Upload
bruce-robertson
View
235
Download
8
Embed Size (px)
Citation preview
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 1/18
1980 Edition
(incorporating Amendment 1 (1984),
Amendments 2 and 3 (1988),
Amendments 5,6,7 and 8 (1989),
Amendment 9 (1990),
and Amendment 10 (1998)
Domestic Sub-Contract
DOM/1
Articles of Agreement
Standard Form of Sub-Contract for Domestic Sub-Contractors: see
clauses 19.2 and 19.3 of the JCT Standard Form of Building
Contract 1980 Edition. ..
(This reprint of DOM/1 is appropriate for use where the form of main
contract is one of the following editions of the JCT Standard Form:
Local Authorities/Private edition/With/Without Quantities and
incorporates main contract amendments Amendment 1: 1984,
Amendment 2: 1986, Amendment 4: 1987, Amendment 5: 1988,
Amendment 6: 1988, Amendment 7: 1988, Amendment 8: 1989,
Amendment 9: 1990, Amendment 10: 1991, Amendment 11: 1992,
Amendment 12: 1993, Amendment 13: 1994, Amendment 14: 1995,
Amendment TC/94: 1994, Amendment 15: 1995, Amendment 16:
1996, Amendment 17: 1997 and Amendment 18: 1998)
The Conditions referred to in Article 1.3 are issued separately for
incorporation in this Form where so required.
IMPORTANT NOTICE
Amendment 4 to Sub-Contract DOM/1 (published in September
1989) is only for use where Amendment 3 to the JCT Standard Form
of Building Contract 1980 Edition applies to the Main Contract. That
Amendment, which only applies to the "Without Quantities" version
of the JCT Standard Form, was issued in March 1987.
Since the "Without Quanti ties" version is a lump sum contract,
which does not contain provision for any part of the Works to be
measured and valued, it wi ll be necessary for Article 2.2 of Sub-
Contract DOM/1 to be deleted in every case where Amendment 4 to
SUb-Contract DOM/1 applies - unless, notwithstanding the use of
the "Without Quantities" version of the Main Contract, the parties to
the Sub-Contract agree that the SUb-Contract Works will be subject
to re-measurement, in which event Article 2.1 of the SUb-Contract
should be deleted. Where Article 2.2 of the SUb-Contract is deleted,
the related provisions in clause 15.2, 17 and 18 of the Sub-Contract
Conditions, and any references elsewhere in those Conditions (eg in
clause 30) to the "Tender Sum" or "Ascertained Final SUb-Contract
Sum", will similarly be inapplicable.
Amendment 4 has not been incorporated in this re-print, but is
available separately.
Articles of Agreement
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 2/18
1980 Edition Articles of Ag reement
Sub-Contract Conditions
Domestic Sub-ContractDOM/1
CORRECTIONS - July 1998
ARTICLES OF AGREEMENT
Front Cover "and Amendment 10 (1998)" should be deleted from the top left hand corner of the front cover of the
Articles of Agreement.
Article 1.3 This should read as follows:
"The Sub-Contract Conditions set out in "the Sub-Contract Conditions for use with the
Domestic Sub-Contract DOM/1" including [b) Amendments 1 to 3, and 5 to 9 thereof inclusive
and published by the Construction Confederation shall be deemed to be incorporated in Sub-
Contract DOM/1 as executed by the parties hereto,"
Article 4.1 The words in parenthethis on the penultimate line should read: "Clause 386 applies"
Part 8 page 11 The last line should be amended to read "Clause 386 applies",
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 3/18
SUB-CONTRACT CONDITIONS
Clause 1.3
Clause 6.1.2
Clause 8B.3
Clause 8C.3.3
Clause 16.3.3.4
Clause 16.4:1
Clause 18.1.2
Clause 19B.5
Clause 20A.6
Clause 21.4.5.1
Clause 21.4.5.4
Clause 28
Clause 32
Clause 35.4
Clause 36.1.6.2
Clause 36.3,2
Clause 36.5
Clause 38A.5.6
Clause 38B.1.2
Clause 38B
Clause 38B.7
A definition of "Statutory Requirements" is required. This is referred to later on in clause 4.1.7. In
order to match the wording of clause 6.1.1 of the JCT 80, the defini tion should read:
"Any Act of Parliament, any instrument, rule or order made under any Act of Parliament, or any
regulation or byelaw of any local authority or of any statutory undertaker which has any
jurisdiction with regard to the Works or with whose systems the same are connected".
It should read in the last line "clause 27 or clause 28 or clause 28A of the Main Contract Conditions".
In the second last line, combine "there from" to make "therefrom".
Combine "there from" to make "therefrom".
Delete - this is a repetition of the text which properly forms the first two l ines of 16.3.4.
At the beginning of the first indented sub-paragraph, the words "compliance with any direction as to
the expenditure of a provisional sum," should be deleted: they are repeated immediately afterwards.
In line 8, the footnote "[dd]" should be footnote ~.
In line 4, correct "clause 19A.5" to "clause 19B.5". 1
In line 2, correct "omission or repayment" to read "omission by repayment".
In line 3, correct "therefore" to "therefor".
This Clause should be deleted because the cross reference to the Main Contract Conditions has been
overtaken by Amendment 18 to JCT 80.
In line 6, correct "contractor" to "Contractor".
Clause 32 should be deleted. 2
The clause number is missing from the beginning of this clause (it should appear immediately below
the clause nos. "35.4 - .6").
Delete the full stop after "Base Date".
Correct "market rice" to "market price" in l ine 2.
The clause number is missing, as for clause 35.4.
In line 2, delete the full stop after "38A.5.5".
In line 1,correct "works" to "Works".
Footnote [hh] "JCT Arbitration Rules" should be amended to "JCT 1998 edition of CIMAR".
The first sentence should read as follows:
"The arbitration shall be conducted in accordance with the JCT 1998 edition of theConstruction Industry Model Arbitration Rules current at the Base Date [hhr
2
This typographical error existed prior to DOM/1 being republ ished in May 1998.
During the drafting of the revisions to the Domestic Sub-Contract DOM/i, clause 32 was drafted and was
the subject of discussions with representatives of the National Specialist Contractors Council and
Specialist Engineering Contractors Group. Although both sub-contractor representative bodies no longer
approve DOM/1 in its present form, it was agreed that clause 32 should be deleted. Due, however, to a
printing error,this did not take place and clause 32 should therefore be deleted from the standard form.
Published by Construction Confederation
Construction House,
5{x)4 Leonard Street, London EC2A 4JX
© Construction Confederation 1998
This form is approved by:
Construction Confederationypeset and produced by Duce & Co
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 4/18
Recitals
Second
Third
Fourth
Articles of Agreement
made the _ dayof __ 19
Between __
of (or whose registered office is si tuated at)
(hereinafter called "the Contractor") of the one part and
of (or whose registered office is si tuated at)
(hereinafter called "the Sub-Contractor") of the other part.
Whereas
First the Contractor desires to have executed the works referred to in the Appendix part 2 and
described in numbered documents, if any, identified in that part of the Appendix (hereinafter
called "the Numbered Documents");
the Sub-Contract Works are to be executed as part of works referred to in the Appendix part 1
Section A, and being carried out by the Contractor under a contract as described in the
Appendix part 1 (hereinafter called "the Main Contract") with
(hereinafter called "the Employer");
the Sub-Contractor has had reasonable opportunity of inspecting all of the provisions of the
Main Contract, or a copy thereof, except the detailed prices of the Contractor included in
schedules and bil ls of quantities;
at the date of the Sub-Contract:
(A) the Sub-Contractor is/is not [a] the user of a current sub-contractor's tax certificate under
the provisions of the Finance (No.Z) Act 1975 or any amendment or re-enactment thereof
(hereinafter called "the Act") in one of the forms specified in Regulation 15 of the Income
Tax (Sub-Contractors in the Construction Industry) Regulations 1975 or any amendment
thereof, and the Schedule thereto (hereinafter called "the Regulations"); where the words
"is not" are deleted, clause 20/\ shall apply to the Sub-Contract and clause 20B shall not
apply; where the word "is" is deleted, clause 20B shall apply to the Sub-Contract and
clause 20A.2 to .8 shall not apply;
(B) the Contractor is/is not [a] the user of a current sub-contractor's tax certificate under the
Act and the Regulations;
(C) the Employer under the Main Contract is/is not [a] a "contractor" within the meaning of the
Act and the Regulations.
Footnote Delete whichever alternative IS not applicable.a]
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 5/18
Main Contract
Provisions
Su b-Contractor's
obi igations
Sub-Contract
Conditions
Sub-Contract
Sum
Tender Sum-
Ascertained Final
Sub-Contract Sum
Adjudication
Settlement of
disputes - arbitration
Now it is hereby agreed as follows:
Article 1
1.1 The SUb-Contractor shall be deemed to have notice of all the provisions of the Main Contract
except the detailed prices of the Contractor included in schedules and bi lls of quantities.
1.2 The SUb-Contractor shall upon and subject to the SUb-Contract Documents and the provisions
of the Main Contract carry out and complete the SUb-Contract Works shown upon and
described by or referred to in those Documents.
1.3 The Sub-Contract Conditions set out in "The Sub-Contract Conditions for use with the
Domestic Sub-Contract DOM/1" including [b] Amendments 1 to 3, and 5 to 10 thereof
inclusive and published by the Construction Confederation and approved by the Construction
Confederation, the National Specialist Contractors' Council and the Specialist Engineering
Contractors' Group shall be deemed to be incorporated in Sub-Contract DOM/1 as executed
by the part ies hereto.
Article 2
2.1 The Contractor shall pay to the Sub-Contractor the VAT-exclusive sum of [b][c]
£ : (words)
(hereinafter referred to as "the Sub-Contract Sum") or such other sum as shall become payable
in accordance with the SUb-Contract.
2.2 The VAT-exclusive Tender Sum is [b][c]
£ : (words)
(hereinafter referred to as "the Tender Sum") and the Contractor shall pay to the SUb-Contractor
such sum or sums as shall become payable in accordance with the Sub-Contract and the total
of such sums is in the Sub-Contract cal led "the Ascertained Final Sub-Contract Sum".
Article 3
3.1 If any dispute or difference arises under the SUb-Contract either Party may refer it to
adjudication in accordance with clause 38A.
Article 4
4.1 Subject to Article 3, if any dispute or difference, except in connection with the enforcement of
any decision of an Adjudicator appointed to determine a dispute or difference or a dispute or
difference under clause 20A or clause 20B to the extent provided in clause 20A.8 or 20B.6,
shall arise between the Contractor and Sub-Contractor whether arising during the execution or
after the completion or abandonment of the Sub-Contract Works or after the determination of
the employment of the Sub-Contractor under Sub-Contract DOM/I (whether by breach or in any
other manner) then it shall be and is hereby referred to arbitration in accordance with clause
38B and the JCT 1998 edition of the Construction Industry Model Arbitration Rules ("CIMAR")
[d] or, if the entry in the Appendix, part 8 stating that "Clause 41B applies" has been deleted,
it shall be determined by legal proceedings.
Footnotes: [b] Amendment 4 to Sub-Contract DOM/1 (published in September 1989) is only for use where Amendment 3 to the JCT
Standard Form of Building Contract 1980 Edition (JCT 80) applies to the Main Contract. That Amendment, which only
applies to the "Without Quantities" version of JCT 80, was issued in March 1987. Since the "Without Quant ities" vers ion
is a lump sum contract, which does not contain provision for any part of the Works to be measured and valued, it will be
necessary for Article 2.2 of Sub-Contract DOM/1 to be deleted in every case where Amendment 4 to Sub-Contract
DOM/1 applies . Where Artic le 2.2 of the Sub-Co-it -ac t is deleted, the related provisions in clauses 15.2, 17 and 18 of the
Sub-Contract Conditions, and any references elsewhere in those Conditions (eg in clause 30) to the "Tender Sum" or
"Ascertained Final Sub-Contract Sum", Wil l similar ly be inapplicable. Where Amendment 4 to Sub-Contract DOM/1 is
to apply, substitute in Article 1.3 reference to "Amendments 1 to 10" for the reference to "Amendments 1 to 3
and 5 to 10"; a number of other amendments (set out in Amendment 4) will also be required in the recitals, Articles andAppendix.
2
[c] Delete Article 2.1 or 2.2 as appropriate. Article 2.2 for use where the Sub-Contract Works are to be completely re-
measured and valued.
[d] For a note on the CIMAR Rules please see JCT 1980 Articles of Agreement: footnote [g.3]
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 6/18
Notes
[e1] For Agreement
executed under hand
and NOT as a deed.
[e2] For Agreement
executed as a deed
under the law of
England and Wales by a
company or other body
corporate: insert the
name of the party
mentioned and Identif ied
on page 1 and then use
either [e3] and [e4] or
[e5]. If t he party is an
individual see note [e6].
[e3] For use if the partyis us.nq ItS common
seal, which should be
aff ixed under the party' s
name .
[e4] For use of the
party's officers
authorised to aff ix I ts
common seal.
[e5] For use if the party [efi]is a company registered
under the Companies
Acts which IS not uSing a
common seal; Insert the
names of the two
off icers by whom the
company is act ing whoMUST be either a
director and the
company secretary or
two directors. and insert
their signatures with
,Director' or 'Secretary'
as appropriate. This
method of execution is
NOT valid for certem
bodies incorooretec by
Act of Parliament or by
charter if exempted
under s. 718(2) of tile
Companies Act 1985.
[e6] If executed as a
deed by an individual.
insert the name at [e2].
delete the words at [e3],su bstitute 'whose
signature is here
subscribed' and inser t
the individual's
signature. The individual
MUST sign in the
presence of a witness
who attests the
signature. Inser t a t [e4]
the s ignature and name
of the witness. Sealing
by an individual ISnot
required.
Other attestation clauses
are requi red under t ile
law of Scotland.
[e1]
[e1]
[e1]
[e2]
[e3]
[e4]
[e2]
AS WITNESS THE HANDS OF THE PARTIES HERETO
Signed by or on behalf of the Contractor
in the presence of:
Signed by or on behalf of the Sub-Contractor _
in the presence of:
EXECUTED AS A DEED BY THE GONTRACTOR
hereinbefore mentioned namely
by affixing hereto i ts common seal
in the presence of:
'OR
acting by a director and its secretary' /two directors' whose signatures are here subscribed:
namely __
[Signaturel DIRECTOR
and _
[Siqnature] _________________ SECRETARY'/OIRECTOR *
AND AS A DEED BY THE SUB-CONTRACTOR
hereinbefore mentioned namely _
[e4]
[e3] by affixing hereto its common seal
in the presence of:
'OR
acting by a director and its secretary' /two directors * whose signatures are here subscribed:
namely
reS]
[Signaturel OIRECTOR
and _
[Siqnature] SECRETARY*/DIRECTOR'
. Deiete as applicable
3
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 7/18
APPENDIX TO DOMII
part 1 Section A
Second recital Works:[f]
Form of Main Contract Conditions: Standard Form of Building Contract, 1980 edition* Local
Authorities/Private edition/With/Without Quantities
including Amendments 1, 2, 4 to 18 and TC/94 thereof
(see footnote [b])
*With/Without Sectional Completion Supplement
Inspection: The Form of Main Contract, the unpriced * Bills of
Quantities/Specification (which incorporates reference to
the general conditions and preliminaries of the Main
Contract) the Contract Drawings and the following
additional documents, if any, .
....................................................................may be inspected at:
Execution of Main Contract: *as a simple contract/as a deed
Main Contract Conditions -
alternative provisions:
the Architect/the Contract Administrator: *Article 3Aj
Article 3B
Without Quantities edition only, Quantity Surveyor: *Article
4A/ Article 4B
the Planning Supervisor: * Article 6.1:~~~~~~ __
the Principal Contractor: *Article 6.2: _
Disputes: Article 7: *arbitration/legal proceedings
Master programme: clause 5.3.1.2 *deleted/not deleted
Assignment: clause 19.1.2 "applies/does not apply
Insurance: clause 21.2.1 insurance * may be required/is
not required
Works insurance: *clause 22A/22B/22C
Joint Fire Code: "applies/does not apply.
"Large Project": "Yes/No
Deferment of Date of Possession: clause 23.1.2
"applies/does not apply
Main Contract Conditions- any amendments to or from the printed Standard Form
identified above:
Footnotes: [f] Insert the same descr iption as in the Main Contract Articles of Agreement
< Delete as applicable
4
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 8/18
part 1 Section B
Main Contract: Appendix and entries therein
Where the Main Contract incorpcrates the Sectional Completion Supplement thereto. delete
part 1 Section B of this Appendix to DOM/1 and substitute a photocopy of the "Appendix
(Sectional Completion Supplement)" from the Main Contract.
Statutory tax deduction scheme
- Finance (No.2) Act 1975
Clause etc.
Fourth recital
and 31
Employer at Base Date * is a
'contractor'zls not a 'contractor'
for the purposes of the Act and
the Regulations
COM Regulations Fifth recital *all the COM Regulations apply/
regulations 7 and 13 only of the
COM Regulations apply
Dispute or difference -
Settlement of disputes
Article 7
41B
41C
Clause 41 B applies *
[. Delete if disputes are to be
decided by legal proceedings
and Clause 41 C isthus to apply]
Base Date 1.3
Date for Completion [9] 1.3
VAT Agreement 15.2 Clause IA of the VAT Agreement
"applies/does not apply
Defects Liability Period (if none 17.2
other stated is 6 months from the
day named in the Certificate of
Practical Completion of the
Works)
Assignment by Employer of
benefits after Practical
Completion
19.1.2 Clause 19.1 .2
* applies/does not apply
Insurance cover for anyone
occurrences arising out of
one event
21.1.1 £-----------------------
Insurance - liability of Employer 21.2.1 Insurance * may be required/is
not required
Amount of indemnity for any
one occurrence or series of
occurrences arising out of
one event
£---------------
Insurance of the Works -
alternative clauses
22.1 * Clause 22A/Clause 22B/
Clause 22C applies
Percentage to cover
professional fees
*22A
22B.1
22C.2
Annual renewal date of
insurance as supplied by
Contractor
22A.3.1
Footnotes: [9] If a later Completion Date has been fixed under Clause 25 this should also be stated here.
. Deiete as applicable
5
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 9/18
Insurance for Employer's loss
of liquidated damages-
clause 25.4.3
Joint Fire Code
Date of Possession
Deferment of the Date of
Possession
Liquidated and ascertained
damages
Period of suspension
(if none stated is 1 month)
Period of delay
(if none stated is, in respect of
clauses 28A.1.1.1 to 28A.1.1.3,
3 months, and, in respect of
clauses 28A.1.1.4 to 28A.1.1.6,
1 month)
Advance payment
Period of Interim Certificates(if none stated is one month)
Gross valuation
Listed items off-site
220
220.2
22FC.1
23.1.1
23.1.2
25.4.13
26.1
24.2
28.2.2
28A.1.1.1 to 28A.1.1.3
28A.1.1.4 to 28A.1.1.6
30.1.1.6
30.1.3
30.2.1.1
30.3.1
Insurance * may be required/
is not required
Period of time _
The Joint Fire Code
*applies/does not apply
If the Joint Fire Code is
applicable, state whether the
insurer under clause 22A orclause 22 B or clause 22C.2 has
specified that the Works are a
"Large Project": *YES/NO
(where clause 22A applies these
entries are made on information
supplied by the Contractor)
Clause 23.1.2
"applies/does not apply
Period of deferment if it is t o be
less than 6 weeks is _
at the rate of£ per _
Clause 30.1.1.6
"applies/does not apply
If applicable:
the advance payment is
£ / %
of the Contract Sum; and will be
reimbursed to the Employer in
the fol lowing amount(s) and at
the following time(s)
An advance payment bond*is/is not required.
a priced Activity Schedule
* is/is not attached to th is
Appendix
*For uniquely identified listed
items a Bond as referred to in
Clause 30.3.1 in respect of
payment for such items is
required for
£_-----------------[Delete if no bond is required.]
• Oelete as applicable
6
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 10/18
Retention Percentage (if lessthan 5 per cent)
Work reserved for Nominated
Sub-Contractors for which the
Contractor desires to tender
Fluctuations:
(if alternative required is not
shown clause 38 shall apply)
Percentage addition
Formula Rules
Adjudication - nominator of
Adjudicator (if no nominator isselected the nominator shall
be the President or a Vice-
President of the Royal
Institute of British Architects)
Settlement of disputes-
Arbitration - appointor (lf no
appointor is selected the
appointor shall be the
President or a Vice President,
Royal Institute of BritishArchitects)
Performance Specified Work
30.3.2 * For listed items that are not
uniquely identi fied a Bond as
referred to in clause 30.3.2in
respect of payment for such
items is required for
L~ ___
[* Delete if Clause 30.3.2 does
not apply.]
30.4.1.1
35.2
37 clause 38
clause 39
clause 40 [h]
38.7 or 39.8
40-,.1.1
rule 3 Base Month
__ ~~~~ 19 __
[i] Non-Adjustable Element
(not to exceed 10%)
rules 10 and 30 (i) Part IjPart II of Section 2 of the
Formula Rules is to apply
41A.2.2 President or a Vice-President or
Chairman or a Vice Chairman:* Royal Institute of British
Architects
* Royal Institution of Chartered
Surveyors
* Construction Confederation
* National Specialist
Contractors' Council
41B.1 President or a Vice-President:
* Royal Institute of British
Architects
* Royal Institution of Chartered
Surveyors
* Chartered Institute ofArbitrators
42.1.1 Identify below or on a separate
sheet each item of Performance
Specified Work to be provided
by the Contractor and insert the
relevant reference in the
Contract Bills
Footnotes: [h] Clause 40 and the Forrnula Rules are not applicable where in Part 1 Section A of this Appendix it IS stated that the
Without Quantities Editions apply.
- Oelete as applicable
[i] Standard Forrn Local Authorities With Quantities Edition only.
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 11/18
part 1 Section C
Obligations or restrictions imposed by the Employer not covered by Main Contract Conditions
(e.g. in Preliminaries in the Contract Bills [j)):
Order of Works: Employer's requirements affecting the order of the Works (if any):
Location and type of access:
First Recital part 2
Particulars of the SUb-Contract Works:
Numbered Documents annexed to Sub-Contract DOM/1 (to be listed here):
* Health and Safety Plan
Footnotes: [j] This information, unless included in the Sub-Contract Specification or Bills of Quantities, should be given e.g. by
repeating here or by attaching a copy of the relevart section of the Preliminaries Bill of the Main Contract Bills (or of the
Main Contract Specification).
, Oelete as applicable
8
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 12/18
Clause 7.2 part 3
Insurance cover for anyone occurrence or series of occurrences arising out of one event
£_----
Clause 11.1 part 4
(1) The date for commencement of the Sub-Contract Works on sitewill be between: . _
and: _
(2) Period[s] required for carrying out and completion of the Sub-Contract Works on site:
weeks
(3) Period required for notice[s] to commence work [in any Section] on site:
weeks
(4) Period required for Sub-Contract Works off site and prior to commencement on site:
weeks
(5) Further details:
[Note: These provisions will need to take account of any Sectional Completion Dates
required under the Main Contract]
9
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 13/18
Clause 16.2
Clause 17.2
part 5
Rates or prices of Sub-Contractor and/or daywork rates or prices: _
Clause 16.3.4.1 and .2
Clause 17.3.3.1 and .2
The daywork percentages are:
Definition Labour Materials Plant
RICS/CC
RICS/ECA
RICS/ECA (Scotland)
RICS/HVCA
Clauses 19A and 19B part 6
Value added tax
clause * 19A/19B will apply
clause 19A.5 "applies/does not apply
clause 19B 5 * applies/does not apply
Clause 21 part 7
Retention
21.5.1 Retention percentage %
Applicable until _
21.5.2 Retention percentage ------------------------------_%
Applicable until _
The retention percentage is to be 5 per cent unless a different percentage is inserted. (This
should not normally exceed the percentage retained under the Main Contract).
The events up to which the retention percentage remains applicable should only be inserted if
they are different from the events indicated in clause 21.5.
• Delete as applicable
10
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 14/18
Clause 38
Clause 27
part 8
[k] Article 3/38A.2.1
The nominator of the Adjudicator shall be the President or a Vice-President or Chairman or a
Vice Chairman:
Royal Institute of British Architects
Royal Institution of Chartered Surveyors
Construction Confederation
National Specialist Contractor's' Council
If no nominator is selected, the nominator shall be the President or a Vice-President of the
Royal Institution of Chartered Surveyors
[I] Clause 38 applies
part 9
27.2 Particular items of attendance (other' than the attendance referred to in clause 27.1).(Details to
be set out here or on a separate sheet(s) which should be initialled by the parties and attached
to this Appendix.)
The items of attendance as necessary in respect of the requirements of the Joint Fire Code, if
applicable, are:
hand bells, whistles, klaxons, manually operated sounders;
security guards;
fire signage e.g. location of fire access routes and escape routes and positions of dry
riser Inlets and fire extinguishers;
fi re doors and fire stopping to l ift shafts, service ducts and voids;
water supplies for fire fighting;
portable fire extinguishers;
maintenance and inspection of fire fighting equipment;
the services of an appropriate number of FireMarshals where the Works are a Large Project
*Temporary Buildings shall be located within the building under construction or within six
metres thereof in respect of which the Contractor shal l connect the fire detection system of the
Temporary Buildings to the Central Station.
Footnotes: [k] Clause 38A provides that when a dispute or difference arises which either party wishes to refer to Aojudication the
ident ity of the Adjudicator is
eit'ler an individual agreed by the Parties
or an individual nominated by one of tile bodies named in the Appendix.
However some Parties may wish to name an Adjudicator in the Contract so that he is readily available if either Party
wishes to refer a dispute or difference to Adjuclication. If the Parties so want then the Adjudicator should be lamed here
and the following amendments to clause 38A should be made:
Clause 38A.2 Delete the text and insert:
The Adjudicator to decide the dispute or difference shall be the individual named as the Adjudicator in the
Appendix Part 8 with whom the Parties have executed the Standard Agreement for the appointment of anAdjudicator issued by the Joint Contracts Tr ibunal ( the "JCT Adjudication Agreement"); provided that, unless
the Parties have otherwise agreed, the individual is not an employee of, or otherwise engaged by, either Party.
[I) Delete if disputes are to be decided by legal proceedinqs and Clause 38C is thus to apply .
• Delete as applicable
11
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 15/18
Clause 34 part 10
Fluctuations: *clause 35/clause 36/clause 37
Clause 35 will apply if no other provision for dealing with fluctuations is stated to be applicable.
Clause 35 part 11
35.2.1 List of materials, goods, electricity including/not including * fuels[m]. (Details to be set out on a
separate sheet(s) which should be initialled by the parties and attached to this Appendix.)
35.6.1 Base Date _
35.7 Percentage %
Clause 36 part 12
36.1.5 Basic transport charges list
(Where applicable details to be set out on a separate sheet(s) which should be initial led by the
parties and attached to this Appendix.)
36.3.1 Materials, goods, electricity including/not including* fuels [n] - l ist of basic prices. (Details to
be set out on a separate sheet(s) which should be initialled by the parties and attached to thisAppendix.)
36.7.1 Base Oate _
Percentage %
Clause 37 part 13
(1) 37.1 The Sub-Contract/Works Contract Formula Rules are those dated
* Part 1/Part IIIof these Rules applies
(2) 37.3.3 Non-Adjustable Elements [n]
and .3.4
_________ % (not to exceed 10%)
(3) 37.4 List of Market Prices
(4) 37.4 Base Date
(5) The Sub-Contract/Works Contract Formula Rules.
Footnotes: [m] Fuel price increases are only allowable where the Contractor and Sub-Contractor have specifically so agreed: see
clauses 35.2.1 and 36.3.1.
In] Only applicable where the Main Contract is let on the Standard Form of Building Contract, Local Authorities Edition.
, Delete as applicable
12
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 16/18
rule 3
rule 3
rule 8
rule 11a
or 11b
rule 43
rule 55a
rule 61a
rule 64
rule 70a
Balance of Adjustable Work ~
any measured work which cannot be allocated to a Work Category:
B a s e M o n t h _
Method of dealing with 'Fix-only' work ~ _
Part I only: the Work Categories apol icable to the Sub-Contract Works:
Part I II only: Weightings of labour and materials ~Electrical Installations or Heating, Ventilating
and Air Conditioning Installations
Labour Materials
Electrical [0] _ _ _ _ _ _ _ _ _ _ _ _ _ _ 0 / 0 ____________ %
Heating, Ventilating and
Air Conditioning [0] _ _ _ _ _ _ _ _ _ _ _ _ _ _ 0 / 0 %
Sprinkler Installations [0] ___________ o~ %
The separate materials index for Sprinkler Installat ions' wil l/wil l not apply.
Lift Installations
Adjustment shall be effected:
* upon completion of manufacture of all fabricated components
• upon delivery to site of all fabricated components
Part III only: Structural Steelwork Installations:
(i) Average price per tonne of steel delivered to fabricator's work:
[-------------------------------------------------------------
(i i) Average price per tonne for erect ion of steelwork:
[-------------------------------------------------------------
Catering Equipment Installations:
apportionment of the value of each item between:
(i ) materials and shop fabrication £------------------
(ii) supply of factor items £_--------
(iii) site installations £------------------
Footnotes: [0] If both specialist engineering formulae apply to the Sub-Contract the percentages for use with each formula should be
Inserted and clearly identif ied. The weightings for sprink ler ins tallat ions may be Inserted where dif ferent weightings are
requ.rec.
, Oetete as Boplicabl8
13
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 17/18
Clause 38B part 14
Settlement of disputes - Arbitration - Appointer
President or a Vice-President:
Royal Institution of Chartered Surveyors
Royal Institute of British Architects
Chartered Institute of Arbitrators
(if no appointer is selected, the appointer shall be the President or a Vice-President, Royal
Institution of Chartered Surveyors. If arbitration not used, delete).
Clause 23 part 15
Identi fy below or on a separate sheet each item of Performance Specified Work to be provided
by the Sub-Contractor and insert the relevant reference in the Numbered Documents.
part 16
Any other matters (e.g. special conditions or agreements on employment of labour, limitation
on working hours) to be set out here after agreement between the Contractor and Sub-
Contractor on these matters:
14
5/13/2018 Dom 1 Articles - slidepdf.com
http://slidepdf.com/reader/full/dom-1-articles 18/18
(including Amendments 1 to 3 and 5 to 10):see "Important Notice" on front cover for informationon Amendment 4 to DOMj 1
Published by Construction ConfederationConstruction House,56-64 Leonard Street, London EC2A 4JX
@ Construction Confederation 1998
Typeset and produced by Duce & Co
D~e 19
Standard Form of Domestic Sub-Contract DOMj11980 Edition
Domestic Sub-ContractDOM/1
Articles ofAgreement
between
and
This form isapproved by:
Construction Confederation