Upload
khangminh22
View
0
Download
0
Embed Size (px)
Citation preview
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
1
ZAMBIA NATIONAL BROADCASTING CORPORATION
REQUEST FOR EXPRESSIONS OF INTEREST (EOI)
PUBLIC PRIVATE PARTNERSHIP (PPP) PROJECT
FOR THE DEVELOPMENT OF TWINPALM LAND
IN LUSAKA ON HIGHEST BEST AND MIXED USE
EOI No: ZNBCPPP/TWINPALM/2020
EOI Issuing Date and Time: Wednesday 19th August 2020, at 08 am
EOI Closing Date and Time: Friday, 18th September 2020, at 2:30 pm
EOI Opening Date and Time: Friday, 18th September 2020, at 2:30 pm
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
2
Table of Contents
1.1 About Zambia National Broadcasting Corporation ........................................................................ 4
1.2 The Opportunity ......................................................................................................................................... 4
1.3 Purpose of this Invitation .......................................................................................................................... 5
1.4 Procurement Model .................................................................................................................................. 5
1.5 The Parties in procurement process ..................................................................................................... 6
1.6 EOI Terms and Conditions ....................................................................................................................... 6
1.7 Project Stakeholders ................................................................................................................................. 6
2. Project Information ............................................................................................................................................ 7
2.1 Project Overview ....................................................................................................................................... 7
2.2 Project Package ........................................................................................................................................ 7
2.3 Project Objectives ..................................................................................................................................... 8
2.4 Site Information .......................................................................................................................................... 8
2.5 Site Investigations ...................................................................................................................................... 9
2.6 Authorisations and approvals ................................................................................................................ 9
3. Project Scope .................................................................................................................................................... 10
3.1 Scope Overview ...................................................................................................................................... 10
3.2 Project Responsibilities ............................................................................................................................ 13
7 Table 6. Activities undertaken or managed by ZNBC ................................................................................. 14
3.3 Design Considerations............................................................................................................................ 15
3.4 Construction Considerations ................................................................................................................ 15
4. Commercial Framework ................................................................................................................................. 16
4.1 Contractual Structure ............................................................................................................................. 16
4.2 Commercial Principles or Risk allocation .......................................................................................... 16
4.3 Commercial Opportunities ................................................................................................................... 16
5. Procurement Process ...................................................................................................................................... 17
5.1 Overview .................................................................................................................................................... 17
5.2 EOI Phase ................................................................................................................................................... 17
5.2.1 tendering period for the EOI ............................................................................................................... 17
5.2.2 Interactive EOI Zoom Meeting ............................................................................................................ 17
5.3 RFP Phase ................................................................................................................................................... 17
5.4 Negotiations .............................................................................................................................................. 18
5.5 Public Sector Comparator .................................................................................................................... 18
5.6 Project Governance ............................................................................................................................... 18
5.7 Project Advisers ........................................................................................................................................ 18
5.8 Project Delivery Timetable .................................................................................................................... 19
6. Content and Evaluation of EOIs ................................................................................................................... 20
6.1 Detailed Content of Evaluation .......................................................................................................... 20
The Evaluation process will consider the scores below: ............................................................................ 20
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
3
6.2 Evaluation Criteria ................................................................................................................................... 20
6.3 Evaluation Approach ............................................................................................................................. 23
6.4 EOI Response Information ..................................................................................................................... 23
6.5 Additional Information ............................................................................................................................... 23
7. Procedural Matters .......................................................................................................................................... 24
7.1 Enquiries ..................................................................................................................................................... 24
7.2 Lodgment Details .................................................................................................................................... 24
7.3 Closing and Opening Times for EOI .................................................................................................... 25
7.4 Late Submission ........................................................................................................................................ 25
7.5 Project Adviser .......................................................................................................................................... 25
7.6 Collection and accessing of request for Expression Of Interest........................................................ 25
8. Acknowledgements ........................................................................................................................................ 25
Appendices ................................................................................................................................................................ 26
Appendix 1: EOI Terms and Conditions .......................................................................................................... 26
Appendix 2. Project Stakeholders .................................................................................................................... 28
Appendix 3: Commercial Principles / Project Associated Risks ......................................................... 29
Appendix 4: EOI Response requirements to the Evaluation Criteria ............................................... 35
Appendix 5: Part C: Additional Information ................................................................................................. 40
Appendix 6. EOI Response Information .......................................................................................................... 41
Tables and Figures
1. Project location ............................................................................................................................................................ 4
2Table 1. Lot 1 of Project Package ............................................................................................................................. 7
3Table 2. Lot 2 of Project Package ............................................................................................................................. 8
4Table 3: Respective approvals responsibilities ....................................................................................................... 9
5 Table 4: Highest Best Use Project distribution ...................................................................................................... 10
6Table 5. Scope of the Project ................................................................................................................................... 13
7 Table 6. Activities undertaken or managed by ZNBC ...................................................................................... 14
8Table 7. Project Advisers ............................................................................................................................................ 18
9Table 8. Project Delivery Timetable ......................................................................................................................... 19
10Table 9a. Weighted Evaluation Criteria .............................................................................................................. 21
11Table 9b. Non-Weighed Evaluation Criterion .................................................................................................... 22
12Table 10: Detailed Weighted Evaluation Criteria ............................................................................................. 36
13.Table 11: Non-Weighted Evaluation Criteria..................................................................................................... 40
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
4
1. INTRODUCTION
1.1 About Zambia National Broadcasting Corporation
Zambia National Broadcasting Corporation (ZNBC) is the oldest and biggest radio and
television company in Zambia. It is wholly owned by the Republic of Zambia and is a
statutory body established in 1988 by the Act of Parliament Cap 154 of the laws of
Zambia. It is mandated to provide radio and television services to entertain, educate
and inform the nation, thereby contributing to the social-economic, cultural, and political
development of Zambia. The Corporation operates under the Ministry of Information and
Broadcasting Services (MIBS).
1.2 The Opportunity
ZNBC owns a 39.392-hectare piece of land on Leopards Hill Road, being SD ‘A’ of Farm
No. 397a. The land is located approximately 9 kilometres east of Lusaka Central Business
District. The site is located between Leopards Hill Cemetery and Bauleni Road along the
Leopards Hill Road leading to the Lusaka South Multi-Facility Economic Zone.
1. Project location
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
5
ZNBC has identified the lack of various amenities in the Country and has since seen the
need to develop a Highest Best and Mixed-Use (HBMU) facility within the metropolitan on
the Twin Palm using the Design, Finance, Build (Construct) Operate (Maintenance) and
Transfer (DFBOT) Procurement Model through the Public Private Partnership contracting
and investing.
To maximise value for money on this land, ZNBC engaged a Consultant to conduct
feasibility study and proposed to divide land for mixed use on a two lot basis for both
long term and short term cash realisation.
ZNBC through tender: ZNBCPPP/TWINPALM/2020: EXPRESSION OF INTEREST FOR THE
DEVELOPMENT OF THE ZNBC TWIN PALM LAND ALONG LEOPARDS HILL ROAD IN LUSAKA
THROUGH A PUBLIC-PRIVATE PARTNERSHIP (PPP) FRAMEWORK ON A DESIGN, FINANCE,
BUILD OPERATE AND TRANSFER (DFBOT) MODEL is seeking to contract with a Project
Developer to:
a) design, finance, construct, operate and transfer the project package; and
b) maintain the project Package over the Operating Phase and hand them back to
ZNBC in accordance with a concession pre-agreed handover condition at the end
of the Term.
ZNBC is seeking Expression Of Interest (EOI) from suitably qualified and experienced unit
firm or consortia, single or multiple capable of delivering lots of the Project in their
entirety. Whilst there will be minimum requirements that must be met in respect of design,
construction and services delivery to be undertaken by Project Companies, ZNBC is
seeking innovative approaches from the private sector that will support the delivery of
the Project in accordance with the Project Objectives whilst offering enhanced value for
money outcomes.
1.3 Purpose of this Invitation
The purpose of this Invitation is to:
(a) invite prospective Respondents to lodge an EOI;
(b) provide details and information concerning the Project to prospective
Respondents; and
(c) set out:
i. the Evaluation Criteria for selecting the Shortlisted Respondents;
ii. the submission requirements for an EOI;
iii. the terms and conditions for the Procurement Process; and
iv. outline the indicative timelines for the delivery of the Project.
Following receipt of EOIs from Respondents, ZNBC may select a number of Shortlisted
Potential Land Developers to proceed to the RFP Phase.
1.4 Procurement Model
ZNBC has approved the delivery of the Project in accordance with a DFBOT PPP
procurement model which is considered to be the model that best balances the control
of project cost and risk with the achievement of the Project Objectives and accordingly,
has been identified as the model most likely to maximise value for money. The Project will
be procured broadly in accordance with the PPP Act including the Public Procurement
Act (PPA) and its Regulations. The legal framework shall provide a basis for developing
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
6
contractual relationships between ZNBC and private parties for the delivery of public
infrastructure and related ancillary services.
1.5 The Parties in procurement process
The Procurement Process is being undertaken and administered by ZNBC which in turn
shall enter contractual arrangements in line with the PPP Act.
1.6 EOI Terms and Conditions
The Terms and Conditions applying to the Procurement Process are set out in Appendix 1
(EOI) Terms and Conditions) to this Invitation.
1.7 Project Stakeholders
Stakeholders will be required to provide oversight to the execution of the project. The
stakeholders in this procurement process are as set out in Appendix 2 (Project
Stakeholders). ZNBC will consult the project stakeholders on delivery of critical
requirements to this project.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
7
2. Project Information
2.1 Project Overview
ZNBC’s mission strives to provide quality Radio and Television services throughout
Zambia to stimulate Cultural, Social, and Economic development while generating
commercial value and attain financial viability for the Corporation.
Under this mission of the five years’ Strategic Plan 2015-2020, ZNBC aims to achieve its
goal through five strategic objectives:
(i) Increase Corporation Revenue;
(ii) To attain financial viability;
(iii) To Utilise New Technologies;
(iv) To acquire quality content; and
(v) To manage the Corporations Resources effectively.
ZNBC has since finished drafting the new strategic plan for the period 2021 to 2025
whose focus is to build on the success of the current strategic plan.
In response to the growing population within Lusaka metropolitan area, the Strategic
implementation Plan broadly identifies timing and location of new HBMU to be
constructed. The project Package has since been developed to address some of the
highest priority deliverables outlined in the Strategic Plan. The HBMU will provide high
quality public amenities to meet community and government expectations. The
Project package will also consider availability of specialised operators by providing
quality facilities in health, higher education, entertainment, sports, and trading
environment.
2.2 Project Package
The total land of 39 hectres has been distributed as in table 1 and 2 which outlines the
project Package that is to be delivered on lot basis including the required completion
days and areas allocated for each lot:
2Table 1. Lot 1 of Project Package
Developer 1: LOT ONE
Description Land Size (SQM)
Warehouse 121,650SQM
Retail Super Markets 25,275SQM
Small Scale Office 15,275SQM
Family Wonderland 16,220SQM
Filling Station 1,665SQM
Roads & Green
Area
20,856SQM
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
8
3Table 2. Lot 2 of Project Package
Developer 2: LOT TWO
Description Land Size (SQM)
University Campus 64,880SQM
Serviced Plots Housing 21,491.50SQM
Hospital Clinic 28,385SQM
Sports Recreation Centre 20,275SQM
Roads & Green Area 15,639SQM
The above Preliminary project package is an outcome of the feasibility study and has
been prepared to allow developers understand the business and project concept.
Detailed project package will be provided at the RFP stage for information and as a
guide for Shortlisted Developers. Shortlisted Developers should not only rely on this master
plan of the project package but in reaction may also be required to develop alternative
projects plans specific for Twin Palm land development. A financially viable alternative
project will attract extra scores at the evaluation criteria of both EOI and RFP stages.
2.3 Project Objectives
The key Project Objectives are to:
a) achieve functional Highest Best Use and Mixed Use designs that provide
quality services to the Lusaka business environments;
b) achieve value for money over the whole-of-life cycle of the infrastructure
pursuant to the Strategic plans;
c) improve financial position of the Corporation; and
d) Expand the business portfolio of the Corporation
2.4 Site Information
On site, there is an existing meter mast which is 250 metres tall. The mast hosts various
clients who transmit radio waves across the country. It is situated right at the centre of
land and covers about half of the land. To make this land available for the development,
the mast will be removed from its existing location, decommissioned and a new 150
metre mast will be constructed on alternative allocated site. The cost of this sub-project is
part of the whole project and is expected to be funded by the developer. For the
purposes of giving client strategic options, the project can be taken up by combined
efforts of two who will undertake the main project. The cost for this project would be paid
in the form of deductions from the percentage of leasing fees due to ZNBC through
rentals.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
9
2.5 Site Investigations
A series of Site assessments and geotechnical investigations have been undertaken for
the site. The results of these investigations will be included within the RFP for information
only. The Shortlisted Respondents will not be entitled to rely on these Site investigations
and will have access to the Sites during the RFP phase in order to undertake their own site
assessment and interpretation as required.
The successful developer shall also be responsible for conducting their own
Environmental Impact Assessment (EIA).
2.6 Authorisations and approvals
ZNBC and the Projects Companies will be responsible for various approvals as in table 3.
4Table 3: Respective approvals responsibilities
ZNBC Developer
Title deed Drawings
Management approvals Environmental Impact Assessment
PPP approvals
Construction permit
Ministerial approvals Trading and business
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
10
3. Project Scope
3.1 Scope Overview
The project has been designed to be operated under the Design, Finance, Build,
Operate and Transfer (DFBOT) Public Private Partnership Procurement Model. This model
underscores the concept places responsibilities on the Project Developer to Design the
project in conformity or countering what is set in this EOI. They will also need to fully
Finance the project in all aspects. They will also need to Build of Construct the Project
through to the full completion. They will then Operate the project for a period of lease
period until the end of the concession period when they are required to Transfer the
infrastructure to ZNBC. Details of applying the DFBOT model are outlined in section 3.2
under table 5.
ZNBC conducted a Feasibility Study on the possible development of land. Arising from
the study report, the overview of the project’s components and Commercial Feasibility
assumptions are as detailed below:
5 Table 4: Highest Best Use Project distribution
Project
Description
Project Justification
Land
size %
Land
Size sqm Storage and
Warehouse
and Logistics
Hub
Warehousing project accounts for the biggest portion of
land at 30.80% and 12.17 hectares big enough to
accommodate various sorts of fleet. Proximity to the
Multi-Facility Economic Zone, Tokyo way and the
Kenneth Kaunda International Airport makes it easily
accessible. The logistics project to act as a dry port
connecting Southern and Northern parts of Zambia. The
project shall also be used for practicals by students
studying supply chain management. The Logistics and
Warehousing will also be targeting the multilateral
express logistics and distribution businesses like DHL,
FedEx, UPS, etc..
30.80 121,650
Retail Super
Markets, Fast
foods and
ATMs
The Retail Market is in two parts. One for Supermarkets,
fast foods, and Financial transaction facilities and the
other for fresh produce. Space covers 6.4% of the land
and measures 2.53 Hectares and centrally located and
easily accessible.
The retail market will also caters for chain stores to
service surrounding areas. Chain stores would consider
harbouring business-like Pep Stores, Shoprite, restaurants,
bars, clothing shops etc..
3.59 25,275
Retail Fresh
and dry
produce
2.81
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
11
Markets
Small Scales
Offices
Located in less congested area and opposite the flow
of traffic into the Lusaka Central Business District.
Capable for subdivision into 50-200sqm and suitable for
SME’s, law firms, utility providers and business
consultancies. It is Proximity to the Multi- Facility
Economic Zone and covers 3.87% of land and 1.53
Hectare space.
3.87 15,275
Family
wonderland
To offer a full entertainment package and varied
traditional and conventional food stuffs. To entertain the
family with ultra-modern fun, play equipment, play toys
of Disney type, horse riding, merry go round, swings, see-
saw, playhouse, slides, swings, spring, trampoline park,
cinema, and more.
The land covers 4.11% of land and 1.62 Hectare space.
It is the most lacking type of family entertainment in
Zambia. It is the desire of the ZNBC to bring together
families and enjoy the beauty of leisure life together with
their children. The place shall also have cinemas and
theatres that will specialise in showing local films and
songs to promote local artistic talent in line with film
policy as envisaged by the Government of the Republic
of Zambia. Students in cinematography and music from
the University shall be made to perform at the family
wonderland.
4.11 16,220
Filling Station Considering the exotics and classic type of
arrangement of an all-inclusive complex, there is a
requirement to have a filling station. Filling Station shall
be positioned strategically at the junction of the
Leopards Road leading to Mult-Facility Economic Zone
and the Road leading into Bauleni Township. It covers
0.4% of land and 0.17 Hectare space.
0.42 1,665
University
Campus
It is the second biggest portion of land covering 16%
and measuring 6.49 Hectares. It is intended to offer
cinematography, music, journalism, public relations,
medicine and Supply Chain. The practical of these
courses to be offered by the University will be
16.43 64,880
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
12
conducted at the project warehouse, hospital, and
ZNBC, family wonderland, ultramodern studios all under
one roof. The University Campus shall offer both
undergraduate and post graduate studies and it shall
be the first and best in Cinematography studies in
Zambia.
New Serviced
plots for
Housing
10% of land sitting on a 4.34 Hectares covers the existing
households which has been proposed to be
maintained. 5.44% of land sitting on 2.15 hectares
covers a green field land which has been proposed to
be serviced and sold to raise funds for immediate use.
5.44 21,497
Existing
Housing
10.98
Hospital/
Clinics
The Hospital land covers 7.19% of the land and
measures 2.84 Hectares. It is centrally located and easily
accessible by the surrounding area. The Hospital shall be
specialised in diagnostics with state-of-the-art
equipment. The specialised medical services shall
supplement what is not yet offered locally and shall be
used as a training place for students pursuing medical
studies.
7.1 28,385
Sports and
recreation
Centre
To be the only full house sports and recreation centre
saving the entire community in the surrounding area, to
contain Gym, 4 Futsal Courts, 1 Basketball Court,1
Netball,1 Swimming pool, theatre, to serve the University
campus and the Hospital and it covers 5.13% of land
and 2.03Hectare space.
5.13 20,275
Road and
Green Area
Roads and green area involved the bituminous tared
roads and a very exotic land-scaped are for all the
complex. It shall cover a total area of 3.65 Hectares,
translating into 8.24% of the total land.
8.24 36,459
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
13
3.2 Project Responsibilities
Project Company will design, construct, and finance the Project and maintain it over the
Operating Phase. Project Company’s responsibilities will be documented in detail in the
Project draft Concessions that will be issued as part of the RFP documentation. An
indicative summary of the main Project Company responsibilities is contained in Table 5
below.
6Table 5. Scope of the Project
Project Element Description
Finance
Project Company is required to directly finance or procure
Project finance to fund the construction and completion of
the entire Project.
Design During the RFP Phase, Respondents will be required to
develop comprehensive design solutions for the Project
Package for submission with their Proposals.
After Contract Close, Project Company will be responsible for
ongoing design development in accordance with the design
development plan to be contained in the Project Agreement.
Works / Build
Project Company is responsible for designing, constructing,
commissioning and completing the Works for the Project.
In broad terms, the Works will comprise the following:
• external works and services on the Sites;
• buildings works within the Sites;
• fitout of the buildings and facilities;
• backbone infrastructure equipment;
• furniture, fittings and equipment;
• Servicing of plots for immediate sale; and
• Construction of roads and landscaping
Performance of off-Site
works
Project Company may be required to undertake some off-Site
works that will be identified in the RFP including traffic and
road reconfigurations under a returned works arrangement.
Facilities Management
Services / Operate
Project Company is responsible for delivering the Facilities
Management Services (the “FM Services”). In broad terms, the
FM Services will comprise the following:
a) Hard FM Services: Project Company is required to provide
a range of hard FM Services over the Operating Phase of
the Project. The extent of the hard management services
is expected to include elements of the following:
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
14
• maintenance; waste management; utilities
management; and life cycle maintenance;
b) Soft FM Services: Project Company is required to provide
soft FM Services over the Operating Phase. The extent of
the soft facilities management services is expected to
include elements of the following:
• general management; help desk services; caretaker
services; grounds and garden maintenance; pest
control; catering services cleaning; security, and
Insurance
Commercial
Opportunities
Project Company may choose to identify commercial
opportunities which are complementary to the operation of
the Project Package for consideration by ZNBC.
Transfer of the project
The Project Company is expected to hand over the project to
ZNBC after a lease period as it shall be prescribed in the
concession agreement.
3.3 Services to be provided by ZNBC
There are a number of activities associated with the Project that do not form part of
the Project.
These activities will be undertaken or managed by ZNBC as summarised in the table
below.
7 Table 6. Activities undertaken or managed by ZNBC
Project Element Description
Site services
and utilities
It is expected that the responsibility for the provision of utility
services to the boundary of each Site prior to construction will
reside with ZNBC.
Site Access
It is expected that the responsibility for the provision access
authority to the site prior to construction will reside with ZNBC.
Modification to roads for access within the Sites and parking will be
the responsibility of Project Company. Project Company may be
required to undertake some off-site works that will be identified in
the RFP including traffic and road reconfigurations under a
returned works arrangement.
ZNBC Obtained As described in Section 2.6, ZNBC will be responsible for obtaining
ZNBC Obtained Authorisations to facilitate the Project. Project Co
will be responsible for complying with the conditions of all ZNBC
Obtained Authorisations and obtaining all other authorisations and
approvals required in relation to the Project.
Authorisations
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
15
3.3 Design Considerations
The RFP for the Project will contain the ZNBC’s “output based” design requirements.
The Specifications will set the minimum standards for the project Highest Best and
Mixed Use.
Respondents may wish to exceed the minimum standards, including where
exceeding the Specifications will offer value for money opportunities with regard to
life cycle and maintenance costs over the Operational Phase.
Where respondents’ offer to RFP exceeds the ZNBC standards in design, projects
alternative, lease fee, and lease period, ZNBC shall offer additional value scores at
evaluation stage.
3.4 Construction Considerations
The RFP for the Project will require the Shortlisted Respondents to demonstrate their
capability to undertake the Works. To enable ZNBC to assess the Respondents
capability the RFP will require the Respondents to provide a variety of plans including
a project management plan, construction management plan, safety management
plan, environmental management plan and quality management plan.
Project Company will be required to undertake the Works based on the agreed plans.
All materials and workmanship will be required to comply with all Zambian laws,
regulations and Building Standards. The works will be subject to review and approval
by an Independent Certifier who will determine whether Project Company has
complied with its obligations under the Agreement, including the Specifications.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
16
4. Commercial Framework
4.1 Contractual Structure
ZNBC intends to contract with Two entities at RFP Stage that will be responsible for the
delivery of the Project. It is envisaged that these entities will be a consortium
comprised of at least one of each of a builder, facilities management subcontractor
and financier, supported by a range of specialist advisers including architectural,
engineering, legal and financial. It is expected that the Project Agreement details
between ZNBC and the successful Respondents will be coined in the contract of
construction, which shall be subject to the approval of the Attorney General. Among
contents of the agreement to be considered and entered into are such as:
a) Builder Side Deed;
b) Subcontractor Side Deed;
c) Finance Side Deed;
d) General Security Agreement; and
e) Independent Certifier Agreement.
f) Respondents are encouraged to explore and propose consortium structures that
best meet the requirements of the Project. ZNBC does not seek to be prescriptive with
respect to the Respondent’s consortium structure.
4.2 Commercial Principles or Risk allocation
The commercial principles for the Project will be broadly consistent with the PPP Act,
Public Procurement Act and its Regulations. Appendix 3 outlines a summary of a
number of the key commercial principles/ Risk Allocation that may apply to the
Project. ZNBC reserves the right to change its position in relation to these commercial
principles.
4.3 Commercial Opportunities
If Respondents wish to explore and identify suitable commercial opportunities that
may be delivered as part of the Project, the commercial opportunities must, as a
minimum:
(a) not conflict with, and preferably will enhance, the core project functions ;
(b) demonstrate an ability to meet all the Project objectives;
(c) be appropriate to be undertaken in the HBMU;
(d) provide a value for money outcome for ZNBC; and or
(e) take into account the ZNBC’s duty of care requirements.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
17
5. Procurement Process
5.1 Overview The intended Procurement Process for engaging Project Company comprises the
stages as described below which is indicative only. ZNBC may change or terminate
this Procurement Process at any stage, including by proceeding in a manner which is
different to that described in this Invitation or in any subsequent RFP.
5.2 EOI Phase The issue of this Invitation is the first stage of the Procurement Process for the Project.
5.2.1 tendering period for the EOI
Invitation for the EOI will run for a period of Four Weeks (One Month), from 19th August
2020 to 18th September 2020 as stipulated on the front page.
5.2.2 Interactive EOI Zoom Meeting
(a) The purpose of interactive Zoom meeting will be to receive feedback and provide
clarifications on the EOI to respondents;
(b) The interactive meeting will take place on Friday, 4th September 2020 from
10:00am to 12:00pm;
(c) Contents of the meeting will be Presented through power point;
(d) The interactive meeting will be conducted through online Zoom meeting; and
(e) Respondents who wish to attend the interactive meeting will need to provide their
email address for the purpose of receiving the Zoom meeting invitation link.
5.3 RFP Phase The second stage of the Procurement Process will be the RFP Phase. This phase will
commence when ZNBC releases the RFP to Shortlisted Respondents. The RFP will
contain the technical, operational, legal, and commercial requirements for the
Project.
ZNBC intends to invite several Shortlisted Respondents to progress to the RFP phase of
the Procurement Process following the evaluation of the EOIs in accordance with this
Invitation.
Shortlisted Respondents will be required to submit fully costed and complete Proposals
in accordance with the RFP requirements covering a period of six weeks (One month,
and two weeks).
It is expected that the RFP Phase will also involve an interactive tender process
between the ZNBC and Shortlisted Respondents. ZNBC intends to engage with
Shortlisted Respondents actively and meaningfully at pre-RFP submission meeting and
during the whole process for the purpose of doubt avoidance.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
18
5.4 Negotiations Following detailed evaluation of Proposals, ZNBC intends to select two Shortlisted
Respondent, but reserves the right to select three or more Shortlisted Respondents, to
proceed to negotiations with a view to resolving all remaining technical, operational,
legal and commercial issues and executing final Project Documents with the Preferred
Respondent(s).
5.5 Public Sector Comparator One aspect of identifying value for money under this procurement of PPP project is the
comparison of submitted proposals with a quantitative benchmark as outlined in the
feasibility study report (FSR). The FSR contents will be used as Public Sector Comparator
(PSC) which will calculate the hypothetical risk-adjusted cost of ZNBC delivering the full
requirements of the RFP under a conventional, fully publicly funded procurement
approach. Through the PSC (and other qualitative benchmarks) it can be assessed
whether the PPP procurement model for the delivery of the Project will deliver value
for money for ZNBC. ZNBC will develop its final PSC prior to the close of the RFP.
5.6 Project Governance ZNBC has deemed the Twin Palm land development Project a “major project” about
its complexity, profile and value. Consistent with the PPP Act, the ZNBC Act and
Strategic Plan, the ZNBC Director General, the Board, the Ministry of Information and
Broadcasting Services (MIBS), and the Attorney General have a lead role and
accountability in making sure that the private investment into this project is well
protected and that the concession agreement will take care of all interests of the
parties to this project.
5.7 Project Advisers The following advisers will assist ZNBC in the Procurement Process. These advisers have
been retained under exclusivity arrangements with ZNBC and are not available to
provide any service or information to any Respondents, or any prospective
Respondents, without the prior written approval of ZNBC.
8Table 7. Project Advisers
Discipline Advisor
Project Planning ZNBC Project Team
Commercial and Facilities Management
adviser Zambia Development Agency (ZDA)
Legal Advisors Director of Legal
Financial Advisors Director of Finance
Architectural and Technical directors
Ministry of works and supply, Ministry of
Housing infrastructure
Site investigations Ministry of Housing and Infrastructure
Capital cost planning Director of Finance
Process Advisor Public Private Partnership Department
Process Executor Head Procurement and Supplies Unit
Project Evaluation of EOI and RFP Project Advisors
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
19
5.8 Project Delivery Timetable Details of the anticipated timing for the Procurement Process and the Project
generally are provided in the timetable below. This timetable is indicative only and
ZNBC reserves the right to change the timetable in its absolute discretion.
9Table 8. Estimates of Project Delivery Timelines
Procurement Process Target Date
Expression of Interest (EOI) Phase
Approval of EOI by PPP 11th August 2020
Release of Invitation of EOIs 19th August 2020
Interactive EOI Zoom Meeting (10:00am – 12:00pm) 4th September 2020
Closing date for lodging EOIs 18th September 2020
Announcement of Shortlisted Respondents 28th September 2020
Request For Proposals (RFP) Phase
Release of RFP 5th October 2020
Opening of Interactive Tendering Process 16th October 2020
Closing Date for lodging Proposals 18th November 2020
Evaluation, Negotiation, Due diligence, and Award Phase
Appointment of Preferred Respondent 18th December 2020
Technical, Design and Financial approvals
Commence design development 31st December 2020
Date for Design Development Acceptance 1st February 2021
Engineering, Procurement and Construction (EPC)
Execution of development Agreement- Decommissioning
and recommissioning Meter mast 31st April 2021
Filling Station and Retail, Office blocks, Storage Logistics,
Family Wonderland, University, Hospital, Serviced plots,
facilities commissioning 31st March 2021
Operating, Contract and Management
Maintenance and Projects 31st December 2050
Project Handover or Extension 2051
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
20
6. Content and Evaluation of EOIs
6.1 Detailed Content of Evaluation Respondents are required to submit EOIs in accordance with the content outlined for
each Evaluation Criteria in the EOI response requirement to the evaluation criterion as set
out in Appendix 4.
The Evaluation process will consider the scores below: (a) The total evaluation score of the EOI will be 100 Percent; and
(b) The minimum weighted evaluation score will be 75 Percent
6.2 Evaluation Criteria ZNBC is seeking to identify Respondents with the vision, capacity, and ability to deliver all
components of the Project and to proceed to the RFP Phase of the Procurement Process.
EOIs will be assessed by ZNBC against the Evaluation Criteria set out below. The
Evaluation Criteria comprises the following:
(a) Weighted Evaluation Criteria: Criteria 1 to 6 have been assigned a weighting
(expressed in percentage terms) which will be used to establish the relative
importance of each criterion in the qualitative assessment of the EOI;
(b) Non-Weighted Financial Evaluation Criterion: Criterion 7 has not been assigned a
weighting and will not be taken into account in the weighted evaluation process.
Nevertheless, the Non-Weighted Evaluation Criteria are an important evaluation
consideration and will be considered as part of the EOI evaluation process and in
ZNBC's decision as to whether or not to shortlist a Respondent; and
(c) Non-Weighted Alternative Project Scope: Criterion 8 has not been assigned a
weighting and will not be taken into account in the weighted evaluation process.
Respondent shall respond to this part of the EOI in two ways:
(i) Provide response to the provided project scope as provided in the EOI; and
(ii) Provide an alternative project scope :
that can yield more investment than the one provided in this EOI,
the proposed scope can offer a better economic feasibility on updated
Cost Benefit Analysis,
the proposed scope is more commercially viable than the one proposed in
the EOI.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
21
The highest numerical scoring EOI for the Weighted Evaluation Criteria may not
necessarily be the highest ranked EOI after taking into consideration the Non Weighted
Evaluation Criterion which are qualitative in nature.
The response information to be included in the EOI is set out in Appendix 4
ZNBC requires Respondents to carefully consider and respond to each criterion when
formulating their EOI responses.
10Table 9a. Weighted Evaluation Criteria
Weighted Evaluation Criteria Weighting
1 Project Understanding and approach
The degree to which the Respondent can demonstrate:
• an understanding of the Project and its importance to ZNBC,
including in the context of providing quality business
environments;
• its approach and strategies for meeting each of the Project
Objectives;
• an understanding and ability to address and incorporate
end user considerations into the design, construction and
maintenance of the Project; and
its ability to successfully deliver innovation and value for
money outcomes to ZNBC
10%
2 Organisational Structure, Experience and Resourcing Strategy
The degree to which the Respondent can demonstrate that it
has the organisational structure, PPP experience and resourcing
strategy suitable to successfully deliver the Project. This includes
consideration of the;
• suitability, appropriateness and adequacy of the
Respondent’s proposed organisational structure;
• relevant and recent experience of the Respondent and
Respondent Members in delivering PPP projects individually
and together with other Respondent Members; and
• ability of the Respondent to successfully resource and deliver
the Project in accordance with the proposed timetable,
based on the Respondent’s track record and its proposed
approach for delivering the Project
20%
3 Commercial Understanding, Structure and Project Finance
Capability
The degree to which the Respondent can demonstrate:
• an understanding and appreciation of the commercial
principles of the Project;
15%
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
22
• the suitability and appropriateness of its commercial and
contractual structure during each phase to successfully deliver
the Project; and
• that it has the skills, track record and capability necessary to
secure and provide the requisite level of competitively priced
private sector finance for the Project.
4 Design Capability, Experience and Approach
The degree to which the Respondent can demonstrate:
• the experience and capacity of its design team to design
social infrastructure projects;
• the experience and capability of the design team in working
in a PPP contracting environment; and
• its proposed approach for undertaking the design task for the
Project and the advantages of this approach.
20%
5 Construction Capability, Experience and Approach
The degree to which the Respondent can demonstrate the
experience and capacity of its construction team to deliver the
Project, including:
• the experience and capacity of its construction team to
deliver social infrastructure projects.
• the experience and capability of the construction team in
working in a PPP contracting environment; and
• its proposed approach to the construction task for the Project
and the advantages of this approach.
15%
6 Facilities Management Capability, Experience and Approach
The degree to which the Respondent can demonstrate the
experience and capacity of its facilities management team to
maintain social infrastructure , including:
the experience and capability of the facilities management
team in maintaining comparable infrastructure;
its proposed approach for the delivery of facilities
management services across multiple sites for the Project
and the advantages of this approach; and
the proposed approach to accommodate facilities
management input into design and construction, with a view
to achieving effective whole of life design outcomes that
offer value for money for ZNBC.
20%
Total Weighted Evaluation Score 100
11Table 9b. Non-Weighed Evaluation Criterion
Non-Weighted Evaluation Criteria
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
23
7 Financial Capacity
That each Respondent Member has the financial strength, capacity, and
experience to successfully deliver its aspect of the Project and can
contribute to the overall ability of the Respondent to finance and deliver all
aspects of the Project.
8 Alternative project Scope
Respondents are encouraged to react to the provided project scope and
propose alternative and more viable projects that would perform better.
6.3 Evaluation Approach In evaluating EOIs, ZNBC will:
(a) assess EOIs against the Non-Weighted Evaluation Criterion;
(b) assess an Alternative project scope to what has been provided;
(c) assess EOIs against the Weighted Evaluation Criteria (which have been ascribed a
weighting on a percentage basis identifying the relative importance of each
criterion);
(d) take into account the performance of the Respondent at any meetings,
interviews or workshops that may be conducted;
(e) take into account the extent to which the response to EOI:
(i) is clear and comprehensive;
(ii) contains all information required by this Invitation; and
(iii) responds consistently to each of the Evaluation Criteria.
In evaluating EOIs, ZNBC may take into account any other information available to
ZNBC concerning the Respondent or its EOI.
6.4 EOI Response Information The Project Respondents are required to fill in the Response Information Form in order to
provide all relevant information as required during the Evaluation process. The Bid
response form is under Appendix 6
6.5 Additional Information Project Respondents are required to provide additional information as outlined in
Appendix 5.
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
24
7. Procedural Matters
7.1 Enquiries All enquiries in respect of this Invitation must be in writing or by email and directed to:
The Head Procurement and Supplies Unit
Zambia National Broadcasting Corporation
Mass Media Complex
Alick Nkhata Road
P.O.Box 50015,Lusaka, Zambia
Telephone: +260211253304
E-mail: [email protected]; [email protected]
The decision on whether to respond to any enquiry and the content and timing of any
response is at the discretion of ZNBC.
7.2 Lodgment Details (a) Respondents must lodge:
(i) one original version of the EOI, marked ‘Original’ and will be taken as the
master copy for assessment purposes;
(ii) a full and complete electronic copy of the EOI formatted as specified for
each Evaluation Criteria and stored on a USB that is arranged in the same
order as the original version; and
(iii) a full and complete electronic copy of the EOI formatted to searchable PDF
and stored on a USB that is arranged in the same order as the original version.
(b) The EOI must be placed in a sealed package and must be clearly marked as
follows:
STRICTLY PRIVATE AND CONFIDENTIAL
Twin Palm Development Project
Expression of Interest (EOI)
EOI Number: ZNBCPPP/TWINPALM/2020
(c) The EOI must be submitted by hand in the tender box at the reception of the
ZNBC Mass Media Complex and addressed to:
The Head Procurement and Supplies Unit
Zambia National Broadcasting Corporation
Ground Floor Mass Media Complex
Alick Nkhata Road,
P.O. Box 50015
Lusaka, Zambia
ZNBC Highest Best Mixed Use TwinPalm Land Public Private Partnership Project – Expression of Interest
25
7.3 Closing and Opening Times for EOI The Closing Time for lodgement of EOIs is as set out on the front page of this Invitation.
7.4 Late Submission If an EOI is not submitted at the place of lodgement specified by the Closing Time
ZNBC may, in its absolute and sole discretion, reject or not consider the EOI.
7.5 Project Adviser The Project Adviser in respect of this Project is the Public Private Partnership
Department. Respondents may contact the Project Adviser in circumstances where
they have concerns as to probity or the conduct of the Procurement Process. Any
contact or communication with the Project Adviser may be disclosed to ZNBC and
ZNBC reserves its rights to deal with the information in accordance with the Terms and
Conditions. The Probity Adviser’s contact details are as follows:
Name: Mr. Solomon Simutowe
Title : ZNBCPPP/TWINPALM/2020 Project Advisor
Institution: Public Private Partnership Department,
Ministry of Finance
P.O.Box 50062, Chimanga Road
Lusaka, Zambia
Email Address: [email protected]
Phone number: +260 211 251843, +260 211,250657, +260 211 253786.
7.6 Collection and accessing of request for Expression Of Interest
Respondents to this Expression of Interest MUST collect a complete set of Request for
Expression of Interest (REOI) containing the full details of the project and other related
information from :
ZNBC Procurement Office, Mass Media Complex, Alick Nhata Road, Lusaka.
ZNBC Website: www.znbc.co.zm/tenders
Emails: [email protected], [email protected]
Phone Number: 00 260 253304
8. Acknowledgements
The production and references for this Expression of interest acknowledges all the
valuable sources of information some of them namely:
8.1 The Zambia’s Public Private Partnership Act No. 14 of 2009,
8.2 The Zambia’s The Public Procurement Act No. 12 of 2008,
8.3 The Western Australian Schools Public Private Partnership Project,
8.4 The South Africa’s Public Private Partnership Manual,
8.5 Zambia Chartered Institute of Logistics and Transport, and
8.6 Anchicon Limited, Zambia
Highest Best Use Public Private Partnership Project-- Invitation for Expression of Interest
26
Appendices
Appendix 1: EOI Terms and Conditions
1.1 No legal relationship
Each Respondent Member acknowledges and agrees that:
(a) neither this Invitation nor the RFP constitute an offer to enter into final Project
Documents;
(b) other than the contract that arises as a consequence of the execution of the
EOI Form:
(i) no contract exists or will arise between ZNBC and the Respondent in
respect of the Project unless and until Contract Close is achieved; and
(ii) neither ZNBC nor the Respondent intend to create a legal relationship.
(c) these Terms and Conditions set out the entire agreement between the
parties in respect of the Procurement Process.
1.2 Inconsistency
ZNBC may elect to issue this Invitation, the RFP and any other Disclosed Information
to the Respondent in hard copy and electronically. To the extent that there is any
inconsistency between a hard copy and an electronic version, unless the Head of
Procurement and Supplied Unit directs otherwise (acting in its discretion), the
electronic copy shall take precedence
1.3 Addenda
Each Respondent Member agrees that:
(a) at any time during the Procurement Process ZNBC may, for any reason (but
without being obliged to do so), amend:
(i) this Invitation; or
(ii) the RFP, by issuing an Addendum to this Invitation or the RFP.
Any Addenda issued shall be deemed to form part of this Invitation or the RFP
(as the case may be). None of ZNBC or any of the ZNBC's Associates will be
liable for any costs, Losses, expenses or damages incurred by the Respondent
as a consequence of any such Addenda;
(b) the Respondent must prepare its EOI or Proposal (as the case may be) to take
into account and reflect the content of any Addendum; and
(c) this Invitation or the RFP may only be amended or supplemented by Addenda
that may be issued.
No statement or representation made by ZNBC or by an Associate of the ZNBC
(whether at an industry briefing, workshop, question and answer session or otherwise)
modifies or supplements this Invitation or the RFP, unless the statement or
representation is confirmed by an Addendum.
Highest Best Use Public Private Partnership Project-- Invitation for Expression of Interest
27
1.4 Status of Respondents Members
Status of Respondent Members
(a) If, after lodgement of its EOI or Proposal:
(i) there is a change in the structure of a Respondent Member or there is
otherwise a change in Control of a Respondent Member; or
(ii) the Respondent replaces, adds, removes or alters the proposed role
of a Respondent Member, the Respondent must:
(iii) promptly notify ZNBC;
(iv) provide ZNBC with sufficient details of the change; and
(v) provide evidence to ZNBC that the new Respondent Member has
agreed to be bound by the Terms and Conditions.
(b) Upon receipt of such notification ZNBC will assess any change and reserves the
right to accept the change and impose such conditions as it thinks fit in
connection with accepting the change or terminate the Respondent's further
participation in the Procurement Process.
Highest Best Use Public Private Partnership Project-- Invitation for Expression of Interest
28
Appendix 2. Project Stakeholders
1. The Ministry of Information and Broadcasting Services (MIBS)
2. Zambia Development Agency (ZDA)
3. Ministry of Works and Supply (MOWS)
4. Ministry of Justice (MoJ)
5. Ministry of Transport and Communication (MTC)
6. Zambia Chartered Institute of Logistics and Transport (ZCILT)
7. Ministry of Health (MoH)
8. Ministry of Higher Education (MOHE)
9. Ministry of Housing and Infrastructure Development
10. Ministry of Tourism and Arts (MTA)
11. Ministry of Youths, Sports and Child Development
29
Appendix 3: Commercial Principles / Project Associated Risks
S/N Categories Description Impact
(1 - 4)
Likelihood
(1 - 4)
Description of Mitigation Measures/Controls in
Place
Allocation
1 Completion/
Construction
related risks
The possibility that the design, procurement,
construction and commissioning of the Facilities
required for the Project may be (i) delayed so that
the delivery of the Services included in the Project
cannot commence at the envisaged start-up date,
or (ii) delayed, unless greater expenditure is
incurred to keep the Project to the envisaged
start-up date, or (iii) delayed because of
variations.
4 2 Special insurance (delay in start-up insurance).
Liquidated damages, construction bonds and
other appropriate security from the Private Party
to achieve completion, unless caused by the
Institution.
Private Party, unless
delay caused by
Institution (including,
Institution variations).
2 Design risk The possibility that the Private Party’s design may
not achieve the required output specifications.
2 2 Clear output specifications. Design warranty.
Consultation with and review by Institution (but
review must not lead to input specifications by Institution)
Private Party.
3 Cost over-run
risk
Possibility that during the design and construction
phase, the actual Project costs will exceed
Projected Project costs.
4
2
Fixed price construction contracts. Contingency
provisions. Standby debt facilities / additional
equity commitments (Shareholder and other
funder commitments); provided that these
commitments are made upfront and
therefore anticipated in the base case
Financial Model. However, if the Project is
not performing as anticipated in the base
case Financial Model, then (to effect a rescue
of the Project) these commitments may be
implemented, but the prior approval of the
Institution is required if such commitments
will increase its liabilities on termination.
Private Party.
30
5 Environmental
risk
This includes not only the possibility of liability
for losses caused by environmental damage (i)
arising from construction or operating
activities (see operating risk) during the
Project Term, but also (ii) arising from pre-
Project Term activities whether undertaken by
the Institution or a third party and not
attributable to the activities of the Private
Party or its subcontractors.
4 2 Remediation works to remedy
preexisting environmental damage as a specific Project
deliverable. Independent monitoring of remediation works.
Thorough due diligence on preexisting environmental conditions.
Special Insurance
In relation to due diligence and
remediation works, the
Private
Party. In relation to insurance, the Institution, but only if there is no or insufficient insurances available to mitigate this risk and if the
Institution’s liability is
capped
6 Market,
demand or
volume risk
The possibility that the demand for the
Services generated by the Project may be less
than projected (whether for example because
the need for the Services ceases or decreases,
or because of competitors entering into the
relevant market, or because of consumer
opposition to the outsourcing of the Services).
3 2 Attempts to acquire letters of
intent for prospective tenants for
the lease of the building combined
with marketing campaigns to
create awareness of the products
and services to be provided
In relation to a revenue
generating Project, the
Private Party.
7 Supply, input
or resource
risk
The possibility of a failure in the supply of the
inputs (particularly, resources) required for
the operation of the Project including non-supply or deficiencies in the quantity
and quality of available supplies
3 1 Supply contracts for supply of
total Project requirements, such
as take and pay contracts.
Private Party
31
8 Utilities supply
Risk
The possibility that the utilities (e.g.
electricity, gas and water) required for the
construction and/or operation of the
Project may not be available.
4 3 Emergency back-up facilities, e.g.
generators. Emergency supply
contracts. Special insurance.
Private Party
9 Insolvency and
outside creditor
risk
The possibility of the insolvency of the
Private Party or any of its Shareholders.
4 2 Reporting obligations in respect of
any litigation; financial information;
disputes with creditors. Substitution
of Private Party in terms of Direct
Agreement.
Private Party.
10 Sub-contractor
risk
The risk of subcontractor defaults or
insolvency. This risk may arise at the
construction and/or operations phases of
the Project.
2
2
Subcontractors must have expertise,
experience and contractual
responsibility for their performance
obligations. Substitution of
subcontractors. Must be based on
Due diligence.
Private Party.
11 Operating risk
(technology,
environmental,
Any factors impacting on the operating
requirements of the Project (including
projected operating expenditure and skills
3
2
Clear output specifications. Penalty
regime and performance
monitoring.
Private Party.
32
cost and
management)
requirements, e.g. labour disputes,
employee competence, employee fraud,
technology failure, environmental
incidents and any failure to obtain,
maintain and comply with necessary
operating permits).
Adequate O&M contract.
Substitution rights.
Security and special insurance
12 Maintenance
risk
The possibility that (i) the cost of
maintaining assets in required condition
may vary from the Projected maintenance
costs, or (ii) the agreed maintenance
programme is not followed.
3
2
Clear output specifications. Penalty
regime and performance
monitoring. Adequate O&M
contract. Substitution rights.
Security and special insurance
Private Party.
13 Force Majeure
(act of God)
risks
This may overlap with operating risk or
completion risk, and includes certain
unexpected factors out of the control of
the Project participants (whether natural
or “man-made”), which may affect the
construction or operation of the Project.
4
1
Define “Force Majeure” narrowly to
exclude risks that can be insured against or are dealt with more
adequately by other mechanisms
such as Relief Events or
Compensation Events. Relief and
Compensation Events.
If risks are insurable
not Force Majeure and risk allocated to
Private Party. If risks
are not insurable,
then risk is shared.
14 Political risk The possibility of action by any government authority that materially and
adversely affects the completion and/or
operation of a Project, or the expected
return on investment of the Private Party’s funders. This risk overlaps with some
financial risks (e.g. tax rate change risk)
and other risks such as operating risk.
4
2
Limit risk to Changes in Law and to
expropriation, nationalisation or
privatisation (collectively,
“expropriating actions”) of the
Institution, services or assets of the
Private Party. Distinguish between
General and Discriminatory Changes
in Law. In relation to Discriminatory
Changes in Law, termination by
Private Party with compensation.
In relation to
Discriminatory
Changes in Law and
expropriating
actions, the
Institution.
In relation to
General Changes in
Law, the Private
Party.
33
15 Regulatory
risk
The possibility that the approvals required
from government authorities for the
Project will not be obtained (other than
planning and environmental approvals,
which elsewhere herein, are specifically
dealt with, see planning risk and
environmental risk).
4
1
Implementation by the Institution of
an intergovernmental liaison
process with the responsible
government authorities before the
procurement phase. Due Diligence
by Private Party to identify
approvals its requires for its
operating requirements If permitted
under applicable law, obtain all such
approvals before the Signature Date.
If any such
approvals (other
than those relating
to Private Party’s
operating
requirements) can
be obtained before
the Signature Date,
the Institution. In
relation to the
Private Party’s
operating
requirements, the
Private Party.
16
Currency or
exchange rate
risk
The possibility that exchange rate
fluctuations will impact on the envisaged
costs of imported inputs required for the
construction or operations phase of the
Project.
3
2
Hedging instruments (e.g. swaps).
Use of relatively stable currency for
projections
Private Party.
17 Interest rate
risk
These are factors affecting the availability
and cost of funds.
4
2
Hedging instruments. Fixed
rate loans
Private Party.
18 Tax rate
change risk
The possibility that changes in applicable
tax rates (income tax rate, VAT) or new
taxes may decrease the Project party’s
anticipated return.
4
3
Termination by Private Party with
compensation for tax increases or new taxes arising from
Discriminatory Changes in Law.
In relation to tax
increases
34
19 Inflation risk The possibility that the actual inflation rate
will exceed the Projected inflation rate.
This risk is more apparent during the
operations phase of the Project.
3
2
Shared between the
Parties in relation to
specified input
items.
20 Insurance risk The possibility (i) that any insurable risks
may become uninsurable in the course of
the Project Term or (ii) of substantial
increases in the rates at which insurance
premia are calculated.
3
2
At the option of the Institution,
selfinsurance by the Institution or, if
the uninsurable event occurs, then
termination of the Agreement with
compensation to the Private Party
if the Private Party
caused the un-
insurability then it
bears the risk. If this test fails, then the
risk is shared.
21 Residua value
Risk
The risk that the Project Assets at
termination or expiry of the Agreement
will not be in the prescribed condition for
handback to the Institution.
4
2
Obligations on Private Party to
maintain and repair. Audit towards
the end of Project Term. Security by
the Private Party in favour of the
Institution, e.g. final condition bond,
or deduction from Unitary Payment.
Reinstatement obligations on Private
Party
If Lack of monitoring by Institution, then
institution.
If negligence to
maintain by private
party, then private
party.
35
Appendix 4: EOI Response requirements to the Evaluation Criteria
Part A: General Instructions
1. Overview
The following detailed information requested below in section 4 is to be provided by Respondents
as part of their EOI. This information will be evaluated against the Evaluation Criteria.
2. General response instructions
Respondents are required to note the following instructions for the EOI:
(a) EOI responses are to be structured in accordance with section 3 below (EOI
Structure) and in a manner that clearly and concisely addresses the EOI response
information;
(b) each page in the EOI should be clearly numbered and contain the identity of the
Respondent in the header or footer;
(c) EOIs are to be sufficiently detailed to enable assessment by ZNBC without
requiring further information from Respondents;
(d) Respondents should not include corporate marketing brochures or similar
materials in the EOI and the use of any images should be relevant to the written
material; and
(e) a separate bound executive summary or the like is not requested or required.
3. EOI Response structure
EOIs should be consistent with the EOI response information structure of section 4 , Table 10 and
Table 11 and as summarised below:
(a) Part A: EOI Response Form (refer to Appendix 6) Respondent must fill in all information required as prescribed in the form under Appendix 6.
(b) Part B: Response to Evaluation Criteria. It is a build up of Table 9a and 9b. (i) B1: Project understanding and approach
(ii) B2: Organisational structure, experience and resourcing strategy
(iii) B3: Commercial understanding, structure and project finance
(iv) B4: Design capability, experience and approach
(v) B5: Construction capability, experience and approach
(vi) B6: Facilities management capability, experience and approach
(vii) B7: Financial capacity
(viii) B8: Alternative Project Scope
(c) Part C: Additional Information as outlined is Appendix 5.
36
4. EOI response information Part A: Respondent’s Details are to complete EOI Form set in Appendix 6
Part B: Response requirements for the Evaluation Criteria
The table in this section identifies for each weighted evaluation criterion, the EOI information and
content requirements (and applicable page limits) and the relevant evaluation criterion weighting.
12Table 10: Detailed Weighted Evaluation Criteria
Weighted Criterion EOI content 100%
B1. Project Understanding and Approach – 10% (Limit: 10 pages) 10
B1.1 The Respondent’s
understanding of the Project and
its importance to ZNBC.
Demonstrate the Respondent’s
understanding of the Project and its
importance to ZNBC.
3
B1.2 The Respondent’s approach
and strategies for meeting each
of the Project Objectives.
Demonstrate the Respondent’s approach
and strategies for achieving the
requirements of each of the Project
Objectives.
2
B1.3The Respondent
understanding and ability to
address and incorporate end user
considerations into the design,
construction & maintenance of
the Project.
Demonstrate the Respondent’s
understanding of the end user issues and the
process of how these will be considered in
the design, construction and maintenance
of the Project. Include references to
strategies that have been successfully
used previously.
2
B1.4 The Respondent’s ability to
successfully deliver innovation
and value for money outcomes to
ZNBC.
Provide examples of opportunities for
innovation and value for money outcomes
on the Project. Provide examples of
innovation and value for money delivered
on other similar projects and how this may
relate to the Project.
3
B2. Organisational Structure, Experience and Resourcing Strategy – 20% (Limit: 10
pages)
B2.1 The Respondent’s
organisational structure.
Outline of the proposed Respondent
Members and their role in the Project. Detail
the overall organisation structure for the
Project, a description of the key roles and
provide details of the key personnel filling
these roles. Detail the proposed organisation
chart for the Design and Construction Phase
and Operational Phase. Provide an
explanation on how these structures will
enable the Respondent to successfully deliver
the Project.
4
B2.2 The Respondent’s PPP and
/or Highest Best Mixed Use
experience
Detail the relevant experience of the
respondent Members in delivering projects
through PPP or similar delivery models. Be
specific about the role of the Respondents in
the project and the relevance this has with this
Project.
6
37
Weighted Criterion EOI Content
B2.3 The
Respondent’s
ability to resource
and deliver social
infrastructure
projects.
Demonstrate the ability of the Respondent to
successfully resource and deliver the Project in
accordance with the proposed timetable, based
on the Respondent’s track record and its
proposed approach for delivering the Project
10
B3. Commercial Understanding, Structure and Project Finance – 15%
(Limit: 10 pages)
15
B3.1 The
Respondent
understanding and
appreciation of
the commercial
principles of the
Project
Demonstrated understanding of the Commercial
principles for this Project and in particular the
commercial principles detailed within section 4.2
and appendix 3.
3
B3.2 The suitability
and
appropriateness of
its commercial and
contractual
structure during
each phase to
successfully deliver
the Project.
Outline Respondent’s preferred commercial and
contractual structure to deliver the Project,
including the nature of contractual arrangements
between parties and the level of and type of any
guarantee(s) and/or parent support expected to
be provided.
Provide diagrams of the above-mentioned
commercial and contractual structures during
each phase of the Project.
Identify the rationale for the Respondent’s
preferred commercial structure and how it will
facilitate successful delivery of the Project.
Provide details of the key personnel that will form
part of the finance team, their role and
4
B3.3 The
Respondent’s skills,
track record and
capability
necessary to secure
and provide the
required levels of
private sector
finance for the
Project.
Respondent to provide sufficient evidence to allow
ZNBC to assess the financial viability, strength and
capacity to fulfil its obligations.
Demonstrate how the Respondent intends to fund
the Project.
Demonstrate the Respondent’s skills, track record
and capability necessary to secure and provide
the required levels of private sector finance for the
Project, including the ability to:
• develop a suitable financing solution for the
Project;
• commit equity to the Project;
• raise the required level of debt for the Project;
• achieve competitive finance terms; and
achieve absolute certainty of finance.
8
B4. Design Capability, Experience and Approach – 20% (Limit: 10
pages)
20
B4.1. The
Respondent’s
design team
experience and
capacity.
Demonstrate experience of the design team to
design the projects components or similar social
infrastructure projects. As part of the response
provide recent examples (not more than 5)
setting out key elements of the projects including:
• the nature of the project and the role
8
38
undertaken by the Respondent (or
consultant, sub-consultant or subcontractor);
• the originally agreed contract sum and
• date for completion;
• the end contract sum and date of
completion (and reasons for any variance);
• details of any innovations on these projects;
• details of problems which arose and how they
were overcome; and
• a reference from the project owner.
Provide details of key personnel that will form part of
the design team, their role and relevant
experience.
B4.2 The
Respondent’s
design team
experience and
capability working
in a PPP contracting
environment.
The Respondent’s proposed approach for
undertaking the design task on this Project.
Explain the advantages of this approach.
Provide details on any Project issues and risks
that will need to be considered through the design
process.
5
B4.3 The
Respondent’s
approach for
undertaking the
design task.
Provide details of the Respondent's proposed
approach in:
• managing design input from Project
stakeholders; and
managing design and construction interfaces with
third parties.
7
B5. Construction Capability, Experience and Approach – 15% (Limit:
10 pages)
15
B5.1 The
Respondent’s
construction team
experience and
capacity
Demonstrate experience of the construction team
to construct HBU and/or similar social infrastructure
projects. As part of the response provide recent
examples (not more than 5) setting out key
elements of the projects including:
• the nature of the project and the role undertaken
by the Respondent (or contractor or
subcontractor);
• the originally agreed contract sum and date for
completion;
• the end contract sum and date of completion
(and reasons for any variance);
• details of any innovations on these projects;
• details of problems which arose and how they
were overcome; and
• a reference from the project owner. Provide
details of key personnel that will form part of the
construction team, their role and relevant
experience.
The Respondent’s proposed approach for
undertaking the construction, focusing on the
Project issues and risks.
Explain the advantages of this approach. Address
how it will manage multiple projects concurrently of
construction.
7
B5.2 The
Respondent’s
The Respondent’s proposed approach for
undertaking the construction task on this Project.
3
39
construction team
experience and
capability working
in a PPP contracting
environment.
Explain the advantages of this approach.
Provide details on any Project issues and risks that
will need to be considered through the
construction process.
B5.3 The
Respondent’s
approach for
undertaking the
construction task.
Provide details of the Respondent's proposed
approach in:
• managing construction input from Project
stakeholders; and
• managing design and construction interfaces
with third parties.
5
B6. Facilities Management Capability, Experience and Approach –
20%, (Limit 10 pages)
20
B6.1 The
Respondent’s
experience and
capacity of its
facilities
management team
to maintain
comparable
infrastructure.
Demonstrated experience of the facilities
management team to maintain and/or similar
social infrastructure facilities, including:
• the nature of the facility and the role
undertaken by the Respondent;
• the originally agreed contract sum and
date for completion;
• the end contract sum and date of
completion (and reasons for any variance);
• details of any innovations on these projects;
• details of problems which arose and how
they were overcome; and
• a reference from the project owner.
Provide details of key personnel that will form part
of the facilities management team, their role and
relevant experience.
6
B6.2 The
Respondent’s
approach for the
delivery of facilities
management
services across
multiple sites for the
Project
The Respondent’s proposed approach for
undertaking the facilities management, focusing
on the Project issues and risks. Within the approach
address how it will manage the transition from
construction to operations as well as the impact of
any staging and multiple sites. Explain the
advantages of this approach
7
B6.3 The
Respondent’s
proposed
approach to
accommodate
facilities
management input
into design, with a
view to achieving
effective whole of
life design
outcomes that offer
value for money for
ZNBC.
Provide a response that explains how the facilities
management team will input into the design
development and construction to achieve
effective whole of life outcomes.
7
40
13.Table 11: Non-Weighted Evaluation Criteria
Non-Weighted Criterion EOI Content
B7. Financial Capacity B7.1 Demonstrate that each
Respondent Member has the
financial strength, capacity and
experience to successfully deliver its
aspect of the Project and can
contribute to the overall ability of
the Respondent to finance and
deliver all aspects of the Project.
For each Respondent Member
provide:
• profile for each director and
executive including qualifications,
experience and position;
• a brief history of the entity
including the year when operations
commenced, and any major
changes in corporate structure,
acquisitions, disposals etc;
• the corporate family tree, outlining
the immediate and ultimate parent,
subsidiaries and other related
entities; and
• financial statements (profit and
loss, balance sheet, cash flow and
notes) for the three most recent full
financial periods.
B8. Alternative Project Scope B8.1 the Respondent is encouraged
to offer alternative Project scope
and demonstrate how the proposed
project scope can be more viable
than the one provided in the
scope.
The overall respondent to react to
the provided project scope and
demonstrate that:
The alternative project scope
can yield more investment than
the one provided in this EOI;
The proposed scope can offer a
better economic feasibility on
updated Cost Benefit Analysis
The proposed scope is more
commercially viable that the
one proposed in the EOI
Respondent shall respond to this
part of the EOI in two ways:
1. Provide response to the
provided project scope; and
2. Provide an alternative project
scope.
Appendix 5: Part C: Additional Information
Respondents are encouraged to provide feedback on any issues of its choosing relating
to the Project. Any information provided in response to this Part C will not be considered
in the evaluation of the EOIs. However, information will usefully be applied for the
intended purpose. Where feedback is required, ZNBC shall respond and provide relevant
feedback.
41
Appendix 6. EOI Response Information
Response instruction: The Respondent is to complete this form in this
format. This Response Form is to be signed by each Respondent
Member.
1. Respondent Details
1.1 Respondent Members
Response instruction: Provide the following details in relation to each
Respondent Member and the Project Company (if applicable). Respondent
Members must include each lead Financier, lead construction contractor,
lead services provider and Project Company (if applicable). A Lead
Respondent Member must also be identified
The Respondent Members are as follows
Respondent Member Corporate Information*
Full Name (Insert)
Place and date of incorporation (Insert)
Company Name (Insert)
Address of Registered office (Insert)
Address for notices (Insert)
Email address for notices (Insert)
Telephone number (Landline) (Insert)
Telephone number (Mobile) (Insert)
Name and position of the individual
nominated as Respondents contacts
(Insert)
*Please duplicate this table tor each Respondent Member
1.2 Respondent’s Associates
Response instruction: Provide a list of the Respondent’s Associates including
consultants, advisors, contractors and subcontractors that have been
engaged by the Respondent Members to assist in the preparation of this EOI
and/or going forward in the Procurement Process if shortlisted.
The Respondent's Associates are as follows:
Organisation Role
[insert] [insert]
[insert] [insert]
[insert] [insert]
[insert] [insert]
[insert] [insert]
42
1.3 Related Party Participants
Response instruction: Disclose all Related Party Participants of each
Respondent Member that may also be a member of a competing
Respondent.
Response instruction: Provide details of any areas in which the
Respondent is currently incomplete and the proposed approach and
timing of obtaining the relevant expertise (including the identity of any
additional Respondent Members).
1.4 Potential additional Respondent Members
2. Terms and Conditions
By lodging its EOI, each Respondent Member confirms and agrees that it is
bound by the Process Terms.
Dated the [insert] day of [insert] 2020.
Response instruction: To be signed by duly authorised officers for each
Respondent Member using one of the execution blocks below. The State
reserves the right to ensure each Respondent Member has signed the
Response Form before further considering the EOI.
Signed for and on behalf of [insert]
(ABN [insert]) by its attorney under
power of attorney dated [insert], in the presence of:
------------------------------------------- ----------------------------------------------- Signature of Witness Signature of Attorney
--------------------------------------------- ----------------------------------------------------
Full name of Witness Full name of Attorney
----- Thank you and all the best -----