10
Document B102™- 2007 Standard Form of Agreement Between Owner and Architect without a Predefined Scope of Architect's Services AGREEMENT made as (II' the Dth day 1.'1' JaBuary ill the YC<I! 20 I-I (III •• ·,)ri/,. indi, OiC Jav. moruh (/11'/ vcur.) Dungan Ncqucnc Architects. Inc. 1<J()6Cahaba Road 1I.\t)lIlllain Bronk. AI. ~522-, ADDITIONS AND DELETIONS: The author of this document has addeeJ information needed for its completion Tile author may also have revised the text of the oriqina: AtA standard torrn. An Additions ilnd Deletions Report that notes added inlormation as well as revisions to the standard iorm text is available from the author and should be reviewed. A vertical line in the left margin of this document indicates where the author nas added necessary information and where the author has added to or d.,leteei from the original AlA text. BETWEEN the Owner: (:\'III11C. I"ga! stat us. address atu! o(/WI' in/ill"ll/(/liull City of Hoover Ion Municipul lane Hoover. A!. 35216-).'i(Hl and the Architect: I.\"al/le. !t'.l'.(/! st atus. addrvss an.! oth«: iniinnunion) Ior the i(}llo\\·in),! Project: (:\'tI/I II', location cuu! deloit,.,! (/cscril'liollj This document has important teqa' consequences, Consultation \vith (In attorney is encouraged with respect to its coruoletion (If modification. Fir" SI:1liPIl "I R(", Bridge lnit. AlA Document 8102"'< - 2007 (fomlorly B i41'" - 1997 Part 1). CljP'/ri~.jhi ,",'! iD17, 1'-i2[j, F!4R, 195!. ~:!::'3.19:;8. 193~. 19t1~. 1966, 19f.17, 1970. 197.\. i9Tl". 1!)87, 19~J7anc 2CI)7 bv Th(; i\mericc111 !nstHIJ\i..' d Arcf1i~f;;:l~:. AU fights res erveo. ·•.. 1[.',::::;,;i~;:~: -i~~i<_~;\1:\ ~>,.-:",:!~.>;l:';~:.; r. :B:·ch:;:~ : 'd d.:; C::'-i~}:/:\.:;hi :"'~~\':~.;~,:: ;::{'-~n ::};_;L~I;_;f j"1'V;",t>: . u!!;~! iE~ !u;ii"t':; r";~:".:){:~<~ i.v., ;)f -;-;: .:, If ,~:;' ,:.:", {jf ~f;~ '\;[, ~'!~:C; :1t!(~: ~;. or .:!:llj' ;~:.;J Ut:l: n~' jL f:i:j~,~i,i.L"~ ',. <In. .! ',;fil 1'1"(';'!"';:; ::--:1 \0 l'<,-; '~~ ··.\i;;:;!j,j, :-';""'i~t l":<-~,oi";.' iHi-3;:.f i.:~,: j.T'>'. Thi~_~dfXllliii·:nl W;'<; pfoducn:i by und~~fOrtlur No.[;72227H.1()1 __ J '.-'ihidl I~xp!r(n;on (lU':! ~)/20 J ,1,and/.'> not inr n--:sl!in. User Notes: r, ;:".::1 Hi c- -,,:~':';' {::'fF ;u:.-i ;'~~(,~iEi_~:! ~nft··.va(f-·aI14:2~·1:Ot on Ol.i?7i201,t 1

Document B102™- 2007 - Al

  • Upload
    others

  • View
    11

  • Download
    0

Embed Size (px)

Citation preview

Page 1: Document B102™- 2007 - Al

Document B102™- 2007Standard Form of Agreement Between Owner and Architect without a Predefined Scopeof Architect's Services

AGREEMENT made as (II' the Dth day 1.'1'JaBuary ill the YC<I! 20 I-I(III •• ·,)ri/,. indi, ·OiC Jav. moruh (/11'/ vcur.)

Dungan Ncqucnc Architects. Inc.1<J()6Cahaba Road1I.\t)lIlllain Bronk. AI. ~522-,

ADDITIONS AND DELETIONS:

The author of this document hasaddeeJ information needed for its

completion Tile author may alsohave revised the text of the oriqina:AtA standard torrn. An Additions ilndDeletions Report that notes added

inlormation as well as revisions to thestandard iorm text is available fromthe author and should be reviewed. Avertical line in the left margin of this

document indicates where the authornas added necessary information

and where the author has added to ord.,leteei from the original AlA text.

BETWEEN the Owner:(:\'III11C. I"ga! stat us. address atu! o(/WI' in/ill"ll/(/liull

City of HooverIon Municipul laneHoover. A!. 35216-).'i(Hl

and the Architect:I.\"al/le. !t'.l'.(/! status. addrvss an.! oth«: iniinnunion)

Ior the i(}llo\\·in),! Project:(:\'tI/I II', location cuu! deloit,.,! (/cscril'liollj

This document has important teqa'consequences, Consultation \vith (In

attorney is encouraged with respect

to its coruoletion (If modification.

Fir" SI:1liPIl "I R(", Bridge

lnit.AlA Document 8102"'< - 2007 (fomlorly B i41'" - 1997 Part 1). CljP'/ri~.jhi,",'! iD17, 1'-i2[j,F!4R, 195!. ~:!::'3.19:;8. 193~. 19t1~. 1966, 19f.17, 1970. 197.\. i9Tl".1!)87, 19~J7anc 2CI)7 bv Th(; i\mericc111 !nstHIJ\i..' d Arcf1i~f;;:l~:.AU fights res erveo. ·•..1[.',::::;,;i~;:~:-i~~i<_~;\1:\ ~>,.-:",:!~.>;l:' ;~:.; r . :B:·ch:;:~ : 'd d.:; C::'-i~}:/:\.:;hi :"'~~\':~.;~,::;::{'-~n::};_;L~I;_;f j"1'V;",t>: . u!!;~!iE~!u;ii"t':; r";~:".:){:~<~i.v., ;)f -;-;: .:, If ,~:;' ,:.:", {jf ~f;~ '\;[, ~'!~:C; :1t!(~: ~;. or .:!:llj' ;~:.;JUt:l: n~'jLf:i:j~,~i,i.L"~',. <In..! ',;fil 1'1"(';'!"';:; ::--:1\0 l'<,-; '~~ ··.\i;;:;!j,j, :-';""'i~t l":<-~ ,oi";.' iHi-3;:.f i.:~,:j.T'>'. Thi~_~dfXllliii·:nl W;'<; pfoducn:i byund~~fOrtlur No.[;72227H.1()1 __J '.-'ihidl I~xp!r(n;on (lU':! ~)/20 J ,1,and/.'> not inr n--:sl!in.User Notes:

r, ;:".::1 Hi c- -,,:~':';'{::'fF ;u:.-i ;'~~(,~iEi_~:!

~nft··.va(f-·aI14:2~·1:Ot on Ol.i?7i201,t

1

Page 2: Document B102™- 2007 - Al

Init.

TABLE OF ARTICLES

ARCHITECT'S RESPONSIBILITIES

2 OWNER'S RESPONSIBILITIES

3 COPYRIGHTS AND LICENSES

4 CLAIMS AND DISPUTES

5 TERMINATION OR SUSPENSION

6 COMPENSATION

7 MISCELLANEOUS PROVISIONS

8 SPECIAL TERMS AND CONDITIONS

9 SCOPE OF THE AGREEMENT

ARTICLE 1 ARCHITECT'S RESPONSIBILITIES§ 1.1 ihc Architect shall provide the' ii)Il11\lin!! pruii.:'ssion;ll '("rlic('~:(Dcscril« lite .'\1.."1>1'\'ottl«: Architvit» SCITit'('s or idcnn}i- ut: I'xhihil or St.'0p( of \'('Jy-in:s d(}(,IIIlJcn{ s{..;:j!J.~Ji)nh rillAn,hiict.:!·S service» and ii1t'Oip!}rrlf('~1 info Ibis documrn: in S('("lioll f/.?I

The Architect shall d('si!;iI a Fire Station to he located on thl' lo: inuncdiarcly North ,)(' Si~n;lIL1rL'l lomc-. officL'building in the town center ofRnss Bridge. The OUllcr 1\ ill work witl: tilt' Land Owner In define the Iinal lo: SIZ<'anddimension». ThL' Fire Station 1\ ill be <1 ~ hay lll1,·-;.tnry slati.m <Inri '\ ill hou-«: one l.ng inc Company (~ stan";. "11("

reserve Quint Apparatus (no starting required) and one t"lilllrl_' RC'C'Ii(' Unit (ail,n.l· kll-:' future starn

The buildin]; Si7C and l"llmpollt'llb are' listed in tilt' allJdwd whllialillll page,

'lhc initial targc: budge'! shall be SI.5\1.

lI'ilrilgl"llJ'/; dch'lnil§ 1.1.1. The Arcilill'ff shall perform the follu\\ill~ la~ks tn provide design services:

1_ Schematic Design (J5~',;of total fee) - j:rn!11 rl«: inf"rJ));lIi'_JIl pr.,,-idn! In tlu: owner, ;,.~;..

.iil' _('IJT~'~' ~u·d.r"'{j~:rdlfi.iiJJ;!:~~i,:~!;):llle .-\rchil ccr wil] cn.'~ltt' phi n, ;t nd clt";.a H(1f1~I~.I"cli,,-,tlt rvv i("\\~aIH.I'-"IllIlle'IlL The ,\rchil<,t"1 WIll "j<il rhl' ,il(" 1<' cvalu.r«: rh,' pUllclllar ,ie\\-, ;[11d ~e11('r;ll

l.opogr~lphic;tl i,,;,"c.' !i) inc1npOLll(' .ht·~c uuiqu« tt:alllrc:-:. inti' ihe dc,,;,ign and b\'()lt! flf {he

huildillg.

Dung;l!l'" 'letpiclIt' _\ n:hitl"l"l:' \nU pI'<",ide 11." lr phIl:' alltl (";\[(."["1'ir e1,",;) ([on" ;i~ "cake! IlL"IKildra\\'1111~S' ;1, \ •."('Ii :1" .mv "Ih,'" clra\\·in).:s .md ,kCtchc; Ill"<:<."'":1[1' In rom,',' till' lko:ign. TheprrICC:'~ \\-ili in\-n\\'(: rlicnr IlK'l'ting:, ;\~ nt:cl'~~~ll\ ({\dC1Crn)il1C rhe dt:~ign (If illt.' fh..-xv projc(l.The :\rrhi!t'ct \\"ill Il"'C ill<ltlricd d:1I:1 :1fld UP'! pCI' "Jiun' fOOl of hC;l1cd :lllti c""kd ar<":110

dl-'it'nninc lhe CO~!o( Ill\.: dc~;~n prior tn pricing h~' f h,.-ncr-;-, roruracror.

'I'll\' .\r •.-hill,,.1 will :"";',1 t hc ()..\'!ler and (:'"llT:1Cl"r 1!I filing d'1CUill"!lis rl''1llll",..d l;,r ihc:1pprp\-;1! of go\-CnHllC!11:1) :luri1nririt.':'. l\-;\~~:d(.n appft',,',,-'d ~('hcln:;Hic d('~igndr;l\\'iilg,~~ f'l.h:~lgll

:;uhmilu! f)OL"lInlCni"" inrllhllllg ,caled dr:m-!I1g' (If fli)"r 1'1;11lS, C:,II'I:\I1[ L"1t'\'~lfl"ll' illd1(;ltin~1l1!1it"n:d :~t'lecli, JIb Jnd si«- pian \\'irh IOClIinn (If prnpo~t ..d huilding ()1" nT1C\\' :l!ld o unnu-nr

h,\' Ihc .-\.ltC. it" rn.Juircd. will be pr(n-idt:d b\' ,\rl:hllcC; i(J { hXHcf.

----------------_._-A1ADoculllelltB102P"-2007{focmerlyB141r"'-1997 Part 1},Cop'i"(i4i;t":~19t7, iHlt\ 194B.l?::d.19~3.1~lf~fL HJ(P, i9n:~. i~lji:",.1907. HllO, 197~l,in77,WB7. 19~7 and 2007 by The American institute of Arcilit{!cts, All rights reserved. \'\'!~f<;-'~::-j'3' IT!~':: !.';.!,!:, r~:;Gt.j:':Ci!,; i~;F! ~:~'~'<k{1L-\' p, S, I t~\,,;'f.-,t •.1:1~fm·•.:~~Lm;_:~"1:!~:(~h';;_Unr,:;~:i;j;·;.':')d ,j:::_lrD~l~h-:~ki(,or ~:i3;. ::H~~;':~'~'.:f tl·.:~.; /tli, D-c"':, ~:.\;:: n~, .:~: :;:-,~J 1>~l;;C'l~<_/ i~ iii,i'!, I'ei:,j it I;: ';(~'...::(~~(:!". 1: :.:..,·im-it~;.d!j;:'n~;Hi~> .. ~:;~.l :,;'d: !.,:., rJ"'--<'~:,1\1'~1 l;'>~ ~rJ\:~J{;;~;!,_'j,~,i.:n it r:'.~·;';ir i·, '~!!;(! :: ~;. ~ ~; T!li;, (~(;;:!Jm2nt ~NDSpfGdUGcj trv }\l!\ soft',vnrr!;,t 1(::;:::Q:01 on 01 i27/20 H

2

undA-r O'~!A-r No,57 :?227R·fn 1.. i v;h!c.h nxp!t·f~S c:n 09/ 7!V2J 14, ~nd i~ not (11 r·:-salf',User Notas~ ( !33 18·W56 l]

Page 3: Document B102™- 2007 - Al

lnit.

Construction Documentation (;7'",; of (0(;11 tee) - \-ia~,'d ••1\ th,' :lpprmTd :-;d1<'lllailCdr;1\\'iJlI~" lilt, \rchi!<'CI WIl1'Tl',lll" (/'1111'\11,,1' gClln.lln\ plan- '111..1 l'ln':lli,'Il'; f.•r th" ()\'dlC,.\

IT\'IC\\', ()\In' dll' (hvtltT pm"ides ,11'1'1'<.\,,11,:Illy dc,i,:',tl J'n'i,inlh \\',,,,lid h" hili",1 al all I1'Hlr],,'raft',

B'l:';cd "11 Ihl' :ti'pril'.'l'd d"'WIl, Ill,' ,\rchill'CI \\'ill prll\'idc (.l'Il',Il'U(tioll ()"CllmnH' indl!tii!l:';I'lulll1.lIl1g, 1I,Ini ,cap" 1.1\'(",11. :1J'fillll'Cillr:iI, <rrurrur.rl, I1lt'Ckl!llCli :lllti cleClricd dr;l\\'inl~' ,llld

speC! (,,:;\1 j, >11',

\1~(1 illcltl(.h:d, a" pan f,f fill' \rc}IlH.'ct'" S<:f\'lCL':'. arc IlHl'r!or t)c::-:ign ""T\'ices. 'rllc-;,c:::.crVICL'S

include dl'\',Hi"n,; nf uhinu.; and IIti1l'r millw.uk 11'1'111', uucnor Illlis\; ,den,inlls :11ld (,,,101'sdecl iOIl';, IiglHill? '1I1dpluml>lllg ti'l;llllT ,ckuinn" ,\ \I sek'ci i••n' ,,'iI.llll.' I'r,'''''1Inl i'or ( h'nl'l'apprr)l'al.

Biddillg/Nq;'Oti:UioIl (S".; of total ti?c) - llu: ,\ n:hill'C I will 1"'0\ itk ":n'iu', fllrcOlllp(,litin' I.idding "I' lht' \•..•.rk 'inti will 'I"j.;t 1i1<'()\\lllT in obl:1ining ;;nd n'\'wwin;; pricll1~',frolll the ('(1l11r:lCloI'S,

'!. Cotistructiou Observation (20~",;of total lee) The \n'hill'([ \\'111 prm'lde cll!l"fruni»I\ph;I'l' service lIiL'iudin;", bill '1>.11li!11ilnl PJ periodic ,ilc \'j'ils 10 "h'([H' COlIslrllCilflll

prr)grcs <, 1"('\'1•.-w ;lil<.1 pr(;Cl·:--.";lli:-~ ()( ,he,}) dCl\>:ing <uliminals, i)r'H.:t';-;:,in~ th.: tlli}llfhl~'

:lppliC:llinlls f"r !,;!\'In,'HI. Illl,'r".r finish ,dc'nioo', 'Int! filla! IW'leel' d""'-,,Ul. TIll' ('~tl'Il!(li'

rhc ,\n:hill'l't's :tuthoril! .iud n"p"llsihilii\ dll1'in:~ rh,: Crllbln!t'li!>11 is dl'snibu\ in litis:lgn:<'Illl'1l! and in lite ,\1.\ .1""1111I<'111,\':;lll, General Conditions of the Co nrr.ut forCOlll'trll<:lioll ,\'IlI"1l \\'ili hc ",w,t! ill lilt' '1'<'Clt'''':lIi'''F,

§ 1,2 Thl' Architect >;hall perform ilS "<'I'\'i\Y~ ('Ol"i,lllll witl: !hc' pro(;:,sl"i1,l! skill and care ordinarily I'r,wiJ<:'d byarchitects pr;lt:licing in the same or <irnilar l"c'aillY under Iii,' ,;rille' or ~imijar circum-aanrcs. The Architect shnllperform il'; service- as c.'\pedi!io\lsly as is l'OnsisiL'n! with Sill'll pr(ll<,'s.;innalski!! and care and Ill<' orderly progrcss olthe l'f(~i,'('t,

§ 1,3 The Arch iiL'l.'tsha 1\ i.k-nti I~va rl'prcs(,IIl;t1i\c' allll1l'ril,'ti 1\1acl (HI hcha] r ur IIll' Arch ilc,'1 \\i 111r"Sp'YI W lilt'Projcct,

§ 1.4 L\cep( with Ihe Cl\l'llcr's knowledge and CO[hCII!. the' Architect shall 1101t'ngage in anv activity. or aCl'cpt all)crnplovmcat. interest or contribution that would rc;asollably appear 1(1cornprorni«: the Architect's proi'c';;;;iolll11judgmcn: with I'l'spc'l'l I,' Ihis Project.

§ 1,5 The Archircc: sha ll mniruain the lilil(lwing insurance tor the duration or this :\grl'cl11cIIL II' anv or therequirements >;l'! forth below exceed thl' types and limir-, llie Architect normally maintains, the (h\'llt'l' shall rcimhurxcth,' Architect lor any additional co-u:(Identit; /.\]JC'- and limns u(in,fll'{lJJ{'(' L·f)\"(-TII.~(-·. an.l ot lu:r insurauc.: j'('l/Jiirt'JIICiJiS app/icah/{' ftJ tli«, JgrCC,llIt'ji!. iFanv.)

,1 (icIlLT,11 l.iabilitv

';;2;\1

.2 Automobile l.iabilitv

51 i\!

S 1\1-,------,-,-_ .._--,-,----------AlA Document B102H~ - 2007 (formerfy B14 t T'~ .- 1997 Part 1). Cop/riGht .r..' H) 17, 1926. i?4U. i9~ 1. j95.} lH:t!3. 1861. t96:~. tH6(i, iHG7. 1970. t:r;r~L 1:371t9,<~7,19H7 <lnd ?OOI hyTlF'; /"morir.an (n!~fitllie (::f J\rchitP.{'.t:;.. All nqhts ros orved, t:",,!,\;·:!.j~;j{ . ':'fj;'.: .;\(/'. ;:·i"~;U!lil.·!Ht k.i pl"~~·L~':;L.jJ~.;'l'U.~i-. ;d:d

':~<~~;"L~·;'·::ulh,:-d.<~;ct i' '!l(:;:<!';w: ,,:-i) f): (i ,/ ~·'Uti.';l:,), H:;:: ,\b\ rJ\;'::lY'\"r~:' (if it, ~;i,~;.'r;,~:~uL ;:~'-,,_;,-"':p!,,('~,,·,':~(.:~lj.,,:t)'U.~d'(,,;- <.--,' :~l;;j': ui:(L:~' ~!1"~ !~';\'!.This prm1uce.j hy AlA so!!'::];-,,: 2111 ,1~?9:0 1 on 01/27:20 1,\

3

I.i!~d.::rO,ch:;[ Hn.':,·(22:270·1!j 1 1 't/ll:C:h l)xni((~s on (hV Hl.'ZCi i-L and is no! for (f~~~lln.User Notes: _.

Page 4: Document B102™- 2007 - Al

Init.

.4 Proii:ssioll,lI l.iahility

In "ddiiioll. rhc Architect "hall require thai its cOllsullanls maint.un I'roli:'s,itHlal linhilu v insurance a, appropriate tothe services prt)\'idt'd and-or lil bt' provided.ARTICLE 2 OWNER'S RESPONSIBILITIES§ 2.1 l ill k..,s otherll'ise provided till' under th is A[!rc<.'Il1l'lll. Ill(' ChI 11('1'shall pr{l\ide in format ion in a Iimcly mannerregarding requirements for and Iimitarions 011ill(' Project.

§ 2,2 The Owner shall idrruif'y a rc'preselltati\'c <lutllt.1rilCd III art Oil the O\'.Il..:r's behalf with rc-pcct In Ihl' Protect. TheOWt1lT shall render decisions <Inti approve the Archiil'CI's <ubmittal-; ill a timelv manner ill order 10 ,lwid unreasonabledcla; ill the orderly and sequential progrcs, orlile' /\rdlirc<·t·s seryiccs.

§ 2,3 lhe Owner shall coordinate the services "I' itx (l\\11 cOllslJiWrtl,'iwith tho«: -crviccs pr(l\idcd hy ihe' Architect.1 ipl)lI the Archirccts request. the Owner sha 11furni;-;.11 t.:opi(·s of th~ SC't)j1('of ('oosul, illg scrvicc-, in lht." contruct-,bC(\\TCn the Owner ,1I1d the OWIl\:'(~consultant«. '1111.'Ov.ncr shall furnish the st?r\'i,','s of con-ultunts other than thosedc'signaled ill this Agreement.. '1he Owner shall require that ir-, conxuluuu-, maintain profcsxional linhilit y insurance asapproprimc to the services provided.

*2.3.1 The ()\\Il(~I'shall furnish Landscape Design. liard Scapc Lavour, and Geotcchllit';l1 En~il\l'('t"illg

services for the Project.

§ 2.4 The O\\'lIcT shall furnish all kgA. insurance and :tc,nul1lillg "'I'I':(es. inl'ludil1l!:llIditing services. thai muy 1)('reasonably Ilc,'cssary at any iimc 1,,1' the Project tn meet tilt' Owners need" and interests.

§ 2.5 The Owner shall provid« pW1li1'1 wrincn IltHicl' 1", ilh' Architect il'tllL' (h.'.'ller bccomc-, ~m;lI'C olany Ellilt <'rdetect in the Proicci. including crrorx. tlmissiollS or il1(t>llSislcnc:ics ill the Architect S lnxtrumcm« of SL'!'\ ice.

~2." The' Owner shall furnish (i) "lI"\e:~S 1<'the r vrchircct IP de's.:rilx physical characteristics. kgal limiuuion-. anduul it Y locations for the site ()r the Project and (ii) a \\TiIlCIl kg;!1 <k"<~ri I't i('11 "I' the' site. 'Ill<;' -urvcy« and leg:! iinformation shall include. a-, applicable. h-'Ti.hh::-s nnd lines of "trl·•....h. allcv-; pavement- and adjoining pr\)p(Tty andstructures: adjacent dunnage: rights-of ..wa», rcsuicuons. easements. cucroachrncrus. zoning. deed restrictions.boundaricx and contours of the sill': locations. di!llel1Siel!\S alld ncccssarv d.ua with respect III c-..isting buildings. otherimprovcmcru-. and trcc-; and inihrl11<1ti<)11concerning available illilily services and linl's. hotl: public and private.above and below grade. including inverts and deplhs. Alllhc information on the SIII'WY shall he referenced \(l a Projectbcnclunark.

ARTICLE 3 COPYRIGHTS AND LICENSES§ 3,1 TIK Architect and the Owner warrant 111;1\in [r;lIl~illi Ilin~ Instrument» or Sen ice'. "I' <lily other in lormauon. file'

Iransmiuing party i~ the copyright owner of -uch inti\f'll1.;;lnn or ha~ pcnuission trom the c"p)Ti~lliowner to Irall"lllilsuch ill limnatitlll tor its lIse on the Project. !rlh~' Owner and Architect intend 10 IralNllil luxtrument-; of Serlin' or :lily

(Ithcr information or docurncnt.uion in digiw! tonn. they shall endeavor to l'stahlish IICC\:SSI!'V protocols g\l\'nllin~such lr~nSnl{SS1011S_

§ 3,2 Tit" Architect and lhe :\rchitlYt's consuhant-, skill he Ikcll1nl the .uuhors and owncr« of their respectivelnsrrurncm-, <,i"Service. ine'llIdiil~ the Drawings and Specifications. and shul] retain all common law. st,i!uh1ry andother reserved rights, including copyright«. SuiJll1issiC'i1 (If distribution of ln-arumcnts \l!"Sen ie•..· to meet omeialregulatory rcquircmcnr-, or 1(11'similar purpUSl'S ill connection \\ ith (ill' Project is 110t to be l'ullSlrtled as publication indcrog.uion urlile rc'stTlcd righ" "fille .vrchitcc: and lile' Archucct ' ...C()!lSUit'lIlIS.

§ 3,3 lIpon cvccui inn otthi-. i\grcc'nH:'l1l. the Architect grants w till' Uwtlcr a noucxclusivc license to use theArcililc'l'l', InSlrlltlll'iliS olService St,k!\" and e\e'IUSi\C\Y for the' I'nl.j<:cL provided that the Owner suhslanliallypcrtorm-, il,; obligauon-; includinl! prompt l:r..l:"I1lelllof all SUli" whrn due. under this Agrt:t"il1ClH. 1"!1('.vrchuect slt:dlobtain similar noncvcluxi vc liccn-«-» [rom the ,\reili!<xl'S c'Ol1-':Ultal1ls <'011-':1';!<:'111\\'llh this ,\gree'IilCIlI. The liccnxct:r<llllcd under this scctinll permits th.: (l\mer In authorize the Contractor. SubcPiHraCI'lrs. Suil-suhc<llltr<l,·lors. and

AlA Document 91021',' - 2007 (formerly 8141 ~0.,4 -1997 Pur! 1). CopYfi~hl'~) j~ f7. lQ:?G. ltH8:. 10::j.1. 1!JS:"I.1tJ5B. lHG1. 191::)]. 1~VH}. jQG7. 19'iG. 197~'. 197/.1£1Hj. 19~.!7and 2D07 by The /V!1uicH1 !n~tltutA 0: !w.:j~1ects.AU tights reserved. 1;V.t.f.::~HNC: This- l?..!l·, 1}O{;'~'d··.-}fl-t;-C'-pr<)'i'.:-r:to1d ty ~;,.:'i. L,j','; ;;!';(;

fi\l,;;·;~;'!tkn0~ Tn.·'<.tl:,':,<.UiFHilh'->~!L;;rJ r:'),'!((':d;JGtio'" ,-,-;-:+;~,~rii·:~i!if.n(i~ ihi'.' -,,; i-" U\\,~;!l1~\~;;i. '.";;' '\H'j ;:;~',;\i\"!~ld it, l!~,-;V r:_":Wt ll' ~",:)'J~~:,;(:;;.-'ii \:dn:i~i:'jp\')n;:dUcr~,~':n(';1/,:iq :)::,' pre:,::-,,; .~.-H::~:~ ::;L~ ',l'i::l.'"i:ni,;:; '~:-I:i,(~i P':.:;~:)~~1\'.'(JwJ':< n",· L~1'J , T!1i~ dnC:'1Oh;lli 'vas pmdt.l{;t:(! i,V /",1.1\ souv.are al 1·~::?9:f)1 On O1127120 14

4

lI!!d(~rOrder No.:::.i":i2:27B;iI) 1 j ;NhL~1~~,\pif~S.OIl (';9:,:1fl!20 H. anrl j~ liO\ (cr rt:~'::.dk:

US"}!'"Notos:

Page 5: Document B102™- 2007 - Al

IniL

!.natl'rial ,>,' cquipm.:nl suppliLTs. as \\cll a..; Iht' Owner', eOIl"iltants and separatt: contractor-; to reproduce applicableportions ulthc Instruments ofSl'nicl' sokh and c",.:!l!sil"cly for liSt' in perfortning scnicl's I()r tht' f'rojl'l'1. If theArchitect righlli.lI!y terminate:, this Agl"l'l'llll'iH k,r caus,: as prolj,kd in Sec!i,\j1s 5.3 and 5.4, the liccnsc gral1le'd in thi-,Scctioll 3 ..' siJalllclmina!t'

§ 3.3,1 In the event the (h'.I1Cr use, tlK lnstrumcnt-, (>!" Service withou; rctainins; the author of the Illstrllllll'llh orService. the (hvl1t:r releases the Architect and ArciJit<x;", L'nnsultlllt( si from all claims and Clllses or actiou ari~il1i"from such uxc».

§ 3.4 [\cept tin' the license's granted in (his ,,\nick :I,no other lie'en,e' or right shall he deemed granted or impliedunder this Agreement. The O\\l1t'1" shall not assign. dl~kgalc. sublilTIlSc' pledge or 0111('1"\\ is\:' transfer any licenscgranted herein to nnothcr pany lI"i thou! the I'ri(\I' \\ ri ucn agrccmcnr of the Arch itect. Any UI1<llltiJori7<'duse of theInstrument- ofService shall be' at the (h\"llt'r', ,ok risk and without liabiliiv h) the Architcc: and tile Architcct«cousultantx.

ARTICLE 4 CLAIMS AND DISPUTES§ 4,1 GENERAL§ 4.1.1 The Owner and Arch iiect ,.,hall commence all claims and causes or act ion, whether in contract. tort. 1>1'otherwise, against the other arising out or or related to th is AgrCl'IlWIl1 ill accordance with the requirements or the'method ofbinding dispute i"(.'solutiol1 sckt.'tc'd in this Agr,·C'lllcnll'.'ililin the period specified hy applicable law, hut inany case not more than I () ycars after the date of Subxrantial Completion n!' the Wmk. Th<' ()\\IKI" and .vrch itcct \\;1i\ c'all t:lailHs and caus~s of a~,tion not commenced in at'cnrdance with this Sect ion 4. i .1.

§ 4.1.210 the' extent damagvs arc' CO\·crC(] by pmpcrty in-uraucc. the (\\\I1Cr and Architect w aivc all right,; again."each other aml <lgainsl the contractor-. consultants, agents and cmph,\"('cs "fthe other for llamagcs. C'\Cl'PIsuch rightsas they may have to the proceeds olsuch in sur.mcc a.s Sc'! {imil in AlA Document A201·-~007. (fellcr;]i Conditions of(he' Contract illI' Con-truciion, ifapnlicablc. lhc Owner or the Architect. as appropriate. shilll require olthecontractors. cnl1SUiWlHS, agent S <lndemployee'S or any (11' them sim ilar wai n'r, in lav.» of the other parties cuumcrarcdherein.

§ 4.1.3 '11K .vrchitcct and Owner \\',Ii I'C con ',,'qm'mial damages 1<)1'clai 111". disputc's or other m;1I lCI'Sin q I!es! ion arisingout or or relating III this i\grl'c:llll'l1l. This mutua! waiver is applieilblc, without limitation, to all conscquential dam.)!!,>due to either party's termination Gflllis ;\grc'c!J]clll, except <\, "pcciile;]lly provided in Section 5.7.

§ 4.2 MEDIATION§ 4.2.1 Any claim, dispute or olher matter in qUl'stion arising out 01'01' rl'iiHL'd tn rhi, A i'reenlL'1l1 shall he subject tomedial ion ;1' a condition precedent to binding di,put<:' resolution. If such matter ;-dates h' (II" is ,he subject 01' a lienarising out of [he Arch itec: 's services. the Architect may proceed in accordance with applicable lave' to comply with the'lien notice Ill" tiling deadlines prior to resolution ,)1" the' matter by mediation 01" by hinding dispute resolution.

§ 4.2.2 The Owner and Architect shall endeavor t,) rcsolv« claims. disputes and other llIallers in question betweenthem by mediation which, tlnkss the panics muruall y agree orhcrwi-«, shall be admini-acrcd by the AmericanArbiuruion ;\ssociation ill accordance with its Construction Industry Mediation I'roccdurcs in effect on the' date or theAgrecment. A request for mediation <hall hl' made in \\Tiling. delivered tll the other party to the Agreemenl. and filedwith the person or entity administering the mediation. The rcquc-a l1l<iYhe mack concurrently wilh the tiling oj' acomplaint or other appropriate demand lor binding dispute resolution but. in such en-lit. mediation shall proceed inadvance nfbinding di:';PlllC rcxolurion proceedings. whicl: shall be stayed pending mediation for a period of (,() daySlrom the dale' of filing. unk-;:; stayed tor a 10111'l'l period by agreemenl ofthe panics or court order. Iran arbi1!'ati')ilprocceding is staYl'd pursuant 10 this Section. Ill,' panics may IHHlclhekss pnKee'd 10the selection ofrh •..arbitra.ort s)and agree upon a schedule !ill' later procl'edings.

§ 4.2.3 The partic-, shal! share ill<.'i!1c'lliawr's fee and ail} !iling [tTS <,qlml!;. f he media1ioll sj-,;lli be IIdel inBirmingham (Jclfcr-ou Coumv). AI.. unlesx another loc.u ion is III uiually <igrct.'(i upon by Owner and Architect.Agreeme'nts reache't1 in mediation sflall he cnl(>rccabk as sL'ulcl1lcm ngrel'J1lciltS in any court h;.ning.illl"isdictiol1thnclIr.

l\lA Document 81021'.1 - 20tH (fonnal1y B141 p.' ~ 1997 Part "1).Copyd~Ii11 ~;::,E!17; 1~~26,h~·~n,1951. E1S:'i.H!5F'., 19';";, 19G3. '26(::.19137, 1f!7iJHr1:L 1977,1937, iH97 and 2G07 tn!"lituteof Arctvtects. AU rights reserved. 5

Unrief C)rder No.5!2227(Q!}1 ..! ',';'!w;h m:pjp~s (In Ont-!';1i2t)H, and j~ not for res.Jk:-User Note.s:

Page 6: Document B102™- 2007 - Al

§ 4,2.411" thl' partil''; dn not I'l'sllhe a dispute thr"lI~h mcdiuuon pUI'SUZlll1 to thi.; Sccuou -l,2. thl' method "fhinliill;!dispute r<:\"IUli<l1l .;hallbl' the 1t:,!1o\':in~:ttluc}: tl:•..II/'ll/'''pri(/!(' [niv, Ittl«: Owucr ani! .'1rcbucc: do 11(11srlr«! o mctlu»! nlhinding dispu!« /"l'SII/lIiit/1I h'-!II\". Ill"

do lJol suhv('t/u(,lIt/y agree in l\Tiring /0 fl hillt!i"g dispute: nsolutio» Nlf.'rltod other t hun /i/(!.!({!ioll. tl« disrnu« \1"11/ he/'(',,,,/1'('(1 in u ,'O/l/"/ III (,Olll/'t'/ell! iurisdiction)

[ 1 ..vrbiuurion pursuant \0 St'c"lioll .1.101' this AgrL'e'1l1<:!1I

[ X ) I iugation ill a court of compctcm juri-diction located in the llirminghal11 Division of JeffersonCounty, ,\ I;lhalll;l

§ 4,3 ARBITRATION§ 4,3,11fihL' partie's have sdected arbitr.uion as the method tor hindil1;! dispute' resnlutiol1 in thi, A grc'cillcnt. JIi)

claim. dispute or other matter ill quc-aion arising nul of or related to thi s Agreement subject Ill. hut not resolved by,mediation shall be sul~i,:ct to arbitr.uion. which unkss lhc' partie.; nuuually agree I)therwj'l'. shall be administcred b)the American Arbitration Asxociation ill aCmrd;JIKC with it,; Con-aruction Industry Arbitration Rules ill ,'nc'ct on thedak' olthi» Agreement. i\ (km:tnd tor arbitration ,hall he: made ill \\Tiling. dclil'lTcd to the other j1iln~ to thisAgn:CiJ1t:I1t. and filed with the person or entity administering the arhitrution.

§ 4.3.1,1" demand 1,)1' arbitration shal! he made IIIl L'arlier rhun concurrently with the iilill,~(Ira rcquc-.t tor mediation,but in no event shall il be mad" after ihc datt' when the institution of !cgalllr equitable proceeding» basd on the claim.dispute or other mailer in question would he barred hy the <1ppli.:ahk statu" oll im iuu ionx. Fur statute ol'f imiuuionxpurposes. receipt ora '\Ti11cl1 demand fix arbitration hy the 11('1"';"'11or entity admini"tering the arbitr.uion siJ:lllconstiuuc the' institu: ion of ll'1;a! or ~'q\lit:lhk pnll'c,'ding" based on the claim. dispute 01"NhCI" maucr in question

§ 4,3.2 The li'l"\;gl)illgagrt'c'lllc'nl to arbiiraii: ;1Ilt! other agrl'l'!I\c'nlS ill urbitrat,: with an addit ional person Ill"('mity dul ycnnscntcrl (0 by parties to thi,; .\;;recll1ent "hali be spL'citil'ally L'nr,lrccahk in ,lccprdallcc with <lI'Pli'\lhk 1;1\\' inBirmingham (Jefferson ('OlIl11)), .\1..

§ 4.3.3 The award rendered by the arbitrator(,) <hall he- linnl. :1I1d judgment may "', entered UP,11l II in ;1Cl'OrcbIlCCI':ithapplicoblc law in Birmingham (.ldlc'rs\l!l Couuty). AI..

§ 4.3.4 CONSOLIDATION OR JOINDER§ 4,3,4.1 l.ithcr party. at lis sole discretion. may consolid.uc all arbitratioll conducted under this :\grL'elllcllt \\,ith anyother arbitration to which it is a party provided that (I) Ihl' arbitration agreCIllCJ1[ go\('rning the other arbitrationpermits consolidation; (21 the nrbiuations to h,: con ..;oii:.i;lt,'d ~lIhslaTlIi,\II\' involve CIH1l1l1ll1l que-nons of la\\ or i:lCt:and O) the arbitrations employ matcriallv similar procedural rules and methods tor s.:kcting arbitrarort«),

§ 4.3.4.2 Either party. at its -ole di,erelioll. may include byjoinder per,pns or emities -ubstantially involved in acommon question of law ,II' fact ,,110";,' prest'llce is required if complete relief is to be accorded in arburaiion. providedthat the party sought to be joined conscnrx in \witing to <uch joinder. Consent to arbitration iJlmhing all additionalperson (II' emily shall not constuut,: couscru til arbitration \)1' any claim. dispurc or other matter in question notdescrihed in the written consuu.

§ 4,3.4,3111<: OWI1(,I"and Architect grant to anv person or entity made a part\ to all arbitration cunducrcd 1I1Hkr thisSection 4.3. whether bv joinder or cO!lsnlilhlli"I1, the sa111<: righls oljoiudcr and C<1I1so lidrn ion as the Ov, ncr andArchitect under this :\gJC:"tn,:nt.

ARTICLE 5 TERMINATION OR SUSPENSION§ 5,1 If the Owner I;lib tll make pavrnerus tn the Architect ill accordance with this i\grceIllL'liI. such Iailurc sha!! becOllsidc'lTd subsr.uuial nonpcrtormancc and caUSe till' (c!'lllinatinil or. ut thc Architect", option. cauce tor sl!sp<.'n.;itm orperformance of scn'i..:cs UlHkr this Agrc(,!11ent. lfthe Architect ekus to suspend services. the Architect shall gi\'c'seven days' w["i/[cl) nol!Ce fl"t rhe C)\\-ncr hcl~--'IYs!fspt>nding ."'I...'ITi{:t:.-';. In the ("\('nl ora suo;;pclI,...;iul1 pf~i:·I"\'icC's. tht'

AlA Document 8102 rv - 2007 (fomleny B141 ~·.l-1997 Par11). Cop-;':'l"ight ':;:; H}17. H)26. 19"H~. ~D51, E.Y.:<t H15B. Hlf)i, Hld3, i9GG. H1G? !~170. Ell.1. 1977,l~)f:fi. 1Dn7 ~1f1d2007 i;w Amoric;m IIlS:itH!(; of Arc!uk:ds. All rights reserved. ~N/.?;'~!t:C: ;!i~-/-\1/), ;>~~.:'::Tl(:nth, ~nG\'::d'(c;; h? !j,::i: ;!i"rd

c::,-:~ ;;~'Id<:n'i ot t),;r; /,;.f. ..• Dr.; :un17n:,, -'",~~;U!,;U;1[k.l" U~";~[n','}. This

"'j linn e! it, m;!.y i"-l~~'ultb': :~.;~~\:t';((~

'/;3$ produce-{! l)\l AlA soil'.o;arn at 14:20:01 en 0 i /2"f!iQ i ,I

6Init.

under Order No_S72227n·h11. 1'/:hich expi((:!s (Ill 09.-'i9:2Ul~. ;:1lld is net for tOSi;1Jo,

User Notes:

Page 7: Document B102™- 2007 - Al

Init.

Archilect shall h uvc no Iiahi! it v tu the Owner IiiI' delay or damage GIlN:d the Owner bccau«: olxuch slIspenSilllj of-ervices. Ikfl1r,' resuming services. lh,' Archilt'Cl shall be paid ;lll sums due prior 10 <uspcnsion and <lily cxpcnxesincurrrd in Iht' intcnuption and rcxum jJl ion orlhl' /\rchilc,'!', ,,'IU('CS, J he Architect',,, it'Cs 1(-;1'the r<'IHGirlillgservicesand the IHlW schedules shall be equitably atij tI>;\cd ,

§ 5.2 If the Owner SllSlk'llds the Project. the Architect shall be compensated lor SCI'\'lces performed prior to notice' ofsuch xu-pen-ion. When the Project is resumed. the Architect shall he compcn-atrd 1,)1'expc'Ibes incurred in theinterruption and resumption of the' Arch Itc'l" 's services. Tile ,\ rchircct 's !\:cs for the remaining services and tile lime

schedules shall he' equitably adjusted,

§ 5,3 II' Ihe O\\nLT -uspcnds Ihl' Project I'or more than (iO cumul.uivc day'S for 1\'<I';0I1Sother than the fault of theArchitcc'L tile Architect may terminate thix ;\grl'CllIcnt hy giving 1l()1 less than sewn days' written notice to the Owner.

.§ 5.4 Lither parly may tcnnin.ue this Agl'Cl'l1ll'l1ll1pollnol less than seven days' wriucn noricc to tll<.'other party should

the other party fail substantially In perform ill accordance with the terms oithi« Agrcl'll)Cnt through no E\LIlt ofth.:party initiatinj: the termination,

§ 5,5 The Climer may lc'rlllin<llc th i, i\grecnlmt upon nul less than SC\'CIl day.;' nriu(,l1 notice 10 the Architect Ii.!!' the'Owncrs convenience unci without L;lU'~'.

§ 5,01n the event of termination not fhe 1;1Ill! ofll1l' Architect. tht' Architect shall I", eompclhated Ii)!' s('!'vieTsperformed prior to termination. together with Rcimbur-nblc L:\~)('l1sl'S then due,

§ 5,7 \ :.

§ 5,8 rile Owner 's rights to use ihe Architect's Inxtrumcnt-, (.( Service in the event "t' ,1 tcrm illation of I h is AgITell1t'l1iare set forth in Arriclv :, and Section (),5.

ARTICLE 6 COMPENSATION§ 6, i lhe Owner shaII compensate lile :\ rcll iin:t Illl' sen ices ,ksni hed in Sect i011 l . I ;IS Sl.'l lunh helm\,. or in theattached exhibit or SCOPl'document incorporated illtn this ,\grccn1('rH ill Sel:tion '),2.(Insert umoun! o]. or basisi,»: COiJl!1(_'J1.\-ation or indic.s!« Ilu' c'shihi! or _"copec/nf1f1HCJI/ in ivhich COfJl!h,,'I1.HJ!ioH isPI'''' 'idcdtor.)

The Architect's ICe for basic >;enice,;, including hard <cape lay-om, Structural. :Vie-chanica!' l.lcctrica] and PlumbingEngineering shall be 7.1)"" ofthe ('ost ofCon-nuction.

§ 6.2 COMPENSATION FOR REIMBURSABLE EXPENSES§ 6,2,1, Reimbursable F\pellSeS arc in addition '(' compcn-cuion tor the ;\rchitl'ct's pruil.'ssi(lllal s~T\ices and includeexpenses incurred by the Architect directly related to tile Pruicl'l. as i(lll(\\\\:(f'aragral,/is ddcll'd)

.4 Priming, reproductions. plots. ,(and:!rd form documents:,5 Postage. handling and delivcry:,6 E.\p.:nse or overtime work requiring higher than regular rilles, if authorized in advance' by the' Owner:,7 Renderings, Illodels, mock-ups. professional pilowgrapity, and presentation m.uerial-, requested hy the

Owner:

,9 All ta\CS levied reimbursable npc'l1ses:(Parugniph'r'deh'[cdi

§ 6,2,2 For R,~imbursabk i'\penses, the cornpcnsati')11 shall k the t',\I)c'rlS('~ incurred by thl' Architect plllS:l11administrative ki:' often prrcenr ( II) "n} ofthe C\PClhCS incurred,

AlA. Document 8102T"~ - 20(1:7{rcrmerty B'i4P'~' --1997 Part 1). Copyliohr ':.. HH7 192G, ENS. iHS L 195~i,!9~8 1961, iS~63, H7lG6. HJG7, '1970, 1Ul4, H(77,,\meriuin instiluterlf .~\fcllitecls. Ail rights r~served.

7

Im:)!}f Orclcf r!<J.S72227D··;O l.. '1 '.':ili,j) ;:c.<"<vir;:;s (,11 (;9'; U,;20 1 ,1, And 13 not kif v:s:1l,~~US"'" Noles:

Page 8: Document B102™- 2007 - Al

lnit.

§ 6.3 COMPENSATION FOR USE OF ARCHITECT'S INSTRUMENTS OF SERVICEIr the Owner terminates the Architect 1,)1'it-; convcn icncc under Section 5.:\ or the Architec: term illal<:, IIIis;\grecmcllllllllkr St"Ciillll 5.:1. lhe 0\\ ncr shall pa\ a li,·,'n.'ing I~'l' as compcnsauon for the Ov.ncr·s LYllltinucd use ofthe Architect .....ln-trumcnt-, "I' Service 'l'ldy lor purp'hes "f the Project as fi11io\,;,;:

§ 6.4 PAYMENTS TO THE ARCHITECT§ 6.4.1 An initial payment ufN.:i\ ($ 1shall be made upon cxecution ofthi-, Agreement and is the IIIin im urn paymentunder this i\grcclllCnl. It shall be credited In the ()\\'Ilc"r', account in the Ililal invoice.

§ 6.4,2\ 'lIlcss othcrwi«, agreed. paymcut-. tor ,c!'licc, shall he made Illonthly in proportion to ,,:r\iecs performed.Payment» are' due and payable(Paragraphs dde/cd)within (.,0) days following presentation olth« Architccis invoice 10 tile Owner.

§ 6.4.3 The Own,'[ shall not withhold amounts from the Architect S compensation to imp,'sl' ;] pcnahy ()I' liquidateddamages 011 the Architect. or to nfrs,'1 SIlins requested hy or paid to contractor» for the cost of L'ilanges ill tht' Workunlcs-, lhr Architect agrees PI' has [""'il found liable 11)1'the umount-. in a binding dispute [eso!tllioil prucixliing.

§ 6.4.4 Records of Reimbursable L'lxllSl'S and SLT\'iet'S pertormcd on till.' hasis 11rllPuriy rat(·, shall he available to theOwner ill mutunlly convenient tirncx and shall not be IIIlrciholi<1bly withheld.

ARTICLE 7 MISCELLANEOUS PROVISIONS§ 7.1 This Agrccmeru shall he governed by the la\'; or the slate 1)1':\ labama, ,'.\ccl't ih.u if' the partic-, have -clcctcdarbitration as tht' method of binding di-putc rc-olut inn, the h:dlT<l1 Arbitration :\ct shall ~o\'l'rn Section -1,3,

§ 7,2 Terms in this Agreement shall haw the <arnc mcaniuj; as those in AlA Documciu ;\21)1 2()07. (jt'l1cralConditions pI' the Conuuct tor Constructi

§ 7,3 '111<,Owner and Ardlit,:,-L respectively. hind th,'msl'h'c'". their agl'lw;, ~lIl'Cl'ssors. assigns and lcgolrcprcscnuuivc- t\) this AgITl'Il1Cf1l. Neither the Onller nor the Architect shall a.ssign this j\~rccllll~n! withuut th.: writll'fl(I1!1SCtlt of the other. except that the Owner may assign this Agreement 10 <Ilender pr\l\iding financing for the Projectif the lender agrt'<'s «) assume tll,.' Owner's rights :'l1d ohligatiulls under this Agrl'l'l11l'lll.

§ 7.4 Itthe Owner reqllL'sb the Architect !\1c'\ccllte certificates. !he proposed langtlag" OfSlIl'1! certiticatc-, shall besubmitted to the Architect for review at kas\ 1-1days prior III the requested dale'S ofexecution. If the O\\I1er rcquc-a-,the Architect to execute nm,CI1lS reasonably required In facilitate assignment to a lender. the Architect shall executeall such CO!1Sl'IHS that arc consistent with this Agrl'C'(lH.'1l1. provided the proposed consent is submiued ill the Architectfor review at iL'aSll-l days prior 1(' execution. The Archiicc: <hall not he required In execute certificates or consentstllat woulc] require knowledge, services Ill' rcsponsihilitil'S beyond the ,,'opc' of ihi..; Agreement.

§ 7.5 Nothing contained in lhi, Ai!rcement shall create a contractual rckuion-hip with or a cause Oral'l ion in favor of athird party ag:lillst either ,hl' Owner or Architect.

§ 7,6 l lnlc« otherwise required in this Agreement. the Architect and the An:hitcct's Lilgincl'l's sh;t11 have 110

rcsponsibilitv for tin' discovcrv. identification. presence. handling. removal or disposal or. (II' exposure of pcrsous to,hazardous materials 01' toxic sub-aunccs ill ally h)!'111 at the Project silc'.

§ 7.7 The Architect shall !t,,\\. the' riglu to include pilotl)grapilic (II' artistic rcprcscnuuion-, "fth;." dcsignoftilC' Prtlyciamong the Architcct« promotional and profc-xiounl mru crial-; ThC' Architect shall be gi\'c'n rt'as()nabk ,}C(CSS to thecompleted Project III make' such rcpre-cnuuion«. I lowcvcr. the Ar<:iliICe!'s marcrial-, shall not include the Owner'sci11llidl'fltiai 1)1'proprietary information if the (h\l1<'f' h:1S prc'\iously advi-cd the Areilitel't ill \\Tiling ol'thc specificinform.uion L'l'llsiticfl'd hy the Owner to be COil fid,:nti,t1 [II' proprietary. The Owner xh.rl l provide prllli:ssiull;d credit tortill' Architect in thl.' OWIlt'r', promououal marcnal-. for the Project.

AlA Document B'1021'" -~ 2007 (formerly 8111.1 Iii -1997 Paf11). CO~lyri9h' iU "1£)i7. 1026. 1~Hg. 19~)1. 1UST 1n:-.S. 19[-)1. 1903. 19G6. 1C!G7. 1970.1914 1977.19B7. EH)7 and 20tH b(fl1o Arnnrir.an lnstiluh~ of AfLbinr:ts. AU rights reserved. V'J,;\f:::';H,~-:":!:-; ;',i~,/\l.c,. ;"J(~l;~..ln\!)il;, is prot"\~'~1:i:.:duy tL~', L~i\'"'~,v}]nt'!]"'n;~:i~F;:;j Tr," ;n";~,. t!n,1uH1!)(L'.'~y$ ;,:-ptoC:I;;: __£kh': {:,;-{t;:~-~:;;J;;i'k)5:{':';'~his /U/\ DCC',i<i;''!:)\, ZW;t fH.iiti()!1 .:-;i' it. t'i~',T1:i:.~~;uf\ii"! ~';;':V;:J}

':";;T),\ti::,~;.,.: iF) '::if! b(;" pn);:'~N;-Lr:'"':jJt(l ~hi": n'!;;::i:!!u:-,'i "·-;;;;:~:ibl\:, U;lc!"~":" U~"".:!~n~:J,This do::::wllt:'mt ~~.·asprouu(:€;cJ by ;\IA sof1wan.:: ati4:29:01ol1 (}1/~U/20 q

8

under Order i,,:o.S72227fHG 1_1 '\o\'tik:rl u~pfres on OUi1~~.'2C l;L ani] is not rn!" rosa!?.User Notes:

Page 9: Document B102™- 2007 - Al

Init.

§ 7.8 nrhc Architect or r iwucr rc'\'c'!WS information spl'ciiicl!iydcsignall'd hy the other pany a, "confidential" or"business proprietarv." the reeTi\ing pany shall heep slIcil informarion suictlv cnnfi(kntial and shall not diseiUSL' ii (0any other person except In (I) its employees. (21lilosc who Ile<.'d to hnu\\ tile conluii of such intonnntion in order toperform services or construction ,nkly and vxcluxivclv 1(1i' the Project. ur C'l its consultants and contracto!"s whoseCOlitracts include' simii,ll' n:,rrictiol1s on the u-«. of con fidel11ial in Iorma: ion.

ARTICLE 8 SPECIAL TERMS AND CONDITIONSSpecial terms and conditions ,hat modify this Agreement arc as follow«:

For ;\dditiollal Ser\'lCt's, agreed upon ill advance in \\Tiling by Owner, that may <1riscduring the cour-«- ni' thc' hOjL'CLthe O\\!lCr shall compensate the ;\rcilitt'Ct and lhe' Architcctx Con·;ul!ants as ['1,IIr,ws;

Arcililec!'s Hourly Fees;Principal Architect $25ii'ilr, Project M;magt'r S!:'5 hr. lnrerior nc~iglll'r S 120 hr. Dralisma!i S 1no hr. andAdministrativ.: Support Personnel $:'\5'hr

Structural Cllllsultant Hourly lec-:SC!lior Principal $200.111'. Principal S ]90·111', Associate S !.'iOhL Sr l'roicct Managl'r S 1~:ihr.Project i\\anager$125'111', A 'N Proicct Manager S l l o hr. Projcci Fnginccr S j OI.1·hr, Uesign Engineer S9()'hr, BEvl Modeler S9(Jhr.L\[)D Operator SHOihL Tech s: Ckri,al S70ll:

Mechanical Convuhants ilouriy Fees:Principal S 125ihr. Sr. Engineer S j 05111'. Senior Designer S j 0". Ik.;igll<'l' SH5hr. [n~' Intern SHOllI', Jr. Iksigl1tT 575hr. DrZli'lsman$65'hr, Admin ixtrutivc >55'111'.

Electrical Consultalll Hourly Fees:Principal S l-luhr. Project f\.l:magcr S 11Oh1, C'.\l) Operator $7() hr. Ckric<11 ~45 hr.

ARTICLE 9 SCOPE OF THE AGREEMENT§ 9.1 This i\grecn1l'i1! represent, the entire and illtl'~!ratt'd agreeillt'1l1IK'iWl't'1l the' Owner and the Archiicct and"';UP(TSlXit:S ail prior ncgotiation-, rcprcxentntion-. or agrccnlcnlS. either wriucn or oral. This AgrcCnh"fH lll~!y bt.--amended only by written instrument signe'd hy both On'ncr and Architect.

§ 9.2 lhi-, AgreemCilt is comprised olthc I(llhllling d(lculllent.-; listed below;.1 AlA Document BI02-2007, Slandani Form Agreclllcnt lktwc<.'11 OWTlL'!'and Architect.2 ;\1;\ Document 1'201 ::'007. Dig.it;iI Data Protocol Lxh ihit. ifcompleted. or the !'ollowing.:

.3 Other documents;(Lis! other dOCltlJ1C!lIS. inchulins; {II(' .irchiu:«: ',\;,';eil/H' oiscrvicc» dtnumcnt, hrrc!»: illCOJI)OI"L/{('d intothe ,i!';/'t·clIlcnt.)

ln itiu] Square hlLHagc Tabul.uions. dated :\U!'.lIsl 5. 20].;

Thi, AgrCCl1ll'IH cnlcr,'d into as olthc day and yeaI' Ilrsl written above.

OWNER ARCHITECT

(.\'ignaliln»

(jary h'c)' t>.Iayn•.fSigJIUllll't')

l.oui-. Ncqucuc. j\L\ (TO. IPrilll~J7;;;;'~,o/ld liIio ~-~---.-.-- ....-----

Dungan N"\jI IC!tc' Architects. Inc.

lfriu/i:d Half I( .ou!City of Hoover

AlA Document B102 f'! ~ 2007 (formerly 8141 T~l -1997 Part 1). COPYf191:t i~" Hl1t, 1926, HHH,IDD1. 1953 1DS8.19G1, HH31. 1;}GG,1:.:m7, 1970. l~rr.;l 1~)71,19FI. 19~17and 2007 bV The ;.\merif:"Hl !nsti~ut8 of Arct.itects , AU rights reserved. ,.·,C·. < !",',.

under Ord':!r l\}o.57:~:22ig401_1 wtricrr eXf1ir'~s on Oft'19f2fl 14. nnd IS not for n.:sd1,:User Notes:

Page 10: Document B102™- 2007 - Al

Hoover Fire Station

Attachment to AlA Document 18102~2007

Initial Square W:ootageTabulations;.'\ugust 5, 2013

t.ocatton W D SF

Engine Bay 36 64 2304Day Room & Kitchen 28 24 672Office ro 12 120Lobby/Entry 8 8 64Support/Ancillary 8 12 96Officer's Quarter wi Bath 12 14 1684 Bunk Rooms w 2 Bath 22 30 660Gear Room 10 10 100Mise Stroage @ Bays 10 20 200Generator 8 10 80Electrical 6 6 36Janitor 4 1.\ '16Laundry 6 6 36

Total H& C Square Footage 4552

Outdoor Spaces

Front Pad 32 x 64Rear Pad 32 x 64Fuel Tank Area 10 x 12Grill and Porch 8 x 12