Intralogistics - Packaging - Food Processing

Intralogistics - Packaging - Food Processing

Ref: 39466Date: 2021-11-13

To,AL RAIQA DATE FRUIT TRADING LLCMussaffah United Arab [email protected]

Subject: Quotation for Fully Electric Stacker with Power Steering & Rider Type

Dear Ismail /Mohammed,

We are pleased to enclose our detailed techno-commercial offer, based on your requirement.

Contents of the Quotation:

Commercial ProposalTerms & ConditionsTechnical Specifications

We hope the same is in line with your requirement. We shall gladly assist you in case you need any furtherclarification or information.

Best Regards,Praveen NPSales ManagerALE INTERNATIONAL LLCMobile: +971 55 201 9318Email: [email protected]

ATCOWORLD A Division of: ALE INTERNATIONAL LLCP3-A06-4, Empire Heights, Business Bay, Dubai, UAE; P.O. Box-17251

T: 04 2279283, F: 04 2279285, E: [email protected], W: www.atcoworld.com


COMMERCIAL PROPOSAL:

S. No. Description UnitPrice Qty Total Delivery

1 FULLY ELECTRIC STACKER WITHRIDER FOLDABLE PLATFORM

Product Code: ALES2062Brand: ATCOLIFTCapacity: 2TonMaximum Lifting Height: 6.2metersWithout Full Free LiftSuitable for open pallets only

AED 45,000/- 1 AED 45,000/- Stock Availableas on date

2 FULLY ELECTRIC STACKER WITHRIDER FOLDABLE PLATFORM

Product Code: ALMB2055Brand: ATCOLIFTCapacity: 2TonMaximum Lifting Height: 5.5metersWithout Full Free LiftSuitable for open pallets only

AED 36300/- 1 AED 36,300/- Stock availableas on date

3 3WHEELS ELECTRIC FORKLIFTSUITABLE FOR COLD STORE

Product Code: ALTKA15-45Brand: ATCOLIFTCapacity: 1.5TonMaximum Lifting Height: 4.5metersSuitable for open and closed palletsSide shift : IncludedOPS : Operator presence sensor includedTyres (Front & Rear) : Black Solid RubberWith Full Free Lift

AED 62000/- 1 AED 62,000/- Within 4 weeks

4

5




TERMS & CONDITIONS:

PriceIncludes Delivery & Installation within UAE.

VATAll prices quoted are exclusive of VATVAT charges will be extra, at actuals, as applicable by the UAE Government, for all deliveries made inside theUAE.

Payment50% advance balance before delivery.

Payment to be made in the name of: ALE INTERNATIONAL LLCALE INTERNATIONAL LLC Bank Details

BANK NAME Bank of Baroda

BANK BRANCH NAME Bur Dubai Main Branch

BANK ACCOUNT NUMBER 90010200030554

IBAN AE760110090010200030554

SWIFT CODE BARBAEAD

BANK CURRENCY AED

BANK ADDRESS BUR DUBAI, DUBAI, UNITED ARAB EMIRATES

DeliveryQuoted delivery time represents the best estimate of shipment. Seller is not liable for delay in delivery due tocauses & forces beyond its control. Seller is not liable for any losses incurred by the Buyer on account of delay indelivery from its side due to the above mentioned and this is well understood & accepted, while placing the order.

UnloadingThe Buyer has to manage the unloading at their site. The Buyer needs to provide forklift, crane and/or unskilledlabor if required, for unloading. The Buyer is responsible for any damage happening to the machines during theunloading process or thereafter.

InstallationFor Deliveries within UAE & Oman (Salalah & Remote Areas excluded):Onsite installation and training is included in the above price. Buyer needs to provide forklift, crane and/or unskilledlabor if required, during installation. In all instances, all recommended utilities like power supply, compressed air,fittings, wire pulling at the required places etc. has to be provided by the Buyer. For Packaging MachineryInstallations, The Buyer needs to provide for all raw material and packing material, during the installation andtraining process. The Seller is not responsible for any sizes/items that were not able to be tested, due to theirabsence during the installation process. The Buyer needs to have an operator with basic machine knowledge, towhom the training can be imparted. The Buyer needs to sign the daily activity reports of our engineers and the finalinstallation report, during & upon successful completion of installation.

ApprovalsBuyer, at its sole cost and expense, shall secure and maintain in effects all approvals, permits and licensesrequired by local authorities to undertake and complete the work related to the project as the case may be,




including without limitations Municipality approvals and No Objection Certificate (NOC) from Environment, Health &Safety (EHS) Authority. Buyer shall indemnify Seller against payment of the cost thereof and against any fines,penalty or delays that may be levied to failure to procure or to comply with such permits or license as well asremedial cost to cure violations thereof.

Site ConditionsThe site is assumed to be flat, clear and leveled. The Buyer will ensure that the site is free of any obstructions thatmay hinder the installation works and complete access to site will be granted to Seller technicians. The Buyer willensure that the projects main contractor and sub-contractors work in line with the schedule of the Seller incooperation and provide a safe work environment with required refreshment areas, drinking water, Electrical powerto operate the hand tools and adequate lighting to Seller and its sub-contractors at free of charge.

Warehouse Floor and Storage SpaceSeller has considered that floor slabs are capable of supporting the loads imposed by the equipment sold. Buyershall confirm same with its contractors.

It is assumed that the floor is flat with variation less than +/- 4mm between any two points An adequate area should be provided adjacent to the installation area for storing of materials, assembly ofthe rack component and tools

Exclusion of LiabilityUnder no circumstances shall the Seller be liable to the Buyer or any other party, for any type of damage, whetherthey are special, consequential, indirect, incidental, exemplary or punitive, whether such damages arise from orresult from a contractual breach, a guarantee, tort (including negligence) of strict liability or otherwise, and even ifthe contract fails to fulfil its essential purpose. Such damages include, but are not limited to, loss of profit orrevenue, loss of use of equipment or a piece of equipment, cost of replacement of equipment, facilities, time costsof stoppage, construction cost increases, reputational damage, Buyer loss, or any claim by Buyers orsubcontractors for such damages.

Ownership of MaterialNotwithstanding delivery of any product to the Buyer, ownership thereof shall remain vested with the Seller, untilthe final payment to the Seller has been cleared in full.

BreachSeller shall be entitled to suspend supplies of product to Buyer or installation work, should any credit limitenvisaged in the payment terms be exceeded. Should any amount payable by Buyer not be paid on the due datefor payment thereof or should Buyer otherwise breach or fail to comply with any term or condition of thisagreement, or should the Buyer be sequestrated or be placed under judicial management or in liquidation (whetherprovisional, final, voluntary or compulsory), or being the dissolution of a partnership prior to Seller having receivedfull payment of all monies owing by the Buyer to Seller in respect of any product, then in any such event andwithout prejudice, Seller shall be entitled:

To suspend performance of Seller obligations until such breach is rectified and/or all such monies havebeen paid or secured to the satisfaction of Seller To recover possession of and remove any product which has not been fully paid To cancel the applicable agreement and to retain all monies previously paid by Buyer to suspend anycredit facility granted to Buyer

ConfidentialityThis document contains proprietary and confidential information. All data submitted to the holder of this proposal isprovided in reliance upon its consent not to use or disclose any information contained herein except in the contextof its business dealings with Seller. The recipient of this document agrees to inform present and future employeeswho view or have access to its content of its confidential nature. The recipient agrees to instruct each employeethat they must not disclose any information concerning this document to others except to the extent that suchmatter are generally known to, and are available for use by, the public. The recipient also agrees not to duplicate or




distribute or permit others to duplicate or distribute any material contained herein without Seller's express writtenconsent.

Force MajeureSeller shall not be liable for failure to perform or for delay in performance due to fire, flood, strike or other labordifficulty, act of God, act of any governmental authority, riot, embargo, fuel or energy shortage, wrecks or delay intransportation, or due to any cause beyond its reasonable control. If any such event occurs, Seller may extenddelivery dates by a period of time necessary to overcome the effect of such delay, allocate available product orcancel any purchase order.

WarrantyAll the materials are guaranteed for manufacturing defects for a period of 12 months from the date of supply. Thefaulty part will be replaced free of cost during the period of the warranty. The cost of transport/courier of the newpart to be borne by the Buyer, in case outside UAE. The warranty shall not apply to normal wear and tear or in theevent our Product is damaged as a result of natural disaster, accident, misuse, abuse, neglect, inappropriatestorage, improper use of MHE, improper application, modification or repair or attachments to the product notapproved by us. Should any person, firm, or corporation other than us have, since the installation of our product,performed or attempted to perform any modification or repair to the product, then this warranty shall become nulland void.

ServiceAll service calls within the UAE & Oman (Salalah and remote areas excluded), will be attended to free of costduring the period of Warranty. Further to that the normal visit charges (AED 500 per hour) will apply. Alternativelythe Buyer can opt for our competitive and comprehensive Annual Maintenance Contracts (AMCs).

CancellationOnce the order is confirmed, the manufacturing of the machines is taken upon immediately. After this Seller cannotaccept any cancellation of order and the Seller cannot refund the advance amount to the buyer, under anycircumstances. This is acknowledged and accepted, while placing the order and this overrides all other terms &conditions, including those mentioned in the Buyer's purchase order.

Validity15days days from the date of this offer.

JurisdictionIn case if any disputes arise, and cannot be settled mutually, or in case of violation of contract by any party, thejurisdiction of the courts of Dubai, UAE will be applicable.

ImagesThe attached picture(s) is/are for representation purpose and aim to provide the best possible depiction of theactual machine supplied. The color and/or look of the actual machine may vary from what is shown in the image.

Powered by TCPDF (www.tcpdf.org)



http://www.tcpdf.org

ELECTRIC STACKERS RIDER (2000KG 6200MM) ALES2062TECHNICALDATA

char

acte

rist

ics

1.1 Model ALES 2062

1.2 Mast Type Triplex1.3 Mast profile H model1.4 Type of drive Full Electric1.5 Operator type Rider1.6 Q Capacity kg 20001.7 C Load center mm 6001.8 Y Wheel base mm 1395

1.9 Electric powersteering(EPS) optional

wei

ght 2.1 Service weight without

battery kg 1320

2.2 Service weight withbattery kg 1530

whe

el

3.1 wheel type PU3.2 b2 Size of front wheels mm 783.3 b3 Size of rear wheels mm 1243.4 b4 Size of drive wheels mm 2303.5 Wheels quantity pcs 1/2/4

chas

sis

4.1 h1 Mast lower height 26854.2 h4 Mast extend height mm 6895

4.3 l1Overall length (withplatform) mm 2615

4.4 Overall length (withoutplatform) mm 2067

4.5 b1Ib2 Rear body width mm 960

4.6 l2 Rear body length mm 585

4.7 B Overall width mm990 (h4≥5000mm

:1100mm)

4.8 H5 Height of tiller arm in driveposition min./max. mm 1030-1200

4.9 b8 Rear body height mm 830

spec

ifica

tions

5.1 b7 Clearance mm 405.2 Slell Fork length mm 11505.3 b5 Overall fork width mm 540/560/580/680

5.4 WaMin.Turning radius(with platform) mm 2100

5.41 WaMin.Turning radius(without platform) mm 1580

5.5 b6 Lowered height of fork mm 905.6 E Fork width mm 1855.7 h3 Lifting height mm 62005.8 H Freelift height mm 2150

5.11Aisle width (800*1200mmpallet): horizontal/vertical(with platform)

mm 2991

5.11Aisle width (800*1200mmpallet): horizontal/vertical(without platform)

mm 2471

5.12

Aisle width (1000*1200mmpallet): horizontal/vertical(with platform) mm 3053

5.12

Aisle width(1000*1200mm pallet):horizontal/vertical(without platform)

mm 2533

perf

orm

ance

6.1 Travel speedladen km/h 5unladen km/h 5.3

6.2 Lift speedladen mm/s 58unladen mm/s 148

6.3 lower speedladen mm/s 145unladen mm/s 80

6.4 Gradeabilityladen % 5unladen % 7

driv

ing

syst

em

7.1 Brake type electromagnetic7.1 Drive motor kw 1.5(vertical motor+EPS)7.2 Lift motor kw 3

7.3 Battery voltage/capacity V/Ah 24V150/210/280/340Ah

7.4 Battery weight kg 2107.5 battery size mm 790×210×5767.6 control system 1230-2402(CURTIS)

ELECTRIC STACKER -RIDER (2000KG 5500MM) – ALMB2055 WITHOUT FFL

Electric pallet stacker series ALMB (Rider type)

Standard1.1 Manufacturer ATCOLIFT1.2 Model ALMB20-551.3 Power type Battery1.4 Driving style Stand on1.5 Rated load Q(kg) 20001.6 Load center C(mm) 6001.7 Front overhang x(mm) 7121.8 Wheelbase y(mm) 1390Weights2.1 Service Weight(incl.battery) kg 1550

2.2 Bridge load at full load, drive side/load-bearing side kg 1416/2082

2.3 Bridge load at unload, drive side/load-bearing side kg 1079/401

Wheels3.1 wheel type PU3.2 Load wheel size mm Φ80×703.3 Drive wheel size mm Φ230×753.4 Stabilizing wheel size mm Φ125×50

3.5 Number of wheels,front/rear(x=drivewheel) 4/1x+2

3.6 Wheel base,drive-bearing side b10(mm) 630/770 3

3.7 Wheel base, load-bearing side b11(mm) 490/380 3

Size4.1 Mast closed height h1(mm) 24304.2 Free lift height h2(mm) /4.3 Lift height h3(mm) 55004.4 Mast extended height h4(mm) 60404.5 Handle height(min/max) h14(mm) 1100/1390 1

4.6 Minimum height of fork surface h13(mm) 904.7 Overall length,Pedal retracted l1(mm) 2130 2

4.8 Overall width b1/b2(mm) 850/1000 3

4.9 Fork size l/e/s(mm) 1150/190/564.10 Fork outside width b5(mm) 680/570 3

4.11 Mast ground clearance m1(mm) 30

4.12 Aisle width (pallet 1000x1200)Load centerC500mm Ast(mm) 2490

4.13 Right-angle stacking aisle width (pallet800x1200)Load center C600mm Ast(mm) 2450

4.14 Turning radius,Pedal retracted Wa(mm) 1655 2

Function5.1 Driving speed, load/unloaded km/h 5.0/6.05.2 Lifting speed,load/unloaded mm/s 85/1305.3 Lowering speed,load/unload mm/s 95/100

5.4 Maximum climbing ability, load/unloaded(S2-5min) %(tanθ ) ≤6/≤8

5.5 Braking method ElectromagneticDrive6.1 Drive motor power (S2-60min) kw 1.56.2 Lift motor power, (S3-15%) kw 36.3 Battery, voltage/rated capacity V/Ah 24/280*

6.4 Battery weight kg 2006.5 steering system Electronic steering 4

Others7.1 Battery replacement method Side pull

7.2 Mast series Double cylinderstriplex mast

PRODUCT SIZE LOAD CHART

ELECTRIC FORKLIFT TRUCK – 1.5 Ton, 3 Wheel Rear Drive, Lift 4500 mm The truck complies with the relevant EU guideline (CE) for industrial trucks

Brand : ATCO LIFT

Basic capacity : 1500 kg @ 500mm Load Center up to 3000 mm height (w/o side shift) Residual capacity : 600 kg @ 500mm Load Center at 4500 mm height (w/o side shift) Operation Control : Hydraulic leaver Type

Drive Power : Electric Driven

Drive Motor : 24V / 2.3 kw/h (Rear driven)

Drive Speed : 6 / 7 km / hr (Laden / Unladen)

Lift Motor : 24V / 3.5 kw/h

Lift height : 4500 mm, 3-Stage Mast with Free Lift Collapsed height : 2100 mm (Door height please check) Free Lift : 600 mm Extended Mast Height: 5180 mm Tilt : 20 / 40 Forward / Backward Fork length : 1220 mm

Tyres (Front & Rear) : Black Solid Rubber

Gradeability : 8 / 10 (Laden / Unladen) Battery : 24V / 480Ah Charger : Included

Side shift : Included OPS : Operator presence sensor included

Note: Lift capacity reduces depending on load’s center of gravity and lifting height. Subtract 300 kg with side shifter.

Equipped with: LED Head Light, Reverse alarm, Suspension adjustable seat, Beacon Light, Load Back Rest, Auto

battery water filling system. OPS-Operator presence system.

Warranty: 1 Year or 2000 Hrs whichever comes first. Refer our standard warranty Terms.

Model : ALTKA15-45

Documents

Intralogistics - Packaging - Food Processing