Upload
william-f-zachmann
View
133
Download
0
Tags:
Embed Size (px)
Citation preview
Volume 30, Issue 26, June 30, 2010
The CentralRegisterPublished by: The Secretary of the Commonwealth, William Francis Galvin
CENTRAL REGISTERPublished weekly by William Francis Galvin, Secretary of the Commonwealth
Volume 30, Issue 26, June 30, 2010
DESIGNER SERVICESRequest for Proposals 1
GENERAL CONTRACTSInvitation to Bid 7
CONTRACTORS OBTAINING PLANS/SPECIFICATIONS 63
CONTRACT AWARDS 74
LEASE, RENTAL, SALE, PURCHASE, ACQUISITION OR DISPOSITION OF REAL PROPERTY
Notice of Proposed Disposition of Real Property 81Office of Lease Management 82Groundwater Discharge Permit -
LIST OF DEBARRED CONTRACTORSDCAM 84Attorney General 85
DEPARTMENT OF INDUSTRIAL ACCIDENTS DEBARMENT LIST 88
LIST OF DECERTIFIED CONTRACTORSDCAM 89
SUPPLIER DIVERSITY OFFICE ( Formerly SOMWBA) -
The Central Register is a state publication of public contracting opportunities, contract awardsand related information received by the Secretary of the Commonwealth under the provisions ofM.G.L. c. 9, § 20A.
William Francis Galvin Secretary of the Commonwealth
STATE BOOKSTORE State House, Room 116
Boston, MA 02133 (617) 727-2834
CENTRAL REGISTER SUBSCRIPTION INFORMATION
The Central Register is available in electronic form only.
The total subscription price is $100 per year.
You may subscribe to this publication on the following website:
http://www.sec.state.ma.us/PublicationSubscriptionPublic/Login.aspx
Please feel free to contact the State Bookstore with any questions that you may have regarding your subscription.
Phone: (617) 727-2834 Email: [email protected]
** State Agencies Only** CHECKS WILL NOT BE ACCEPTED FROM STATE AGENCIES.
State agencies are required to use the IE/ITI system. State agencies must complete the following information in order for their subscription to be processed.
DEPT. CODE (3 letters): _________________________________ORG. # (4 numbers): ____________________________________________ AMOUNT TO BE ENCUMBERED: $___________________________________________ AGENCY NAME: ___________________________________________________________________________________________________ CONTACT NAME: __________________________________________________________________________________________________ ADDRESS: ________________________________________________________________________________________________________ PHONE:__________________________________ CONTACT EMAIL:________________________________________________________
CENTRAL REGISTER - DESIGNER SERVICESPublic projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline.CR-1
AGENCY:Bedford, Town of Public Schools101 McMahon Rd.Bedford, MA 01821
Marcia Pyles
PHONE: 781-275-5290
PROJECT: Lane School Energy Management System Upgrade Project.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: BEDLNEMS10
ADDITIONAL INFORMATION
FAX: 781-275-8429
Designer's Fee: Negotiated Estimated Construction Cost: $150,000.
SCOPE: Upgrade existing Network 8000 system with next generation IA series components.
BRIEFING SESSION:
DEADLINE FOR APPLICATION FORM:7/15/10 @ 2:00 P.M.
Time Period for Completed Project:12/31/10
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: 6/30/10
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
AGENCY:Duxbury, Town of Public Safety Building Committee878 Tremont St.Duxbury, MA 02332
Scott J. Lambiase, Director of Inspectional Services
PHONE: 781-934-1100
PROJECT: The Public Safety Building Committee requests proposals for project management services for the renovation of the existing fire station.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
ADDITIONAL INFORMATION
FAX: 781-934-1118
Designer's Fee: Negotiated Estimated Construction Cost: $4.5 Million
SCOPE:
BRIEFING SESSION:
DEADLINE FOR APPLICATION FORM:7/14/10 @ 3:00 P.M.
Time Period for Completed Project:
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY:
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
1
CENTRAL REGISTER - DESIGNER SERVICESPublic projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline.CR-1
AGENCY:Duxbury, Town ofLocal Housing Partnershipc/o Planning Department878 Tremont St.Duxbury, MA 02332
Thomas A. Broadrick, AICP, Planning Director
PHONE: 781-934-1100
PROJECT: The Duxbury Local Housing Partnership is seeking proposals for qualified architectural, landscape architecture, and engineering consultants to provide design plans and specifications for two lots with affordable housing to be constructed on Franklin Street in Duxbury.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
ADDITIONAL INFORMATION
FAX: 781-934-1137
Designer's Fee: Negotiated Estimated Construction Cost: $300,000
SCOPE:
BRIEFING SESSION: 7/6/10 at 1:00 P.M.
DEADLINE FOR APPLICATION FORM:7/19/10 @ 4:00 P.M.
Time Period for Completed Project:
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY:
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
AGENCY:Foxborough, Town of Boyden Library Board of Trustees10 Bird St.Foxborough, MA 02035
Jerry M. Cirillo, Library Director
PHONE: 508-543-1261
PROJECT: Request for the services of a qualified "Owner's Project Manager" as defined in M.G.L. c. 149, § 44A½ and as further defined by the provisions of a Request For Services for the design, repair, renovation and/or expansion of the Boyden Library.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: 2010-LIB
ADDITIONAL INFORMATION
FAX: 508-543-1193
Designer's Fee: Negotiated Estimated Construction Cost: $8.9 Million
SCOPE: Provide Project Management services for the design, repair, renovation and/or expansion of the Boyden Library.
BRIEFING SESSION: 7/6/10 at 7:00 P.M. at the above agency address.
DEADLINE FOR APPLICATION FORM:7/14/10 @ 1:00 P.M.
Time Period for Completed Project:Up To 24 - Months
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: 6/23/10
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
2
CENTRAL REGISTER - DESIGNER SERVICESPublic projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline.CR-1
AGENCY:Hubbardston, Town ofOffices of Town Clerk, Town Administrator and LibraryP.O. Box 2067-7A Main St.Hubbardston, MA 01452
Debra A. Roussel
PHONE: 978-928-1400 ext. 200
PROJECT: Jonas G. Clark Library Building Historical Preservation and Architectural Services Project.
Copies of previous studies and other relevant documents will be available for review at the briefing session. Minimum Requirements: Current State/National certification; Completion of five similar projects; $1 Million minimum professional liability insurance; Staff or sub-contractors, five years related experience.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
ADDITIONAL INFORMATION
FAX: 978-928-3392
Designer's Fee: Negotiated NTE $10,000Estimated Construction Cost:
SCOPE: The Town of Hubbardston is seeking a preservation survey to evaluate existing electrical, plumbing and heating systems and future use of the Jonas G. Clark Library building.
BRIEFING SESSION: 7/23/10 (Mandatory)
DEADLINE FOR APPLICATION FORM:8/23/10 @ 5:00 P.M.
Time Period for Completed Project:120 - Days
CONTRACT INFORMATION:
Preservationist
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: 6/30/10 at the above agency address or by email to [email protected]
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
AGENCY:Lincoln, Town of Board of Selectmen16 Lincoln Rd.Lincoln MA 01773
Anita Scheipers
PHONE: 781-259-2603
PROJECT: Town Offices Building Feasibility Study (with possible continuation of work for full design, construction documents and construction oversight if funding approved).
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
ADDITIONAL INFORMATION
FAX:
Designer's Fee: Negotiated Estimated Construction Cost:
SCOPE:
BRIEFING SESSION: 7/7/10 at 10:00 A.M.
DEADLINE FOR APPLICATION FORM:7/16/10 @ 10:00 A.M.
Time Period for Completed Project:
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: Office of the Town Administrator at the above agency address, 781-259-2603 or electronically upon request.
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
3
CENTRAL REGISTER - DESIGNER SERVICESPublic projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline.CR-1
AGENCY:New Bedford, City ofHousing Authority (NBHA)Modernization Office725 Pleasant St.New Bedford, MA 02740
Anne Shoemaker
PHONE: 508-997-4852
PROJECT: Energy Engineering Design Services for Bay Village for co-generation system that will be located at Bay Village but heat/hot water to be used off-site. Electricity to be used at Bay Village.
The time for design and construction documents is 21 days. Only firms that can meet that deadline should respond.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: NBHA #168
ADDITIONAL INFORMATION
FAX: 508-997-4825
Designer's Fee: Set Fee $170,000.Estimated Construction Cost: $1,200,000.
SCOPE: Design and construction documents for co-generation system at Bay Village with heat/hot water to be piped off-site. Scope to include design and plans/specs for co-gen including all piping, electrical work, etc.
BRIEFING SESSION:
DEADLINE FOR APPLICATION FORM:7/16/10 @ 4:30 P.M.
Time Period for Completed Project:21 - Days (Design), 1 - Year (Construction)
CONTRACT INFORMATION:
Energy Engineer
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: 6/30/10 in writing, mailed or faxed to NBHA.
EMAIL:
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
AGENCY:Plymouth, Town of 11 Lincoln St.Plymouth, MA 02360
Pamela D. Hagler, Procurement Officer
PHONE: 508-747-1620 ext. 210
PROJECT: OPM services for replacement of 201,000 square foot roof at the Plymouth Community Intermediate School (PCIS), 117 Long Pond Rd., Plymouth.
Please check the Town's website for updated information at www.plymouth-ma.gov, following the links to Town Departments, Procurement, Current Bids.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: 21019
ADDITIONAL INFORMATION
FAX: 508-830-4133
Designer's Fee: Negotiated Estimated Construction Cost: $5,500,000
SCOPE: Project oversight, design assistance, aide in developing bid and contract documents, bid assistance, supervise and inspect installation, administer final "punch list" and provide complete turnover and training package.
BRIEFING SESSION:
DEADLINE FOR APPLICATION FORM:7/15/10 @ 4:00 P.M.
Time Period for Completed Project:2 - Years
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: 7/1/10
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
4
CENTRAL REGISTER - DESIGNER SERVICESPublic projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline.CR-1
AGENCY:Stoneham, Town of ***CANCELLED***Public SchoolsSchool Building Committee149 Franklin St.Stoneham, MA 02180
Anthony DiCologero
PHONE: 781-279-3802 ext. 304
PROJECT: The Town of Stoneham is seeking the services of a qualified Owner’s Project Manager (OPM) as defined in M.G.L. c. 149, § 44A½ to provide Project Management Services for the design, construction, addition to and/or renovation of the Stoneham Middle School in Stoneham. Subject to Mass. School Building Authority (MSBA) approval and subject to funding authorized by the Town of Stoneham, the OPM contract may be amended to include continued Project Management Services through design development, construction documents, bid and award, construction and final closeout of the potential Project. A potential approved Project may include renovation or renovation and addition of the existing School and/or new construction.
Respondent’s Project Director must be MCPPO certified. The Project Director be registered by the Commonwealth of Massachusetts as an architect or professional engineer with at least five years experience in the construction and supervision of construction and design of public buildings or, if not registered, the individual must have at least seven years said experience. Any questions must be submitted in writing to Dr. Les Olson, Superintendent of Schools at the above agency address or [email protected] by 7/1/10 at 4:00 P.M. All RFS responses are due by the deadline. Responses must be sealed and addressed to Dr. Les Olson, Superintendent of Schools, 149 Franklin St. Room 121C, Stoneham MA 02180, Attn: RFS Owner’s Project Manager.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: 20100623
ADDITIONAL INFORMATION
FAX:
Designer's Fee: Negotiated Estimated Construction Cost: $30,000,000 - $50,000,000
SCOPE: Estimates of the duration of the phases of an approved project are: Feasibility Study/Schematic Design Phase, months 1-12; Design Development/Construction Documents/Bidding Phase, months 13-30; Construction Phase, months 31-58.
BRIEFING SESSION: Voluntary informational meeting/site visit: 6/29/10 at 10:00 A.M. at Stoneham Middle School, 101 Central St., Stoneham.
DEADLINE FOR APPLICATION FORM:7/7/10 @ 10:00 A.M.
Time Period for Completed Project:58 - Months
CONTRACT INFORMATION:
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: 6/23/10 at 9:00 A.M. from Anthony DiCologero, Administrator of School Finance at the above agency address, [email protected] or 781-279-3802
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
5
CENTRAL REGISTER - DESIGNER SERVICESPublic projects where the construction cost is estimated to exceed $100,000. Published two weeks prior to application deadline.CR-1
AGENCY:Taunton, City ofMunicipal Airport CommissionTaunton Municipal AirportP.O. Box 441Westcoat Drive
Mr. Daniel Raposa, Airport Manager
PHONE: 508-821-2973
PROJECT: Projects in the three year period may include, but are not limited to, the following: Perform Environmental Assessment of Future Airport Development; Land Acquisition; Install Water Main Along Westcoat Drive; Install Supplemental Windcones; Site Development for Hangar Complex; Rehab Runway 4-22 and Construct Enhanced Safety Areas; Construct Taxiway to Runway 4-22; Equipment Purchase; Construct Access Road to West Side of Airport and Install Power/Lighting Along Road; Install Airport Security Enhancements; Other projects as deemed necessary.
Firms will be judged in accordance with FAA Advisory Circular 150/5100-14D, Chapter 2, Paragraphs 7a through 7l. The top three firms will be invited to appear for presentations and interviews.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
ADDITIONAL INFORMATION
FAX: 508-821-3723
Designer's Fee: Negotiated Estimated Construction Cost:
SCOPE: Seeking to engage a qualified consulting firm(s) to perform airport planning, design, construction engineering, environmental and administrative functions associated with all phases of airport development and improvements.
BRIEFING SESSION:
DEADLINE FOR APPLICATION FORM:7/28/10 @ 3:00 P.M.
Time Period for Completed Project:10/1/10 - 9/30/13
CONTRACT INFORMATION:
Environmental, Construction Inspection
SPECIFIC DESIGNER SERVICES
Specify
PROJECT PROGRAM AVAILABILITY: By contacting the Airport Manager’s office at 508-821-2973.
EMAIL: [email protected]
Architect PlannerLandscape Architect ProgrammerEngineer Land Surveyor Space Planner Project Manager
Other
6
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Abington, Town ofWater Department96 East Water St.Rockland, MA 02370
Above agency address, 7/1/10 at 9:00 A.M.
PHONE: 781-878-0901CONTACT INFORMATION
PROJECT NUMBER: A11-01
FAX: 781-982-8332
PROJECT:Provide Excavation Services.
ESTIMATED COST: $50,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 11:00 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Daniel F. Callahan EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Alford, Town of Highway Garage5 Alford Center Rd.Alford, MA 01230-8999
Above agency address or by calling 413-528-6327.
PHONE: 413-528-6327CONTACT INFORMATION
PROJECT NUMBER: 1
FAX: 413-528-4581
PROJECT:Approximately 950 tons of Bituminous Concrete in place with tack coat.
ESTIMATED COST: $70,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 9:00 A.M.
ADDITIONAL INFORMATION Bids due at the Selectmen's Office by the deadline.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Monty Green EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
7
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Amherst, Town of 4 Boltwood DriveAmherst, MA 01002
Roy S. Brown Architects, 85 Chilson Rd., Amherst, MA 01002, 6/30/10 after 2:00 P.M.
PHONE: 413-596-2360CONTACT INFORMATION
PROJECT NUMBER: 10-06-02
FAX: 413-596-2360
PROJECT:Interior Renovations at South Amherst School, 1001 South East St., Amherst.
ESTIMATED COST: $55,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Project walk-through: 7/6/10 at 10:00 A.M. Plandeposit is $50, payable to Roy Brown. Plan mailing fee is $20, payable to Roy Brown. Plans and Specs mailed by USPS only.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Roy S. Brown Architects EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Andover, Town ofCentral Purchasing Office36 Bartlet St.Andover, MA 01810
Above agency address, 6/30/10 after 9:00 A.M.
PHONE: 978-623-8216CONTACT INFORMATION
PROJECT NUMBER: Bid No. 001/07-10/185
FAX: 978-623-8240
PROJECT:Andover High School Resilient Track Resurfacing and Repair.
ESTIMATED COST: $50,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Elaine M. Shola, Purchasing Agent EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
8
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Andover, Town ofCentral Purchasing Office36 Bartlet St.Andover, MA 01810
Above agency address, 6/30/10 after 10:00 A.M.
PHONE: 978-623-8216CONTACT INFORMATION
PROJECT NUMBER: Bid No. 017/04-10/185
FAX: 978-623-8240
PROJECT:Roof Replacement to High Plain Elementary and Wood Hill Middle Schools, Andover.
ESTIMATED COST: $850,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Masonry
SUB BID DEADLINE: 7/15/10 @ 11:00 A.M. GENERAL BID DEADLINE: 7/22/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid walk-through: 7/7/10 at 2:00 P.M. at the Wood Hill Middle School, Main Entrance, 11 Cross St., Andover. A refundable deposit of $100.00 is required for Bid Documents and/or Bid documents can be mailed for an additional non-refundable fee of $60.00. Checks are to be made payable to the Town of Andover.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Elaine M. Shola, Purchasing Agent EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Attleboro, City ofPurchasing OfficeGovernment Center77 Park St.Attleboro, MA 02703
Above agency address, Monday - Friday, 8:30 A.M. - 4:00 P.M.
PHONE: 508-223-2222 ext. 3262CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-222-3046
PROJECT:Removal of Underground fuel storage tanks and installation and upgrade of above ground storage tanks at the following pump stations: George Ide Drive, Rutledge Drive and West St. in Attleboro.
ESTIMATED COST:
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Joan Ouellette EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
9
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Barnstable, Town of 230 South St.Hyannis, MA 02601
On the Town of Barnstable website, Bid & RFP System at www.town.barnstable.ma.us.
PHONE: 508-862-4741CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-862-4717
PROJECT:Barnstable High School Interior Painting project, 744 West Main St., Hyannis.
ESTIMATED COST: $60,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/8/10 at 10:00 A.M. at the site.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Johanna Boucher EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Billerica, Town of ***SUB-BIDS ONLY***Parker School Permanent Public Building Committee365 Boston Rd.Billerica, MA 01821
Online at www.jlaprojects.com, 6/30/10 at 9:00 A.M.
PHONE: 617-744-3120CONTACT INFORMATION
PROJECT NUMBER: 08-01
FAX: 617-924-3800
PROJECT:RFQ for Elevator Subcontractor pre-qualification for a new construction project of an 89,000 square foot elementary school in Billerica.
ESTIMATED COST: $90,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Elevator Subcontractor RFQ Only
SUB BID DEADLINE: 7/14/10 @ 11:00 A.M. GENERAL BID DEADLINE:
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Melissa Gagnon EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
10
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Boston, City ofHousing AuthorityProcurement Department52 Chauncy St.Boston, MA 02111
Above agency address or by email request to [email protected], 6/30/10.
PHONE: 617-988-4396CONTACT INFORMATION
PROJECT NUMBER: BHA 0518-01
FAX: 617-988-4292
PROJECT:Furnish all labor, materials and equipment to repair random cracks, remove tree roots fill and repair surface, clean all catch basins to city mains and resurface/re-coat playing areas on two bituminous concrete all-weather playing courts.
ESTIMATED COST: $24,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 12:00 P.M.
ADDITIONAL INFORMATION Site visit: 7/8/10 at 10:00 A.M. at the M.E. McCormack Housing Development, Veterans Park, Kemp St. and Devine St., South Boston.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Jerry Curreri, Project Manager EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Boston, City ofPublic SchoolsDepartment of Planning and Engineering26 Court St. 2nd FloorBoston, MA 02108
Above agency address, 7/7/10.
PHONE: 617-635-9125CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-635-9252
PROJECT:Masonry and Waterproofing at the Edward Everett Elementary School, 71 Pleasant St., Dorchester.
ESTIMATED COST: $100,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 12:00 P.M.
ADDITIONAL INFORMATION This project requires a DCAM Certificate in Masonry.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Virginia O'Brien EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
11
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Boston, City ofWater and Sewer Commission980 Harrison Ave.Boston, MA 02119
Above agency address, 6/30/10. Office Hours: Monday - Friday, 9:00 A.M. - 4:00 P.M.
PHONE: 617-989-7216CONTACT INFORMATION
PROJECT NUMBER: 10-201014
FAX:
PROJECT:Furnish and Install Approximately 1,060 Square Yards of Carpet Tile at the Commission Headquarters.
ESTIMATED COST: $49,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Mandatory Pre-bid Meeting: 7/8/10 at 11:00 A.M.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Eleni Vidalis EMAIL:
CONTRACTOR QUALIFICATION:
AGENCY:Boylston, Town of Board of Selectmen221 Main St.Boylston, MA 01505
Above agency address or by email request to [email protected], Monday - Thursday, 8:00 A.M. - 2:00 P.M.
PHONE: 508-869-2261CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:Type I Bituminous Concrete In Place.
ESTIMATED COST: $35,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Bids available electronically by request. Prevailing Wage rates apply.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Don Parker EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
12
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Bridgewater, Town of ***REVISED***Selectmen's Office25 South St.Bridgewater, MA 02324
Above agency address, 6/30/10. Office Hours: Monday - Thursday, 8:00 A.M. - 4:00 P.M.; Friday, 8:00 A.M. - 1:00 P.M.
PHONE: 978-750-9062 ext. 14CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:Exterior improvements including siding replacement, custom wood window replacement, EPDM roofing and painting. Minor interior improvements including plumbing, carpentry, doors and hardware.
ESTIMATED COST: $650,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Painting
SUB BID DEADLINE: 7/20/10 @ 2:00 P.M. GENERAL BID DEADLINE: 7/29/10 @ 2:00 P.M.
ADDITIONAL INFORMATION ***Pre-Bid Conference: 7/15/10 at 11:00 A.M. $50 deposit required for bid documents in the form of a check, payable to the Town of Bridgewater.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Linda Duntley, Gienapp Design Associates, LLC EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Bridgewater, Town of Office of SelectmenMemorial BuildingCentral SquareBridgewater, MA 02324
Above agency address, 6/30/10. Office Hours: Monday - Thursday, 8:00 A.M. - 4:00 P.M.; Friday, 8:00 A.M. - 1:00 P.M.
PHONE: 617-482-7080CONTACT INFORMATION
PROJECT NUMBER: 2010069
FAX: 617-482-7417
PROJECT:Installation of traffic signal equipment, conduit, vehicle loop detectors, pavement markings and signage at the intersection of Pleasant St. and Prospect St.
ESTIMATED COST: $30,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 12:00 P.M.
ADDITIONAL INFORMATION Refundable deposit of $25.00 is required for each set of plans and specifications in the form of a certified check, treasurer's or cashier's check, payable to the Town of Bridgewater.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Robbie Burgess, P.E. EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
13
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Brockton, City of Building Department45 School St.Brockton, MA 02301
C.B.I. Consulting, Inc., 250 Dorchester Ave., Boston, MA 02127, 617-268-8977, 6/30/10.
PHONE: 508-580-7191CONTACT INFORMATION
PROJECT NUMBER: #BD 11-WM2
FAX:
PROJECT:Masonry Restoration and Window Replacement at the War Memorial Building.
ESTIMATED COST: $300,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Aluminum Windows, Glass & Glazing
SUB BID DEADLINE: 7/14/10 @ 1:00 P.M. GENERAL BID DEADLINE: 7/21/10 @ 1:00 P.M.
ADDITIONAL INFORMATION All prospective bidders are strongly encouraged to attend a pre-bid conference on 7/8/10 at 10:00 A.M. at the War Memorial Building., 156 West Elm St., Brockton. A $25.00 refundable document charge is required. Bid documents will be mailed upon receipt of an additional, non-refundable $25.00 check or money order. All checks or money orders must be made payable to CBI Consulting, Inc.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Michael Morris EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Cambridge, City ofHousing Authority166 Prospect St.Cambridge, MA 02139
Above agency address, 6/30/10 at 12:00 P.M.
PHONE: 617-520-6393CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-547-9821
PROJECT:Heating and Domestic Hot Water System Upgrades and Water Efficiency Improvements.
ESTIMATED COST: $440,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Plumbing
SUB BID DEADLINE: 7/14/10 @ 2:00 P.M. GENERAL BID DEADLINE: 7/26/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Site visits: 7/7/10 at 10:00 A.M. and 7/20/10 at 10:00 A.M. at the Management Office, 50 Churchill Ave., Cambridge. Please call for directions.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Carolyn Grassl EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
14
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave. Room 303Cambridge, MA 02139
Above agency address, 7/1/10. Office Hours: Monday, 8:30 A.M. - 8:00 P.M.; Tuesday - Thursday, 8:30 A.M. - 5:00 P.M.; Friday, 8:30 A.M. - 12:00 P.M.
PHONE: 617-349-4310CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-349-4008
PROJECT:HVAC Upgrades, Central Square Branch Library.
ESTIMATED COST: $600,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Electrical
SUB BID DEADLINE: 7/15/10 @ 2:00 P.M. GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid conference: 7/8/10 at 9:00 A.M. at the Central Square Branch Library, 45 Pearl St., Cambridge.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Cynthia H. Griffin EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave.Cambridge, MA 02139
Above agency address, 7/1/10. Office Hours: Monday, 8:30 A.M. - 8:00 P.M.; Tuesday - Thursday, 8:30 A.M. - 5:00 P.M.; Friday, 8:30 A.M. - 12:00 P.M.
PHONE: 617-349-4310CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-349-4008
PROJECT:Roof Repairs at Various City and School Buildings.
ESTIMATED COST: $125,000/Year (1 - Year)
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION This bid may be downloaded from the City's website at www.cambridgema.gov, following the links to Online Services, Current Bid List, Construction.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Cynthia H. Griffin EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
15
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave.Cambridge, MA 02139
Above agency address, 7/1/10. Office Hours: Monday, 8:30 A.M. - 8:00 P.M.; Tuesday - Thursday, 8:30 A.M. - 5:00 P.M.; Friday, 8:30 A.M. - 12:00 P.M.
PHONE: 617-349-4310CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-349-4008
PROJECT:Harvard Square Improvement Project, Contract 3.
ESTIMATED COST: $3,000,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid conference: 7/13/10 at 2:00 P.M. at the Public Works Department Conference Room, 147 Hampshire St., Cambridge.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Cynthia H. Griffin EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave.Cambridge, MA 02139
Above agency address, 7/1/10. Office Hours: Monday, 8:30 A.M. - 8:00 P.M.; Tuesday - Thursday, 8:30 A.M. - 5:00 P.M.; Friday, 8:30 A.M. - 12:00 P.M.
PHONE: 617-349-4310CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-349-4008
PROJECT:Michael J. Lombardi Building: Carpet Replacement.
ESTIMATED COST: $19,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid conference: 7/13/10 at 10:00 A.M. at the Michael J. Lombardi Building, 831 Massachusetts Ave. 2nd Floor, Cambridge.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Cynthia H. Griffin EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
16
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave.Cambridge, MA 02139
Above agency address, 7/1/10. Office Hours: Monday, 8:30 A.M. - 8:00 P.M.; Tuesday - Thursday, 8:30 A.M. - 5:00 P.M.; Friday, 8:30 A.M. - 12:00 P.M.
PHONE: 617-349-4310CONTACT INFORMATION
PROJECT NUMBER:
FAX: 61-349-4008
PROJECT:City Wide Pavement Markings.
ESTIMATED COST: $230,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION This bid may be downloaded from the City's website at www.cambridgema.gov, following the links to Online Services, Current Bid List, Construction.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Cynthia H. Griffin EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Chelsea, City of ***REVISED***500 Broadway Room 206Chelsea, MA 02150
6/2/10.
PHONE: 617-466-4224CONTACT INFORMATION
PROJECT NUMBER: 2010-136
FAX: 617-466-4225
PROJECT:Provide all labor, materials and equipment necessary for the installation of new windows at Engine One Fire House, 38 Sagamore Ave., Chelsea.
ESTIMATED COST: $50,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/28/10 @ 10:00 A.M.***
ADDITIONAL INFORMATION Pre-Bid conference: ***7/14/10 at 9:00 A.M. at the site. ***$50.00 refundable deposit required in the form of a check.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Robert H. Bishop EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
17
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Chelsea, City of ***REVISED***Office of the Chief Procurement Officer500 Broadway Room 206Chelsea, MA 02150
Above agency address, 5/26/10.
PHONE: 617-466-4224CONTACT INFORMATION
PROJECT NUMBER: 2010-128
FAX: 617-466-4225
PROJECT:Installation of rooftop HVAC unit at Engine One Fire House, 38 Sagamore Ave., Chelsea.
ESTIMATED COST: $70,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/28/10 @ 11:00 A.M.***
ADDITIONAL INFORMATION Pre-bid conference: ***7/14/10 at 10:00 A.M. at the site. $50.00 refundable*** deposit required.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Robert H. Bishop EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Chicopee, City ofParks Department687 Front St.Chicopee, MA 01013
Chicopee Purchasing Department, 274 Front St., Chicopee, MA 01013, Monday - Friday, 8:00 A.M. - 4:30 P.M.
PHONE: 413-594-1557CONTACT INFORMATION
PROJECT NUMBER: 10-39
FAX: 413-594-1577
PROJECT:Chicopee Parks dept seeks bids for improvements to Lincoln Grove park. Project involves installation of playground equipment, prep of a 60x60 area for new skate park and skate park equipment and fence.
ESTIMATED COST: $35,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Please contact Stan Walczak, Parks Director at 413-594-3481 with any questions regarding this project.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Brian Salamon Purchasing Agent EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
18
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:East Longmeadow, Town ofBoard of Public WorksDepartment of Public Works Office60 Center SquareEast Longmeadow, MA 01028
Tighe & Bond, 53 Southampton Rd., Westfield, MA 01085, 6/30/10. Office Hours: Monday - Friday, 8:00 A.M. - 5:00 P.M. (holidays excluded).
PHONE: 413-562-1600CONTACT INFORMATION
PROJECT NUMBER: E-507
FAX: 413-562-5317
PROJECT:The work consists of the upgrade of the existing Watchaug Brook Pump Station, including selective demolition, installation of three new wastewater pumps (to be provided by the Town), controls, level sensing systems, process piping, standby generator, electrical work, ventilation work and all necessary appurtenances for a complete and operational sewage pumping station upgrade.
ESTIMATED COST: $950,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Electrical
SUB BID DEADLINE: 7/27/10 @ 2:00 P.M. GENERAL BID DEADLINE: 8/3/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Refundable deposit for documents is $100. Bidding Documents will be mailed upon request via U.P.S. Ground Service delivery for a non-refundable handling and postage charge of $25.00. All deposit, handling, and postage charges must be prepaid. In lieu of the handling and postage charge, prospective bidders may provide a UPS or FedEx account number.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
David R. Prickett, P.E. EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Fairhaven, Town of Board of Selectmen40 Center St.Fairhaven, MA 02719
Dyer Brown SouthCoast, Architects, One Johnny Cake Hill, New Bedford, MA 02740, 7/2/10, 9:00 A.M. - 5:00 P.M.
PHONE: 508-999-6220CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-990-1265
PROJECT:Exterior window painting on the Second and Third Floor, West and North Elevation of the Fairhaven Town Hall and the exterior windows above the clock in the Clock Tower.
ESTIMATED COST: $30,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Dyer Brown SouthCoast Architects EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
19
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Fall River, City of Department of Community MaintenanceOne Government CenterFall River, MA 02722
Purchasing Department at the above agency address, 6/30/10. Office Hours: Monday - Friday, 9:00 A.M. - 4:00 P.M.
PHONE: 508-324-2251CONTACT INFORMATION
PROJECT NUMBER: Written Quote #2
FAX:
PROJECT:Repair and Maintenance to various roofs on city buildings.
ESTIMATED COST: $20,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION 50% payment bond must be submitted by thesuccessful bidder.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Arlene Robinette EMAIL:
CONTRACTOR QUALIFICATION:
AGENCY:Fall River, City of Department of Community MaintenanceOne Government CenterFall River, MA 02722
Purchasing Department at the above agency address, 6/30/10. Office Hours: Monday - Thursday, 9:00 A.M. - 4:00 P.M.
PHONE: 508-324-2251CONTACT INFORMATION
PROJECT NUMBER: written quote #3
FAX: 508 324 2255
PROJECT:Carpentry Repair and Maintenance Services in city owned buildings.
ESTIMATED COST: $20,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION 50% Payment bond must be submitted by thesuccessful bidder.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Arlene Robinette EMAIL:
CONTRACTOR QUALIFICATION:
20
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Fall River, City of Department of Community MaintenanceOne Government CenterFall River, MA 02722
Purchasing Department at the above agency address, Monday - Thursday, 9:00 A.M. - 4:00 P.M.
PHONE: 508-324-2251CONTACT INFORMATION
PROJECT NUMBER: IFB 11-05
FAX: 508 324 2255
PROJECT:HVAC Maintenance and Support Services for the Fall River Government Center, Main Library Police and Fire Department Buildings.
ESTIMATED COST: $50,000/Year (3 - Years)
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION 5% bid deposit, DCAM Certification in HVAC. 100% Labor Payment and Performance Bond bythe successful bidder.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Arlene Robinette EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Fall River, City of Department of Community MaintenanceOne Government CenterFall River, MA 02722
Purchasing Department at the above agency address, 6/30/10. Office Hours: Monday - Thursday, 9:00 A.M. - 4:00 P.M.
PHONE: 508-324-2251CONTACT INFORMATION
PROJECT NUMBER: IFB 11-06
FAX: 508 324 2255
PROJECT:Preventative Maintenance and Repair for Elevators located at One Government Center, Fall River.
ESTIMATED COST: $20,000/Year (3 - Years)
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION 5% Bid Deposit. 50% Labor and Payment Bond is required from the successful bidder.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Arlene Robinette EMAIL:
CONTRACTOR QUALIFICATION:
21
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Fall River, City of Department of Community MaintenanceOne Government CenterFall River, MA 02722
Purchasing Department at the above agency address, 6/30/10. Office Hours: Monday - Thursday, 9:00 A.M. - 4:00 P.M.
PHONE: 508-324-2251CONTACT INFORMATION
PROJECT NUMBER: IFB 11-07
FAX: 508 324 2255
PROJECT:Electrical Maintenance and Repair Services for City of Fall River Buildings under the Public Works jurisdiction.
ESTIMATED COST: $20,000/Year (3 - Years)
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/19/10 @ 11:00 A.M.
ADDITIONAL INFORMATION 5% Bid Deposit. 50% Labor and Payment Bond must be submitted by the successful bidder.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Arlene Robinette EMAIL:
CONTRACTOR QUALIFICATION:
AGENCY:Fitchburg, City ofOffice of the Purchasing Agent718 Main St.Fitchburg, MA 01420
Above agency address, 6/30/10 after 2:30 P.M.
PHONE: 978-345-9576CONTACT INFORMATION
PROJECT NUMBER:
FAX: 978-345-9588
PROJECT:Excavation and disposal of petroleum contaminated soils at the Central Steam Plant site, 465 Westminster St., Fitchburg. Plant built in 1928 and served as heat/power source for eight paper mills. Coal, gas and petroleum products used at the site. No UST or AST removal included in project, no work in the steam plant building. The work site is adjacent to the building. The city has retained an LSP to oversee the project. Plant abandoned by previous owner and city acquired the property. Work site is in close proximity to the Nashua River. Petroleum contaminants identified, other contaminants such as metals may be present. GC will dig test pits for monitoring purposes. Monitoring is not included in the contract.
ESTIMATED COST: $90,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/15/10 at 10:00 A.M. at the Central Steam Plant, 465 Westminster St., Fitchburg. Plan deposit is $45, refundable if bid documents are returned within seven calendar days of bid opening, Mail fee is $15 (non-refundable). Separate company checks made payable to the City of Fitchburg.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Lois Ogilvie EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
22
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Gardner, City of 95 Pleasant St.Gardner, MA 01440
6/28/10.
PHONE: 978-632-0426CONTACT INFORMATION
PROJECT NUMBER: 2011-103
FAX:
PROJECT:Maintenance shed construction at Municipal Golf Course: Removal of existing building; repair of foundation; building new maintenance shed.
ESTIMATED COST: $30,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Mary A Delaney EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Gloucester, City of Purchasing Department9 Dale Ave.Gloucester, MA 01930
Above agency address, 6/30/10.
PHONE: 978-281-9710CONTACT INFORMATION
PROJECT NUMBER: 10189
FAX: 978-281-8763
PROJECT:Mill Pond Tidegate Project: Experienced General/Marine Contractor to install a new tide gate and make alterations to existing weir wall.
ESTIMATED COST: $60,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/28/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/14/10 at 9:00 A.M. $25.00 non-refundable fee to receive bid documents.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Donna Compton EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
23
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Greenfield, City of Office of the Mayor14 Court SquareGreenfield, MA 01301
Above agency address, 7/1/10 at 9:00 A.M.
PHONE: 413-772-1567CONTACT INFORMATION
PROJECT NUMBER: 10-0522
FAX: 413-772-1519
PROJECT:Replacement of flooring in elementary school.
ESTIMATED COST: $60,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 3:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Marjorie Lane Kelly EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Greenfield, City of Office of the Mayor14 Court SquareGreenfield, MA 01301
Above agency address, 7/1/10 at 9:00 A.M.
PHONE: 413-772-1567CONTACT INFORMATION
PROJECT NUMBER: 10-0521
FAX: 413-772-1519
PROJECT:Repair and painting of elementary school trim.
ESTIMATED COST: $95,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Marjorie Lane Kelly EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
24
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Groton, Town ofHistorical Commission173 Main St.Groton, MA 01450
Town Manager's Office, 173 Main St., Groton, MA 01450, Monday - Friday, 8:00 A.M. - 4:00 P.M. or by email from [email protected].
PHONE: 978-486-0688CONTACT INFORMATION
PROJECT NUMBER: CPA
FAX: 978-448-1115
PROJECT:Request for qualifications from consultants to qualify them to receive a Request for proposals to develop an agricultural context for the town. Qualified consultants will be eligible to receive the RFP.
ESTIMATED COST: $30,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 9/1/10 @ 10:00 A.M.
ADDITIONAL INFORMATION RFP will be available to qualified consultants on 7/30/10.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Mike Roberts EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Harvard, Town of 13 Ayer Rd.Harvard, MA 01451
Above agency address, 6/21/10.
PHONE: 978-456-4100CONTACT INFORMATION
PROJECT NUMBER:
FAX: 978-456-4113
PROJECT:Replace a retaining wall and install a fence at the elementary school.
ESTIMATED COST: $30,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Lorraine A. Leonard EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
25
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Harwich, Town ofWater Department196 Chatham Rd.Harwich, MA 02645
Polaris Consultants, 1495 Hancock St. Suite. 206, Quincy, MA 02169, Attn: Jason Federico, 6/30/10. Office Hours: Monday - Friday, 8:30 A.M. - 4:30 P.M.
PHONE: 617-689-1010CONTACT INFORMATION
PROJECT NUMBER: 104-1003.00
FAX: 617-689-3010
PROJECT:Furnishing all plant, labor, services, equipment, materials, devices, facilities and appurtenances for the installation of new materials, equipment and facilities and appurtenant work as shown on the Drawings and as specified for a 4.46 million gallon per day iron and manganese water filtration facility.
ESTIMATED COST: $3,000,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Electrical; Masonry; Painting; Plumbing; HVAC
SUB BID DEADLINE: 8/18/10 @ 10:00 A.M. GENERAL BID DEADLINE: 9/1/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Each bid must be accompanied by a copy of the current Certificate of Eligibility issued by the Deputy Commissioner of the Division of Capital Asset Management (DCAM) showing that the bidder has the classification and capacity rating to perform the work required (Sewage and Water Treatment Plants for General Contractors and the applicable sub-bid category of work for Sub-bidders). Each bid must also be accompanied by an update statement in the form prescribed by the DCAM Deputy Commissioner.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Paul Costello EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Haverhill, City of 4 Summer St. Room 105Haverhill, MA 01844
Above agency address or online at www.ci.haverhill.ma.us or www.comm-pass.com, 7/2/10 at 12:00 P.M.
PHONE: 978-420-3606CONTACT INFORMATION
PROJECT NUMBER: IFB001.11
FAX: 978-521-4348
PROJECT:Installation of a synthetic field at Haverhill Stadium.
ESTIMATED COST: $1,000,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/17/10 @ 2:00 P.M.
ADDITIONAL INFORMATION The City reserves the right to reject any or all proposals, in whole or in part, and to waive informalities that are in the City's best interest.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Robert DeFusco EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
26
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Hingham, Town of 210 Central St.Hingham, MA 02043-2757
By calling the Hingham Town Administrator's Office at 781-741-1400, 7/7/10.
PHONE: 781-741-1400CONTACT INFORMATION
PROJECT NUMBER:
FAX: 781-741-1454
PROJECT:Renovation of a portion of Hingham Town hall to establish a regional public safety dispatch center.
ESTIMATED COST: $900,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: All typical building trades.
SUB BID DEADLINE: 7/23/10 @ 12:00 P.M. GENERAL BID DEADLINE: 7/30/10 @ 12:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Kevin Paicos EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Hingham, Town ofLincoln Apartments, LLC210 Central St.Hingham, MA 02043
Nashoba Blue, Inc., 433 Main St., Hudson, MA 01749, 978-568-1167 or online at www.biddocsonline.com (may be viewed electronically and hard copy requested), 7/1/10.
PHONE: 781-335-4773CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:The demolition of existing boilers and associated pumps, piping and ductwork and replacement with new high efficiency modular boilers including all associated pumps, piping, ductwork and other appurtenances. The Work will include all associated plumbing, electrical work and louvers.
ESTIMATED COST: $55,900
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 2:00 P.M.
ADDITIONAL INFORMATION The existing buildings will be available for inspection on 7/12/10 at 10:30 A.M. at 86 Central St., Hingham. There is a plan deposit of $50 per set (maximum of two sets), electronically paid or in the form of a certified or cashier's check, payable to BidDocs Online, Inc. Mailing fee is $40/set (non-refundable), electronically paid or in the form of a certified or cashier's check, payable to BidDocs Online, Inc.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Jamie Beaulieu EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
27
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Holland, Town of27 Sturbridge Rd.Holland, MA 01521
Above agency address, 6/29/10, 9:00 A.M. - 4:00 P.M.
PHONE: 413-245-7108 ext. 101CONTACT INFORMATION
PROJECT NUMBER:
FAX: 413-245-7037
PROJECT:The Town of Holland invites sealed bids for the Phase 1 Storm Drain Construction and Related Work on a Section of Sturbridge Rd. The work to be done under this contract consists of the Phase 1 improvements for Sturbridge Road which includes storm drain construction and related work. Phase 1 construction begins at Station 21+45 and ends at 32+16. The total project length is approximately 1,071 feet. Work includes the installation of storm drain conduit, catch basins, drianage manholes, headwall, asphalt apron, rip rap aprons, a hydrodynamic separator unit, trench resurfacing, bioretention, asphalt widening, asphalt overlay, +/- 60 feet of full road depth repair and other incidental work necessary to complete the project.
ESTIMATED COST: $350,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Mandatory Pre-Bid conference: 7/8/10 at 2:00 P.M. in the Selectmen Meeting Room at the above agency address. Bids must be accompanied by a bid deposit of 5% of the greatest possible bid amount, considering all alternates, payable to the Town of Holland. All bids for this project are subject to the provisions and minimum wage rates required by M.G.L. c. 30, § 39M and M.G.L. c. 149, §§ 26 - 27H.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Kristin LaPlante EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Holyoke, City of 536 Dwight St.Holyoke, MA 01040
AECOM, 701 Edgewater Drive, Wakefield, MA 01880.
PHONE: 781-246-5200CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:City of Holyoke Wastewater Treatment Plant Headworks Improvements. The work includes modifications to the existing Holyoke WWTP including demolition work and installation of pre-purchased mechanically operated screens and appurtenant work. Completion time for the project will be calculated as calendar days from the date specified in the Notice to Proceed as follows: 60 calendar days for substantial completion; 90 calendar days for contract completion.
ESTIMATED COST:
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Mandatory pre-bid meeting: 7/7/10 at 10:00 A.M. at the Holyoke Wastewater Treatment Plant, 1 Berkshire St., Holyoke. $150 document deposit. Non-refundable P&H fee of $20, payable to AECOM for each set of documents requested by mail. Sealed Bids for the subject project will be received by United Water Environmental Services, Inc. Bid Security of 5% of the value of the bid in the form of a certified, treasurer's or cashier's check, payable to United Water Environmental Services, Inc. Successful bidder must furnish 100% Performance Bond and 100% Labor and Materials Bond. Commonwealth of Massachusetts minimum wage rates and public works employment laws are applicable.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Linda Arpino EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
28
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Lakeville, Town of Selectmen's Office346 Bedford St.Lakeville, MA 02347
Above agency address or by email request to [email protected], 7/6/10 at 9:00 A.M.
PHONE: 508-946-8803CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-946-0112
PROJECT:Cleaning and sealing of construction and random cracks in bituminous concrete pavement and related services on certain Town roads and properties.
ESTIMATED COST: $60,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 3:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Tracie Craig EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Lakeville, Town of Selectmen's Office346 Bedford St.Lakeville, MA 02347
Above agency address or by email request to [email protected], 7/6/10 at 9:00 A.M.
PHONE: 508-946-8803CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-946-0112
PROJECT:Road resurfacing: Approximately 2,000 tons of bituminous concrete type 1 top and binder. Bid is for "on street" only.
ESTIMATED COST: $100,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 3:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Tracie Craig EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
29
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Lexington, Town ofPurchasing Office1625 Massachusetts Ave. Room 105Lexington, MA 02420
Above agency address, 6/30/10 at 9:00 A.M.
PHONE: 781-274-8357CONTACT INFORMATION
PROJECT NUMBER: #10-56
FAX: 781-274-8344
PROJECT:Supply and deliver/pickup bituminous concrete products as needed for the DPW. This is for supply, delivery and or pick-up only, not for "in-place".
ESTIMATED COST: $100,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Mark Valetti EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Longmeadow, Town of 735 Longmeadow St. Suite 101Longmeadow, MA 01106
Above agency address, 413-565-4136 or online at www.longmeadow.org at the "Purchasing Dept." tab.
PHONE: 413-565-4136CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:IFB for Glenbrook Middle School Wall Construction and Locker Installation: The Town is soliciting bids for wall construction and locker installation.
ESTIMATED COST: $30,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 9:00 A.M.
ADDITIONAL INFORMATION Mandatory pre-bid tour: 7/9/10 at 10:00 A.M. at the main entry of the Glenbrook School, 110 Cambridge Circle, Longmeadow. Bids received from those that have not attended the tour will be rejected. 5% bid deposit required. Sealed bids will be accepted at the office of the Chad Thompson, Purchasing Coordinator until the deadline, at which time a Public bid opening will immediately follow. Late bids will be rejected.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Chad Thompson, Purchasing Coordinator EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
30
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Lynn, City ofPurchasing Department3 City Hall Square Room 205Lynn, MA 01901
Above agency address, 6/30/10 at 8:30 A.M. Office Hours: Monday, Wednesday and Thursday, 8:30 A.M. - 4:00 P.M.; Tuesday, 8:30 A.M. - 8:00 P.M.; Friday, 8:30 A.M. - 12:30 P.M.
PHONE: 781-586-6893CONTACT INFORMATION
PROJECT NUMBER: 03-53
FAX: 781-477-7027
PROJECT:Supply of Time and Materials HVAC Service for the City of Lynn Inspectional Services Department.
ESTIMATED COST: $250,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/20/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Deadline for Questions on this bid is 7/7/10 at 12:00 P.M. Fax Questions to Charles White at 781-477-7027 or email to [email protected]. This is bid under M.G.L. c. 30B.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Charles E. White EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Marblehead, Town ofHousing Authority26 Rowland St.Marblehead, MA 01945
Above agency address, 6/30/10. Office Hours: Monday, Tuesday and Thursday, 8:00 A.M. - 4:00 P.M.; Wednesday, 12:00 P.M. - 4:00 P.M.; Friday, 8;00 A.M. - 12:00 P.M.
PHONE: 781-631-2580CONTACT INFORMATION
PROJECT NUMBER:
FAX: 781-639-2340
PROJECT:The Replacement of Underground Heating Lines at New Farrell Court 667-4 Elderly Housing Complex.
ESTIMATED COST: $15,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Site Visit: 7/21/10, 9:00 A.M. - 10:00 A.M. For an appointment, call John Bonfanti, Maintenance Foreman at 781-631-2580. Bid Forms and Contract Documents will be available upon deposit of $15.00/set in the form of a certified or cashier's check, payable to the Marblehead Housing Authority. Additional Sets will be available for $15.00/Set. Bidders requesting the documents to be mailed must include a separate check for $10.00/set.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Debby Larkin, Assistant Executive Director EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
31
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Marshfield, Town of Department of Public Works870 Moraine St.Marshfield, MA 02050
Above agency address, 6/30/10. Office Hours: Monday - Friday, 8:30 A.M. - 4:30 P.M.
PHONE: 781-834-5559CONTACT INFORMATION
PROJECT NUMBER: Contract No. 2011-03
FAX: 781-837-7163
PROJECT:Remove and dispose existing mechanical surface aerators (one per aeration tank) and replace with new mixers/aerators and related appurtenances. Furnish and install instrumentation and control equipment including but not limited to dissolved oxygen sensors and variable frequency drives to provide process control. The base bid includes the upgrade of tanks 1 and 2 while the upgrade of tank 3 is an alternate bid item.
ESTIMATED COST: $600,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Electrical
SUB BID DEADLINE: 7/22/10 @ 2:00 P.M. GENERAL BID DEADLINE: 7/29/10 @ 2:00 P.M.
ADDITIONAL INFORMATION There is no charge for documents. Please direct inquiries to James Dymant, P.E., Beta Group, 401-333-2382. DCAM Certification for Sewage and Water Treatment Plants required.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Paul F. Tomkavage, P.E. EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Millis, Town of Board of Selectmen900 Main St.Millis, MA 02054
Above agency address, 7/1/10. Office Hours: Monday - Thursday, 8:30 A.M. - 4:30 P.M.
PHONE: 508-376-5424CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-376-2442
PROJECT:Furnish and Install 20 Hp Stationary Compactor and Containers at Millis Transfer Station.
ESTIMATED COST: $61,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 11:00 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
James Mckay EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
32
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Milton, Town of Department of Public Works629 Randolph Ave.Milton, MA 02186
Above agency address, 6/30/10 at 9:00 A.M.
PHONE: 617-898-4801CONTACT INFORMATION
PROJECT NUMBER: T10-2
FAX: 617-698-1290
PROJECT:Total full depth reconstruction of an approximately 7900 square foot municipal bituminous concrete parking lot. The project will also include construction of a 200 Linear Foot block retaining wall, concrete wheel chair ramp, site grading and excavation, granite curbing, tree removal, loam and seed, signage and pavement marking.
ESTIMATED COST: $50,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 9:00 A.M.
ADDITIONAL INFORMATION Project is time sensitive. The successful bidder must be capable of fully completing the scope of work by 9/11/10.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Dale Horsman EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Natick, Town of ***REVISED COST**Public Schools13 East Central St.Natick. MA 01760
From R.F. Walsh or by email request to [email protected], 6/30/10.
PHONE: 617-778-0900CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-778-0999
PROJECT:General Contractors for pre-qualification of a new 254,000 square foot high school located at 20 West St., Natick. The school department is seeking statements of qualifications from general contractors.
ESTIMATED COST: $65,000,000***
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 1:00 P.M.
ADDITIONAL INFORMATION General Contractors who have previously submitted Statements of Qualifications pursuant to the initial Request for Qualifications will not be required to re-submit their Statement of Qualifications.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
David Billings, R.F. Walsh collabortive partners EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
33
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Natick, Town ofHousing Authority4 Cottage St.Natick, MA 01760
Online at www.BidDocsOnline.com, 6/30/10.
PHONE: 508-653-2971CONTACT INFORMATION
PROJECT NUMBER: DHCD Project # 202022
FAX: 508-650-9982
PROJECT:Replacement of existing oil fired or gas fired boilers, furnaces, breeching, fuel oil or gas piping and duct work, related plumbing and electrical work at Forest Green Family Housing 200-1 and 705s at Westview Avenue, Hunter Hill Court, South Main Street, Pond Street and 9 School Street.
ESTIMATED COST: $560,000 [Includes Alternate]
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Section 15401 Plumbing
SUB BID DEADLINE: 7/29/10 @ 2:00 P.M. GENERAL BID DEADLINE: 8/12/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Walk-through: 7/14/10 at 11:00 A.M. at the above agency address.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Eileen Manning-Merritt EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:New Marlborough, Town of Highway Department603 Mill River Southfield Rd.Mill River, MA 01244-0099
Town Hall, 807 Mill River Southfield Rd., Mill River, MA 01244, 6/18/10. Office Hours: Monday - Friday, 9:00 A.M. - 3:00 P.M.
PHONE: 413-229-8165CONTACT INFORMATION
PROJECT NUMBER:
FAX: 413-229-6674
PROJECT:Paving Norfolk and Cagney Hill Rd.: Three locations, +/- 458 tons in place application of DOT approved bituminous concrete, both base binder and Modified Top.
ESTIMATED COST: $45,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 3:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Peter Marks, Highway Superintendent EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
34
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Newton, City of ***RE-BID***1000 Commonwealth Ave.Newton, MA 02459
Online at www.ci.newton.ma.us/bids, 7/1/10 after 10:00 A.M.
PHONE: 617-796-1220CONTACT INFORMATION
PROJECT NUMBER: 10-97
FAX: 617-796-1227
PROJECT:Elliot Street HVAC Equipment Replacement.
ESTIMATED COST: $125,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Pre-Bid Conference: 7/8/10 at 10:00 A.M. at Elliot Street Garage, 80 Elliot St., Newton. 5% Bid Surety Required. DCAM Category: Mechanical Systems or HVAC and Plumbing.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Paula Hudak, Acting Chief Procurement Officer EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Newton, City of 1000 Commonwealth Ave.Newton, MA 02459
Online at www.ci.newton.ma.us/bids, 7/1/10 after 10:00 A.M.
PHONE: 617-796-1220CONTACT INFORMATION
PROJECT NUMBER: 10-98
FAX: 617-796-1227
PROJECT:Water Main Rehabilitation at Various Locations.
ESTIMATED COST: $1,850,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 10:30 A.M.
ADDITIONAL INFORMATION 5% Bid Surety Required.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Paula Hudak, Acting Chief Procurement Officer EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
35
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:North Attleboro, Town of Department of Public Works49 Whiting St.North Attleboro, MA 02760
Above agency address, 6/30/10 at 8:00 A.M.
PHONE: 508-695-9621CONTACT INFORMATION
PROJECT NUMBER: Chestnut Street
FAX: 508-643-0568
PROJECT:Removal of existing 8" water main and replacement with 12" CLDI water main, removal and replacement of various drainage infrastructure, reclamation and resurfacing of existing roadway and sidewalks and all other appurtenances required to complete work on Cestnut St.
ESTIMATED COST: $600,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 1:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Bill McDowell EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Northampton, City of Central Services240 Main St.Northampton, MA 01060
Above agency address or by email request to [email protected], 6/30/10. Office Hours: Monday - Friday, 9:00 A.M. - 4:00 P.M.
PHONE: 413-587-1055CONTACT INFORMATION
PROJECT NUMBER:
FAX: 413-587-1248
PROJECT:Northampton Central Services invites proposals under M.G.L. c. 25A, § 11C to design and install a photovoltaic system with data acquisition system at 80 Locust St., Northampton.
ESTIMATED COST:
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Proposals must include a "Non-Price Proposal" and a "Price Proposal". System size of 52–90 kWdc is contingent on level of grant funds secured by 6/30/10. The City reserves the right to reject any or all bids.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Chris Mason EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
36
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Peabody, City of Office of the Purchasing Agent24 Lowell St.Peabody MA 01960
Above agency address, 6/22/10.
PHONE: 978-538-5902CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:Provide Maintenance to specified Systems in Peabody Water Department facilities.
ESTIMATED COST:
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Maria Ataide EMAIL:
CONTRACTOR QUALIFICATION:
AGENCY:Peabody, City of Office of the Purchasing Agent24 Lowell St.Peabody MA 01960
Above agency address, 7/1/10.
PHONE: 978-538-5902CONTACT INFORMATION
PROJECT NUMBER:
FAX:
PROJECT:HVAC and Energy Upgrades to Peabody Institute Library, Main Branch.
ESTIMATED COST: $1.9 Million
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Painting, Acoustical Ceiling, Roofing, Electrical
SUB BID DEADLINE: 7/20/10 @ 2:00 P.M. GENERAL BID DEADLINE: 7/29/10 @ 2:00 P.M.
ADDITIONAL INFORMATION DCAM Prime Category: HVAC or Mechanical. Information herein may be modified as set forth by City of Peabody in legal advertisement and/or Bid Documents. Deposit and mailing fees apply. ARRA partial funding for this project.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Maria Ataide EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
37
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Pittsfield, City of Purchasing Office70 Allen St.Pittsfield, MA 01201
Above agency address, 6/30/10 after 12:00 P.M.
PHONE: 413-499-9470CONTACT INFORMATION
PROJECT NUMBER: 11-003
FAX: 413-499-9463
PROJECT:Rehabilitation of Pittsfield High School Basement Corridor.
ESTIMATED COST: $45,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-Bid: 7/7/10 at 10:00 A.M. in the lobby of Pittsfield High School. $25.00 spec fee, $25.00 additional fee for mailing.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Colleen Hunter-Mullett EMAIL:
CONTRACTOR QUALIFICATION:
AGENCY:Plymouth, Town ofRedevelopment Authority11 Lincoln St.Plymouth, MA 02360
Procurement Division at the above agency address, 7/1/10 at 12:00 P.M. Office Hours: Monday, Wednesday and Thursday, 7:30 A.M. - 5:00 P.M.; Tuesday, 7:30 A.M. - 7:00 P.M.; Closed Friday.
PHONE: 508-747-1620 ext. 210CONTACT INFORMATION
PROJECT NUMBER: 21018
FAX: 508-830-4133
PROJECT:Roof repairs and related work at the 1820 Court House, 26 Court St., Plymouth.
ESTIMATED COST: $150,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Please check the Town's website for updated information and possible pre-bid date at www.plymouth-ma.gov at the Bids and RFPs link.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Pamela D. Hagler, Procurement Officer EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
38
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Quincy, City ofOffice of the Purchasing Agent1305 Hancock St.Quincy, MA 02169
Above agency address or online at www.quincyma.gov, 6/30/10.
PHONE: 617-376-1060CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-376-1074
PROJECT:Road Improvements, Summer 2010.
ESTIMATED COST: $1,500,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION MassHighway pre-qualification will be required when submitting a bid. Bids without MassHighway pre-qualification will be rejected. Specifications available at the above agency address for a non-refundable printing charge of $25.00. (Attn: Kathryn R. Hobin.)
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Kim Trillcott EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Reading, Town of Engineering Office16 Lowell St.Reading, MA 01867
Above agency address, 7/1/10 at 1:00 P.M.
PHONE: 781-942-9082CONTACT INFORMATION
PROJECT NUMBER: 11-03
FAX:
PROJECT:California Road Sewer Main Replacement.
ESTIMATED COST: $140,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Ryan Percival EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
39
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Revere, City of Purchasing Department281 BroadwayRevere, MA 02151
Above agency address, 7/1/10.
PHONE: 781-286-8157CONTACT INFORMATION
PROJECT NUMBER: DPCD-2010-1003
FAX: 781-485-2796
PROJECT:Lynn Street Water Main Repair.
ESTIMATED COST: $100,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Specifications may be obtained upon receipt of a $25 refundable deposit in the form of a certified check or equivalent, payable to the City of Revere. Bidders requesting documents to be mailed to them must include a separate certified check or equivalent for $10.00.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Marie E. Zelandi EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Revere, City ofHousing Authority70 Cooledge St.Revere, MA 02151
Above agency address, 6/18/10.
PHONE: 781-284-4394CONTACT INFORMATION
PROJECT NUMBER: Job 2009-03
FAX: 781-284-0065
PROJECT:Clerk of the Works for Bathroom Replacement Project Phase One (28 Units).
ESTIMATED COST: $10,192.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 1:00 P.M.
ADDITIONAL INFORMATION Successful candidate will be considered for subsequent phases.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Greg Farkas EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
40
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Rockland, Town of Sewer CommissionP.O. Box 330Rockland, MA 02370
AECOM, 701 Edgewater Drive, Wakefield, MA 01880, 6/24/10.
PHONE: 781-224-6094CONTACT INFORMATION
PROJECT NUMBER: Contract 10-1
FAX: 781-224-6546
PROJECT:Rehabilitation of sewer system including chemical sealing of sewer manholes, joint testing and sealing and CIPP lining of mainline sewer pipe and lateral service connections.
ESTIMATED COST: $327,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/28/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Bid opening will be in the Selectman's Conference Room, 242 Union St., Rockland.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Mark Meserve EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Rockland, Town ofWater Department96 East Water St.Rockland, MA 02370
Above agency address, 7/1/10 at 9:00 A.M.
PHONE: 781-878-0901CONTACT INFORMATION
PROJECT NUMBER: R11-01
FAX: 781-982-8332
PROJECT:Provide Excavation Services.
ESTIMATED COST: $50,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 11:15 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Daniel F. Callahan EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
41
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Rowe, Town of Board of Selectmen321 Zoar Rd.Rowe, MA 01367
Above agency address or by phone or email request, 6/30/10 at 8:00 A.M.
PHONE: 413-339-5520CONTACT INFORMATION
PROJECT NUMBER: Solar PV Project
FAX:
PROJECT:Turnkey design, procurement and installation of a pole style ground mounted photovoltaic energy system at Rowe Elementary School.
ESTIMATED COST: $147,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Mandatory Pre-Bid Conference: 7/8/10 at 11:00 A.M. DCAM Certification required. Funded in part with ARRA funds and administered through Dept of Energy Resources (DOER). Procurement under M.G.L. c. 25A, § 11C. 5% Bid Deposit required.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Ellen Miller, Administrator Town of Rowe EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Saugus, Town of 298 Central St.Saugus, MA 01960
PHONE: 781-231-4125CONTACT INFORMATION
PROJECT NUMBER: 24-10
FAX: 781-231-5666
PROJECT:Contractor agrees to complete at contractor's own cost and expense all work and furnish all machinery, tools, equipment, facilities, plant, labor, supervision, materials and other requisites to complete all work. Where paving comes in contact with curb cuts (either present or proposed) they will be constructed in accordance with applicable laws prior to the application of any pavement the entire surface to be paved shall be cleared of dirt leaves, vegetation and/or other foreign matter using power sweepers.
ESTIMATED COST: $350,000/Year
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 11:00 A.M.
ADDITIONAL INFORMATION This is a Three Year Contract.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Michele Wendell EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
42
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Sheffield, Town of Board of SelectmenP.O. Box 32521 Depot SquareSheffield, MA 01257
Above agency address, 6/28/10 at 9:00 A.M.
PHONE: 413-229-7000 ext. 152CONTACT INFORMATION
PROJECT NUMBER:
FAX: 413-229-7010
PROJECT:Resurfacing Various Roads and Streets.
ESTIMATED COST: $150,000.
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/16/10 @ 3:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Joseph A. Kellogg, Town Administrator EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Springfield, City ofWater and Sewer Commission250 M St. ExtensionAgawam, MA 01001
Above agency address, 6/30/10 at 10:00 A.M.
PHONE: 413-787-6256 ext 162CONTACT INFORMATION
PROJECT NUMBER: CA 1020-10
FAX: 413-787-6269
PROJECT:Fabrication of a steel trash system for a hydro power station per Springfield Water and Sewer Commission Specification.
ESTIMATED COST: $350,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/19/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Daniel Downie EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
43
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Stow, Town of 380 Great Rd.Stow, MA 01775
6/30/10.
PHONE: 978-897-2193CONTACT INFORMATION
PROJECT NUMBER: 2010-1
FAX: 978-897-4534
PROJECT:Town Office Building Emergency Generator Connection, Manual Transfer Switch, Wiring, Lighting Fixtures and Programmable Thermostats.
ESTIMATED COST: $50,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Pre-Bid Meeting: 7/7/10 at 10:00 A.M. at the above agency address.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Craig Martin, P.E. Building Commissioner EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Tewksbury, Town of Selectmen’s Office1009 Main St.Tewksbury, MA 01876
7/1/10, online at www.Projectdog.com, enter Project code #788441 in the project locator box, follow the prompts to the downloadable bid set free of charge.
PHONE: 781-494-9000CONTACT INFORMATION
PROJECT NUMBER:
FAX: 781-494-9007
PROJECT:The Town of Tewksbury is seeking contractor’s bids for storm water drainage maintenance at outfall pipes and replacement of drainage culvert on Pleasant St. Work address is Tewksbury High School, 320 Pleasant St., Tewksbury.
ESTIMATED COST: $85,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/19/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-Bid Conference: 7/13/10 at 3:00 P.M. at Tewksbury High School, 320 Pleasant St., Tewksbury. Bidders may pick up one free bid set in the form of a CD at ProjectDog, 18 Graf Rd., Newburyport, MA 01950. Bidders may purchase paper documents online and bidders may call ProjectDog for details on a refundable plan deposit.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Peter D. Collins EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
44
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Walpole, Town of Purchasing Office135 School St. Room 118Walpole, MA 02081
Above agency address, 6/30/10 at 10:00 A.M. Office Hours: Monday, Wednesday and Thursday, 8:00 A.M. - 4:00 P.M.; Tuesday, 8:00 A.M. - 8:00 P.M.; Friday, 8:00 A.M. - 12:00 P.M. (closed 7/5/10).
PHONE: 508-660-7290CONTACT INFORMATION
PROJECT NUMBER: 2011-02
FAX: 508-668-2240
PROJECT:Electrical Service and Maintenance of Town of Walpole Buildings and Facilities. One-year bid with option to renew for two subsequent years.
ESTIMATED COST: $90,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/6/10 at 10:00 A.M. in Room 112 at the above agency address. This is not a mandatory meeting but it is strongly suggested. 5% Bid Bond with bid submission, A 50% Payment Bond required of successful bidder. OSHA certification required. Prevailing wages to be paid. Fax or email request for specs to be mailed.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Deborah McElhinney EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Waltham, City of 610 Main St.Waltham, MA 02452
For specs, call Elaine at 781-314-3242 or Geri at 781-314-3243.
PHONE: 781-314-3240CONTACT INFORMATION
PROJECT NUMBER:
FAX: 781-314-3245
PROJECT:Hardy Pond Road Utility Improvements.
ESTIMATED COST: $700,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 10:30 A.M.
ADDITIONAL INFORMATION Pre-Bid Meeting: 7/14/10 at 10:30 A.M. For Technical info, call David Doran at 781-982-5400.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Purchasing Dept. EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
45
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Wareham, Town of Town Administrator's Office54 Marion Rd.Wareham, MA 02571
Above agency address or online at www.wareham.ma.us.
PHONE: 508-291-3100 ext. 3103CONTACT INFORMATION
PROJECT NUMBER: ware 0610001
FAX: 508-291-3124
PROJECT:Installation of a 60 foot MET Tower at the Wastewater pollution Control Facility.
ESTIMATED COST: $20,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Contractor should contact the Town Administrator's Office with any questions.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
JOhn Sanguinet EMAIL: jsanguinet@wareham, ma,us
CONTRACTOR QUALIFICATION:
AGENCY:Webster, Town ofPublic Schools41 East Main St.Webster, MA 01570
By contacting Ted Avlas.
PHONE: 508-943-0104CONTACT INFORMATION
PROJECT NUMBER:
FAX: 508-949-2364
PROJECT:Install new Johnson Controls FX60 network controller to re[place existing N-30-1. Remove, Install, Program, Train.
ESTIMATED COST: $10,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 12:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Ted Avlas EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
46
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Wellesley, Town ofPublic Schools **CANCELLED**Business Office40 Kingsbury St.Wellesley, MA 02481-4827
Above agency address, 6/14/10 after 9:00 A.M.
PHONE: 781-446-6210CONTACT INFORMATION
PROJECT NUMBER: 17-61610
FAX: 781-446-65207
PROJECT:Lighting retrofit for Upham Elementary School.
ESTIMATED COST: $52,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/2/10 @ 1:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Liam Hurley, Assistant Business Administrator EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:West Boylston, Town of Board of Selectmen, Town Administrator and Parks Facilities Committee127 Hartwell St.West Boylston, MA 01583
Nashoba Blue, 433 Main St., Hudson, MA 01749, 978-568-1167 or online at www.biddocsonline.com (may be viewed electronically and hardcopy requested), 6/30/10. Viewing only with the Town Clerk at the above agency address.
PHONE: 508-835-3490CONTACT INFORMATION
PROJECT NUMBER: WLI #20921
FAX: 508-835-4102
PROJECT:Preservation of the Goodale Park Tennis and Basketball Courts at Goodale Street, West Boylston.
ESTIMATED COST: $618,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Mandatory Pre-Bid Conference: 7/9/10 at 10:30 A.M. held at Goodale Park, approx 56 Goodale St., West Boylston. Plan deposit is $50/set (refundable), electronically paid or in the form of a certified or cashier's check, payable to BidDocs Online, Inc. Mailing fee is $40/set (non-refundable), electronically paid or in the form of a certified or cashier's check, payable to BidDocs Online, Inc.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Patrick Inderwish EMAIL:
CONTRACTOR QUALIFICATION:
47
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:West Newbury, Town of Town Clerk's Office381 Main St.West Newbury, MA 01985
Above agency address, through 7/14/10 at 4:30 P.M.
PHONE: 978-363-1100 ext. 110CONTACT INFORMATION
PROJECT NUMBER: DPW 11-02
FAX: 978-363-1117
PROJECT:Replace the roofs at the Town Hall, 491 Main St., West Newbury, according to specifications.
ESTIMATED COST: $35,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 1:00 P.M.
ADDITIONAL INFORMATION Contact DPW Director Gary Bill at 978-363-1100 ext. 120 to examine the Town Hall roofs. OSHA training, 5% Bid Bond, 50% Payment Bond and Prevailing Wage required.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Lawrence J. Murphy EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:West Springfield, Town ofHousing Authority37 Oxford PlaceWest Springfield, MA 01089
Nashoba Blue, Inc., 433 Main St., Hudson, MA 01749 or online at www.biddocsonline.com, 6/30/10.
PHONE: 413-786-9600CONTACT INFORMATION
PROJECT NUMBER: DHCD #309033
FAX:
PROJECT:Replacement of Furnaces and Boilers at the Birch Park Circle Apartments and Scattered Sites for the West Springfield Housing Authority.
ESTIMATED COST: $848,328.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Electrical
SUB BID DEADLINE: 7/21/10 @ 12:00 P.M. GENERAL BID DEADLINE: 8/4/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-Bid Conference and walk-through: 7/13/10 at 9:00 A.M. at 144 Birch Park Circle, West Springfield. Plan deposit is $50.00 per set, payable to BidDocs Online, Inc. Bidders requesting sets to be mailed must include a separate check for $40.00/set UPS ground or $65.00/set UPS overnight payable to BidDocs Online, Inc.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Kurt Warren EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
48
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Westborough, Town of Department of Public Works131 Oak St.Westborough, MA 01581
AECOM, Inc., 300 Baker Ave. Suite 290, Concord, MA 01742, 7/1/10 at 8:30 A.M.
PHONE: 978-371-4078CONTACT INFORMATION
PROJECT NUMBER: 10-03
FAX: 978-371-2468
PROJECT:South Street Water Main Replacement 10-03. The Work consists of furnishing and installing approximately 6,000 linear feet of 12” diameter ductile iron water main and appurtenances on South St. and Upton Rd. The new water main will replace an existing water main. Temporary bypass piping will be required. A pavement overlay, new castings, and granite curbs will be required during the following calendar year.
ESTIMATED COST:
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 10:00 A.M.
ADDITIONAL INFORMATION A copy of the Contract Documents for the work may be obtained upon the deposit of $50.00 in the form of a check or money order, payable to AECOM. Deposit will be refunded if the contract documents are returned in good condition to the issuing office, postpaid if mailed, within 30 days after the opening of bids. Contract Documents will be mailed to prospective bidders upon receipt of a separate check or money order for $25.00 (non-refundable), payable to AECOM. Deposits and mail fees that are sent to AECOM by mail, FedEx, UPS or any type of carrier must be addressed to the attention of Spec/Plan Request.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Darlene Guilfoy EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Westborough, Town ofPublic Schools45 West Main St.Westborough, MA 01581
6/25/10 at 1:00 P.M.
PHONE: 508-836-7700 ext. 1013CONTACT INFORMATION
PROJECT NUMBER: Cafeteria Roof Repair
FAX: 508-836-7704
PROJECT:Demolition and removal of existing roofing material and replacement of cafeteria roof membrane and materials approximately 6,000 square feet.
ESTIMATED COST: $50,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Brian Schlegel EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
49
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Westford, Town ofPublic SchoolsOffice of the Superintendent23 Depot St.Westford, MA 01886
Westford Public Schools Business Office, 23 Depot St., Westford, MA 01886, 6/30/10. Office Hours: Monday - Friday, 9:00 A.M. - 3:00 P.M.
PHONE: 978-692-5560 ext. 2106CONTACT INFORMATION
PROJECT NUMBER:
FAX: 978-392-4497
PROJECT:Boiler Replacement and Gas Conversion, Robinson Elementary School, Westford.
ESTIMATED COST: $75,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Mandatory pre-bid meeting and site walk-through: 7/6/10 at 9:00 A.M. at the Robinson Elementary School, 60 Concord Rd., Westford.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Kathleen Auth, Director of School Finance EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Weston, Town of Department of Public Works598 Boston Post Rd.Weston, MA 02493
DPW Temporary Office (aka Fiske Law Office), 598 Boston Post Rd., Weston, MA 02493, 6/30/10. Office Hours: Monday - Friday, 7:00 A.M. - 3:00 P.M.
PHONE: 781-893-7320 ext. 345CONTACT INFORMATION
PROJECT NUMBER: D11-01
FAX: 781-899-5690
PROJECT:Drainage Improvement Project, 482 Glen Rd., Weston.
ESTIMATED COST: $25,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Bids and specs are available at no charge, must be picked up and will not be mailed. Bid opening will be at Town Hall, 11 Townhouse Rd., Weston.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Stephen R. Fogg, P.E. EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
50
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Weston, Town of Department of Public Works598 Boston Post Rd.Weston, MA 02493
DPW Temporary Office (aka Fiske Law Office), 598 Boston Post Rd., Weston, MA 02493, 6/30/10. Office Hours: Monday - Friday, 7:00 A.M. - 3:00 P.M.
PHONE: 781-893-7320 ext. 345CONTACT INFORMATION
PROJECT NUMBER: W11-01
FAX: 781-899-5690
PROJECT:Robin Road Water Main Improvements.
ESTIMATED COST: $100,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 11:30 A.M.
ADDITIONAL INFORMATION Bids and specs are available at no charge, must be picked up and will not be mailed. Bid opening will be at Town Hall, 11 Townhouse Rd., Weston.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Stephen R. Fogg, P.E. EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Westwood, Town ofPublic Schools220 Nahatan St.Westwood, MA 02090
Andrew T. Johnson Co., 15 Tremont Place, Boston, MA 02108, 617-742-1610, Reed Construction Data, Dodge Report/McGraw-Hill, 6/30/10 at 2:00 P.M.
PHONE: 617-547-5400CONTACT INFORMATION
PROJECT NUMBER: 08098.01
FAX: 617-354-5758
PROJECT:Thurston Middle School Driveway and Landscape Improvement Project.
ESTIMATED COST: $200,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid conference and site walk-through: 7/7/10 at 9:00 A.M. at Thurston Middle School, 850 High St., Westwood.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Steve Szramiak EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
51
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Winchendon, Town ofDepartment of Public Works109 Front St.Winchendon MA 01475
Above agency address.
PHONE: 978-297-0170CONTACT INFORMATION
PROJECT NUMBER: Bid # 2011-01 and # 2011-02
FAX: 978-297-5403
PROJECT:Paving and Reclamation and related work on various town streets.
ESTIMATED COST: $350,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Michael P. Murphy sr EMAIL: [email protected]
CONTRACTOR QUALIFICATION: Department of Highway
AGENCY:Capital Asset Management, Division of (DCAM) ***SUB-BIDS ONLY***1 Ashburton Place Room 1610Boston, MA 02108
DCAM Bid Room at the above agency address or online at www.comm-pass.com, 6/30/10.
PHONE: 617-727-4003CONTACT INFORMATION
PROJECT NUMBER: UMB0502 DC3
FAX: 617-727-5514
PROJECT:RFQs for Construction Sub-Contractors: Interim Structural Stabilization and Various Repairs, (Medium Voltage Electrical)at UMass Boston, Harbor Campus, Boston.
ESTIMATED COST: $22,000,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Medium Voltage Electrical ($1,500,000.00)
SUB BID DEADLINE: 7/15/10 @ 12:00 P.M. GENERAL BID DEADLINE:
ADDITIONAL INFORMATION Firms interested in bidding on the Medium-Voltage Electrical Sub-Trade must submit a Qualifications Statement by the deadline and be pre-qualified. This RFQ is the first part of a two-part procurement process for Trade Sub-Contractors. Once pre-qualified, firms will be invited to submit bids for this sub-category. The designer is Simpson, Gumpertz & Hegar.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
DCAM Bid Room EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
52
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Capital Asset Management, Division of (DCAM)1 Ashburton Place Room 1610 ***CORRECTED***Boston, MA 02108
DCAM Bid Room at the above agency address, 6/23/10, 8:30 A.M. - 4:30 P.M.
PHONE: 617-727-4003CONTACT INFORMATION
PROJECT NUMBER: UMW1001# HC1
FAX: 617-727-5514
PROJECT:The project is to provide and install two new boilers and related equipment in the basement of the CERC Building. The category of work is Mechanical or HVAC.
ESTIMATED COST: $442,226.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Electrical
SUB BID DEADLINE: 7/8/10 @ 12:00 P.M. GENERAL BID DEADLINE: 7/16/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid walk-through: 6/29/10 at 10:00 A.M. at the CERC Building, 200 Trapelo Rd., Waltham. Contact Robert Harvey, 617-727-4030 ext. 228. The Designer is R.D Kimball Co., Inc., 200 Brickstone Square, Andover, MA 01801, 978-296-6200. Plan deposit is $50*** (refundable) in the form of a Company check or money order, payable to the Commonwealth of Massachusetts.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
DCAM Bid Room EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Conservation and Recreation, Department of (DCR)251 Causeway St. 6th FloorBoston, MA 02114
Above agency address.
PHONE: 617-626-1497/617-626-1428CONTACT INFORMATION
PROJECT NUMBER: P10-2630-C1A
FAX: 617-626-1449
PROJECT:Renovations to the Connors Pool Facility. All Bidders must be DCAM Certified in the work they are bidding on. GCs must be DCAM Certified as a General Contractor
ESTIMATED COST: $5,000,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Masonry; Roofing & Flashing; Metal Windows; Glass & Glazing; Lathing & Plastering; Painting; Plumbing; HVAC; Electrical
SUB BID DEADLINE: 7/21/10 @ 11:00 A.M. GENERAL BID DEADLINE: 7/28/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/15/10 at 10:30 A.M. at 148 Newton St., Waltham. There is no Charge for CD's. A Business Card is required to obtain a CD. All bidders must submit DCAM Certification with their bids.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Josh Kane, Engineer/J. Mae Cabral for CDs EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
53
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Conservation and Recreation, Department of (DCR)251 Causeway St. Suite 600Boston, MA 02114-2104
Above agency address, 6/30/10 at 9:00 A.M.
PHONE: 617-626-1391CONTACT INFORMATION
PROJECT NUMBER: P10-2654-C1A
FAX: 781-278-5701
PROJECT:The project consists of the rehabilitation of the Otis Reservoir Dam, including the rehabilitation of the existing spillway, outlet works and embankment improvements. Project Title: Otis Reservoir Dam Rehabilitation.
ESTIMATED COST: $3,000,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bidding conference: 7/9/10 at 10:00 A.M. at Otis Reservoir Dam, Otis. A set of plans and specs in electronic format on a compact disk (CD) will be available at the above agency address at no charge. In addition, all prospective bidders, at the time project plans and specifications are requested from DCR, must submit a complete R109 Request for Proposal Form in order to acquire plans and specifications. A bidder requesting a CD by mail must send to DCR a complete FedEx label with an account number. For technical questions, contact Matthew Taylor at 781-278-5803. For plans and specs contact Max Santana at [email protected].
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Max Santana for plans & specs; Matthew Taylor, for technical questions EMAIL: [email protected];; matthew.taylor@gza.
CONTRACTOR QUALIFICATION:
AGENCY:Convention Center Authority, MassachusettsAdministrative OfficesBoston Convention and Exhibition Center415 Summer St.Boston, MA 02210
Above agency address, 6/30/10, 9:00 A.M. - 5:00 P.M.
PHONE: 617-954-2177CONTACT INFORMATION
PROJECT NUMBER:
FAX: 617-954-2297
PROJECT:Boston Convention and Exhibition Center Marquee and Video Wall Project.
ESTIMATED COST: $2,000,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Miscellaneous Metals, Electrical, Plumbing, Masonry
SUB BID DEADLINE: 7/23/10 @ 12:00 P.M. GENERAL BID DEADLINE: 7/28/10 @ 12:00 P.M.
ADDITIONAL INFORMATION Pre-bid Conference: 7/8/10 at 1:00 P.M. DCAM Certificate: General Construction.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Theresa Ruane EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
54
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Fitchburg State CollegeCapital Planning and Maintenance160 Pearl St.Fitchburg, MA 01420
Nashoba Blue, 433 Main St., Hudson, MA 01749, 978-568-1167, 7/2/10 during regular business hours.
PHONE: 978-665-3423CONTACT INFORMATION
PROJECT NUMBER: C010 Bid # F81-11
FAX: 978-665-3682
PROJECT:Anthony Phase 3 Renovations. This Project is open to Bidders holding a DCAM Prime/General Certificate of Eligibility in the General Building Construction category of work.
ESTIMATED COST: $900,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: 220000 Plumbing, 230000 HVAC, 260000 Electrical
SUB BID DEADLINE: 7/16/10 @ 10:00 A.M. GENERAL BID DEADLINE: 7/28/10 @ 10:00 A.M.
ADDITIONAL INFORMATION Pre-Bid Conference: 7/9/10 at 9:00 A.M. in the Dupont Building Conference Room at Fitchburg State College. The first set of Bid Documents per bidholder are free. Additional sets per bidholder are $50 per set (non-refundable). Bid Documents may be mailed on request for a fee of $50 (non-refundable) per mailed set (covers handling and mailing charges). Fitchburg State College reserves the right to waive any informalities or reject any bids if it is in the public interest to do so. Prevailing Wage Rates apply.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Nancy FitzGerald EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Franklin Regional Transit Authority (FRTA) ***SUB-BIDS ONLY***474 Main St.Greenfield, MA 01301
Above agency address, by calling 413-774-2262, or by email to [email protected], 6/30/10, 9:00 A.M. - 4:00 P.M. or online at www.comm-pass.com.
PHONE: 413-774-2262CONTACT INFORMATION
PROJECT NUMBER:
FAX: 413-772-2202
PROJECT:Construction of a regional transit center facility in Greenfield. Main features include a 22,000 square foot, zero-net energy (ZNEB) transit center building and associated site and utility work. This RFQ is re-issued for specific sub-trades, pursuant to 810 CMR 10.08(11)(a). SOQs for General Contractors and for all other FSB categories have already been received as the result of a prior RFQ. The prior RFQ resulted in fewer than three responses for the Elevators and Fire Protection FSB categories. The present re-issued RFQ is directed only to Elevator and Fire Protection FSB subcontractors.
ESTIMATED COST: $11 Million
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Elevators, Fire Protection
SUB BID DEADLINE: 7/15/10 @ 1:00 P.M. GENERAL BID DEADLINE:
ADDITIONAL INFORMATION This advertisement is a solicitation for pre-qualified bidders, the first phase of a two-step process, as provided in M.G.L. c. 149, § 44D¾ . In Phase I, FRTA will select respondents it deems to be pre-qualified in accordance with the criteria set forth in the RFQ. Only Subcontractor firms pre-qualified for this project in Phase I will be permitted to submit bids in Phase II. This required SOQ is different from DCAM Certification. All filed sub-bids contractors must be pre-qualified for this project, even they are already DCAM Certified.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Michael Perrault, Assistant Administrator, FRTA EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
55
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Manchester/Essex Regional School DistrictSchool Building Committee36 Lincoln St.Manchester, MA 01944
Marshall/Gary, 200 Harvard Mills Square Suite 402, Wakefield, MA 01880, 6/30/10 at 2:00 P.M.
PHONE: 978-526-4919CONTACT INFORMATION
PROJECT NUMBER: 0602.01
FAX: 978-526-7585
PROJECT:Three Tennis Courts. The work consists of earthwork, drainage, paving, fencing, retaining wall, lawns and planting.
ESTIMATED COST: $400,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid site inspection: 7/7/10 at 10:00 A.M. $50 deposit for Bid Documents plus $25 for mailing.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Avi Urbas EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Port Authority, Massachusetts Capital Programs DepartmentOne Harborside DriveEast Boston, MA 02128
Above agency address, 6/25/10.
PHONE: 617-568-5950CONTACT INFORMATION
PROJECT NUMBER: M384-C1
FAX: 617-568-5998
PROJECT:Ship Bollards Replacement at Black Falcon Cruise Terminal, South Boston.
ESTIMATED COST: $190,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/21/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Bid Documents in electronic format may be obtained free of charge at the above agency address with any addenda or amendments that the Authority may issue and a printed copy of the Proposal form.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
To Ly EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
56
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Port Authority, Massachusetts Capital Programs DepartmentOne Harborside DriveEast Boston, MA 02128
Above agency address, 6/23/10.
PHONE: 617-568-5950CONTACT INFORMATION
PROJECT NUMBER: HP1110-C1
FAX: 617-568-5998
PROJECT:FY 11-12 Airfield Pavement Repairs Term Contract, Hanscom Airfield, Bedford.
ESTIMATED COST: $225,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Bid Documents in electronic format may be obtained free of charge at the above agency address with any addenda or amendments that the Authority may issue and a printed copy of the Proposal form.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Joe Gaidis EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Public Health, Department of Tewksbury HospitalFacilities Office365 East St.Tewksbury MA 01876-1998
Above agency address, 6/30/10 at 12:00 P.M.
PHONE: 978-8517321 ext. 2802CONTACT INFORMATION
PROJECT NUMBER: THCP0106
FAX: 978-858-3829
PROJECT:Security Fence: Demolition and removal of existing fence and the installation of a new security fence.
ESTIMATED COST: $45,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Walk-Through: 7/7/10 at 9:00 A.M. in the C1 Conference Room of the Saunders Building at the above agency address. Plans/Specs will not be mailed, faxed or emailed. Tewksbury Hospital will arrange to have FedEx pick up plans/specs at your expense by emailing a request to [email protected] and including a mailing address and FedEx account number. There is no charge for these plans/specs.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Roger Gauthier, Maintenance Coordinator for External Programs EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
57
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Salem State CollegeFacilities DepartmentAdministration Building352 Lafayette St. 2nd FloorSalem, MA 01970
Above agency address, 6/30/10 at 11:00 A.M.
PHONE: 978-542-6004CONTACT INFORMATION
PROJECT NUMBER: SSC 2010-D, Contract No. 2
FAX: 978-542-7700
PROJECT:Located at 70 Loring Ave., this ARRA-funded project includes build-out of second floor office space and some corollary first floor work. The work includes but is not limited to roofing and flashing, metal windows, acoustical ceilings, fire protection, plumbing, HVAC and electrical work. Owner will occupy its first floor spaces and a separate first floor construction project will be underway during the entire second floor construction period. This is to be considered a "Green Friendly" project, but certification is not being sought. The General Contractor and Subcontractors must recognize LEED standards with respect to all demolition, disposal and new construction work.
ESTIMATED COST: $1,300,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Roofing & Flashing; Metal Windows; Acoustical Tile; Plumbing; HVAC; Electrical.
SUB BID DEADLINE: 7/21/10 @ 11:00 A.M. GENERAL BID DEADLINE: 7/28/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-bid conference: 7/2/10 at 10:00 A.M. at the site. Bidding Documents may be examined at the above agency address and sets of Documents may be obtained by depositing $100 per set in the form of a company, treasurer's, cashier's or bank check, payable to Salem State College (SSC). Refund will be made to those returning the Documents in satisfactory condition within ten working days after the general bid opening, otherwise the deposit will become the property of SSC. SSC will not mail documents. Messenger and other types of delivery services are agents of the Bidder. SSC assumes no responsibility for the timely delivery or receipt of Bidding Documents. To ensure a sufficient quantity of Documents remains on hand, SSC requests that bidders call in advance of anticipated time of pickup.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Phil Merkle EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:University of Massachusetts - AmherstPhysical Plant Division360 Campus Center WayAmherst, MA 01003-9248
Procurement Department, Goodell Building, 140 Hicks Way Room 407, Amherst, MA 01003, 6/30/10 at 2:00 P.M.
PHONE: 413-545-0361CONTACT INFORMATION
PROJECT NUMBER: UMAPP11-008
FAX: 413-545-1643
PROJECT:Campus: Berkshire, Hampshire and Middlesex Houses Exterior Painting.
ESTIMATED COST: $150,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Mandatory Pre-bid meeting: 7/7/10 at 11:00 A.M. in the Physical Plant Conference Room at the above agency address.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Peter Royer EMAIL:
CONTRACTOR QUALIFICATION: DCAM Certificate
58
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:University of Massachusetts - AmherstProcurement OfficeGoodell Building140 Hicks Way Room 407Amherst, MA 01003
Above agency address, 6/30/10.
PHONE: 413-545-0361CONTACT INFORMATION
PROJECT NUMBER: UMA11-01
FAX:
PROJECT:Fine Arsts Center Curtain Theater Dimming System Upgrade. Category of Work: Electrical.
ESTIMATED COST: $40,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/7/10 at 10:00 A.M. at the Fine Arts Center Curtain Theater.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Peter Royer EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:University of Massachusetts - DartmouthFoster Administration Building285 Old Westport Rd. Room #008North Dartmouth, MA 02747
Above agency address, 6/30/10, 9:00 A.M. - 4:00 P.M.
PHONE: 508-999-9223CONTACT INFORMATION
PROJECT NUMBER: DD11HF2
FAX: 508-999-8120
PROJECT:Resident Dining Hall First Floor Office Renovation: Minor renovations to office suite; Two new metal stud and gypsum board walls to underside of deck/slab, One wall is fire rated corridor, the other is new office separation wall; Minor flex duct work with relocated diffusers; Minor alterations to ceiling tiles; New carpet and one new door.
ESTIMATED COST: $23,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Site Visit: 7/7/10 at 9;00 A.M. at the above agency address. No plan deposit required.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Doreen D. Arruda EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
59
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:University of Massachusetts - Lowell 883 Broadway St.Lowell, MA 01854
Nashoba Blue, Inc., 433 Main St., Hudson, MA 01749, 978-568-1167 or online at www.biddocsonline.com (may be viewed electronically or hard copy requested).
PHONE: 978-934-3500CONTACT INFORMATION
PROJECT NUMBER: CL11-MD-0011
FAX: 978-934-5070
PROJECT:Interior Signs for UMass Lowell.
ESTIMATED COST: $250,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/14/10 @ 11:00 A.M.
ADDITIONAL INFORMATION Pre-Bid Conference: 7/6/10 at 11:00 A.M. at the UMass Lowell Board of Trustees Room, Cumnock Hall, One University Ave., Lowell.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Michael Durkin EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
AGENCY:Wannacomet Water CompanyBoard of Water CommissionersOne Milestone Rd.Nantucket, MA 02554
Haley & Ward, Inc., 25 Fox Rd., Waltham, MA 02541, 6/30/10, 8:00 A.M. - 4:30 P.M.
PHONE: 781-890-3980CONTACT INFORMATION
PROJECT NUMBER: 2010-1
FAX: 781-890-1491
PROJECT:Madaket Road Water Main and Appurtenant Work.
ESTIMATED COST: $1,265,000.00
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/15/10 at 1:00 P.M. at the above agency address. Plans and specifications deposit is $50.00 (refundable) in the form of a check, payable to Haley & Ward, Inc. To have plans and specifications mailed, please send a non-refundable check for $25.00, payable to Haley & Ward, Inc., 25 Fox Rd., Waltham, MA 02451. Please view www.haleyward.com for any additional information.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Leo R.Yuskus EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
60
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Water Resources Authority, Massachusetts (MWRA)Charlestown Navy Yard100 First Ave. Building 39Boston, MA 02129
7/2/10.
PHONE: 617-242-6000CONTACT INFORMATION
PROJECT NUMBER: OP-134
FAX: 617-788-4896
PROJECT:Crane Maintenance Service.
ESTIMATED COST: $170,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 3:00 P.M.
ADDITIONAL INFORMATION Pre-bid conference: 7/7/10 at 11:00 A.M. in Conference Room 1B, Chelsea Facility, 2 Griffin Way, Chelsea. Contact MWRA's Document Distribution Office at 617-788-2575 to obtain bid documents.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Al Bhatti EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Water Resources Authority, Massachusetts (MWRA)Charlestown Navy Yard100 First Ave. Building 39Boston, MA 02129
6/30/10.
PHONE: 617-242-6000CONTACT INFORMATION
PROJECT NUMBER: 6795
FAX: 617-788-4896
PROJECT:Prison Point CSO Facility HVAC and Odor Control Systems Upgrade. Contractor Category: HVAC.
ESTIMATED COST: $3,100,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES: Division 16 - Electrical
SUB BID DEADLINE: 7/27/10 @ 11:30 A.M. GENERAL BID DEADLINE: 8/19/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid conference: 7/14/10 at 10:00 A.M. at the Prison Point Facility in Cambridge. Attendees must contact Kim Dennis at 617-305-5728 by 7/13/10 at 12:00 P.M. for access instructions/directions. Contact MWRA's Document Distribution Office at 617-788-2575 to obtain bid documents. Funding Source for work to be performed under this contract is the Massachusetts Water Pollution Abatement Trust.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Meredith Norton EMAIL: [email protected]
CONTRACTOR QUALIFICATION: DCAM Certificate
61
CENTRAL REGISTER - GENERAL CONTRACTSPublic Contracts that are construction related and estimated to exceed $10,000. Published two weeks prior to general bid opening.CR-2
AGENCY:Worcester State CollegeAdministration Building486 Chandler St. Room 330Worcester, MA 01602
Above agency address, 7/1/10 after 2:00 P.M.
PHONE: 508-929-8462CONTACT INFORMATION
PROJECT NUMBER: 10-11
FAX: 508-929-8167
PROJECT:This project generally consists of removal of existing wooden footbridge and installation of new precast/prestressed concrete plank footbridge with metal guardrail system in addition to a custom fabricated, metal trash rack at existing spillway adjacent to footbridge.
ESTIMATED COST: $85,000
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/22/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid walk-through: 7/13/10 at 10:00 A.M. at Lake Ellie, located near the track and field on campus. There is no fee and no deposit for the plans and specifications. Plans and specifications will not be mailed unless a UPS or FedEx shipper number is provided.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Nicole LeBlanc EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
AGENCY:Worcester State CollegeAdministration Building486 Chandler St. Room 330Worcester, MA 01602
Above agency address, 6/30/10. Office Hours: Monday - Friday, 8:00 A.M. - 4:00 P.M.
PHONE: 508-929-8462CONTACT INFORMATION
PROJECT NUMBER: 10-13
FAX: 508-929-8167
PROJECT:Provide preventative maintenance and repairs on the College's Commercial kitchen and refrigeration equipment, parts, repairs or emergency repairs on an as needed basis as well as regularly scheduled preventative maintenance.
ESTIMATED COST: $30,000/Year
PLANS/SPECIFICATIONS AVAILABLE(place, date and time)
(required for building contracts over $100,000 and highway contracts over $50,000)
CONTRACT INFORMATION:
SUB BID CATEGORIES:
SUB BID DEADLINE: GENERAL BID DEADLINE: 7/15/10 @ 2:00 P.M.
ADDITIONAL INFORMATION Pre-bid meeting: 7/8/10 at 10:00 A.M. at the first floor entrance of the Student Center Building located on campus. Specifications will not be mailed. Please email company and contact information to [email protected] to request specifications. This is a prevailing wage job.
(date and time)(date and time)
AWARDING AUTHORITY AND PROJECT INFORMATION
Nicole LeBlanc EMAIL: [email protected]
CONTRACTOR QUALIFICATION:
62
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Agawam, Town of Office of the Mayor36 Main St.Agawam, MA 01001
PROJECT NUMBER: 08-2046PROJECT: Roadway/Parking Redesign at Agawam Housing Authority.
AWARDING AUTHORITY:
CONTACTRick Misiaszek
PHONE 413-786-9600 FAX: 413-786-8699EMAIL: [email protected]
Mountain View Landscapes & Lawncare, Inc.67 Old James St.Chicopee, MA 01020
Morais Concrete Service, Inc.108 Rocus St.Springfield, MA 01104
C. & A. Construction Co., Inc.P.O. Box 377157 Carmelina's CircleLudlow, MA 01056
The Lane Construction Corp.P.O. Box 491Westfield, MA 01086
A. Martins & Son Construction, InP.O. Box 51421Indian Orchard, MA 01151
Gomes Construction Co., Inc.136 Carmelina’s CircleLudlow, MA 01056
AGENCY:
Andover, Town of 36 Bartlet St.Andover, MA 01810
PROJECT NUMBER: Bid No. 027/06-10/301PROJECT: Miscellaneous Road Materials and Aggregates.
AWARDING AUTHORITY:
CONTACTElaine M. Shola, Purchasing Agent
PHONE 978-623-8216 FAX: 978-623-8240EMAIL: [email protected]
Heffron MaterialsP.O. Box 176North Reading, MA 01864
Bateson Enterprises, Inc.111 Argilla Rd.Andover, MA 01810
Pavement Maintenance Systems P.O. Box 3848Peabody, MA 01961
P.J. Keating Co.998 Reservoir Rd.Lunenburg, MA 01462
Jayco Landscape Supply Co., Inc.94 West St.Waltham, MA 02451
Brox Industries, Inc.1471 Methuen St.Dracut, MA 01826-5439
F.P. Reilly & Son, Inc.206 Andover St. #11Andover, MA 01810
Benevento Asphalt Corp., Sand &Stone DivisionP.O. Box 454Wilmington, MA 01887
Felix Marino Co.P.O. Box 43132 Corwin St.Peabody, MA 01960
Allied Paving 38 Graniteville Rd.Chelmsford, MA 01824
Newport Construction Corp.164 Burke St. Suite 1ANashua, NH 03060
Kingston Corp.61 Camelot DrivePlymouth, MA 02360
W.L. French Excavating Corp.3 Survey CircleNorth Billerica, MA 01862
Aggregate Industries1715 BroadwaySaugus, MA 01906
AGENCY:
Andover, Town of36 Bartlet St.Andover, MA 01810
PROJECT NUMBER: WR001/06-10/185PROJECT: Screening and Refinishing of Hardwood Floors in Gymnasiums, Halls
and Stages Throughout Various Andover Schools,
AWARDING AUTHORITY:
CONTACTElaine M. Shola, Purchasing Agent
PHONE 978-623-8216 FAX: 978-623-8216EMAIL: [email protected]
Rainbow Floors, LLC680 Nortontown Rd.Guilford, CT 06437
63
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Andover, Town of36 Bartlet St.Andover, MA 01810
PROJECT NUMBER: Bid No. 028/06-10/301PROJECT: Painting of Road Markings.
AWARDING AUTHORITY:
CONTACTElaine M. Shola, Purchasing Agent
PHONE 978-623-8216 FAX: 978-623-8240EMAIL: [email protected]
Markings, Inc.30 Riverside DrivePembroke, MA 02359
HiWay Safety Systems, Inc.9 Rockview WayRockland, MA 02370
R.P.M. Sweeping160 Andover St.Wilmington, MA 01887
J.M.'s Painting & Contracting Co22 Washington St.Dedham, MA 02026
AGENCY:
Andover, Town of36 Bartlet St.Andover, MA 01810
PROJECT NUMBER: Bid No. 030/06-10/185PROJECT: Sanborn Elementary School Chimney Liner, Andover.
AWARDING AUTHORITY:
CONTACTElaine M. Shola, Purchasing Agent
PHONE 978-623-8216 FAX: 978-623-8240EMAIL: [email protected]
Santa General Construction4 Russell CourtWoburn, MA 01801
ProjectDog18 Graf Rd. Suite 8Newburyport, MA 01950
Boston Chimney & Tower Co., LLP.O. Box 272Peabody, MA 01960-6772
Enterprise Equipment Co., Inc.276 Libbey ParkwayWeymouth, MA 02189
International Chimney Corp.55 South Long St.Williamsville, NY 14221
Allied Weatherproofing Co., Inc.P.O. Box 4265Andover, MA 01810
International Chimney Corp.P.O. Box 260Buffalo, NY 14231-0260
AGENCY:
Andover, Town of36 Bartlet St.Andover, MA 01810
PROJECT NUMBER: Bid No. 031/06-10/185PROJECT: South Elementary School Chimney Repairs, Andover.
AWARDING AUTHORITY:
CONTACTElaine M. Shola, Purchasing Agent
PHONE 978-623-8216 FAX: 978-623-8240EMAIL: [email protected]
Santa General Construction4 Russell CourtWoburn, MA 01801
J.M.'s Painting and Contracting Co22 Washington St.Dedham, MA 02026
Contracting Specialists, Inc.453 South Main St.Attleboro, MA 02703
ProjectDog18 Graf Rd. Suite 8Newburyport, MA 01950
Boston Chimney & Tower Co., LLP.O. Box 272 Peabody, MA 01960-6772
Enterprise Equipment Co., Inc.276 Libbey ParkwayWeymouth, MA 02189
International Chimney Corp.55 South Long St.Williamsville, NY 14221
Allied Weatherproofing Co., Inc.P.O. Box 4265Andover, MA 01810
Folan Waterproofing & ConstructioCo., Inc.795 Washington St.South Easton, MA 02375
64
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Barnstable, Town of Department of Public Works230 South St.Hyannis, MA 02601
PROJECT NUMBER: 07-000-10-001PROJECT: Bridge Rehabilitation, Mill/Keveny Lane Bridge.
AWARDING AUTHORITY:
CONTACTDenise Geoffrion
PHONE 508-862-4091 FAX: 508-862-4711EMAIL: denise,[email protected]
A.G.M. Marine Construction30 Echo Rd.Mashpee, MA 02649
U.E.L. Contractors, Inc.270 Airport Rd.Fitchburg, MA 01420
Bay State Regional Contractors73 Desert Sands LaneYarmouth Port, MA 02675
Northern Construction Services775 Pleasant St.Weymouth, MA 02189
Jobs2bid30 Controls Drive Suite 200Shelton, CT 06484
E.T. & L. Corp.P.O. Box 295873 Great Rd. Suite 202Stow, MA 01775
Lawrence Lynch Corp.P.O. Box 913396 Gifford St.Falmouth, MA 02541
Manual R. Pavao Contractors, InP.O. Box 2602 Brook St.Rehoboth, MA 02769
Pavao Construction Co., Inc.1892 County St.Dighton, MA 02715
Chapman Waterproofing395 Columbia Rd.Boston, MA 02155
Tasco Construction92 Stony Brook Rd.Belmont, MA 02178
James A. Gross, Inc.55 East Main St. Suite 7Webster, MA 01570
Wes Construction Corp.650 Industrial DriveHalifax, MA 02338
Robert Briggs49 Telegraph Rd.Dennis Port, MA 02639
P.A. Landers351 Winter St.Hanover, MA 02339
AGENCY:
Barnstable, Town of Procurement230 South St.Hyannis, MA 02601
PROJECT NUMBER:PROJECT: Barnstable High School Chiller Replacement Project.
AWARDING AUTHORITY:
CONTACTJohanna Boucher
PHONE FAX:EMAIL:
REMSCO, Inc.310 South St.Plainville, MA 02762
Montle Plumbing &; Heating Co., 432 Jefferson St. Fall River, MA 02721-5111
HealthyAirSolution, Inc.29 Walnut Rd.Norwell, MA 02061
Dawn WarburtonP.O. Box 526 Marstons Mills, MA 02648
Banner Environmental Services, In16 Back River Way Duxbury, MA 02332
D.D.S. Industries, Inc.250 Ace St.Fall River, MA 02720
Integrity Mechanical Contractors, I89 North Water St. New Bedford, MA 02740
Wind River Environmental577 Main St. Hudson, MA 01749
Enterprise Equipment Co., Inc.276 Libbey Parkway Weymouth, MA 02189
Sparks Co., Inc.451 Long Highway Little Compton, RI 02837
Johnson Controls, Inc.2 Starline Way Unit #8 Cranston, RI 02921
M.M. Environmental Engineering153 Wagon TrailHanson, MA 02341
C.A.M. HVAC116 Lydia Ann Rd.Smithfield, RI 02917
AALANCO80B Turnpike Rd.Westborough, MA 01581
Poirier &; Springer, Inc.17E Sterling Rd.Billerica, MA 01862
Trane50 Vision BoulevardEast Providence, RI 02914
Seekonk Heating Services, Inc.911 Taunton Ave. Seekonk, MA 02771
Independent Mechanical ContractoInc.29 Cummings Park Suite 422Woburn, MA 01801
Multitemp Mechanical Corp.231 Norfolk St. Walpole, MA 02081
Multitemp Mechanical Corp.231 Norfolk St. Walpole, MA 02081
Mercury Mechanical Services, Inc.855 Washington St. Weymouth, MA 02189
REMSCO, Inc. 310 South St. Plainville, MA 02762
Onvia1260 Mercer St. Seattle, WA 98109
65
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Cambridge, City of Purchasing Department 795 Massachusetts Ave.Cambridge, MA 02139
PROJECT NUMBER: 5232PROJECT: First Street Parking Garage 2010 Waterproofing.
AWARDING AUTHORITY:
CONTACTCynthia Griffin
PHONE 617-349-4310 FAX: 617-349-4008EMAIL:
ProjectDog 18 Graf Rd.Newburyport, MA 01950
CProjects.com 30 Controls Drive Shelton, CT 06484
AGENCY:
Cambridge, City of Purchasing Department 795 Massachusetts Ave.Cambridge, MA 02139
PROJECT NUMBER: 5231PROJECT: 2010 Water Works Construction Contract.
AWARDING AUTHORITY:
CONTACTCynthia Griffin
PHONE 617-349-4310 FAX: 617-349-4008EMAIL: [email protected]
R.H. White Construction 41 Central St. Auburn, MA 01501
Tufts, Inc. 142 Mystic Ave.Medford, MA 02155
ProjectDog18 Graf Rd.Newburyport, MA 01950
Acoustical Thermal Insulators, In101 Old Bedford Rd. Westport, MA 02790
Century Drywall, Inc.1992 Louisquisset Pike Lincoln, RI 02865
Water Works Supply Corp.869 Eastern Ave. Malden, MA 02148
AGENCY:
Cambridge, City of Purchasing Department 795 Massachusetts Ave.Cambridge, MA 02139
PROJECT NUMBER: 5227PROJECT: Energy Management System Repair Maintenance and Monitoring.
AWARDING AUTHORITY:
CONTACTCynthia Griffin
PHONE 617-349-4310 FAX: 617-349-4008EMAIL: [email protected]
Johnson Controls, Inc., Systems & Service 39 Salem St.Lynnfield, MA 01940-5240
AGENCY:
Cambridge, City of Purchasing Department 795 Massachusetts Ave.Cambridge, MA 02139
PROJECT NUMBER: 5224PROJECT: Cambridge Reservoir Gate House Improvements.
AWARDING AUTHORITY:
CONTACTCynthia Griffin
PHONE 617-349-4310 FAX: 617-349-4008EMAIL: [email protected]
Folan Waterproofing & ConstructioCo.795 Washington St.South Easton, MA 02375
L.M. Heavy Civil Construction, LL10 Commerce Way Westford, MA 01886
66
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Cambridge, City of Purchasing Department 795 Massachusetts Ave.Cambridge, MA 02139
PROJECT NUMBER: 5219PROJECT: Cambridge Park Drive Area Drainage Improvements Project Contract
12.
AWARDING AUTHORITY:
CONTACTCynthia Griffin
PHONE 617-349-4310 FAX: 617-349-4008EMAIL: [email protected]
L.M. Heavy Civil Construction, LL10 Commerce Way Westford, MA 01886
Pilh, Inc. 35 North St. Suite 200Canton, MA 02021
Mass Bay Electrical Corp. 125 Orleans St.East Boston, MA 02128
Oldcastle Precast 41 Almedia Rd.Rehoboth, MA 02769-1097
AGENCY:
Danvers, Town ofHousing Authority14 Stone St.Danvers, MA 01923
PROJECT NUMBER:PROJECT: Redevelopment of Rand Circle Federal Housing Project.
AWARDING AUTHORITY:
CONTACTJames Haskell
PHONE 508-648-5548 FAX: 978-356-1512EMAIL: [email protected]
B.S.C. Group15 Elkins St.Boston, MA 02127
N.O.A.H.143 Border St.East Boston, MA 02128
AGENCY:
Franklin, Town of 355 East Central St.Franklin, MA 02038
PROJECT NUMBER: 2010-44PROJECT: Wachusett Roadway.
AWARDING AUTHORITY:
CONTACTNorma Collins
PHONE 508-553-4866 FAX: 508-541-5253EMAIL: [email protected]
John J. Amara & Sons, Inc.P.O. Box 366344Hyde Park, MA 02136
Walsh Contracting Corp.82 North Ave.Attleboro, MA 02703
DeFelice Corp.366 BroadwayDracut, MA 01826
AGENCY:
Franklin, Town of 355 East Central St.Franklin, MA 02038
PROJECT NUMBER: 2010-28PROJECT: Solar Panels at Parmenter School.
AWARDING AUTHORITY:
CONTACTNorma Collins
PHONE 508-553-4866 FAX: 508-541-5253EMAIL: [email protected]
Broadway Electrical Co., Inc.295 Freeport St.Boston, MA 02122
Waterline Industries7 London LaneSeabrook, NH 03784
Wayne Griffin Electric116 Hopping Brook Rd.Holliston, MA 01746
67
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Lynn, City ofHousing Authority and Neighborhood Development92 Curwin CircleLynn, MA 01905
PROJECT NUMBER: 09-AJA04PROJECT: HCP Conversion of six Units with three buildings at Curwin Circle,
MA 23-1.
AWARDING AUTHORITY:
CONTACTArnold Jacobson Associates
PHONE 781-935-2500 FAX: 781-935-2519EMAIL: [email protected]
New England Builders & Contracto290 Broadway Suite 137Methuen, MA 01844
N.G. Environmental Contractors, L49 Blanchard St. Suite 107Lawrence, MA 01843
AGENCY:
Lynn, City ofPurchasing Department3 City Hall Square Room 205Lynn,MA 01901
PROJECT NUMBER: 03-51PROJECT: Restoration of the Lynn Classical High School Athletic Field.
AWARDING AUTHORITY:
CONTACTCharles E.White
PHONE 781-586-6893 FAX: 781-477-7027EMAIL: [email protected]
Mennino Construction Co., Inc.76 Oakville St.Lynn, MA 01905
G.V.W., Inc.1200 Bennington St.East Boston, MA 02128
H.J. Contracting Solutions, Inc.6 Millett LaneSwampscott, MA 01907
Weed & Feed, Inc.d/b/a D.H.T. Golf Services8 Meadow Park Rd. Unit 3Plymouth, MA 02360
ProjectDog18 Graf Rd. Unit 8Newburyport, MA 01950
CProjects.com/Jobs2bid.com30 Controls Drive Suite 200Shelton, CT 06484
AGENCY:
Millbury, Town of 127 Elm St.Millbury, MA 01527
PROJECT NUMBER:PROJECT: Building Maintenance and Repair Service for On-Call Electrician.
AWARDING AUTHORITY:
CONTACTJoyce Ostrowski
PHONE 508-865-4710 FAX:EMAIL: [email protected]
Ostrow Electric Co.9 Mason St.Worcester, MA 01609
Coviello Electric77 Mystic Ave.Medford, MA 02155
Brite-Lite Electrical Co., Inc.11 Front St.Weymouth, MA 02188
ProjectDog18 Graf Rd.Newburyport, MA 01950
Staiti Electric222 Peterson Rd.Palmer, MA 01069
Raymond Croteau Electric244 Burlingame Rd.Palmer, MA 01069
Renaud Electric & CommunicationInc.18 Providence Rd.Sutton, MA 01590
68
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Millbury, Town of 127 Elm St.Millbury, MA 01527
PROJECT NUMBER:PROJECT: Building Maintenance and Repair Service for On-Call Plumbing.
AWARDING AUTHORITY:
CONTACTJoyce Ostrowski
PHONE 508-865-4710 FAX:EMAIL: [email protected]
Grasseschi Plumbing & Heating, In1299 Grafton St.Worcester, MA 01604
ProjectDog18 Graf Rd.Newburyport, MA 01950
Scott Gervais Plumbing60 Berlin St.Auburn, MA 01501
AGENCY:
Monson, Town of Board of Selectmen110 Main St.Monson, MA 01057
PROJECT NUMBER:PROJECT: Park Avenue Infrastructure Improvements.
AWARDING AUTHORITY:
CONTACTPaul Bracciotti
PHONE 413-781-6045 FAX: 413-732-2593EMAIL: [email protected]
Pioppi Construction727 Tipton Rock Rd.Southbridge, MA 01550
Baltazar Contractors83 Carmelina's CircleLudlow, MA 01056
Caracas Construction592 Holyoke St.Ludlow, MA 01056
Mass-West Construction50 West State St.Granby, MA 01033
Borges Construction165 Carmelina's CircleLudlow, MA 01056
Jack Goncalves & Sons172 Munsing St.Ludlow, MA 01056
Ricciardi Brothers, Inc.20 Envelope TerraceWorcester, MA 01604
U.E.L. Contractors270 Airport Rd.Fitchburg, MA 01420
A. Pereira Construction Co.11 Chapin St.Ludlow, MA 01056
J.L. Raymaakers & Sons Construct1106 East Mountain Rd.Westfield, MA 01085
A. Martins & Sons Construction250 Verge St.Springfield, MA 01129
Palmer Paving25 Blanchard St.Palmer, MA 01069
Gomes Construction Co., Inc.136 Carmelina's CircleLudlow, MA 01056
Morais Concrete108 Rocus St.Springfield, MA 01104
C. Naughton Corp.48 Dorothea DriveWeymouth, MA 02188
Vellano Brothers69 Neck Rd.Westfield, MA 01085
Ludlow Construction19 Carmelina's CircleLudlow, MA 01056
AGENCY:
Natick, Town ofBoard of Selectmen75 West St.Natick, MA 01760
PROJECT NUMBER: W-125PROJECT: Installation of Springvale Gravel Packed Wells.
AWARDING AUTHORITY:
CONTACTGregory J. Eldridge, P.E.
PHONE 781-890-3980 FAX: 781-890-1491EMAIL: [email protected]
Denis L. Maher Co.P.O. Box 13019 Westford Rd.Ayer, MA 01432-0130
Maher Services, Inc.71 Concord St.North Reading, MA 01864
Frank G. Sullivan Drilling Co., Inc408 Parker Rd.Lancaster, MA 01523
McGraw-Hill Construction3315 Central Ave.Hot Springs, AR 71913
69
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Natick, Town ofBoard of Selectmen75 West St.Natick, MA 01760
PROJECT NUMBER: W-124PROJECT: Rehabilitation of the Town Forest and Broad Hill Reservoirs.
AWARDING AUTHORITY:
CONTACTGregory J. Eldridge, P.E.
PHONE 781-890-3980 FAX: 781-890-1491EMAIL: [email protected]
G.V.W., Inc.1200 Bennington St.East Boston, MA 02128
R.M. Pacella, Inc.3 Madison St.Plainville, MA 02762
Bridges, LLCP.O. Box 405Sandown, NH 03873
AGENCY:
North Reading, Town ofSchool DepartmentSherman Rd.North Reading, MA 01864
PROJECT NUMBER: M03009-FPROJECT: North Reading Middle School and High School Roof Replacement.
AWARDING AUTHORITY:
CONTACTHeather DeLorey
PHONE 617-241-2807 FAX: 617-241-2857EMAIL: [email protected]
M.D.M. Engineering51 Sawmill Rd.Dudley, MA 01571
ProjectDog18 Graf Rd. Suite 8Newburyport, MA 01950
Reed Construction Data30 Technology Parkway South Suit500Norcross, GA 30092-2912
McGraw-Hill Construction/DodgReports3315 Central Ave.Hot Springs, AR 71913
Gibson Roofs, Inc.369 Winter St.Hanover, MA 02339
Commercial Roofing & ContractinInc.P.O. Box 647340 Kennedy DrivePutnam, CT 06260
Greenwood Industries, Inc.P.O. Box 2800Worcester, MA 01613-2800
Capeway Roofing Systems, Inc.P.O. Box 708664 Sanford Rd.Westport, MA 02790
J.D. Rivet & Co., Inc.P.O. Box 51068Indian Orchard, MA 01151
Eagle Rivet Roof Service Corp.1030 New Britain Ave. RearWest Hartford, CT 06110
S.R.C. Roofing, Inc.166 Brook Rd.Quincy, MA 02169
Rockwell Roofing, Inc.44 Pond St.Leominster, MA 01453
P.O. Roofing, LLC3 Dolge CourtOxford, MA 01540
Signature Roofing Systems, Inc.P.O. Box 335Norwell, MA 02061
Newton Roofing Co.69 Howard St.Watertown, MA 02472
Weathershield, Inc.69 West St.Milford, MA 01757
70
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Pittsfield, City of70 Allen St.Pittsfield, MA 01201
PROJECT NUMBER: 10-049PROJECT: Demolition of Two Buildings.
AWARDING AUTHORITY:
CONTACTColleen Hunter-Mullett
PHONE 413-499-9470 FAX: 413-499-9463EMAIL:
Northern Foundations, Inc.290 Hubbard Ave.Dalton, MA 01226
D. Condron Construction, Inc.721 South Main St. Lanesboro, MA 01237
J.H. Maxymillian, Inc.1801 East St.Pittsfield, MA 01201
Form-All Construction Services, 34C Britton St.Pittsfield, MA 01201
Associated Building Wreckers352 Albany St.Springfield, MA 01105
Donovan Construction Co.94 Merriam St.Pittsfield, MA 01201
Francesco Demolition12 Canoe Club LanePembroke, MA 02359
Jay-Mor Enterprises, Inc.P.O. Box 195Bridge St.Pelham, NH 03076
John’s Tractor & Excavation Servi21 Old Williamstown Rd.Lanesboro, MA 01237
L.B. Corp.P.O. Box 388 Lee, MA 01238
Waterman Excavating, Inc.P.O. Box 555Cheshire, MA 01225
C.G. Blacktop & ConstructionP.O. Box 1671Pittsfield, MA 01202
AGENCY:
Watertown, Town ofDepartment of Public Works124 Orchard St.Watertown, MA 02472
PROJECT NUMBER: 10-01WPROJECT: Construction of Water Main Replacement.
AWARDING AUTHORITY:
CONTACTJudy Ketcham
PHONE 978-692-1913 FAX: 978-692-4578EMAIL: [email protected]
Aqualine Utility, Inc.268 Washington St.East Bridgewater, MA 02333
U.E.L. Contractors, Inc. 270 Airport Rd. Fitchburg, MA 01420
S.B. General Contracting 14 Renmar Ave. Walpole, MA 02081
Revoli Construction 90 Earl's WayFranklin, MA 02038
FED Corp. 1039 East St. Dedham, MA 02026
Reed Construction Data 20 Technology Parkway South Suit500 Norcross, GA 30092
N. Granese & Sons 18 Yorkshire Rd. Marblehead, MA 01945
G.T.A. Co., Inc. 140 Tremont St. Everett, MA 02149
Dodge Reports 34 Crosby Drive Suite 201 Bedford, MA 01730
Ventresca, Inc. 3 Thomas Circle Stoneham, MA 02180
M.E. Smith, Inc. 109 Hastings Rd. Spencer, MA 01562
Mattuchio Construction 323 Commercial St. Malden, MA 02148
Ferguson Waterworks 2 Whitman Rd. Canton, MA 02021
71
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Weymouth, Town of75 Middle St.Weymouth, MA 02189
PROJECT NUMBER:PROJECT: LED Traffic Signals.
AWARDING AUTHORITY:
CONTACTAdele Cullinane
PHONE 781-682-3843 FAX: 781-331-3378EMAIL: [email protected]
Traffic Signals224 North Fehr WayBay Shore, NY 11706
Dagle Electrical Construction Corp285 Salem St.Woburn, MA 01801
Republic I.T.S.8 Progress Rd.Billerica, MA 01821
Energy Conservation, Inc.P.O. Box 726Hanson, MA 02341
J.E. Guertin, Inc.280 Irving St.Framingham, MA 01702
Highway TechP.O. Box 12098 Sabattus Rd.Sabattus, ME 04280
Prime Vendor4622 Cedar Ave.Wilmington, NC 28403
Blais Electrical Corp.15 Proctor St.Framingham, MA 01702
Hank Chen1663 Second St.Pomona, CA 91766
AGENCY:
Norfolk County 614 High St.Dedham, MA 02026
PROJECT NUMBER:PROJECT: Upgrade of Electrical System and New Generator for the Norfolk
County Registry of Deeds.
AWARDING AUTHORITY:
CONTACTNancy McNealy
PHONE 781-461-6139 FAX: 781-326-6480EMAIL: [email protected]
Gemini Electric, Inc.8 Priscilla LaneAuburn, NH 03030
Annese Electrical Services280 Libbey Industrial ParkwayWeymouth, MA 02189
ProjectDog18 Graf Rd. Suite 9Newburyport, MA 01950
Hub Electric Service10 Draper St. Unit 19Woburn, MA 01801
Brite Lite Electrical Co.11 Front St.Weymouth, MA 02188
Dodge Reports34 Crosby Drive Suite 101Bedford, MA 01730
Dagle Electrical Corp.285 Salem St.Melrose, MA 02178
AGENCY:
Onset Fire DistrictBoard of Water CommissionersP.O. Box 17115 Sand Pond Rd.Onset, MA 02558
PROJECT NUMBER: 16PROJECT: Gravel Packed Well No. 7.
AWARDING AUTHORITY:
CONTACTBethany Santangelo
PHONE 781-890-3980 FAX: 781-890-1491EMAIL: [email protected]
Maher Services, Inc.71 Concord St.North Reading, MA 01864
72
CENTRAL REGISTER - PERSONS RECEIVING BIDDING DOCUMENTSCR-5
AGENCY:
Salem State College 352 Lafayette St. Salem, MA 01970
PROJECT NUMBER: SSC 2010-A, Contract # 2PROJECT: Located at 70 Loring Ave., this ARRA-funded project includes first
floor shops, offices, breakroom and two new stairways and a new two-stop elevator.
AWARDING AUTHORITY:
CONTACTPhil Merkle
PHONE 978-542-6004 FAX: 978-542-7700EMAIL: [email protected]
Linwood Construction, LLC561 Windsor St.Somerville, MA 01243
Seaver Construction, Inc. 57 Russell St. Level 2 Woburn, MA 01801
Brite Lite Electrical Co.11 Front St.Weymouth, MA 02188
T.L.T. Construction Corp.One Pope St.Wakefield, MA 01860
Delta Elevator Service Corp.115 Shawmut Rd.Canton, MA 02011
Capone Iron Corp. 20 Turcotte Memorial Drive Rowley, MA 01969
Prism Builder, Inc.107 Audubon Road Building 1Wakefield, MA 01880
Wayne J. Griffin Electric, Inc.116 Hopping Brook Rd.Holliston, MA 01746
N.E.R. Construction Management 867 Woburn St.Wilmington, MA 01887
Kneeland Plumbing & Heating, Inc63 Hammond St. Rowley, MA 01969
Massey Construction Corp. 144 Stetson Ave.Swampscott, MA 01907
Hall Sheetmetal Works, Inc. 11 River St. #1 Middleton, MA 01949
United Elevator Company, Inc. 150 Recreation Park Drive Suite #8Hingham, MA 02043
Northern Contracting Corp.68 Jackson St. Canton, MA 02021
V. & G. Iron Works, Inc. 1500 Shawsheen St. Tewksbury, MA 01876
Ostrow Electric Co.9 Mason St.Worcester, MA 01609
Capital Masonry Corp.277 South St.Walpole, MA 02081
G.V.W.1200 Bennington St. East Boston, MA 02128
Reed Construction Data 30 Technology Parkway South Suit500Norcross, GA 30092
The McGraw-Hill Co., Inc./F.W.Dodge East Plan Acquisition34 Crosby Drive Suite 201 Bedford, MA 01730
ProjectDog 18 Graf Rd. Suite 8Newburyport, MA 01950
P.J. Dionne Co., Inc.60 Jonspin Rd.Wilmington, MA 01887
Quinn Brothers of Essex, Inc. 239 Western Ave. Essex, MA 01929
Royal Steam Heater Co.499 Main St.Gardner, MA 01440
Essex County Craftsmen, Inc. 60 Ward St.Salem, MA 01970
Thomas E. Snowden, Inc. 189 Central St. Saugus, MA 01906
Chapman Waterproofing Co.395 Columbia Rd.Dorchester, MA 02125
73
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Billerica, Town ofHousing Authority16 River St.Billerica, MA 01821
Bob Cox
PHONE: 978-667-2175
DESCRIPTION:16 River Street Roof Replacement.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER:
FAX: 978-667-1156
CONTRACT AMOUNT:
$193,200.00Joe Squillante, Inc.13 Doane Rd.Medford, MA 02155
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Boston, City of Public Facilities Department26 Court St.Boston, MA 02108
Ken MacDonald
PHONE: 617-635-4807
DESCRIPTION:Winthrop School Life Safety and Accessibility Project.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 6837
FAX: 617-635 4852
CONTRACT AMOUNT:
$1,106,800.00Northern Contracting Corp.P.O. Box 9668 Jackson St.Canton, MA 02021
Sub Contract Award:
EMAIL:
PROJECT TYPE: General Contract
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave.Cambridge, MA 02139
Cynthia H. Griffin
PHONE: 617-349-4310
DESCRIPTION:Improvements to City Clerk and Public Work Archive Vaults.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 5206
FAX: 617-349-4008
CONTRACT AMOUNT:
$247,462.00Eagle Point Builders, Inc.54 Burnham St.Belmont, MA 02178
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
74
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Cambridge, City ofPurchasing Department795 Massachusetts Ave.Cambridge, MA 02139
Cynthia H. Girffin
PHONE: 617-349-4310
DESCRIPTION:FY 10, Contract 2: Remedial Reconstruction of Sanitary Sewers, Combined Sewers and Storm Drains and Emergency Work.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 5207
FAX: 617-349-4008
CONTRACT AMOUNT:
$683,423.56Mattuchio Construction Co.323 Commercial St.Malden, MA 02148
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Everett, City ofHousing Authority393 Ferry St.Everett, MA 02149
John P. Coddington, Executive Director
PHONE: 617-387-6389
DESCRIPTION:Furnace Replacement Project: 326 units at the Ch. 200-1 Russell Street and Ch. 200-2 Winthrop/Duncan Road neighborhoods.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: DHCD FISH #093042
FAX: 617-389-4936
CONTRACT AMOUNT:
$1,588,000.00E. Amanti & Sons, Inc.390 Highland Ave.Salem, MA 01970
Sub Contract Award: $96,728: Brothers Electrical Co., LLC, 16 Pheasant Lane, Topsfield, MA 01983.
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Fitchburg, City of Office of the Purchasing Agent718 Main St.Fitchburg, MA 01420
Lois Ogilvie
PHONE: 978-345-9576
DESCRIPTION:Road resurfacing, reclamation, cold planning and bituminous in place.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER:
FAX: 978-345-9588
CONTRACT AMOUNT:
$2,768,171.00P.J. Keating Co.998 Reservoir Rd.Lunenburg, MA 01462
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
75
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Fitchburg, City of Office of the Purchasing Agent718 Main St.Fitchburg, MA 01420
Lois Ogilvie
PHONE: 978-345-9576
DESCRIPTION:Fitchburg High School and Longsjo Middle School Surveillance System Upgrades.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: �
FAX: 978-345-9588
CONTRACT AMOUNT:
$69,430.00Ostrow Electric Co.9 Mason St.Worcester, MA 01609
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Lynn, City ofPurchasing Department3 City Hall Square Room 205Lynn, MA 01901
Charles E. White
PHONE: 781-586-6893
DESCRIPTION:Replacement of Dust Collection System at Lynn Vocational Technical Institute.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER:
FAX: 781-477-7027
CONTRACT AMOUNT:
$74,331.00Eugene Ricciardelli, Inc.P.O. Box 632856 Salem St.Lynnfield, MA 01940
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Newton, City of 1000 Commonwealth Ave.Newton, MA 02459
Re Cappoli
PHONE: 617-796-1220
DESCRIPTION:Zervas School Boiler Replacement.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 10-60
FAX: 617-796-1227
CONTRACT AMOUNT:
$146,630.00Fraser Engineering Co., Inc. 65 Court St.Newtonville, MA 02460-9142
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
76
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Newton, City of 1000 Commonwealth Ave.Newton, MA 02459
Re Cappoli
PHONE: 617-796-1220
DESCRIPTION:Replacement of Emergency Generator at Peirce Elementary School.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 10-51
FAX: 617-796-1227
CONTRACT AMOUNT:
$157,800.00Systems Electrical Services, Inc.387 Prospect PlaceRevere, MA 02151
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:North Andover, Town of 120 Main St.North Andover, MA 01845
Ray Santilli
PHONE: 978-688-9516
DESCRIPTION:General Contractor services for additions/alterations to Chief's secretary's office at new North Andover Police Station.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER:
FAX: 978-688-9556
CONTRACT AMOUNT:
$34,500E.M.J. Corp.800 South St. Suite 370Waltham, MA 02453
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: Designer Services
AGENCY:North Brookfield, Town ofHousing Authority271 North Main St.North Brookfield, MA 01535
Agnes Davis
PHONE: 508-867-2826
DESCRIPTION:Scope of Work: EMG, exterior repairs, Grove Street School Apartments 705-1.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 198021004
FAX: 508-867-2826
CONTRACT AMOUNT:
$153,880.00P. & P. General ContractorsP.O. Box 518Webster, MA 01570
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
77
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Templeton, Town ofHousing Authority99 Bridge St.Baldwinville, MA 01436
Templeton Housing Authority
PHONE: 978-939-2374
DESCRIPTION:Roof and Window replacement at 667-1 Elderly/Handicapped Housing, Phoenix Court Development.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: DHCD FISH 294014
FAX: 978-939-2374
CONTRACT AMOUNT:
$488, 250.00Alpha Contracting Associates, Inc.P.O. Box 87020 Mulberry LaneDedham, MA 02026
Sub Contract Award: F.G.F. Construction Network Service, Inc.52A Shirving Rd.Epping, NH 03042
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:University of Massachusetts - Amherst140 Hicks WayAmherst, MA 01003
Peter Royer Associate Director of Procurement
PHONE: 413-545-0361
DESCRIPTION:Conte Polymer Chiller: Install New Chiller.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: UMA10-45
FAX: 413-5451643
CONTRACT AMOUNT:
$328,890.00Inglewood Development Corp.123 Dwight Rd.Longmeadow, MA 01106
Sub Contract Award: 15000 HVAC: B. & G. Mechanical, $121,765. 16000 Electrical: Zap Electrical, Inc., $99,519.
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Westfield, City of 59 Court St.Westfield, MA 01085
Tammy Tefft
PHONE: 413-572-6254
DESCRIPTION:Cold Planning and Profiling and Bituminous Concrete in place.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 2214
FAX: 413-572-1708
CONTRACT AMOUNT:
Lane ConstructionP.O. Box 491Westfield, MA 01086
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
78
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Development Finance Agency, Massachusetts 160 Federal St. 7th FloorBoston, MA 02110
Kathryn Giardi or Sarah Nelson, Winter Street Architects
PHONE: 978-744-7379 ext. 132
DESCRIPTION:State Pier Office Building Renovation, 2 State Pier, Gloucester: Sub-bid work includes purchase and installation of the windows related to the renovation of the office building on the Jodrey Street State Pier.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER:
FAX: 978-741-0240
CONTRACT AMOUNT:
$230,154.00Prism Builders107 Audubon Rd.Wakefield, MA 01880
Sub Contract Award: Windows: A. & A. Window Products, 15 Joseph St., Malden, MA 02148. Painting: Bello Painting Co., 585 East St., Weymouth, MA 02189.
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Springfield Technical Community CollegeP.O. Box 9000One Armory SquareSpringfield, MA 01102-9000
Margaret Solitario
PHONE: 413-755-4700
DESCRIPTION:B02 AC System Replacement: Install two new Liebert Model DS042ADA0E1929A where existing Edpac units are located. Project includes removal and disposal of Edpac units, Freon, Gylcol, wiring and old controls.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 2010-20
FAX: 413-755-6040
CONTRACT AMOUNT:
$76,761.00AALANCO Service Corp.80B Turnpike Rd.Westborough, MA 01581
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
79
CENTRAL REGISTER - CONTRACT AWARDCR-4
AGENCY:Springfield Technical Community CollegeP.O. Box 9000One Armory SquareSpringfield, MA 01102-9000
Margaret Solitario
PHONE: 413-755-4700
DESCRIPTION:B02 Fire Protection System Replacement: Remove existing Halon fire suppression system in building 2 room 100 and all related equipment, piping, wiring and controls. Install new with new fully functional FM 200 Fire suppression system.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: 2010-21
FAX: 413-755-6040
CONTRACT AMOUNT:
$45,400.00Carlysle Engineering, Inc.132 Brookside Ave.Jamaica Plain, MA 02130
Sub Contract Award:
EMAIL: [email protected]
PROJECT TYPE: General Contract
AGENCY:Whittier Regional Vocational Technical High School District115 Amesbury Line Rd.Haverhill, MA 01830-1898
Mark C. Lydon
PHONE: 781-494-9000
DESCRIPTION:Whittier Regional Technical Vocational High School Roof Replacement.
AWARDING AUTHORITY:
CONTACT INFORMATION:
CONTRACT AWARDED TO:
PROJECT NUMBER: MSBA ID 200908850605
FAX: 781-494-9007
CONTRACT AMOUNT:
$1,542,000Greenwood Industries50 Howe Ave.Millbury, MA 01527
Sub Contract Award: Painting: King Painting, North Andover. Plumbing: Araujo Brothers Plumbing & Heating, New Bedford.
EMAIL: [email protected]
PROJECT TYPE: General Contract
80
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Boston, City ofHousing AuthorityProcurement Department52 Chauncy St.Boston, MA 02111
BHA Procurement Department
PHONE 617-988-4041
DESCRIPTION OF PROPERTY:
The Boston Housing Authority (BHA) invites interested Development Partners to submit proposals for the implementation of the Old Colony Phase Two redevelopment project. The successful Development Partner must demonstrate the ability and experience to implement a comprehensive mixed-finance, mixed-income, mixed-use rental redevelopment plan. Award of the contract is subject to approval by HUD and an award of HOPE VI or other HOPE VI-like federal funding.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: BHA 10D-OC-005
FAX 617-988-4292
ESTIMATED VALUE, SOURCE OF VALUATION:$4.5 Million.
PROPOSAL DEADLINE DATE AND TIME:
7/30/10
ADDITIONAL INFORMATION The BHA’s contribution for this redevelopment project is estimated at $14.5 million based on the federal funding that is expected to be made available. Complete details, qualification and submission requirements can be found in the RFP. RFP packages are available free of charge by email request to [email protected]. Hard copy RFP Packages may be obtained at the above agency address, 9:00 A.M. - 5:00 P.M. for a non-refundable fee of $100 in the form of check or money order, payable to the BHA. The RFP package will be mailed to prospective respondents upon request for an additional $15 fee. Questions or requests for modifications regarding this RFP will be accepted in writing only until 7/9/10 at 2:00 P.M.
Email: [email protected]
12:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Chicopee, City ofTreasurer's Office274 Front St.Chicopee, MA 01013
Brian Salamon Purchasing Agent
PHONE 413-594-1557
DESCRIPTION OF PROPERTY:
The City of Chicopee is seeking proposals for the redevelopment of a residential lot located Mckinstry Ave. (Map 393, Parcel 22) containing approximately 6,113 square feet of property. The City acquired title to the property by virtue of a land court judgment in a tax lien case.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: 10/36
FAX 413-594-1577
ESTIMATED VALUE, SOURCE OF VALUATION:$58,300 by City of Chicopee Assessor's Office.
PROPOSAL DEADLINE DATE AND TIME:
7/30/10
ADDITIONAL INFORMATION Please contact Ernie Laflamme, City Treasurer at 413-594-1562.
Email: [email protected]
11:00 A.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
81
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Great Barrington, Town of 334 Main St.Great Barrington, MA 01230
Kevin O'Donnell, Town Manager
PHONE 413-528-1619 ext. 2
DESCRIPTION OF PROPERTY:
Former Housatonic School complex, 207 Pleasant St., Housatonic: Masonry and wood frame construction, approximately 21,662 square feet (includes basement level, first and second floors). Lot size is .65 acres (28,622 square feet.)
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
FAX 413-528-2290
ESTIMATED VALUE, SOURCE OF VALUATION:$1,188,200 according to Assessor's records.
PROPOSAL DEADLINE DATE AND TIME:
7/30/10
ADDITIONAL INFORMATION Optional pre-proposal visit: 7/9/10 at 10:00 A.M. at the site. RFP Package and related information available at www.townofgb.org.
Email: [email protected]
2:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Hopkinton, Town ofPublic Schools89 Hayden Rowe St.Hopkinton, MA 01748
Geoffrey MacDonald, Director of Finance
PHONE 508-417-9385
DESCRIPTION OF PROPERTY:
The Hopkinton Public Schools is seeking approximately 5000 square feet of office space to house its central administration functions in the vicinity of 88 Hayden Rowe St. The description of property needs, evaluation criteria, proposal submission requirements and general contract terms and conditions are set forth in the proposal specifications. The district is currently leasing office space at 89 Hayden Rowe St. and is seeking the equivalent.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: RE-1
FAX 508-497-9833
ESTIMATED VALUE, SOURCE OF VALUATION:
PROPOSAL DEADLINE DATE AND TIME:
8/2/10
ADDITIONAL INFORMATION Please call Geoffrey MacDonald at 508-417-9385 with any questions.
Email: [email protected]
4:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
82
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Rehoboth, Town ofBoard of Selectmen 148 Peck St.Rehoboth, MA 02769
David J. Marciello, Town Administrator
PHONE 508-252-3758 ext. 107
DESCRIPTION OF PROPERTY:
Best value project proposal for installation of a large scale ground mounted photovoltaic electric production facility on land owned by the Town of Rehoboth.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
FAX 508-252-5342
ESTIMATED VALUE, SOURCE OF VALUATION:$100,000/Year, or best value, for ten+ years.
PROPOSAL DEADLINE DATE AND TIME:
8/4/10
ADDITIONAL INFORMATION For copy of RFP, contact Helen Dennen at the above agency address, 508-252-3758 ext. 107 or [email protected].
Email: [email protected]
10:00 A.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Springfield, City of Office of Procurement36 Court St. Room 405Springfield, MA 01103
Lauren Stabilo
PHONE 413-787-6284
DESCRIPTION OF PROPERTY:
Purchase of Unique Property from the Roman Catholic Bishop of Springfield, a corporation sole. The City is faced with a number of old school buildings that needed to be closed or in need of immediate reconstruction. The City is in need of school facilities immediately to accommodate students both during reconstruction of existing schools and due to the obsolescence of existing schools. To build a new school would be cost prohibitive to the City and would take years and is insufficient to meet the City's immediate need. For the period commencing in August, 2010, the City will lease the facility for $320,300 per annum, net lease, for three years with the option to extend for two more years.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: Bid No. 10-589
FAX 413-787-6295
ESTIMATED VALUE, SOURCE OF VALUATION:$320,300 per annum by current appraisal.
PROPOSAL DEADLINE DATE AND TIME:
ADDITIONAL INFORMATION Our Lady of Mt. Carmel is located on 36 Margaret St., Springfield. Approximately 32,030 square feet, on three levels, with on-site parking. Renovations to existing buildings are time consuming and do not satisfy the City's immediate need. The Catholic Diocese of Springfield has closed its Mt. Carmel School. This facility meets the City's needs, is virtually turn key and is immediately available.
Email: [email protected]
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
83
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Springfield, City of Office of Procurement36 Court St. Room 405Springfield, MA 01103
Lauren Stabilo
PHONE 413-787-6284
DESCRIPTION OF PROPERTY:
The City of Springfield is requesting proposals for the sale/redevelopment of various residential properties: SS Quincy St., parcel 10015-0128; SS Quincy St., parcel 10015-0119; NS Quincy St., parcel 10015-0018; NS Quincy St., parcel 10015-0023; SS Quincy St., parcel 10015-0101; SS Union St., parcel 11750-0203; SS Union St, parcel 11750-0231 and 11750-0233; SS Tyler St., parcel 11715-0081; 236 Tyler St.; 245 Tyler St.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: Bid No. 11-004
FAX 413-787-6295
ESTIMATED VALUE, SOURCE OF VALUATION:$5,000 Minimum bids for properties.
PROPOSAL DEADLINE DATE AND TIME:
8/4/10
ADDITIONAL INFORMATION Site Tours: 7/14/10 and 7/21/10, 10:00 A.M. - 10:45 A.M. at 236 Tyler St.; 7/14/10 and 7/21/10, 11:00 A.M. - 11:45 A.M. at 245 Tyler St. No additional tours can be accommodated. All attendees should bring flashlights.
Email: [email protected]
2:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Springfield, City ofParking Authority150 Bridge St.Springfield, MA 01103-1417
Harold King
PHONE 413-787-6118
DESCRIPTION OF PROPERTY:
The Springfield Parking Authority (SPA) in Springfield will receive sealed bids for the purchase of the parking garage and property at 41 Harrison Ave., Springfield. The property consists of 1.75± acres of land (78,059 square feet per City of Springfield records), located in Springfield at the intersection of Harrison Ave. and Dwight St. The parking structure is located between Harrison Ave. and East Court St. (Falcon’s Way). The structure serves approximately 750 monthly parkers working in the area. The major venue serviced is the MassMutual Convention Center. The facility was constructed in 1971 and consists of five parking levels and one on-grade level providing parking for approximately 1232 vehicles. The total parking area for the six level structure is approximately 375,000 square feet or approximately 75,000 square feet per typical parking level.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: 2010-001
FAX 413-787-6165
ESTIMATED VALUE, SOURCE OF VALUATION:$12,875,009.
PROPOSAL DEADLINE DATE AND TIME:
8/17/10
ADDITIONAL INFORMATION Bid documents are available at www.parkspa.com.
Email: [email protected]
2:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
84
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Westborough, Town of Town Manager's Office34 West Main St.Westborough, MA 01581
James Malloy, Town Manager
PHONE 508-366-3030
DESCRIPTION OF PROPERTY:
The property is located at 146 Oak St. and consists of 3.33 acres of land, improved by a two story wood frame dwelling, constructed in 1820. The building contains 3,696 square feet of open living area with forced hot water oil heat, an asphalt roof and has access to town water and sewer. There is also a shed on the property. The property was listed in the National Register of Historic Places in 1980 and is currently zoned Highway Business.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: Nathan Fisher Hse-RFP2010
FAX 508-366-3099
ESTIMATED VALUE, SOURCE OF VALUATION:$875,100 Total Value.
PROPOSAL DEADLINE DATE AND TIME:
8/2/10
ADDITIONAL INFORMATION Building Value is $359.800, Land Value is $515,300. A tour of the property will be conducted on 7/8/10 at 10:00 A.M. All inquiries or questions regarding this RFP should be in writing no later than 7/16/10 and directed to James J. Malloy, Town Manager at the above agency address, by fax to 508-366-3099 or by email to [email protected].
Email: [email protected]
12:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Winchendon, Town ofRedevelopment Authority109 Front St.Winchendon, MA 01475
Gerald W. White
PHONE 978-297-5418
DESCRIPTION OF PROPERTY:
Property is an island in Lake Momomonac. It is mostly wooded and is located just south of the New Hampshire border. Property is approximately .75 acres (assessor's Map M1 0 3).
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
FAX 978-297-5411
ESTIMATED VALUE, SOURCE OF VALUATION:$25,800 by Town assessor.
PROPOSAL DEADLINE DATE AND TIME:
8/2/10
ADDITIONAL INFORMATION Bid packages may be obtained by contacting Gerald W. White. Electronic packages are the preference. There will be building restrictions.
Email: [email protected]
3:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
85
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Bay Transportation Authority, Massachusetts (MBTA)c/o Transit Realty Associates, LLC (TRA)77 Franklin St. 9th FloorBoston, MA 02110
Paul Dawson
PHONE 617-482-2525
DESCRIPTION OF PROPERTY:
Operation of MBTA system-wide payphones plus opportunity for ancillary services. License Term: Four years plus two two-year option terms.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
FAX 617-482-0210
ESTIMATED VALUE, SOURCE OF VALUATION:$10,000/Year Minimum Annual Guaranteed Fee.
PROPOSAL DEADLINE DATE AND TIME:
8/11/10
ADDITIONAL INFORMATION RFP and offer forms must be obtained from the TRA website at www.transitrealty.com or from TRA at the above agency address. Award will be based on Best Value to the MBTA.
Email: [email protected]
1:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Capital Asset Management and Maintenance, Division of (DCAM)1 Ashburton Place 15th FloorBoston, MA 02108
Warren A. Madden, Project Manager, OREM
PHONE 617-727-8090 ext. 565
DESCRIPTION OF PROPERTY:
DCAM, pursuant to M.G.L. c. 7, § 40H is soliciting proposals to lease the existing water tower within the former Medfield State Hospital site, 45 Hospital Rd., Medfield, not to exceed 5,000± Square Feet for ancillary equipment. The proposed lease term is ten years with an option to be extended for two additional five-year periods. Proposals are sought from individuals or entities that provide wireless telecommunication services (e.g. cellular and personal communication providers, radio common carriers and paging companies) and are licensed by the Federal Communications Commission (FCC) ("Wireless Telecommunications Service Provider(s)" or "Service Provider(s)") or that install, manage and operate telecommunications equipment and can procure Service Providers to the Site ("Facilities Management Company" or "Companies"). All proposals will be subject to local zoning and bylaws, if applicable.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
FAX 617-727-6074
ESTIMATED VALUE, SOURCE OF VALUATION:
PROPOSAL DEADLINE DATE AND TIME:
10/1/10
ADDITIONAL INFORMATION All proposals for the first submission deadline must be received at the above agency address, as specified in the RFP, no later than 10/1/10 at 5:00 P.M. All proposals will be opened at the Office of Real Estate Management at the above agency address at the deadline. The Commonwealth reserves the right to reject any and all proposals it may receive.
Email: [email protected]
5:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
86
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Capital Asset Management and Maintenance, Division of (DCAM)on behalf of Fitchburg State College1 Ashburton PlaceBoston, MA 02108
Thatiana Gibson, Project Manager
PHONE 617-727-8090 ext. 588
DESCRIPTION OF PROPERTY:
Fee simple interest in one 1047 square foot single family home on approximately 2,420 square feet of land located at 145 North St., Fitchburg. The Commissioner of the Division of Capital Asset Management and Maintenance has determined that competitive advertising will not be beneficial to Commonwealth interests because of the unique qualities or location of the property needed, namely: The property is located within the target area of parcels recently acquired for the college, and is completely surrounded by college properties; This property fronts on North Street approximately at street grade and is blighted by a run-down residential structure; Acquisition of this property is needed to allow the College to eliminate blight on North Street and to assemble a large parcel which can in a cost-effective manner be converted to surface parking via demolition of existing structures and paving.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: REVISED
FAX 617-727-6074
ESTIMATED VALUE, SOURCE OF VALUATION:$120,000 Proposed Price.
PROPOSAL DEADLINE DATE AND TIME:
ADDITIONAL INFORMATION Names of Parties Having Beneficial Interests in the Property: FSC Foundation Supporting Organization, Inc.
Email: [email protected]
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
AGENCY:Transportation, Department of (MassDOT)Office of Real Estate and Asset DevelopmentTen Park Plaza Suite 4470Boston, MA 02116-3969
Frank Vallarelli
PHONE 617-248-2987
DESCRIPTION OF PROPERTY:
Property is a rectangular-shaped parcel, located outside layout lines of Route 3 South, and off Route 44/Samoset St., abutting Nathaniel St., in the Town of Plymouth. Parcel is bounded on the east side by a Commonwealth Electric Utility Easement, on the west by a Commonwealth Gas Utility Easement and Nathaniel Street to the south. Shape: Rectangular. Area: One parcel of land totaling 1.71+/- Acres. Features: Vacant Land. Current Use: Surplus Property. Frontage: Nathaniel St., no access to Route 3 or the Interchange Ramp System. Utilities: Prospective bidders responsible for determining availability and adequacy of any utilities. Zoning: AC (Arterial Commercial). Term: Quitclaim Deed. MassDOT will determine the fair market value of the parcel on the basis of an independent professional appraisal commissioned by MassDOT.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER: Parcel 7-14-UR
FAX 617-248-2906
ESTIMATED VALUE, SOURCE OF VALUATION:
PROPOSAL DEADLINE DATE AND TIME:
8/12/10
ADDITIONAL INFORMATION Parcel will be sold subject to conditions listed and other conditions specified in the RFP and/or Letter of Acceptance issued. Request for proposals from any individual or entity capable of complying with the terms, conditions and restrictions contained. The following information must be included in the proposal: Brief description of proposed use of Parcel; Proposed purchase price for Parcel; Name and contact information of proponent or authorized representative; If applicable, describe legal status of entity. All partners or co-venturers participating must be identified. The legal jurisdiction under which the individual or entity is organized and operating must be indicated. A non-refundable cashier’s check for $2,000 must accompany proposal, to be deducted from the requirements concerning "deposit amounts" from the successful bidder. Proposal cover sheet must be completed, signed and submitted.
Email: [email protected]
5:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
87
CENTRAL REGISTER - ACQUISITION OR DISPOSITION OF REAL PROPERTYThe proposed sale, rental, acquisition or disposition of public property which is 2,500 sq.ft. or more. Must be published 30 days prior to the proposed deadline.CR-3
AGENCY:Capital Asset Management and Maintenance, Division of (DCAM)on behalf of the Lemuel Shattuck Hospital under the care and control of the Department of Public Health1 Ashburton PlaceBoston, MA 02108
Warren A. Madden, Project Manager, OREM
PHONE 617-727-8090 ext. 565
DESCRIPTION OF PROPERTY:
DCAM, on behalf of the Lemuel Shattuck Hospital under the care and control of the Department of Public Health, pursuant to M.G.L. c. 7, § 40H is soliciting proposals to lease portions of the Lemuel Shattuck Hospital site, 170 Morton St., Boston, not to exceed 5,000± Square Feet. The proposed lease term is ten years with an option to be extended for two additional five-year periods. Proposals are sought from individuals or entities that provide wireless telecommunication services (e.g. cellular and personal communication providers, radio common carriers and paging companies) and are licensed by the Federal Communications Commission (FCC) ("Wireless Telecommunications Service Provider(s)" or "Service Provider(s)") or that install, manage and operate telecommunications equipment and can procure Service Providers to the Site (Facilities Management Company or "Companies"). All proposals will be subject to local zoning and bylaws, if applicable.
AWARDING AUTHORITY:
CONTACT INFORMATION:
PROJECT NUMBER:
FAX 617-727-6074
ESTIMATED VALUE, SOURCE OF VALUATION:
PROPOSAL DEADLINE DATE AND TIME:
10/1/10
ADDITIONAL INFORMATION All proposals for the first submission deadline must be received at the above agency address, as specified in the RFP no later than 10/1/10 at 5:00 P.M. All proposals will be opened at the Office of Real Estate Management at the above agency address at the deadline. The Commonwealth reserves the right to reject any and all proposals it may receive.
Email: [email protected]
5:00 P.M.
TRANSACTION TERMS:
ACQUISITION: DISPOSITION:PURCHASE LEASE SALE LEASE
88
DIVISION OF CAPITAL ASSET MANAGEMENT AND MAINTENANCE
OFFICE OF LEASING AND STATE OFFICE PLANNING ONE ASHBURTON PLACE, 14th FLOOR – ROOM 1411
BOSTON, MASSACHUSETTS 02108 617-727-8000
WEEK OF JUNE 27, 2010
LEASED SPACE SOUGHT FOR STATE AGENCIES The Division of Capital Asset Management and Maintenance Office of Leasing and State Office Planning is advertising the availability of the Requests for Proposals (RFPs) listed below. The RFP includes the Lease Proposal form, instructions for submitting proposals, and the Commonwealth standard lease and associated documents. Please note that proposals must be received at the Office of Leasing and State Office Planning at the address listed above by the submission deadline. Proposals received after the deadline will not be considered. You may request an RFP by writing to the address listed above, telephoning the Office at 617-727-8000 x355, or by coming to the Office at the address listed above. When requesting a copy of the RFP, please include the name, address, and telephone and fax numbers of the person to receive the RFP; if you mail in your request, please enclose a business card with this information. Allow up to nine business days for receipt of the RFP by mail. If submitting a proposal by mail or other delivery, please allow sufficient time for receipt of the proposal at the appropriate office as mail is routed internally from a central point. These Request for Proposals can also be obtained through the Internet at: http://www.comm-pass.com Unless otherwise noted, the Commonwealth is seeking a five-year lease. Deadline Project # User Agency Space Type Usable Sq.
Ft.(USF)Location
06/30/10 2:00 PM
201032000.1 Department of Transitional Assistance
Office Approximately 16,400
Burlington, Everett, Lexington, Malden, Medford, Melrose, North Reading, Reading, Stoneham, Wakefield, Wilmington, Winchester, or Woburn
07/07/101
2:00 PM
201033000.1 Executive Office of Health & Human Services, and its Department of Transitional Assistance, Massachusetts Rehabilitation Commission, and the Department of Developmental Services
Office Approximately 18,500
Ashburnham, Ashby, Ayer, Barre, Berlin, Bolton, Clinton, Fitchburg, Gardner, Groton, Harvard, Hubbardston, Lancaster, Leominster, Lunenburg, Pepperell, Princeton, Shirley, Sterling, Templeton, Townsend, Westminster, or Winchendon
Page
2
07/14/101
2:00 PM
201018000.2 Executive Office of Health & Human Services, and its Department of Children & Families, Department of Mental Health, Department of Transitional Assistance and the Massachusetts Rehabilitation Commission
Office Approximately 54,000
Amesbury, Andover, Boxford, Georgetown, Groveland, Haverhill, Lawrence, Merrimac, Methuen, Newbury, Newburyport, North Andover, Rowley, Salisbury, or West Newbury
08/04/10 2:00 PM
201030000.1 Department of Children & Families
Office Approximately 22,800
Chicopee, Ludlow, or Springfield, as further defined on Map Attachment C-5 in the RFP
08/05/10 2:00 PM
201039000.1 Department of Revenue
Office Approximately 21,200
Burlington, Malden, Medford, Reading, Stoneham, Wakefield, or Woburn
1 Ten year term, with Tenant’s right to surrender up to 25% of the Usable Area any time after the third anniversary of the Date of Occupancy
"''''Public awarding authorities are advised to check all three lists. Applicable law prohibitsfirms debarred by either state entities or the federal government from submitting bids or
proposals to any Massachusetts public agency or entity. The law also prohibits public agenciesand entities from soliciting or considering bids or proposalsfrom debarred individuals andfinns
and prohibits execution, renewal or extension of contracts with an individual or finn debarredby any of the above referenced governmental entities.
** Please note that this list consists only of individuals andfirms debarred by the Division ofCapital Asset Management pursuant to G.L. c. 29, §29F and G.L. c. 149, §44C. The
Massachusetts Office of the Attorney General maintains a separate list of additional individualsandfirms debarred by that office that is available in the Central Register or by contacting theAttorney General's Office directly at (617) 727-2200 x. 3277. The United States Government
also maintains a list of contractors debarred by federal agencies which is available on theinternet at httD://enls.arnet.gov
DAVID B. PERINI
COMMISSIONER
LESLIE KIRWAN
SECRETARY
ADMINISTRATION & FINANCE
Tel: (617) 727-4050Fax: (617) 727-5363
CONTRACTORS DEBARRED OR SUSPENDEDBY THE
DIVISION OF CAPITAL ASSET MANAGEIV1ENT
~ The Commonwealth of MassachusettsExecutive Office for Administration and Finance
Division of Capital Asset ManagementOne Ashburton Place
Boston, Massachusetts 02108
DEVAL L. PATRICK
GOVERNOR
TIMOTHY P. MURRAY
WEtrrENANT GOVERNOR
No Firms Are Currently Debarred by the Division of Capital Asset Management,check the resources listed above for other debarments.
«;4
1
THE COMMONWEALTH OF MASSACHUSETTS OFFICE OF THE ATTORNEY GENERAL
ONE ASHBURTON PLACE BOSTON, MASSACHUSETTS 02108
MARTHA COAKLEY (617) 727-2200 ATTORNEY GENERAL TTY (617) 727-4765 www.mass.gov.ago
DEBARMENT LIST: June 10, 2010
1. Milton Marder of 18 Maple Street, Maynard, MA 01754, is debarred for a period of 8
years beginning March 16, 2005 through March 15, 2013. 2. TMJ Construction Corporation, and its owner, Michael Jenkins, both of 72
Amherst Road., Merrimack, NH, 03054, are debarred for a period of 5 years beginning April 13, 2006 through April 12, 2011.
3. James A. Curran, of 7 Curran Lane, Holyoke, MA 01040, is debarred for a period of 5
years beginning April 5, 2006 through April 4, 2011. 4. Rand Stoneworks, Inc. of 326 U.S. Route 1, Scarborough, ME 04074 and John
Jeffrey Rand, its president, of 46 Belfield Road, Cape Elizabeth, ME 04107, are debarred for a period of 10 years beginning March 14, 2007 through March 13, 2017.
5. Shannon Construction Corporation, of 15 Speedway Avenue, Brighton, MA 02134
and Laurence Moloney, its owner, of 15 Highgate Road, Wayland, MA 01778, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties from March 20, 2008 through March 19, 2011.
6. Bay State Painters and Josephine Christopoulos, both of 10 Danielle Drive, Danvers,
MA 01913, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning April 7, 2008 through April 6, 2013.
7. Olympic Painting and Roofing, Inc. and George Vosiliodes, both of 515 Lowell
Street, Peabody, MA 01960, are debarred pursuant to M.G.L. c.152, §25C beginning August 6, 2008 through August 5, 2011.
8. Homer Contracting and Ekatenni Bouboulis, both of 195 Broadway Arlington, MA
02174, are debarred pursuant to M.G.L. c.152, §25C beginning February 23, 2009 through August 22, 2010.
9. American East Painting, Inc. of 56 Ballou Avenue, Dorchester, MA 02124 and Anthony Celestine, its owner are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning August 4, 2009 through August 3, 2010.
2
10. SRS Contractors, Inc. of 153 Winthrop Avenue, Lowell, MA 01851, Sina Min and Sambeth Yim, its owners, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning September 29, 2009 through September 28, 2010. 11. National Abatement of P.O. Box 4386, Peabody, MA 01960 and Jimmy Net, its owner, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning October 1, 2009 through September 30, 2010. 12. Nealco Environmental Services, Inc. of 5 Caspian Way, Dorchester, MA 02125 and Neal Cass, its owner, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning October 27, 2009 through October 26, 2011. 13. Payne Contracting company, Inc. and Emmanuel M. Payne, its owner, both of 34 Mallon Road, Apartment 1, Dorchester, MA 02121, are debarred pursuant to M.G.L. c. 149, § 27C beginning September 29, 2009 through September 28, 2010. 14. Trend Systems, LLC, of 29 Railroad Avenue, Merrimack, NH 03054 and Muhamed Bejtovic, its owner, are debarred pursuant to M.G.L. c. 149, § 27C beginning October 9, 2009 through October 8, 2010. 15. Lima Drywall, LLC, of 1 Grant Way, Yarmouth, MA 02673 and Leonardo Lima, its owner, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning November 12, 2009 through November 11, 2010. 16. Greystone Equipment, LLC and Louis Allard, its owner, both of 26 Greenhill Road,
Johnston, RI, 02919 are debarred pursuant to M.G.L. c. 149, § 27C beginning February 3, 2010 through February 2, 2011.
17. Hallmark Construction Company and Steve M. Allard, its owner, both of 7 Thurber
Boulevard, Smithfield, RI 02117 are debarred pursuant to M.G.L. c. 149, § 27C beginning February 3, 2010 through February 2, 2011.
18. All-Pro Construction Management, LLP of 2 Holly Lane, Hudson, NH, 03051,
Sylvain A. Michaud and Bill Poulin, its owners, are debarred pursuant to a settlement agreement between the Office of the Attorney General and the debarred parties beginning March 31, 2010 through September 30, 2010.
19. Northeast Asbestos Abatement, Inc., of 21 Payne Street, Lowell, MA 0185, Vandy
Duch and Mark Pech, its owners, are debarred pursuant to M.G.L. c. 149, § 27C beginning December 15, 2009 through December 14, 2010.
3
20. Avanti Construction, of 4980 North Main Street, Fall River, MA 02720 and Rodrigo Ziliotto, its owner, are debarred pursuant to M.G.L. c. 149, § 27C beginning April 5, 2010 through April 4, 2011.
21. Borere Builders, LLC, of 59 Coddington Street, Quincy, MA 02169, and Maykon
Oliveira, its owner, are debarred pursuant to M.G.L. c. 149, § 27C beginning April 6, 2010 through April 5, 2011.
22. ABD Construction, LLC, of 1703 Main Street, Weymouth, MA 02190, and Almiro
DaSilva, its owner, are debarred pursuant to M.G.L. c. 149, § 27C beginning April 6, 2010 through April 5, 2011.
23. D. C. Flooring, of 27 Highland Street, Milford, MA 01727, and David J. Carlson, its
owner, are debarred pursuant to M.G.L. c. 149, § 27C beginning March 3, 2010 through March 2, 2011.
24. J. P. Caruso, LLC, of 10 Lookout Terrace, Lynnfield, MA 01940, and Joseph P.
Caruso, its owner, are debarred pursuant to M.G.L. c. 149, § 27C beginning May 6, 2010 through May 5, 2011.
Department of Industrial Accidents600 Washington Street, 7th Floor
Boston, Massachusetts 02111
~ THE COMMONWEALTH OF MASSACHUSETTS
~'IJ---J~I----~. Q --."--.
:;1 .. ';
1•<:1 '~d
~~~., ~o,j •••••,
DEVAL L. PATRICKGovernor
TIMOTHY P. MURRAYLieutenant Governor
PAUL V. BUCKLEYCommissioner
Department of Industrial Accidents Debarment List
Under the provisions of the Workers' Compensation Law, Massachusetts Genem1 Laws, Chapter 152,Section 25C (10), once a business has been issued a Stop Work Order by the Department ofIndustrialAccidents, it is prevented from bidding on or participating in any state or municipal funded contmcts for aperiod of three (3) years and, where applicable, is subject to penalties provided under M.G.L., Chapter 152,Section 25C (5), which provides for imprisonment for not more than one year or by a fine of not more thanone thousand five hundred dollars, or by both such fine and imprisonment.
Companies currently on the debannent list can be found on tlle following link:
http://www .mass. govIElwdl docs/ dialinvestigations/ debarment _list.x1s
The Commonwealth of MassachusettsExecutive Office for Administration and Finance
Division of Capital Asset ManagementOne Ashburton Place
Boston, Massachusetts 02108
DEVAL L. PATRICK Tel: (617) 727-4050 LESLIE KIRWANGOVERNOR Fax: (617) 727-5363 SECRETARY,
ADMINISTRATION & FINANCE
TIMOTHY P. MURRAY DAVID B. PERINILIEUTENANT GOVERNOR COMMISSIONER
CONTRACTORS DECERTIFIED BY THEDIVISION OF CAPITAL ASSET MANAGEMENT
The following contractors are decertified by the Division of Capital Asset Management from bidding on public building work pursuant to M.G.L. Chapter 149. To determine if a contractor is currently certified by DCAM, please check for the contractor’s name on DCAM’s certified contractors’ listings (at www. mass.gov/dcam under Contractor Certification on the “Related Links” menu). In addition, if you are seeking information on debarred contractors specifically, please be sure to also check information posted by state agencies in the Secretary of State’s Central Register publication, as well as with the Massachusetts Attorney General’s Office, Department of Industrial Accidents, and Massachusetts Highway Department. These agencies and their contact information can be found at the State of Massachusetts web site accessed at www.mass.gov.
Contractor: United States Elevator, Inc.1275 Bloomfield AvenueFairfield, NJ 07004
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149,§44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: April 15, 2010End Date: Until further notice
Contractor: Suburban Middlesex Insulation, Inc.823 Pleasant StreetNorwood, MA 02062
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149,§44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: May 4, 2010End Date: Reapplication not before May 4, 2011
Contractor: Eagle Eyes Contractor, Inc.366 Riverside AvenueMedford, MA 02155
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149,§44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: December 2, 2009End Date: Reapplication not before October 27, 2010
The Commonwealth of MassachusettsExecutive Office for Administration and Finance
Division of Capital Asset ManagementOne Ashburton Place
Boston, Massachusetts 02108
DEVAL L. PATRICK Tel: (617) 727-4050 LESLIE KIRWANGOVERNOR Fax: (617) 727-5363 SECRETARY,
ADMINISTRATION & FINANCE
TIMOTHY P. MURRAY DAVID B. PERINILIEUTENANT GOVERNOR COMMISSIONER
CONTRACTORS DECERTIFIED BY THEDIVISION OF CAPITAL ASSET MANAGEMENT
(continued)
Contractor: Keystone Elevator Company, Inc.320 Libbey Industrial ParkwayWeymouth, MA 02189
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149, §44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: September 13, 2002End Date: Until further notice
Contractor: The Tyree Organization, Ltd.9 Otis StreetWestborough, MA 01581
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149, §44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: November 1, 2002End Date: Reapplication not before July 23, 2010
Contractor: EastCoast General Contractors, Inc.150 Westford Road, Unit #6Tyngsboro, MA 01879
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149, §44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: August 14, 2007End Date: Reapplication not before July 23, 2010
The Commonwealth of MassachusettsExecutive Office for Administration and Finance
Division of Capital Asset ManagementOne Ashburton Place
Boston, Massachusetts 02108
DEVAL L. PATRICK Tel: (617) 727-4050 LESLIE KIRWANGOVERNOR Fax: (617) 727-5363 SECRETARY,
ADMINISTRATION & FINANCE
TIMOTHY P. MURRAY DAVID B. PERINILIEUTENANT GOVERNOR COMMISSIONER
CONTRACTORS DECERTIFIED BY THEDIVISION OF CAPITAL ASSET MANAGEMENT
(continued)
Contractor: Atlantic Construction and Restoration, Inc.59 Doane Street, Unit #7Lowell, MA 01851
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149, §44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: May 20, 2008End Date: Reapplication not before July 23, 2010
Contractor: W.P.I. Construction, Inc.4 Tanner RoadWebster, MA 01570
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149, §44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: January 15, 2009End Date: Reapplication not before January 15, 2010
Contractor: Cape Cod Builders and General Contracting, Inc.7 Herring Pond RoadPlymouth, MA 02360
Decertified By: Division of Capital Asset ManagementAuthority: G.L. c. 149,§44DRestrictions: Decertified from submitting bids to perform work pursuant to G.L. c. 149Effective Date: March 20, 2008End Date: Reapplication not before March 20, 2009