii
CONTENTS 1
1.0 EVAPORATOR DESCRIPTION .........................................................................................1 2
2.0 242-A EVAPORATOR HISTORICAL PERFORMANCE .................................................2 3
2.1 242-A Evaporator Production ...................................................................................2 4
2.2 Facility Upgrades ......................................................................................................2 5
2.2.1 Project B-534 Upgrades ................................................................................3 6
2.2.2 Upgrades between 1996 and 2003 ................................................................3 7
2.2.3 Upgrades after 2003 ......................................................................................3 8
2.2.4 242-A Documented Safety Analysis and Technical Safety 9
Requirement Upgrades ..................................................................................4 10
2.2.5 Conclusions Regarding Upgrades .................................................................5 11
2.3 Testing, Surveillance, and Maintenance Progams ....................................................5 12
2.3.1 Testing Program ............................................................................................5 13
2.3.2 Surveillances and Inspections .......................................................................5 14
2.3.3 Maintenance Program ...................................................................................6 15
3.0 PLANS FOR USING THE 242-A EVAPORATOR ............................................................7 16
3.1 Assumptions ..............................................................................................................7 17
3.2 Steady-State Evaluation of Required Evaporator Capability ....................................9 18
3.3 Dynamic Evaluation of Modeled Operating Scenario ............................................11 19
3.3.1 Raw Schedule Results .................................................................................12 20
3.3.2 Reliability, Availability, and Maintainability Considerations ....................12 21
3.3.3 Limiting Permit Condition Assessment ......................................................13 22
3.3.4 242-A Evaporator Demand .........................................................................13 23
3.3.5 Overall Volume Balance for Modeled Operating Scenario ........................14 24
3.4 Contingency Evaluation ..........................................................................................15 25
3.4.1 Evaporator Outage at Start of Retrieval of Last Two A Tank Farm 26
Tanks ...........................................................................................................15 27
3.4.2 Evaporator Outage after Retrieval of First Two AX Tank Farm 28
Tanks ...........................................................................................................15 29
3.5 ADDITIONAL Opportunities to Improve Waste Volume Reduction 30
Posture .....................................................................................................................15 31
4.0 WHY THE U.S. DEPARTMENT OF ENERGY HAS CONFIDENCE IN THE 32
EVAPORATOR ..................................................................................................................18 33
4.1 242-A Evaporator Integrity, Life Extension, and Contingency Planning ...............18 34
4.2 242-A Evaporator Operating Strategy Provides Contingency ................................19 35
4.3 Conclusion Regarding 242-A Evaporator Capability .............................................19 36
5.0 REFERENCES ....................................................................................................................20 37
38
39
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
iv
APPENDICES 1
Appendix A Detailed Volume Balance for Modeled Scenarios ............................................... A-i 2
3
FIGURES 4
Figure 1-1. Simplified Pictorial Flow Diagram for the 242-A Evaporator. ....................................1 5
Figure 3-1. Steady-State Average Annual Waste Volume Reduction Requirements. ..................11 6
7
TABLES 8
Table 3-1. Proposed Milestones. .....................................................................................................9 9
Table 3-2. Example Steady-State Volume Balance Calculation. .................................................10 10
Table 3-3. Estimated Demand on the 242-A Evaporator. .............................................................14 11
Table 3-4. Summary of Double-Shell Tank Space Evaluation for Next Nine Retrievals. ...........14 12
Table 3-5. Single-Shell Tank Retrieval Demands on Double-Shell Tank Space. ........................17 13
14
15
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
v
TERMS 1
Acronyms 2 ALARA as low as reasonably achievable 3
DFLAW direct feed low-activity waste 4
DOE U.S. Department of Energy 5
DSA Documented Safety Analysis 6
DST double-shell tank 7
Ecology Washington State Department of Ecology 8
ETF Effluent Treatment Facility 9
FY fiscal year 10
HFFACO Hanford Federal Facility Agreement and Consent Order 11
HTWOS Hanford Tank Waste Operations Simulator 12
IQRPE Independent Qualified Registered Professional Engineer 13
LAW low-activity waste 14
LAWPS Low-Activity Waste Pretreatment System 15
LERF Liquid Effluent Retention Facility 16
M&TE measuring and test equipment 17
MMR Modeling Modification Request 18
RAM reliability, availability, and maintainability 19
RCRA Resource Conservation and Recovery Act 20
RPP River Protection Project 21
SpG specific gravity 22
SIS safety instrumented system 23
SSC structures, systems, and components 24
SST single-shell tank 25
SVF Spreadsheet Verification and Release Form 26
TEDF Treated Effluent Disposal Facility 27
TOC Tank Operations Contractor 28
TRU transuranic 29
TSR Technical Safety Requirements 30
TWINS Tank Waste Information Network System 31
WRPS Washington River Protection Solutions, LLC 32
WVR waste volume reduction 33
WVRF waste volume reduction factor 34
WTP Waste Treatment and Immobilization Plant 35
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
vi
Units 1 °F degrees Fahrenheit 2
ft2 square feet 3
gpm gallons per minute 4
kgal thousand gallons 5
M molar 6
Mgal million gallons 7
Torr 1 Torr = 1/1760 of a standard atmosphere, absolute pressure 8
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
1
1.0 EVAPORATOR DESCRIPTION 1
The 242-A Evaporator is designed to reduce waste volume and, therefore, reduce the number of 2
double-shell tanks (DSTs) required to store liquid waste at the Hanford Site. The process uses a 3
forced-circulation vacuum evaporation system operating at low pressure (approximately 60 torr) 4
and low temperature (approximately 125°F) to concentrate radioactive waste solutions. 5
Major design features include the vapor-liquid separator, the recirculation loop, and the reboiler 6
where steam is applied to heat the waste to boiling (see Figure 1-1). A large recirculation pump 7
pumps the waste through the recirculation loop and reboiler back to the vapor-liquid separator 8
vessel. A slurry pump transfers the concentrated waste back to the DST system. Steam jets in 9
the vapor line reduce the pressure (draw vacuum) in the vapor-liquid separator vessel as the 10
steam condenses. Condensers condense the water vapor from the process and steam from the 11
vacuum jets, with condensate draining to the condensate collection tank. The forced-circulation 12
design reduces fouling, and operating at reduced pressure lowers the operating temperature, 13
resulting in less stress on operating equipment. 14
The 242-A Evaporator is operated on a campaign basis. A campaign, typically consisting of 15
approximately 1 Mgal of waste feed, is staged and sampled. Once laboratory analyses are 16
completed and the waste is approved for processing, the waste is fed to the 242-A Evaporator 17
facility from feed tank 241-AW-1021. The concentrated product (slurry) is returned to the DST 18
system. The feed rate is typically 70-120 gpm and the boil-off (waste volume reduction [WVR]) 19
rate is typically 30-40 gpm. A typical campaign has a processing time of 10 days to two weeks. 20
Figure 1-1. Simplified Pictorial Flow Diagram for the 242-A Evaporator. 21
22
1 Hereinafter, tank farms, DSTs, and single-shell tanks (SSTs) are referred to by their short name, omitting the
“241-” prefix.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
2
2.0 242-A EVAPORATOR HISTORICAL PERFORMANCE 1
2.1 242-A EVAPORATOR PRODUCTION 2
The 242-A Evaporator entered into service in 1977. Through 2015, a feed volume of over 3
130 Mgal has been processed through the facility, and a WVR2 of over 80 Mgal has been 4
achieved. 5
There have been two outage periods where facility upgrades were performed to ensure the 6
operability of the facility. From 1989 to 1994 there was an outage to allow for equipment 7
upgrades and the construction of the Liquid Effluent Retention Facility (LERF). The LERF now 8
receives process condensate from the 242-A Evaporator and stores it for treatment at the Effluent 9
Treatment Facility (ETF). A Resource Conservation and Recovery Act (RCRA) permit for the 10
242-A Evaporator was issued. 11
There was another extended outage at the 242-A Evaporator from 2010 to 2014. Evaporator 12
operations were not necessary for DST space management during that time. Equipment and 13
safety basis upgrades were performed during the outage. 14
Since September 2014, when waste processing resumed, through September 2015, a total of four 15
campaigns have been performed. A feed volume of 4.6 Mgal was processed and a WVR of 16
1.9 Mgal was achieved during these four campaigns. This recent performance demonstrates the 17
facility’s capability under the current permitting and operational environment. 18
An average annual 242-A Evaporator WVR of 1.0 to 1.5 Mgal should be attainable if necessary 19
to support the Tank Operations Contractor’s (TOC) mission. This is a conservative planning 20
basis; peak facility performance is significantly higher. Taking all campaigns together, the 242-21
A Evaporator is expected to operate with a single-pass WVR Factor (WVRF)3 between 15% and 22
59%4. Within this range, the WVRF for a specific campaign depends on the chemical 23
composition and concentration of the feed relative to the target composition. The WVRFs can 24
vary significantly between campaigns due to different feed and target compositions; single-pass 25
WVRs of 150 kgal to 500 kgal are typical. Additionally, maintenance, upgrades, possible 26
equipment failure, environmental permit limitations, and other logistical issues must be 27
considered in estimating annualized performance. 28
2.2 FACILITY UPGRADES 29
The 242-A Evaporator has undergone numerous upgrades over its lifetime. The facility was 30
constructed in 1977 under Project B-100. The original design life of the 242-A Evaporator was 31
10 years. 32
2 Waste volume reduction (WVR) is the reduction in the volume of the waste stored in the DST system due to
operation of the 242-A Evaporator. 3 Waste volume reduction factor (WVRF) expresses the WVR as a percentage of the feed volume to the 242-A
Evaporator. Sometimes the term WVR is used imprecisely and interchangeably with WVRF. 4 This single-pass range, used for planning purposes, corresponds to the current operating window for the 242-A
Evaporator as described in RPP-17152, Hanford Tank Waste Operations Simulator (HTWOS) Version 8.1 Model
Design Document. This operating window considers physical limitations of the 242-A Evaporator, namely
minimum and maximum slurry flowrates, maximum feed flowrate, and maximum boil-off flowrate.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
3
Portions of the 242-A Evaporator were expanded and upgraded in 1983. These modifications 1
added 1,500 ft2 to the 242-A Building and included: 2
• Expanding the control room, relocating instrumentation, and adding a new annunciator 3
panel; 4
• Expanding the men’s change room and adding a women’s change room; and 5
• Adding a pre-engineered lean-to building to house both clean and soiled laundry 6
(displaced by other expansions) and a storage area. 7
2.2.1 Project B-534 Upgrades 8
A major upgrade project (Project B-534) was initiated fiscal year (FY) 1987 and completed prior 9
to the 1994 restart. The purpose was to extend the operating life by 10 more years. The B-534 10
modifications included: 11
• Adding reboiler instrumentation to improve monitoring and control 12
• Upgrading the P-B-1 recirculation pump to increase liquid velocity through the reboiler 13
• Upgrading slurry systems to allow pumping of thicker slurry 14
• Implementing upgrades to lighting, power, service crane controls, and plant 15
communication systems 16
• Replacing old plant controls with a microprocessor-based control system 17
• Constructing a water services building to provide backflow prevention, strainer, and 18
pressure regulation to the water supply 19
• Adding insulation to the vapor-liquid separator (C-A-1 vessel) to better regulate process 20
temperatures 21
• Replacing the primary condenser E-C-1. 22
Additionally, LERF and ETF were constructed during this outage to store and treat the process 23
condensate generated from the 242-A Evaporator, in addition to other site waste streams. 24
2.2.2 Upgrades between 1996 and 2003 25
Other modifications were made after Project B-534 that included upgrades to: 26
• Re-route steam condensate from 207-A retention basins to the Treated Effluent Disposal 27
Facility (TEDF) – 1997. 28
• Re-route used condenser cooling water from B-pond to TEDF– 1997. 29
• Replace the aging coal-fired steam plant with a new package boiler annex – 1998. 30
• Add new slurry jumpers with relief valves and a coriolis meter to protect piping from 31
overpressure and improve process control – 2003. 32
• Remove the obsolete ion-exchange column – 2003. 33
2.2.3 Upgrades after 2003 34
Major facility upgrades conducted from 2004 to 2009 include: 35
• Replacement of the inter-condenser (E-C-2), the after-condenser (E-C-3), and steam jets 36
(life extension of critical process components) – 2004. 37
• Replacement of air compressors – 2006 through 2010. 38
• Instrument upgrades (e.g., pressure, temperature, and flow) for life extension and 39
improved process control – 2007 to present. 40
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
4
• Upgrade of the facility supply-side ventilation system from steam heating/evaporative 1
cooling to a modern electric system – 2008. 2
• Upgrade of the exhaust-side ventilation system (higher stack; improved maintainability, 3
flow, and pressure control) – 2011. 4
Major facility upgrades conducted from 2010 to 2014 include: 5
• The facility being placed in shutdown mode to address critical required upgrades and to 6
support the new Documented Safety Analysis (DSA). 7
• New steam traps and a re-designed reboiler steam condensate flow piping system to 8
improve condensate drainage. 9
• The installation of a new dip tube leg flush manifold to allow easier flushing of dip tube 10
sensing lines during operation. 11
• Upgrades to the RC-1 (steam condensate), RC-2 (used raw water), and RC-3 (process 12
condensate) effluent sampling systems. 13
• The installation of safety significant systems for the new 242-A DSA (described in 14
Section 2.2.4). 15
2.2.4 242-A Documented Safety Analysis and Technical Safety Requirement Upgrades 16
The 242-A Evaporator DSA was upgraded in 2014 to meet Change Notice 3 requirements of 17
DOE-STD-3009-94, Preparation Guide for U. S. Department of Energy Nonreactor Nuclear 18
Facility Documented Safety Analyses. 19
• The primary change in the 242-A DSA and Technical Safety Requirements (TSRs) was 20
the implementation of hazard analysis and controls to improve the protection of the 21
facility worker. 22
• The DSA upgrade also implemented the use of ISA-84 safety instrumented system 23
(SIS) to enhance the protection of the facility worker. 24
A full suite of new safety-significant structures, systems, and components (SSCs) was developed 25
and installed in the facility. These safety SSCs address potential accidents identified in the 26
hazard analysis of the new DSA, and are designed to protect the facility and collocated workers. 27
These safety SSCs are summarized below. 28
• The Flammable Gas SIS protects the facility worker and collocated worker from 29
flammable gas deflagration. 30
• The High Level SIS protects the facility worker from the effects of a waste flow-over 31
of the C-A-1 vessel. 32
• Backflow preventers prevent waste backflow into manned areas of the facility. 33
• The seismic shutdown system allows manual activation of the SISs listed above using 34
an emergency stop button. 35
• Pump P-B-2 pressure relief valve protects the facility and collocated workers from a 36
fine spray of waste from the jumpers downstream of pump P-B-2. 37
• The E-A-1 reboiler is now credited as safety significant to protect facility workers in 38
the condenser room from a tube rupture. 39
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
5
• The slurry line vacuum breaker protects tank farm piping from water hammer 1
damage. 2
2.2.5 Conclusions Regarding Upgrades 3
Upgrades have been carried out almost continuously during the life of the facility, with plans to 4
continue upgrades in the future. These upgrades have extended the life of the facility well 5
beyond the original 10-year projection. Refer to Section 4.1 for a discussion of ongoing life 6
extension planning and projected facility life. 7
2.3 TESTING, SURVEILLANCE, AND MAINTENANCE PROGAMS 8
The TOC maintains and implements programs for initial testing, in-service surveillance, and 9
maintenance of SSCs. These programs are described in RPP-13033, Tank Farms Documented 10
Safety Analysis.5 11
2.3.1 Testing Program 12
The TOC Testing Program ensures that SSCs comply with design, safety, and acceptance 13
criteria; that the SSCs can be started and operated efficiently and safely; and that new, modified, 14
and refurbished SSCs are thoroughly tested in an organized manner before being accepted and 15
placed in service (RPP-13033). The Testing Program is implemented through TFC-PLN-26, 16
Testing Program Plan. Testing consists of construction acceptance tests, visual inspections, leak 17
tests, factory acceptance tests, and operational acceptance tests. 18
RPP-13033 explains that testing is performed by qualified personnel in accordance with 19
approved written instructions. These instructions typically include the test objectives, test 20
methods, test conditions, sequence of testing, applicable cautions, recovery actions, and 21
acceptance criteria. Test results are evaluated to confirm that the test meets established 22
requirements and to ensure acceptability of tested SSCs. 23
2.3.2 Surveillances and Inspections 24
RPP-13033 states: 25
The TOC program for in-service surveillance, inspection, and testing activities is 26
described in TFC-PLN-29. This maintenance program contains the necessary 27
provisions sufficient to provide reasonable assurance that SSCs are capable of 28
fulfilling their intended function. In-service surveillance, inspection, and testing 29
activities are performed in accordance with TOC procedures documented in a 30
computerized maintenance management system database. 31
Surveillance requirements have been established for selected safety-significant SSCs whose 32
functional requirements can be verified through testing. There are two types of surveillance tests 33
– calibrations and functional tests. Calibration surveillances are developed to ensure components 34
perform according to manufacturer and engineering specifications. Functional tests are 35
developed to evaluate the performance of the safety-significant SSCs. Functional tests are 36
5 The 242-A DSA (HNF-14755, 242-A Evaporator Documented Safety Analysis) refers to RPP-13033 for a
discussion of the TOC maintenance, testing, and surveillance programs.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
6
performed on selected safety-significant SSCs where it is practical to verify system functional 1
safety criteria. 2
The TOC controls measuring and test equipment (M&TE) to ensure the accurate performance of 3
facility instrumentation and equipment for testing, calibration, and repairs. The M&TE that is 4
used to support calibration, functional testing, and data collection on plant-installed equipment 5
must be calibrated and traceable to nationally recognized standards. Calibration of the M&TE is 6
performed offsite at an approved calibration laboratory. 7
2.3.3 Maintenance Program 8
The Maintenance Management Program is established under U.S. Department of Energy (DOE) 9
Order 433.1B, Maintenance Management Program for DOE Nuclear Facilities. The 10
Maintenance Program implementation is further described in TFC-PLN-29, Nuclear 11
Maintenance Management Plan. 12
RPP-13033 explains that the TOC is responsible for ensuring the maintenance program is in 13
place and that it meets the facility needs and requirements. The maintenance program is 14
implemented using approved TOC procedures. Maintenance organization training, maintenance 15
facilities and equipment, post-maintenance testing, control and calibration of M&TE, and 16
maintenance history and trending are described in the TOC procedures. The maintenance 17
program considers factors related to health, safety, environment, maintaining risks at a level as 18
low as reasonably achievable (ALARA), and hazardous waste management. 19
Inspections, audits, reviews, investigations, and self-assessments are incorporated into the 20
surveillance and maintenance programs. RPP-13033 states: 21
Maintenance history can be developed for SSCs through the work management 22
system database. Corrective and preventive maintenance and calibration information 23
can be accessed through the work management system or through the contractor 24
archives of completed work requests. Engineering and maintenance personnel can 25
use the records for activities such as failure analysis, conducting maintenance 26
assessments, preventive maintenance, predictive maintenance, outage planning, 27
improving the maintenance program, identifying needed equipment modifications, 28
and trending of SSC performance. 29
30
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
7
3.0 PLANS FOR USING THE 242-A EVAPORATOR 1
As discussed in Section 1.0, the 242-A Evaporator is used to reduce waste volume and therefore 2
reduce the number of DSTs required to store liquid waste at the Hanford Site. The 242-A 3
Evaporator supports several interdependent mission objectives: 4
• General management of DSTs 5
• Retrieval of waste from AY-102 6
• Retrieval of waste from SSTs 7
• Preparation of feed for Low-Activity Waste Pretreatment System (LAWPS) / direct feed 8
low-activity waste (LAW) (or DFLAW), and 9
• Management of returns from LAWPS / DFLAW. 10
The purpose of the subsections in this chapter are to: 11
• Section 3.1 – List key assumptions affecting the demand on the 242-A Evaporator 12
(used in both Section 3.2 and Section 3.3). 13
• Section 3.2 – Demonstrate that the 242-A Evaporator capacity is not the limiting 14
consideration in meeting the four DOE-proposed Consent Decree milestones in 15
Table 3-1 using a steady-state evaluation. 16
• Section 3.3 – Demonstrate the three proposed milestones can be met within the 17
existing WVR capability of the 242-A Evaporator. The demonstration was 18
underpinned by a sophisticated computer simulation model in conjunction with 19
considerations of reliability, availability, and maintainability (RAM). 20
• Section 3.4 – Provide additional evaluations that demonstrate the proposed milestones 21
can still be met in the event of contingencies such as an 18-month 242-A Evaporator 22
outage. 23
• Section 3.5 – List several opportunities for improving the WVR posture. 24
3.1 ASSUMPTIONS 25
Key assumptions affecting the demand on the 242-A Evaporator for the modeled operating 26
scenario, include: 27
• Retrieval of C-Farm is assumed to complete in FY 2016. 28
• The waste in AY-102 is retrieved starting in FY 2016 and the space in AY-102 is 29
assumed to be unavailable for the remainder of the evaluation. 30
• The Consent Decree milestones for initiating the retrieval of two A/AX Tank Farm 31
retrievals and initiating two additional retrievals will reflect DOE’s proposed 32
milestone dates of 12/31/2018 and 12/31/2020, respectively, accounting for a one-33
year delay due to the use of increased worker protective equipment arising from 34
concerns about tank farm vapor exposures. See Table 3-1. 35
• The Consent Decree milestones for initiating the retrieval of the five remaining 36
retrievals will reflect DOE’s proposed milestone dates of 03/31/2023, accounting for 37
a one-year delay due to the use of increased worker protective equipment arising from 38
concerns about tank farm vapor exposures. See Table 3-1. 39
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
8
• The Consent Decree milestone for the completion of the retrieval of the next nine 1
SSTs will reflect DOE’s proposed date of 03/31/2024, accounting for a two-year 2
delay due to the use of increased worker protective equipment arising from concerns 3
about tank farm vapor exposures. See Table 3-1. 4
• Retrieval of A-103, which is governed exclusively by the Hanford Federal Facility 5
Agreement and Consent Order (HFFACO, Ecology et al. 1989) rather than the 6
Consent Decree, begins after 03/31/2024. 7
• For operational planning purposes, the LAWPS and the Waste Treatment and 8
Immobilization Plant’s (WTP) LAW Vitrification Facility are assumed to operate in 9
the Direct Feed mode, beginning pretreatment on 10/01/2021 and vitrification on 10
12/31/2021. Note: LAWPS and WTP LAW operation are not required for the next 9 11
retrieval completion or evaporator operational success. 12
• The maximum operating level of six of the eight DSTs in AP Tank Farm have been 13
previously implemented, providing about 600 kgal of usable space. The level rise for 14
the seventh AP Tank Farm DST is planned for FY 2016, which will provide an 15
additional 100 kgal of usable space. 16
• The minimum schedule duration from sampling waste feed for the 242-A Evaporator 17
to the start of processing is a minimum of three months before that startup of 18
LAWPS/DFLAW. After the startup of LAWPS/DFLAW it is assumed that it will 19
take two months6 to sample 242-A Evaporator feed. 20
• The WVR for each 242-A Evaporator campaign is calculated based on the chemical 21
composition of the waste staged for evaporation. The historical (since 2003) average 22
terminal SpG of 1.43 is used to set the initial WVR target, which may then be reduced 23
to comply with the 242-A Evaporator safety basis, ALARA requirements and 24
operating limitations of the 242-A Evaporator 25
• The feed preparation strategy for the 242-A Evaporator uses blending to increase the 26
WVR. For example, existing concentrated supernate is blended with sparingly solute 27
dilute wastes from retrieval. 28
• Estimates of the retrieval parameters (assumed technologies, as-retrieved waste 29
volume, water and chemical additions, and minimum retrieval duration7) for each 30
SST are provided by SVF-1647, Rev. 58. 31
• The design for A Tank Farm retrievals begins in FY 2016 to enable a six-month 32
acceleration of date on which each individual A Tank Farm SST is ready to begin 33
retrieval operations. 34
• The modeled operating scenario takes no credit for DST space in West Area. 35
6 The three-month duration can be reduced to about two months if the 222-S Laboratory is fully staffed for three
shifts/day, 24/7, and given priority to support the analysis, hot boil-downs and reporting for 242-A Evaporator
operations. Current operations are based on a single shift. 7 The minimum retrieval durations for A and AX Tank Farm retrievals has been increase by 50% to account for
additional retrieval time expected based on a qualitative assessment of past retrieval performance. 8 SVF-1647, 2014, “SVF-1647 Rev 5 Calculation of SST Retrieval Volumes and Durations.xlsx,” Filename
‘SVF-1647 Rev 5.xlsx,’ Rev. 5, Washington River Protection Solutions, LLC, Richland, Washington.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
9
Table 3-1. Proposed Milestones.
Event Proposed Date
Initiate 2 A/AX retrievals 12/31/2018
Initiate 2 additional A/AX retrievals 12/31/2020
Initiate 5 remaining retrievals 03/31/2023
Complete 9 retrievals 03/31/2024
3.2 STEADY-STATE EVALUATION OF REQUIRED EVAPORATOR CAPABILITY 1
A simple steady-state evaluation of the required evaporator capability was performed to estimate 2
the average annual WVR that would provide sufficient DST space to complete nine retrievals by 3
a specific date. This evaluation took no credit for the net gain in space from operating LAWPS / 4
DFLAW and conservatively allocated space for the dilution water used to prepare the DFLAW 5
hot commissioning feed. The rest of the assumptions are as described in Section 3.1. 6
The results of this evaluation show an estimate of the average annual WVR required for 7
completing the nine retrievals based on a range of assumed completion dates. Separate curves 8
are shown for three choices (0, 1, and 2 Mgal) of the desired amount of available operating 9
space9 remaining after the retrievals are complete. Table 3-2 shows an example calculation for 10
the case where 2 Mgal of space is assumed to remain in East Area DSTs and the nine retrievals 11
being completed on the proposed milestone date of 03/31/2024. In this case, the average annual 12
WVR for the eight-year period of evaluation starting at FY 2016, and maintaining the assumed 13
2 Mgal of space is about 0.84 Mgal per year (this can also be seen on Figure 3-1 at the 14
intersection of the “2 Mgal” curve with the vertical line in FY 2024). 15
9 The available operating space does not include the 1.265 Mgal of required emergency space.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
10
Table 3-2. Example Steady-State Volume Balance Calculation.
Volume Balance Terms Mgal
Desired available DST space in East Area on date next 9 retrievals are
assumed to be completed 2.00
Starting available DST space in East Area at start of FY 2016 - 3.31
Space gained by AP-106 Level Rise - 0.10
As-retrieved volume of remaining C-Farm tanks, AY-102, and the 9 A/AX
tanks + 7.93
Dilution water of LAWPS / DFLAW hot commissioning feed + 0.58
Net space gain from operating LAWPS / DFLAW (no credit taken) - 0
Total WVR from FY 2016 to completion date = 7.10
Annual WVR (divide Total WVR by 8.5 years: FY2016 to 3/31/2024
inclusive) =
0.84
(Mgal/yr)
The average annual WVR for a reasonable range of assumed completion dates for the next nine 1
retrievals and the proposed milestone date of 03/31/2024 ranges between about 0.60 Mgal/yr and 2
1.35 Mgal/yr (see Figure 3-1). Both of these values are well within the previously demonstrated 3
capacity of the 242-A Evaporator (see Section 2.1). The larger values occur when an assumed 4
2 Mgal of available tank space, above and beyond emergency space requirements, remain in the 5
East Area DSTs at the completion of the retrievals. Using this model demonstrates that the 6
WVR capacity of the Evaporator is not a limiting constraint in meeting the proposed milestone 7
for completing nine retrievals. 8
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
11
Figure 3-1. Steady-State Average Annual Waste Volume Reduction Requirements. 1
2
3.3 DYNAMIC EVALUATION OF MODELED OPERATING SCENARIO 3
The steady-state evaluation demonstrates that the 242-A Evaporator capacity is not limiting the 4
ability to retrieve the nine A/AX Tank Farm SSTs by 03/31/2024. However, a more 5
sophisticated evaluation is required to account for the timing of retrievals, transfers, and 6
evaporator campaigns. An operating scenario (sequence and timing of retrievals, level rises, 7
waste transfers, and evaporator campaigns) was simulated using the Hanford Tank Waste 8
Operations Simulator (HTWOS). HTWOS is a computer modeling tool that per RPP-17152: 9
…accounts for the major systems required to accomplish the River Protection 10
Project (RPP) mission to store, process, and immobilize the Hanford tank wastes 11
for disposal. 12
… HTWOS simulates the movement of waste material through the tank farm 13
system in support of single-shell tank (SST) retrieval, 242-A Evaporator 14
operation, waste retrieval from double-shell tank (DST) farms, feed delivery to 15
the Waste Treatment and Immobilization Plant (WTP), as well as supplemental 16
treatment systems and transuranic (TRU) waste processing. This enables WRPS 17
to evaluate impacts to processing throughput caused by possible changes in 18
0.0
0.5
1.0
1.5
2022 2023 2024
Ave
rage
An
nu
al W
aste
Vo
lum
e R
edu
tio
n (
Mga
l per
yea
r)
Assumed Completion Date for Completion of "Next 9" Retrievals (Fiscal Year)
Remaining DST Operating Space = 2 Mgal
Remaining DST Operating Space = 1 Mgal
Remaining DST Operating Space = 0 Mgal
Proposed Milestone for Complete Next 9 Retrievals
Early A-105 Completion
See text for example calculation
Largest average annual Waste Volume Reduction (see text for explaination and assumptions) for steady-state evaluation
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
12
event-driven activities such as pumping, sampling, storage, recycle, separation, 1
and chemical reactions. 2
The HTWOS modeling tool uses information about waste properties, system 3
configurations, desired end-states, target milestones, and other parameters 4
associated with waste processing scenarios to: 5
• Simulate the waste storage, retrieval, feed staging, and treatment 6
processes; 7
• Evaluate the relationship between tank waste retrieval and treatment 8
activities; 9
• Link and evaluate new facility capacities, project requirements and 10
schedules, and contractor integration; 11
• Evaluate integration across multiple process steps and programs; 12
• Verify existing plans for accomplishing the RPP mission; and 13
• Develop future plans. 14
3.3.1 Raw Schedule Results 15
The modeled operating scenario10 demonstrates that there is sufficient DST space and 242-A 16
Evaporator capacity to complete the retrievals of the next nine SSTs (AX-101, -102, -103, 17
and -104; and A-101, -102, -104, -105, and -106) by the DOE-proposed 03/31/2024 Consent 18
Decree milestone date and to meet the other three proposed milestones in Table 3-1. This 19
operating scenario estimates that the four proposed milestones will be met with margin (i.e., in 20
advance of the milestone dates). That margin provides confidence in our ability to execute the 21
operating scenario and meet the proposed milestone dates in light of the following 22
considerations. 23
• As with all HTWOS scenarios, this operating scenario provides point estimates and 24
does not explicitly address RAM impacts related to the DSTs, transfer system, and 25
the 242-A Evaporator. 26
• The scope of DST upgrade projects needed to support LAWPS operations is not yet 27
defined. Therefore, the impact of scheduling necessary transfers and 242-A 28
Evaporator campaigns around those projects has not been addressed by the operating 29
scenario. 30
3.3.2 Reliability, Availability, and Maintainability Considerations 31
As discussed in Section 3.3.1, the estimated retrieval completion dates provided by the HTWOS 32
model are point estimates. As such, additional time needs to be added to the dates provided by 33
HTWOS to account for RAM considerations. This section may help inform decisions as to how 34
much additional time may be required to ensure confidence in meeting the proposed milestone 35
dates. 36
10 The modeled operating scenario was prepared using the Hanford Tank Waste Operations Simulator according
to MMR-50072, 242-A Evaporator Support of A and AX Farm Retrieval, and identified as MMR-50072-early-
AFarm-8.1-8.3r1-2015-10-11-at-20-56-06.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
13
RPP-RPT-55891, One System Double-Shell Tank Space Management Evaluation Assessment 1
Report, evaluated the impact of equipment failures for the DSTs, transfer system, and the 242-A 2
Evaporator on several near-term milestones, including the existing Consent Decree milestone for 3
completing nine additional retrievals. The report found that when equipment failures were 4
addressed, the average projected completion date increased about 1.5 years. 5
3.3.3 Limiting Permit Condition Assessment 6
The modeled operating scenario requires the 242-A Evaporator to operate for an approximate 7
total of 130 days11 or about 6% of the time over the six-year period from FY 2016 to FY 2021, 8
inclusive. This compares favorably to the RCRA permit, Radioactive Air Emission Licenses, 9
Air Operating Permit, and State Waste Discharge Permit (limiting) which allow the 242-A 10
Evaporator to operate up to 152 days per year12. In other words, this operating scenario requires 11
the 242-A Evaporator to operate, on average, at about 14% of the permitted capacity in order to 12
achieve what is required for thenext nine A and AX SST retrievals. Thus, permit modifications 13
are not anticipated to be needed, but can and will be requested with enough lead time to allow 14
242-A Evaporator operations to continue as planned. 15
3.3.4 242-A Evaporator Demand 16
During the above period, the 242-A Evaporator is estimated to recover 6.4 Mgal of DST tank 17
space, or WVR; this is approximately 1 Mgal of WVR per year. This compares favorably to the 18
historical and current capabilities of the 242-A Evaporator as discussed in Section 2.1. 19
The required WVR and the estimated number of 242-A Evaporator campaigns needed to 20
successfully execute the modeled scenario are shown in Table 3-3. The estimated annual WVR 21
is based on the chemical properties of the specific tanks that are projected to be processed 22
through the 242-A Evaporator that fiscal year. 23
11 This is the total estimated time during which the 242-A Evaporator is actually concentrating waste from the
model. Operating time required per campaign may vary depending on periods in which the 242-A Evaporator is
idling with the C-A-1 vessel full of waste, time in which E-C-1 condenser cooling water is running before and after
a campaign, or the time in which “cold” training runs are performed. 12 RPP-RPT-57991, One System River Protection Project Integrated Flowsheet, Table 7-2, 242-A Evaporator
Environmental Permit Constraints.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
14
Table 3-3. Estimated Demand on the 242-A Evaporator.
Fiscal Year Waste Volume Reductiona Estimated Number of Campaignsc
Annualb
(kgal)
Cumulative
(kgal)
Annual Cumulative
2016 700 700 3 3
2017 1,000 1,700 4 7
2018 700 2,400 1 8
2019 1,400 3,700 3 11
2020 900 4,600 2 13
2021 1,800 6,400 3 16 a The estimated single-pass WVRFs from campaigns spanning FY 2016 through FY
2021 range from about 21% to 57%. The WVRF for individual campaigns is calculated
based on the chemical composition of the waste staged for evaporation. b The average required annual WVR is a nominal 1 Mgal per year. c The number of estimated evaporator campaigns may vary for process or operational
considerations as long as the target WVR is met.
3.3.5 Overall Volume Balance for Modeled Operating Scenario 1
Table 3-4 provides an overall DST space evaluation to complete the retrievals of the next nine 2
SSTs (AX-101, -102, -103, and -104; and A-101, -102, -104, -105, and -106) by the DOE-3
proposed 03/31/2024 Consent Decree milestone date. The accounting of DST space begins the 4
start of FY 2016 and continues until the four proposed Consent Decree milestones in Table 3-1 5
are projected to be met. At that time, there remains approximately 1.61 Mgal of available space 6
in the East Area DSTs beyond the 1.265 Mgal of space allocated for emergencies. 7
Table 3-4. Summary of Double-Shell Tank Space Evaluation for Next Nine Retrievals.
Contribution Cross
Reference
Volumea
(Mgal)
Headspace in East Area DSTs at Start of FY 2016 Table A-1a 5.26
Headspace in AY-102 and Group A DSTs, and Emergency space Table A-1b - 1.95
DST space required for retrievals of C-Farm, A-Farm (excluding A-103),
AX-Farm, and AY-102; and dilution water for preparing the LAWPS /
DFLAW hot commissioning feed
Table A-1c - 8.51
Increase maximum operating level in AP-106 (Level Rise) Table A-1d + 0.10
Net Space Gained by LAWPS / DFLAW Operation until end of “Next 9”
Retrievals Table A-1d + 0.18
Estimated 242-A waste volume reduction (FY 2016 – end of “Next 9”
Retrievals) Table A-1e + 6.43
Estimated Space Available in East Area at the end of “Next 9” Retrievals Table A-1f = 1.51 a Volume estimates are from an HTWOS model run documented by MMR-50072, identified as MMR-50072-early-
AFarm-8.1-8.3r1-2015-10-11-at-20-56-06.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
15
3.4 CONTINGENCY EVALUATION 1
Two hypothetical outage scenarios were performed to assess the robustness of the modeled 2
operating scenario against reasonable contingencies. Collectively, these demonstrate there is 3
adequate tank space and 242-A Evaporator capacity to meet DOE’s proposed milestone date of 4
03/31/2024. In line with modeled operating scenario in Section 3.3.5, these outage scenarios 5
include the 576 kgal of dilution water to prepare the initial feed for LAWPS which is added to 6
DST AP-107 in February 2021. This value is part of the 8.51 Mgal in Table 3-4. 7
3.4.1 Evaporator Outage at Start of Retrieval of Last Two A Tank Farm Tanks 8
This hypothetical outage scenario demonstrates that DOE’s proposed Consent Decree milestone 9
to complete retrieval of the next nine SSTs by 03/31/2024 can still be met in spite of a 10
hypothetical 18-month outage of the 242-A Evaporator, beginning at the start of the retrieval of 11
the last two A Tank Farm SSTs under the Consent Decree. The timing of this hypothetical 12
outage, from February 2021 through August 2022, was selected to exacerbate the impacts on 13
DOE’s proposed completion milestone for the next nine tanks by overlapping the retrieval of A-14
105 which requires a nominal 1.6 Mgal of WVR. 15
The results for this outage scenario show that the estimated retrieval completion dates continue 16
to meet DOE’s four proposed milestone dates with loss of about half of the margin for the 17
completion of the nine SSTs by 03/31/2024. By design, the remaining three proposed milestones 18
are met with little change in margin. 19
3.4.2 Evaporator Outage after Retrieval of First Two AX Tank Farm Tanks 20
This hypothetical outage scenario demonstrates that DOE’s proposed Consent Decree milestone 21
to complete retrieval of the next nine SSTs by 03/31/2024 can still be met in spite of an 18-22
month outage of the 242-A Evaporator, beginning after the retrieval of the first two AX Tank 23
Farm SSTs has been completed. The timing of this hypothetical outage, from September 2017 24
through March 2019, was selected to exacerbate the impacts on DOE’s proposed completion 25
milestone for the two additional A/AX retrievals by overlapping a period in which several 242-A 26
Evaporator campaigns were planned. 27
The results for the outage scenario show that the estimated retrieval completion date for the next 28
nine SSTs continues to meet DOE’s proposed milestone date of 03/31/2024, albeit with loss of 29
about a third of the margin. The estimated dates for meeting the other three proposed milestones 30
are met with little change in margin. 31
3.5 ADDITIONAL OPPORTUNITIES TO IMPROVE WASTE VOLUME 32
REDUCTION POSTURE 33
There are other opportunities that might improve the WVR posture – some of these are 34
underway, some under consideration, and others would require the cooperation from the 35
Washington State Department of Ecology (Ecology). 36
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
16
These include: 1
• Preliminary AX retrieval flowsheets suggest that the total volume of waste retrieved 2
from those tanks, including necessary water and chemicals, may be reduced by up to 3
1 Mgal. 4
• Up to six additional DSTs in AN and AW Tank Farms are being reviewed as 5
potential candidates for increasing the maximum operating level. If successful, this 6
could provide up to a nominal 600 kgal of additional DST space. 7
• The TOC has been actively identifying and procuring spare parts for the 242-A 8
Evaporator, including possible procurement of a spare reboiler as discussed in 9
Section 4.1. Recovery from a failure of the reboiler would likely take longer than the 10
hypothetical 18-month outage if a spare is not available, and significantly shorter than 11
the outage if a spare is available. 12
• The TOC has recognized the need to maintain a set of spare waste transfer pumps to 13
support the DST waste transfers needed to support 242-A Evaporator operations, 14
especially the AW-102 transfer pump which provides feed to the 242-A Evaporator, 15
and other high-use DST-to-DST transfer pumps (RPP-RPT-55891). 16
• Current estimates of the volume of water and chemicals needed to retrieve the waste 17
in and under the liner of SST A-105 assume that multiple technologies will be applied 18
in an attempt to retrieve all of the waste down to the limits of the technologies. As 19
can be seen in Table 3-5, the 37 kgal of waste in A-105 is currently estimated13 to 20
result in an as-retrieved volume of 1.7 Mgal due to the required 1.6 Mgal of water and 21
chemicals (1.1 Mgal of water, 470 kgal of 1M oxalic acid, 38 kgal of 19M sodium 22
hydroxide, and 8 kgal of 3M sodium hydroxide) to reach the assumed retrieval 23
endpoint. However, the introduction of this volume of liquids could inadvertently 24
mobilize and transport the contaminants further into the underlying base materials 25
and soil. To minimize the potential for environmental harm, DOE and Ecology 26
should consult with the TOC to ensure the retrieval methods and end-points are 27
protective of human health and the environment. A risk-based retrieval approach for 28
this SST might significantly reduce the demand on DST space and the 242-A 29
Evaporator for this retrieval by reducing the quantity of water and chemicals used. 30
13 SVF-1647, 2014, “SVF-1647 Rev 5 Calculation of SST Retrieval Volumes and Durations.xlsx,” Filename
‘SVF-1647 Rev 5.xlsx,’ Rev. 5, Washington River Protection Solutions, LLC, Richland, Washington.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
17
Table 3-5. Single-Shell Tank Retrieval Demands on Double-Shell
Tank Space.
Tank Current
Waste
Volume
(kgal)
As-
Retrieved
Waste
Volume
(kgal)
Post-Evap
Volume
(kgal)
Required
WVR
(kgal)
As-
Retrieved to
Current
Volume
(kgal:kgal)
AX-104 7 211 14 198 28.6
AX-102 30 428 60 367 14.3
AX-103 106 869 228 642 8.2
AX-101 357 1,630 867 763 4.6
A-102 40 231 73 157 5.8
A-101 320 1,080 676 404 3.4
A-106 79 446 172 274 5.7
A-104 28 127 52 75 4.5
A-105 37 1,734 88 1,646 47.2
Totals 1,005 6,755 2,229 4,526 6.7
1
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
18
4.0 WHY THE U.S. DEPARTMENT OF ENERGY HAS CONFIDENCE 1
IN THE EVAPORATOR 2
4.1 242-A EVAPORATOR INTEGRITY, LIFE EXTENSION, AND CONTINGENCY 3
PLANNING 4
As described above, since operations were initiated in 1977, two multi-year outages have 5
occurred. The first, from 1989 to 1994, was to allow for major upgrades and construction of 6
LERF/ETF. The second, from 2010 to 2014, was an operational decision to perform upgrades 7
and a DSA revision (available DST space was sufficient to support ongoing operations at that 8
time). 9
Other than these two outages, the longest outage has been 12 months between waste processing 10
campaigns or ‘cold runs’ (operating the 242-A Evaporator with water to demonstrate 11
proficiency). That is, to date the major facility outages have been strategic decisions, not due to 12
equipment breakdown. 13
The facility has had routine integrity assessments on a frequency recommended by an 14
Independent Qualified Registered Professional Engineer (IQRPE). The last integrity assessment 15
was performed in 2007 (reported in RPP-RPT-33306, IQRPE Integrity Assessment Report for the 16
242-A Evaporator Tank System). The report projected the minimum remaining life of each 17
major vessel tested (e.g., reboiler, C-A-1 vessel, recirculation loop, condensate collection tank, 18
and condensers) to be greater than 20 years. The next recommended integrity assessment is in 19
10 years, or 2017 (and is scheduled for 2017). 20
Facility upgrades are currently guided by the Life Extension Study (HNF-3327, Engineering 21
Study for the 242-A Life Extension Upgrades for Fiscal Years 2010 Through 2052) and 22
RPP-RPT-55977, Infrastructure Stewardship Plan, along with risk/probability study results. 23
These two documents contain the long-term and short-term upgrade plans, respectively. 24
A reliability assessment was issued in 2011 (RPP-RPT-49610, Reliability Assessment of the 25
242-A Evaporator at the Hanford Tank Farms). The report concluded that “continued integrity 26
assessments and equipment upgrades, along with a pro-active maintenance strategy, should keep 27
the evaporator operating for another 30 years.” 28
The E-A-1 reboiler was classified as a safety-significant component in HNF-14755 in 2014. 29
Integrity testing was performed and the component was declared leak-tight14 (RPP-RPT-57257, 30
Test Report for Leak-Tightness of Reboiler Vessel E-A-1 at 242-A Evaporator Facility). A 31
reboiler corrosion evaluation was prepared (RPP-RPT-58179, Evaluation of Halide Stress 32
Corrosion Cracking and Pitting in the 242-A E-A-1 Reboiler as it Relates to Operating 33
Parameters and Tank Waste Chemistry). This report indicates that via review of operational 34
history and leak integrity testing the reboiler tubes have not experienced any through wall 35 penetrations and that flushing procedures that follow each 242-A Evaporator campaign have been 36 effective at preventing under-deposit corrosion during idle times. In addition, recommended 37
chemistry and flushing controls have been incorporated into campaign process control plans. 38
14 Leak tightness is determined by a liquid tracer test used to verify the integrity of the vessel.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
19
As the reboiler is a critical piece of equipment, there is a risk of a delay to the TOC mission if the 1
existing reboiler fails. Specification, procurement, and replacement of a safety-significant spare 2
E-A-1 reboiler is expected to take greater than two years. Procurement of a qualified spare 3
reboiler would reduce the risk to the retrieval mission by reducing the replacement time to 4
approximately one year, which is consistent with the duration of previous unplanned outages due 5
to equipment breakdown. 6
The TOC maintains an integrated Operations, Engineering, Nuclear Safety, Environmental, and 7
Design staff to monitor facility operation, identify issues and improvements, and provide an 8
ongoing upgrade and maintenance capability that can support maintaining facility availability. 9
4.2 242-A EVAPORATOR OPERATING STRATEGY PROVIDES CONTINGENCY 10
The 242-A Evaporator planned usage is a fraction of the allowable usage under the permits 11
discussed in Section 2.3, and the permits restrict usage to 152 calendar days or less. Planning to 12
operate a fraction of the available calendar days effectively builds in contingency for many 13
operational issues that might arise. Equipment issues that preclude operations for weeks to 14
months may not affect the annual operating time. 15
For example, in 2014 and 2015, numerous operational challenges arose, including: a Tank Farms 16
transfer pump failed, which led to a revised feed staging strategy for the EC-01 campaign; the 17
242-A Evaporator ammonia monitor failed and was replaced prior to EC-01; a valve in the feed 18
line failed and was repaired during EC-01; and another Tank Farms pump failed and was 19
replaced prior to performing feed staging transfers for the EC-03 campaign. Notwithstanding 20
these issues, four campaigns were completed in a span of thirteen calendar months. As these 21
issues occur, repairs are often performed during times when the facility is not processing, thus 22
repair times do not count against the permitted operating limits. 23
4.3 CONCLUSION REGARDING 242-A EVAPORATOR CAPABILITY 24
Recent and historical performance of the 242-A Evaporator demonstrates that the facility will be 25
able to support the planned A and AX Tank Farm retrieval activities. The facility has 26
demonstrated the ability to process large volumes of feed in a short period of time, and to meet 27
the operational needs of the Tank Farms. The 242-A Evaporator is mechanically sound and 28
capable of sustained operation. However, the procurement of a qualified spare E-A-1 reboiler 29
would lower mission risk by reducing the reboiler replacement time from greater than two years 30
to approximately one year. 31
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
20
5.0 REFERENCES 1
DOE O 433.1B, 2010, Maintenance Management Program for DOE Nuclear Facilities, U.S. 2
Department of Energy, Washington, D.C. 3
DOE-STD-3009-94, 2006, Preparation Guide for U. S. Department of Energy Nonreactor 4
Nuclear Facility Documented Safety Analyses, Change Notice No. 3, U. S. Department of 5
Energy, Washington, D. C. 6
Ecology, EPA, and DOE, 1989, Hanford Federal Facility Agreement and Consent Order – Tri-7
Party Agreement, as amended, Washington State Department of Ecology, U. S. 8
Environmental Protection Agency, and U. S. Department of Energy, Olympia, 9
Washington. 10
HNF-3327, 2009, Engineering Study for the 242-A Life Extension Upgrades for Fiscal Years 11
2010 Through 2052), Rev. 2, Washington River Protection Solutions, LLC, Richland, 12
Washington. 13
HNF-14755, 2015, 242-A Evaporator Documented Safety Analysis, Rev. 5, Washington River 14
Protection Solutions, LLC, Richland, Washington. 15
MMR-50072, 2015, 242-A Evaporator Support of A and AX Farm Retrieval, Rev. 0, Washington 16
River Protection Solutions, LLC, Richland, Washington. 17
RPP-13033, Tank Farms Documented Safety Analysis, as amended, Washington River Protection 18
Solutions, LLC, Richland, Washington. 19
RPP-17152, 2015, Hanford Tank Waste Operations Simulator (HTWOS) Version 8.1 Model 20
Design Document, Rev. 12, Washington River Protection Solutions, LLC, Richland, 21
Washington. 22
RPP-RPT-33306, 2008, IQRPE Integrity Assessment Report for the 242-A Evaporator Tank 23
System, Rev. 2, CH2M HILL Hanford Group Inc., Richland, Washington. 24
RPP-RPT-49610, 2011, Reliability Assessment of the 242-A Evaporator at the Hanford Tank 25
Farms, Rev. 0, Washington River Protection Solutions, LLC, Richland, Washington. 26
RPP-RPT-55891, 2013, One System Double-Shell Tank Space Management Evaluation 27
Assessment Report, Rev. 0, Washington River Protection Solutions, LLC, Richland, 28
Washington. 29
RPP-RPT-55977, 2014, Infrastructure Stewardship Plan, Rev. 0, Washington River Protection 30
Solutions, LLC, Richland, Washington. 31
RPP-RPT-57257, 2014, Test Report for Leak-Tightness of Reboiler Vessel E-A-1 at 242-A 32
Evaporator Facility, Rev. 1, Washington River Protection Solutions, LLC, Richland, 33
Washington. 34
RPP-RPT-57991, 2015, One System River Protection Project Integrated Flowsheet, Rev. 1, 35
Washington River Protection Solutions, LLC, Richland, Washington. 36
RPP-RPT-58179, 2015, Evaluation of Halide Stress Corrosion Cracking and Pitting in the 37
242-A E-A-1 Reboiler as it Relates to Operating Parameters and Tank Waste Chemistry, 38
Rev. 0, Washington River Protection Solutions, LLC, Richland, Washington. 39
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
21
State Water Discharge Permit Number ST 4502, 2012, Washington State Department of 1
Ecology, Richland, Washington. 2
SVF-1647, 2014, “SVF-1647 Rev 5 Calculation of SST Retrieval Volumes and Durations.xlsx”, 3
Filename ‘SVF-1647 Rev 5.xlsx’, Rev. 5, Washington River Protection Solutions, LLC, 4
Richland, Washington. 5
TFC-PLN-26, Testing Program Plan, as amended, Washington River Protection Solutions, LLC, 6
Richland, Washington. 7
TFC-PLN-29, Nuclear Maintenance Management Plan, as amended, Washington River 8
Protection Solutions, LLC, Richland, Washington. 9
10
11
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
A-i
1
APPENDIX A 2
DETAILED VOLUME BALANCE FOR MODELED SCENARIOS 3
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
A-1
Table A-1 provides an overall DST space evaluation to complete the retrievals of the next 9 1
SSTs (AX-101, -102, -103, and -104; and A-101, -102, -104, -105 and -106) by the DOE-2
proposed 03/31/2024 Consent Decree milestone date. The accounting of DST space begins the 3
start of FY 2016 and continues until the four proposed Consent Decree milestones (see 4
Table 3-1) are projected to be met. Each of the six sub-tables (a-f) provide one part of the 5
volume balance as explained below. Bolded terms refer to items in the sub-tables. 6
Table A-1a shows the total headspace present in the DSTs at the start of FY 2016. The 7
5.26 Mgal of Headspace in East Area DSTs at Start of FY 2016 is the unused physical DST 8
tank space in East Area without regard to any restrictions on the use of that space. 9
This physical space must be reduced by restrictions that govern the use of the space. The 10
Restricted Headspace in East Area DSTs includes the headspace over the East Area DSTs 11
containing Group A waste and by the 1.265 Mgal of required emergency space allocation. 12
Additionally, the headspace in AY-102, shown explicitly on its own line, is not available for use. 13
This results in 3.31 Mgal of Space Available for Retrievals in East Area at the Start of 14
FY 2016 (see Table A-1b). 15
The 8.51 Mgal of Total Required Space in East Area is the DST space before concentration 16
through the 242-A Evaporator that is required to receive and store the as-retrieved waste from 17
the remainder of C-Farm retrievals, the A and AX Tank Farm SSTs excluding A-103, the waste 18
to be removed from AY-102, and the dilution water needed to prepare the hot commissioning 19
feed for LAWPS (see Table A-1c). 20
Table A-1d calculates that there is a 4.92 Mgal Tank Space Deficit in East Area (without 21
Evaporator Operation). The Space Available for Retrievals at Start of FY 2016 is reduced 22
for taking AY-102 out-of-service15, increased by the one pending AP-Farm level rise, and 23
increased by the Net Space Gained by LAWPS / DFLAW Operation until end of “Next 9” 24
Retrievals. Finally, the Total Required Space in East Area is subtracted to determine the DST 25
space deficit. If the evaporator were operated to only achieve a WVR of 4.92 Mgal, then there 26
would be zero available DST space remaining in East Area at the end of the retrievals of the 27
“Next 9” SSTs. As a rule of thumb, in practice there is a significant loss in operational flexibility 28
and the ability to transfer and concentrate waste as the available space is reduced so that it 29
approaches or dips below 1 Mgal. 30
Table A-1e reports 6.43 Mgal of Estimated waste volume reduction (FY 2016 – end of 31
“Next 9” Retrievals based on the results of the HTWOS run for the modeled operating scenario. 32
The final DST Space Accounting (including Evaporator Operation) in Table A-1f shows that the 33
Estimated Space Available in East Area at the end of “Next 9” Retrievals is 1.51 Mgal 34
Tables A-2 and A-3 show similar calculations for the two outage scenarios. The only difference 35
between the calculations is slightly different waste volume reduction numbers (Section F in the 36
tables) due to the modeled evaporator outages. 37
15 Since the headspace in AY-102 at the start of the accounting period was already accounted for in Table A-1d,
only the waste in AY-102 needs to be included in Table A-1d.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
A-2
Table A-1. Detailed Double-Shell Tank Space Evaluation for Next Nine Retrievals for the 1
Modeled Operating Scenario. 2
Volumea
(Mgal)
Table A-1a. Total DST Headspace in East Area at Start of FY 2016
All headspace in the 28 East and West Area DSTs 6.32
Headspace in West Area DSTs (No credit for headspace in West Area DSTs) - 1.06
Headspace in East Area DSTs at Start of FY 2016 = 5.26
Table A-1b. DST Space Available for Retrievals at Start of FY 2016
Headspace in East Area DSTs at Start of FY 2016 5.26
Restricted Headspace in East Area DSTs:
Group A (0.46 Mgal) and Emergency Space allocation (1.265 Mgal) - 1.72
Exclude headspace in AY-102 before waste is removed - 0.23
Space Available for Retrievals in East Area at Start of FY 2016 = 3.31
Table A-1c. DST Space Required for Retrievals and LAWPS (FY16 – end of “Next 9”
Retrievals)
Remainder of C Farm (C-105 and C-111) as retrieved volume 0.42
Retrieval of A and AX Farm (excluding A-103) as retrieved volume + 6.76
Retrieval of AY-102, current volume + 0.76
AP-107 Dilution (LAWPS Hot Commissioning Feed Preparation) + 0.58
Total Required Space in East Area = 8.51
Table A-1d. DST Space Accounting (without Evaporator Operation)
Space Available for Retrievals in East Area at Start of FY 2016 3.31
Increase Maximum Operating Level in AP-106 (Level Rise) + 0.10
Net Space Gained by LAWPS / DFLAW Operation until end of “Next 9” Retrievals + 0.18
Total Required Space in East Area - 8.51
Tank Space Deficit in East Area (without Evaporator Operation) = -4.92
Table A-1e. Waste Volume Reduction due to 242-A (FY2016 – end of “Next 9” Retrievals)
Estimated waste volume reduction (FY 2016 – end of “Next 9” Retrievals) 6.43
Table A-1f. DST Space Accounting (including Evaporator Operation)
2E Space Available Deficit (without Evaporator Operation) -4.92
Estimated waste volume reduction (FY 2016 – end of “Next 9” Retrievals) + 6.43
Estimated Space Available in East Area at the end of “Next 9” Retrievals = 1.51 a Volume estimates are from an HTWOS model run documented by MMR-50072, and identified as MMR-50072-early-
AFarm-8.1-8.3r1-2015-10-11-at-20-56-06. This model run begins with the Best-Basis Inventory as downloaded by the Tank
Waste Information Network System (TWINS) in 3Q FY 2015, adjusted for historical waste transfers, retrievals, and
campaigns; and reconciled as needed against actual tank waste level surface readings, also reported by TWINS in 3Q
FY 2015.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
A-3
Table A-2. Detailed Double-Shell Tank Space Evaluation for Next Nine Retrievals for the 1
18 month Evaporator Outage after the Retrieval of First Two AX Tank Farm Tanks. 2
Volumea
(Mgal)
Table A-2a. Total DST Headspace in East Area at Start of FY 2016
All headspace in the 28 East and West Area DSTs 6.32
Headspace in West Area DSTs (No credit for headspace in West Area DSTs) - 1.06
Headspace in East Area DSTs at Start of FY 2016 = 5.26
Table A-2b. DST Space Available for Retrievals at Start of FY 2016
Headspace in East Area DSTs at Start of FY 2016 5.26
Restricted Headspace in East Area DSTs:
Group A (0.46 Mgal) and Emergency Space allocation (1.265 Mgal) - 1.72
Exclude headspace in AY-102 before waste is removed - 0.23
Space Available for Retrievals in East Area at Start of FY 2016 = 3.31
Table A-2c. DST Space Required for Retrievals and LAWPS (FY16 – end of “Next 9”
Retrievals)
Remainder of C Farm (C-105 and C-111) as retrieved volume 0.42
Retrieval of A and AX Farm (excluding A-103) as retrieved volume + 6.76
Retrieval of AY-102, current volume + 0.76
AP-107 Dilution (LAWPS Hot Commissioning Feed Preparation) + 0.58
Total Required Space in East Area = 8.51
Table A-2d. DST Space Accounting (without Evaporator Operation)
Space Available for Retrievals in East Area at Start of FY 2016 3.31
Increase Maximum Operating Level in AP-106 (Level Rise) + 0.10
Net Space Gained by LAWPS / DFLAW Operation until end of “Next 9” Retrievals + 0.18
Total Required Space in East Area - 8.51
Tank Space Deficit in East Area (without Evaporator Operation) = -4.92
Table A-2e. Waste Volume Reduction due to 242-A (FY2016 – end of “Next 9” Retrievals)
Estimated waste volume reduction (FY 2016 – end of “Next 9” Retrievals) 6.43
Table A-2f. DST Space Accounting (including Evaporator Operation)
2E Space Available Deficit (without Evaporator Operation) -4.92
Estimated waste volume reduction (FY 2016 – end of “Next 9” Retrievals) + 6.47
Estimated Space Available in East Area at the end of “Next 9” Retrievals = 1.55 a Volume estimates are from an HTWOS model run documented by MMR-50072, and identified as MMR-50072-Run1-
Middle-Campaign-8.1-8.3r1-2015-10-22-at-20-05-19. This model run begins with the Best-Basis Inventory as downloaded by
the Tank Waste Information Network System (TWINS) in 3Q FY 2015, adjusted for historical waste transfers, retrievals, and
campaigns; and reconciled as needed against actual tank waste level surface readings, also reported by TWINS in 3Q
FY 2015.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
RPP-RPT-59046 Rev. 0
A-4
Table A-3. Detailed Double-Shell Tank Space Evaluation for Next Nine Retrievals for the 1
18 month Evaporator Outage at the Start of Retrieval of Last Two A Tank Farm Tanks. 2
Volumea
(Mgal)
Table A-3a. Total DST Headspace in East Area at Start of FY 2016
All headspace in the 28 East and West Area DSTs 6.32
Headspace in West Area DSTs (No credit for headspace in West Area DSTs) - 1.06
Headspace in East Area DSTs at Start of FY 2016 = 5.26
Table A-3b. DST Space Available for Retrievals at Start of FY 2016
Headspace in East Area DSTs at Start of FY 2016 5.26
Restricted Headspace in East Area DSTs:
Group A (0.46 Mgal) and Emergency Space allocation (1.265 Mgal) - 1.72
Exclude headspace in AY-102 before waste is removed - 0.23
Space Available for Retrievals in East Area at Start of FY 2016 = 3.31
Table A-3c. DST Space Required for Retrievals and LAWPS (FY16 – end of “Next 9”
Retrievals)
Remainder of C Farm (C-105 and C-111) as retrieved volume 0.42
Retrieval of A and AX Farm (excluding A-103) as retrieved volume + 6.76
Retrieval of AY-102, current volume + 0.76
AP-107 Dilution (LAWPS Hot Commissioning Feed Preparation) + 0.58
Total Required Space in East Area = 8.51
Table A-3d. DST Space Accounting (without Evaporator Operation)
Space Available for Retrievals in East Area at Start of FY 2016 3.31
Increase Maximum Operating Level in AP-106 (Level Rise) + 0.10
Net Space Gained by LAWPS / DFLAW Operation until end of “Next 9” Retrievals + 0.18
Total Required Space in East Area - 8.51
Tank Space Deficit in East Area (without Evaporator Operation) = -4.92
Table A-3e. Waste Volume Reduction due to 242-A (FY2016 – end of “Next 9” Retrievals)
Estimated waste volume reduction (FY 2016 – end of “Next 9” Retrievals) 6.43
Table A-3f. DST Space Accounting (including Evaporator Operation)
2E Space Available Deficit (without Evaporator Operation) -4.92
Estimated waste volume reduction (FY 2016 – end of “Next 9” Retrievals) + 6.44
Estimated Space Available in East Area at the end of “Next 9” Retrievals = 1.52 a Volume estimates are from an HTWOS model run documented by MMR-50072, and identified as MMR-50072-after-ax102-
8.1-8.3r1-2015-10-13-at-21-35-10. This model run begins with the Best-Basis Inventory as downloaded by the Tank Waste
Information Network System (TWINS) in 3Q FY 2015, adjusted for historical waste transfers, retrievals, and campaigns; and
reconciled as needed against actual tank waste level surface readings, also reported by TWINS in 3Q FY 2015.
3
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
EXHIBIT D
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
RIVER PROTECTION PROJECT SYSTEM PLAN
Retrieve and Treat Hanford’s Tank Waste and Close the Tank Farms to Protect the Columbia River
Approved for Public Release; Further Dissemination Unlimited
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page i
River Protection Project System Plan
Date Published:
October 2014
P.O. Box 450 Richland, Washington 99352
Release Approval Date
By GE Bratton at 2:24 pm, Nov 05, 2014
Approved for Public Release; Further Dissemination Unlimited
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page ii
DISCLAIMERS
Some of the activities described herein may be subject to the analysis required by the National Environmental Policy Act, 42 USC §4321, et seq. They are included within this document for planning purposes only, not for decisional purposes.
System Plan, Rev. 7 is being submitted in accordance with Hanford Federal Facility Agreement
and Consent Order (HFFACO, Ecology et al. 1989) milestone M-062-40 and describes the disposition of all tank waste managed by the U.S. Department of Energy (DOE), Office of River Protection (ORP), including the retrieval of tanks not addressed by the Consent Decree in State of Washington v. Dept. of Energy, Case No. 08-5085-FVS (E.D. WA, October 25, 2010) and the completion of the treatment mission as depicted in the five scenarios selected by Washington State Department of Ecology (Ecology). These five scenarios were selected and defined solely by Ecology without modification by DOE. ORP elected to not select or define scenarios for evaluation in System Plan, Rev. 7. In comparison to System Plans previously submitted by DOE both prior to and after implementation of HFFACO milestone M-062-40, this System Plan, Rev. 7 is unique in that a current baseline was not evaluated.
The five presented cases selected and defined by Ecology for evaluation in System Plan, Rev. 7 are all what-if cases with outcomes that are based on certain key assumptions approved by Ecology, do not reflect the current status of ORP’s mission, and do not reflect a complete and adequate understanding of assumptions of facility interim and startup dates associated with resolution of technical issues with the Waste Treatment and Immobilization Plant and the need to establish new or revised baselines for key project components.
TRADEMARK DISCLAIMER
Reference herein to any specific commercial product, process, or service by trade name, trademark, manufacturer, or otherwise, does not necessarily constitute or imply its endorsement, recommendation, or favoring by the United States government or any agency thereof or its contractors or subcontractors.
Oracle, Primavera P6®, and Java are registered trademarks of Oracle and/or its affiliates. Other names may be trademarks of their respective owners.
Scientific or technical information is available to United States government and United States government contractor personnel through the Office of Scientific and Technical Information, known as OSTI. It is available to others through the National Technical Information Service.
This report has been reproduced from the best available copy.
Printed in the United States of America.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page iv
This page intentionally left blank.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page v
HISTORY SHEET
Revision Date Reason for Revision Revised By
0 August 2002 Initial issuance. K.R. Wells
1 April 2003 Reflect proposed changes and additions to the waste treatment processes and facilities to accelerate mission completion.
K.R. Wells
2 September 2003 Reflect a Target Case, which depicts the mission based on how the U.S. Department of Energy, Office of River Protection expects the Waste Treatment and Immobilization Plant (WTP) to perform and a Stretch Case, which depicts the mission if significant increases in both WTP and non-WTP low-activity waste (LAW) treatment performance are realized.
P.J. Certa
3 May 2008 Reflects a Reference Case, which depicts a mission scenario based on beginning full WTP operations in 2019, in conjunction with supplemental LAW treatment and supplemental transuranic packaging. Generally aligned with key features of the fiscal year 2007 baseline.
P.J. Certa
3A July 2008 Incorporate comments from the Office of Management and Budget.
P.J. Certa
4 September 2009 Reflects a Baseline Case consistent with the Performance Management Baseline. An Initial Planning Case consistent with the interim and draft Performance Measurement Baseline under the new Tank Operations Contract and an Unconstrained Case are used to evaluate program impacts against assumed success criteria.
M.N. Wells
5 November 2010 Reflects a Baseline Case, which provides the technical basis for the Performance Measurement Baseline, and a Sensitivity Case in which all potential transuranic tank waste is processed through WTP.
M.N. Wells
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page vi
Revision Date Reason for Revision Revised By
6 October 2011 Reflects a Baseline Case, which provides the technical basis for the Performance Measurement Baseline, and nine additional scenarios jointly selected by the Office of River Protection and the Washington State Department of Ecology to meet the requirements of Hanford Federal Facility Agreement and Consent Order (Ecology et al. 1989) milestone M-062-40.
M.N. Wells
7 October 2014 Utilizes the Baseline Case originally presented in System Plan, Rev. 6, plus five additional scenarios selected and defined by the Washington State Department of Ecology only, in order to meet the requirements of Hanford Federal Facility Agreement and Consent Order milestone M-062-40D.
M.N. Wells
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page ES-1
EXECUTIVE SUMMARY
The U.S. Department of Energy (DOE), Office of River Protection (ORP), manages the River Protection Project. The mission of the River Protection Project is to retrieve and treat Hanford’s tank waste and close the tank farms to protect the Columbia River. As a result, the Office of River Protection is responsible for the retrieval, treatment, and disposal of approximately 56 million gallons1 of radioactive waste contained in the Hanford Site waste tanks and closure of all tanks and the associated equipment.
System Plan, Rev. 7 is being submitted in accordance with Hanford Federal Facility Agreement
and Consent Order (HFFACO, Ecology et al. 1989) milestone M-062-40 and describes the disposition of all tank waste managed by the U.S. Department of Energy (DOE), Office of River Protection (ORP), including the retrieval of tanks not addressed by the Consent Decree in State of Washington v. Dept. of Energy, Case No. 08-5085-FVS (E.D. WA, October 25, 2010) and the completion of the treatment mission as depicted in the five scenarios selected by Washington State Department of Ecology (Ecology). These five scenarios were selected and defined solely by Ecology without modification by DOE. ORP elected to not select or define scenarios for evaluation in System Plan, Rev. 7. In comparison to System Plans previously submitted by DOE both prior to and after implementation of HFFACO milestone M-062-40, this System Plan, Rev. 7 is unique in that a current baseline was not evaluated.
The five presented cases selected and defined by Ecology for evaluation in System Plan, Rev. 7 are all what-if cases with outcomes that are based on certain key assumptions approved by Ecology, do not reflect the current status of ORP’s mission, and do not reflect a complete and adequate understanding of assumptions of facility interim and startup dates associated with resolution of technical issues with the Waste Treatment and Immobilization Plant and the need to establish new or revised baselines for key project components.
Background
The ORP strategy2 for completing the River Protection Project mission involves a number of interrelated activities and facilities. ORP will reduce risk to the environment posed by tank wastes by:
• Retrieving the waste from the single-shell tanks and delivering the waste to the WTP.
• Constructing and operating WTP, which includes a Pretreatment Facility; a Low-Activity Waste Facility; a High-Level Waste Facility; an Analytical Laboratory; and the balance of facilities, which provides supporting services, like utilities.
• Evaluating supplemental treatment capability, which analysis includes for purposes of this SP7 a second low-activity waste vitrification facility, as set forth in the State’s defined scenarios, to treat the remainder of the low-activity waste fraction not immobilized by the Low-Activity Waste Facility.
1 Refer to HNF-EP-0182, Waste Tank Summary Report for Month Ending April 30, 2014, Rev. 316. The total volume of tank waste fluctuates over time because water and chemicals may be added to tanks to facilitate waste retrieval processes; water is also removed by evaporation. 2 Some of the activities described herein may be subject to analysis required by the National Environmental Policy
Act of 1969 and are included in this document for planning purposes only, not for decisional purposes.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15
ORP-11242 Revision 7
Page ES-2
• Developing and deploying supplemental pretreatment capability.
• Developing and deploying treatment and packaging capability for potential transuranic tank waste, followed by interim storage at the Central Waste Complex pending determination of the final disposal pathway.
• Deploying interim storage capacity for the immobilized high-level waste pending determination of the final disposal pathway.3
• Disposing of packaged immobilized low-activity waste onsite at the Integrated Disposal Facility.
• Closing the single-shell and double-shell tank farms, ancillary facilities, and associated waste management and treatment facilities.
• Optimizing the overall mission with resolution of technical and programmatic uncertainties; upgrading the tank farms to provide a steady, well-balanced feed to WTP.
As opportunities arise to improve project and plant performance or reduce risk, changes are made to the Tank Operations Contract or the WTP Contract, as appropriate. Implementation of these changes is managed through the Baseline Change Request process.
The HFFACO4, also known as the Tri-Party Agreement, was signed by DOE, Ecology, and the U.S. Environmental Protection Agency in 1989. This comprehensive agreement includes milestones for regulatory compliance and environmental remediation. Between 2007 and 2009, DOE and Ecology negotiated new and revised HFFACO milestones, along with new milestones in a Consent Decree5 filed in federal district court. That Consent Decree resolved a lawsuit filed in 2008 by the State of Washington against DOE. Both the Consent Decree and HFFACO changes became effective on October 25, 2010, the date the Consent Decree was entered into federal court. One of the new HFFACO milestones, M-062-40, requires ORP to prepare a System Plan every 3 years.
Purpose
This revision of the River Protection Project System Plan (Rev. 7) is an update to the previous revision (Rev. 6) issued in October 2011. SP7 satisfies the requirements of HFFACO milestone M-062-40D. The Office of River Protection’s Baseline Case is the same case as was previously used in System Plan, Rev. 6. For purposes of SP7, the term Baseline Case refers to a reference case that is modified with additional Ecology-defined assumptions to define additional scenarios. SP7 does not form the technical basis for either the near-term baseline or the out-year planning estimate range because of uncertainties in the baseline as a result of currently unresolved technical issues at WTP. Additionally, ORP elected not to select or define any cases for this SP7.
3 Office of River Protection planning, with regard to final disposal of immobilized high-level waste, is subject to recognition of uncertainties with regard to an assumed, planned offsite geologic repository. 4 Ecology, EPA, and DOE, 1989, Hanford Federal Facility Agreement and Consent Order – Tri-Party Agreement, as amended, Washington State Department of Ecology, U.S. Environmental Protection Agency, and U.S. Department of Energy, Olympia, Washington. 5 Consent Decree, 2010, State of Washington v. DOE, Case No. 08-5085-FVS (October 25), Eastern District of Washington.
Case 2:08-cv-05085-RMP Document 196-3 Filed 11/13/15